Post on 23-Mar-2020
transcript
1 NCB.CW/W-1
Birla Vishvakarma Mahavidyalaya, Mota Bazar, Vallabh Vidyanagar, Anand, Gujarat-388120
Ph.:91 2692 230104 (o) Fax: 91 2692 230762
NATIONAL COMPETITIVE BIDDING
FOR
(CIVIL WORKS COSTING US $100,000 AND BELOW)
BVM-CW-Extension of Library Building
UNDER
Technical Education Quality Improvement
Programme -Phase II
[TEQIP]
(A WORLD BANK ASSISTED PROJECT)
2 NCB.CW/W-1
Birla Vishvakarma Mahavidyalaya, Vallabh Vidyanagar Mota Bazar, Vallabh Vidyanagar, Anand
GOVERNMENT OF GUJARAT
PROJECT
AGREEMENT NO. ———————
NATIONAL COMPETITIVE BIDDING
(CIVIL WORKS COSTING US $100,000 AND BELOW)
* Should be the same as for the deadline for receipt of bids or promptly thereafter.
NAME OF WORK : BVM-CW-Extension of Library Building
PERIOD OF SALE : FROM - 15.09.2014
TIME: 10:30 Hrs
BIDDING DOCUMENT : TO - 16.10.2014
TIME: 16:00 Hrs
LAST DATE AND TIME
FOR RECEIPT OF BIDS
: DATE 16.10.2014
TIME : 16:00 HOURS
* TIME AND DATE OF
OPENING OF BIDS
: DATE 16.10.2014
TIME: 16:30 HOURS
PLACE OF OPENING OF
BIDS
: Principal office, BVM Engineering College,
Mota Bazar, Vallabh Vidyanagar, Anand-
388120,Gujarat
OFFICER INVITING BIDS : Dr. F. S. Umrigar
4 NCB.CW/W-1
GOVERNMENT OF Gujarat TEQIP-II PROJECT
INVITATIONS FOR BIDS (IFB)
NATIONAL COMPETITIVE BIDDING
Date: 09.09.2014
Bid No. : TEQIP-II/GJ/GJ1G02/250
1. The Government of India has received a credit from the International Development Association / loan from
the International Bank for Reconstruction & Development towards the cost of Technical Education Quality
Improvement Programme[TEQIP]-Phase II Project and intends a part of the funds to cover eligible payments
under the contracts for construction of works as detailed below. Bidding is open to all bidders from eligible source
countries as defined in the IBRD Guidelines for Procurement. Bidders from India should, however, be registered
with the Government of Gujarat or other State Governments/Government of India, or State/Central Government
Undertakings. Bidders are advised to note the minimum qualification criteria specified in Clause 4 of the
Instructions to Bidders to qualify for the award of the contract.
2. The Principal, Birla Vishvakarma Mahavidyalaya, Vallabh Vidyanagar invites bids for the construction
of works detailed in the table. The bidders may submit bids for any or all of the following works, for the package or
for any of the slices.
3. Bidding documents (and additional copies) may be purchased from the office of Birla Vishvakarma
Mahavidyalaya, Vallabh Vidyanagar from 15.09.2014 TIME: 10:30 Hrs to 16.10.2014 TIME: 16:00 Hrs, for a
non-refundable fee (three sets) as indicated, in the form of cash or Demand Draft on any Scheduled bank payable at
Vallabh Vidyanagar in favour of Principal, BVM Interested bidders may obtain further information at the same
address. Bidding documents requested by mail will be dispatched by registered/speed post on payment of an extra
amount of Rs 250. The Birla Vishvakarma Mahavidyalaya, Vallabh Vidyanagar will not be held responsible for
the postal delay if any, in the delivery of the documents or non-receipt of the same.
4. Bids must be accompanied by security of the amount specified for the work in the table below, drawn in
favour of Principal, BVM. Bid security will have to be in any one of the forms as specified in the bidding document
and shall have to be valid for 45 days beyond the validity of the bid.
5. Bids must be delivered to Birla Vishvakarma Mahavidyalaya, Vallabh Vidyanagar on or before 16:00
hours on 16.10.2014 and will be opened on the same day at 16:30 hours, in the presence of the bidders who wish to
attend. If the office happens to be closed on the date of receipt of the bids as specified, the bids will be received and
opened on the next working day at the same time and venue.
6. Other details can be seen in the bidding documents.
5 NCB.CW/W-1
TABLE
Package No. Name of
work
Approximate
value of work
(Rs.)
Bid
security
(Rs.)
Cost of
document
(Rs.)
Period of
completion
TEQIP-
II/2014/GJ1G02/NCB/16
BVM-CW-
Extension of
Library
Building
3000000/- 150000/- 1500/- (Non-
refundable)
105 Days
____________________________________________________________________________________________
Seal of office
7 NCB.CW/W-1
Section 1: Instructions to Bidders
Table of Clauses
A. General Page No. D. Submission of Bids Page No.
1. Scope of Bid 7 19. Sealing and Marking of Bids 13
2. Source of Funds 7 20. Deadline for Submission of Bids 13
3. Eligible Bidders 7 21. Late Bids 14
4. Qualification of the Bidder 7 22. Modification and Withdrawal of Bids 14
5. One Bid per Bidder 9
6. Cost of Bidding 10
7. Site Visit 10
B. Bidding Documents E. Bid Opening and Evaluation
8. Content of Bidding Documents 10 23. Bid Opening 14
9. Clarification of Bidding Documents 10 24. Process to be Confidential 14
10. Amendment of Bidding Documents 10 25. Clarification of Bids 15
26. Examination of Bids and Deter- 15
mination of Responsiveness
27. Correction of Errors 15
C. Preparation of Bids 28. Currency for Bid Evaluation
29. Evaluation and Comparison of Bids 16
11. Language of Bid 11 30. Preference for Domestic Bidders
12. Documents Comprising the Bid 11
13. Bid Prices 11 F. Award of Contract
14. Currencies of Bid and Payment 11
15. Bid Validity 11 31. Award Criteria 16
16. Bid Security 12 32. Employer's Right to Accept any Bid 16
and to Reject any or all Bids
17. Alternative Proposals by Bidders 12 33. Notification of Award 16
18. Format and Signing of Bid 13 34. Performance Security 17
35. Advance Payment and Security
36. Adjudicator
37. Corrupt or Fraudulent Practices 17
8 NCB.CW/W-1
A. General
1. Scope of Bid
1.1 The Birla Vishvakarma Mahavidyalaya, Vallabh Vidyanagar (referred to as Employer in these documents)
invites bids for the construction of works (as defined in these documents and referred to as "the works")
detailed in the table given in the Invitation for Bids (IFB). The bidders may submit bids for any or all of the
works detailed in the table given in IFB.
1.2 The successful bidder will be expected to complete the works by the intended completion date specified in the
Contract data.
2. Source of Funds
2.1 The Government of India has received a loan/credit from the International Bank for Reconstruction and
Development/the International Development Association (hereinafter interchangeably called ―the Bank‖)
towards the cost of Technical Education Quality Improvement Programme[TEQIP]-Phase II Project and
intends to apply a part of the funds to cover eligible payments under the contract for the Works. Payments by
the Bank will be made only at the request of the borrower and upon approval of the Bank in accordance with
the Loan/Credit Agreement, and will be subject in all respects to the terms and conditions of that Agreement.
Except as the Bank may specifically otherwise agree, no party other than the borrower shall derive any rights
from the Loan/Credit Agreement or have any rights to the loan/credit proceeds.
2.2 The loan agreement prohibits a withdrawal from the loan account for the purpose of any payment to persons
or entities, or for any import of goods, if such payment or import, to the knowledge of the Bank, is prohibited
by a decision of the United Nations Security Council, taken under Chapter VII of the Charter of the United
Nations.
3. Eligible Bidders
3.1 This Invitation for Bids is open to all bidders from the eligible countries as defined under the IBRD
Guidelines for Procurement. Any materials, equipment, and services to be used in the performance of the
Contract shall have their origin in the eligible source countries.
3.2 All bidders shall provide in Section 2, Forms of Bid and Qualification Information, a statement that the Bidder
is not associated, nor has been associated in the past, directly or indirectly, with the Consultant or any other
entity that has prepared the design, specifications, and other documents for the Project or being proposed as
Project Manager for the Contract. A firm that has been engaged by the Borrower to provide consulting
services for the preparation or supervision of the works, and any of its affiliates, shall not be eligible to bid.
3.3 Government-owned enterprises in the Employer‘s country may only participate if they are legally and
financially autonomous, operate under commercial law and are not a dependent agency of the Borrower or
Sub-borrower.
3.4 Bidders shall not be under a declaration of ineligibility for corrupt and fraudulent practices issued by the Bank
in accordance with sub-clause 37.1.
4. Qualification of the Bidder
4.1 All bidders shall provide in Section 2, Forms of Bid and Qualification Information, a preliminary description
of the proposed work method and schedule, including drawings and charts, as necessary.
4.2 In the event that Pre-qualification of potential bidders has been undertaken, only bids from prequalified
bidders will be considered for award for Contract. These qualified bidders should submit with their bids any
information updating their original prequalification applications or, alternatively, confirm in their bids that the
originally submitted prequalification information remains essentially correct as of date of bid submission. The
update or confirmation should be provided in Section 2.
4.3 If the Employer has not undertaken prequalification of potential bidders, all bidders shall include the
following information and documents with their bids in Section 2:
9 NCB.CW/W-1
(a) copies of original documents defining the constitution or legal status, place of registration, and
principal place of business; written power of attorney of the signatory of the Bid to commit the Bidder;
(b) total monetary value of construction work performed for each of the last five years;
(c) experience in works of a similar nature and size for each of the last five years, and details of works
under way or contractually committed; and clients who may be contacted for further information on
those contracts;
(d) major items of construction equipment proposed to carry out the Contract;
(e) qualifications and experience of key site management and technical personnel proposed for the
Contract;
(f) reports on the financial standing of the Bidder, such as profit and loss statements and auditor's reports
for the past five years;
(g) evidence of adequacy of working capital for this contract (access to line (s) of credit and availability of
other financial resources);
(h) authority to seek references from the Bidder's bankers;
(i) information regarding any litigation or arbitration resulting from contracts executed by the Bidder in
the last five years or currently under execution. The information shall include the names of the parties
concerned, the disputed amount, cause of litigation, and matter in dispute; and
(j) proposals for subcontracting components of the Works which in aggregate add to more than 20 percent
of the Contract Price [for each, the qualifications and experience of the identified sub-contractor in the
relevant field should be annexed; no vertical splitting of work for sub-contracting is acceptable].
4.4 Bids from Joint ventures are not acceptable.
4.5 A. To qualify for award of the contract, each bidder in its name should have in the last five years:
i.e 2013-14
(a) achieved, in at least two financial years, a minimum annual financial turnover (in all classes of civil
engineering construction works only) of Rs.60 Lacs @ (usually not less than two times the estimated
annual payments under the contract);
(b) satisfactorily completed (not less than 90% of contract value), as a prime contractor, at least one
similar work of value not less than Rs.25.00 lacs @ (usually not less than 80% of estimated value of
contract);
(c) deleted;
(d) The contractor or his identified sub-contractor should possess required valid electrical license for
executing the building electrification works and should have executed similar electrical works totaling
Rupees 3.00lacs @**
in any one year.
(e) The contractor or his identified sub-contractor should possess required valid license for executing the
water supply/sanitary engineering works and should have executed similar water supply/sanitary
engineering works totaling Rupees 3.00lacs @**
in any one year.
@ at 1.5 lacs* price level. Financial turnover and cost of completed works of previous years shall
be given weightage of 5% per year based on rupee value to bring them to —————* price
level.
**
at least 50% of the estimated value of electrical/ water supply works. **
at least 50% of the estimated value of electrical/ water supply works.
10 NCB.CW/W-1
4.5 B. Deleted.
4.5 C. To qualify for a package of contracts made up of this and other contracts for which bids are
invited in the IFB, the bidder must demonstrate having experience and resources sufficient to meet the
aggregate of the qualifying criteria for the individual contracts.
4.6 Sub-contractors' experience and resources shall not be taken into account in determining the bidder's
compliance with the qualifying criteria except to the extent stated in para 4.5 (A) above.
4.7 Bidders who meet the minimum qualification criteria will be qualified only if their available bid capacity is
more than the total bid value. The available bid capacity will be calculated as under:
Assessed Available Bid capacity = ( A*N*1.5 - B )
where
A = Maximum value of civil engineering works executed in any one year during the last five years (updated
to ————* price level) taking into account the completed as well as works in progress.
N = Number of years prescribed for completion of the works for which bids are invited.
B = Value, at ————* price level, of existing commitments and on-going works to be completed during
the next.......years (period of completion of the works for which bids are invited)
Note: The statements showing the value of existing commitments and on-going works as well as the
stipulated period of completion remaining for each of the works listed should be countersigned by the
Engineer in charge, not below the rank of an Executive Engineer or equivalent.
4.8 Even though the bidders meet the above qualifying criteria, they are subject to be disqualified if they have:
- made misleading or false representations in the forms, statements and attachments submitted in proof of
the qualification requirements; and/or
- record of poor performance such as abandoning the works, not properly completing the contract,
inordinate delays in completion, litigation history, or financial failures etc.; and/or
- participated in the previous bidding for the same work and had quoted unreasonably high bid prices
and could not furnish rational justification to the employer.
5. One Bid per Bidder
5.1 Each bidder shall submit only one bid for one contract. A bidder who submits or participates in more than
one Bid (other than as a subcontractor or in cases of alternatives that have been permitted or requested) will
cause all the proposals with the Bidder‘s participation to be disqualified.
6. Cost of Bidding
6.1 The bidder shall bear all costs associated with the preparation and submission of his Bid, and the Employer
will in no case be responsible and liable for those costs.
* the financial year in which bids are received
11 NCB.CW/W-1
7. Site visit
7.1 The Bidder, at the Bidder‘s own responsibility and risk is encouraged to visit and examine the Site of Works
and its surroundings and obtain all information that may be necessary for preparing the Bid and entering into a
contract for construction of the Works. The costs of visiting the Site shall be at the Bidder's own expense.
B. Bidding Documents
8. Content of Bidding Documents
8.1 The set of bidding documents comprises the documents listed in the table below and addenda issued in
accordance with Clause 10:
Invitation for Bids
Section 1 Instructions to Bidders
2 Forms of Bid and Qualification Information
3 Conditions of Contract
4 Contract Data
5 Specifications
6 Drawings
7 Bill of Quantities
8 Forms of Securities
8.2 Of the three sets of the bidding documents supplied, two sets should be completed and returned with the
bid.
9. Clarification of Bidding Documents
9.1 A prospective bidder requiring any clarification of the bidding documents may notify the Employer in
writing or by cable (hereinafter "cable" includes telex and facsimile) at the Employer's address indicated in
the invitation to bid. The Employer will respond to any request for clarification which he received earlier
than 15 days prior to the deadline for submission of bids. Copies of the Employer's response will be
forwarded to all purchasers of the bidding documents, including a description of the enquiry but without
identifying its source.
10. Amendment of Bidding Documents
10.1 Before the deadline for submission of bids, the Employer may modify the bidding documents by issuing
addenda.
10.2 Any addendum thus issued shall be part of the bidding documents and shall be communicated in writing or
by cable to all the purchasers of the bidding documents. Prospective bidders shall acknowledge receipt of
each addendum by cable to the Employer.
10.3 To give prospective bidders reasonable time in which to take an addendum into account in preparing their
bids, the Employer shall extend as necessary the deadline for submission of bids, in accordance with Sub-
Clause 20.2 below.
C. Preparation of Bids
11. Language of the Bid
11.1 All documents relating to the bid shall be in the English language.
12. Documents comprising the Bid
12 NCB.CW/W-1
12.1 The bid submitted by the bidder shall comprise the following:
(a) The Bid (in the format indicated in Section 2).
(b) Bid Security;
(c) Priced Bill of Quantities;
(d) Qualification Information Form and Documents;
and any other materials required to be completed and submitted by bidders in accordance with these
instructions. The documents listed under Sections 2, 4 and 7 of Sub-Clause 8.1 shall be filled in without
exception.
12.2 Bidders bidding for this contract together with other contracts stated in the IFB to form a package will so
indicate in the bid together with any documents offered for the award of more than one contract.
13. Bid Prices
13.1 The contract shall be for the whole works as described in Sub-Clause 1.1, based on the priced Bill of
Quantities submitted by the Bidder.
13.2 The bidder shall fill in rates and prices and line item total (both in figures and words) for all items of the
Works described in the Bill of Quantities alongwith total bid price (both in figures and words). Items for
which no rate or price is entered by the bidder will not be paid for by the Employer when executed and
shall be deemed covered by the other rates and prices in the Bill of Quantities. Corrections, if any, shall be
made by crossing out, initialing, dating and rewriting.
13.3 All duties, taxes, and other levies payable by the contractor under the contract, or for any other cause, shall
be included in the rates, prices and total Bid Price submitted by the Bidder.
13.4 The rates and prices quoted by the bidder shall be fixed for the duration of the Contract and shall not be
subject to adjustment on any account.
14. Currencies of Bid and Payment
14.1 The unit rates and the prices shall be quoted by the bidder entirely in Indian Rupees.
15. Bid Validity
15.1 Bids shall remain valid for a period not less than ninety days after the deadline date for bid submission
specified in Clause 20. A bid valid for a shorter period shall be rejected by the Employer as non-
responsive.
15.2 In exceptional circumstances, prior to expiry of the original time limit, the Employer may request that the
bidders may extend the period of validity for a specified additional period. The request and the bidders'
responses shall be made in writing or by cable. A bidder may refuse the request without forfeiting his bid
security. A bidder agreeing to the request will not be required or permitted to modify his bid except as
provided in 15.3 hereinafter, but will be required to extend the validity of his bid security for a period of the
extension, and in compliance with Clause 16 in all respects.
15.3 In the case of contracts in which the Contract Price is fixed (not subject to price adjustment), in the event
that the purchaser requests and the Bidder agrees to an extension of the validity period, the contract price, if
the Bidder is selected for award shall be the bid price corrected as follows:
The price shall be increased by the factor (value of factor B)1
for each week or part of a week that has
elapsed from the expiration of the initial bid validity to the date of issue of letter of acceptance to the
successful Bidder.
1 The value of B is based on the country’s inflation for the period in question. The borrower inserts the value in the bid document prior to
issue.
13 NCB.CW/W-1
15.4 Bid evaluation will be based on the bid prices without taking into consideration the above correction.
16. Bid Security
16.1 The Bidder shall furnish, as part of his Bid, a Bid security in the amount as shown in column 4 of the table
of IFB for this particular work. This bid security shall be in favour of Principal, BVM and may be in one
of the following forms:
- a bank guarantee issued by a nationalized / Scheduled Bank located in India or a reputable Bank
located abroad in the form given in Section 8; or
- Bank draft/Letter of credit, in favour of Principal, BVM payable at Vallabh Vidyanagar
16.2 Bank guarantees issued as surety for the bid shall be valid for 45 days beyond the validity of the bid.
16.3 Any bid not accompanied by an acceptable Bid Security and not secured as indicated in Sub-Clauses 16.1
and 16.2 above shall be rejected by the Employer as non-responsive.
16.4 The Bid Security of unsuccessful bidders will be returned within 28 days of the end of the bid validity
period specified in Sub-Clause 15.1.
16.5 The Bid Security of the successful bidder will be discharged when the bidder has signed the Agreement and
furnished the required Performance Security.
16.6 The Bid Security may be forfeited
(a) if the Bidder withdraws the Bid after Bid opening during the period of Bid validity;
(b) if the Bidder does not accept the correction of the Bid Price, pursuant to Clause 27; or
(c) in the case of a successful Bidder, if the Bidder fails within the specified time limit to
(i) sign the Agreement; or
(ii) furnish the required Performance Security.
17. Alternative Proposals by Bidders
17.1 Bidders shall submit offers that comply with the requirements of the bidding documents, including the basic
technical design as indicated in the drawing and specifications. Alternatives will not be considered.
18. Format and Signing of Bid
18.1 The Bidder shall prepare one original and a copy of the documents comprising the bid as described in
Clause 12 of these Instructions to Bidders, bound with the volume containing the Form of Bid, and clearly
marked "ORIGINAL" and "COPY" as appropriate. In the event of discrepancy between them, the
original shall prevail.
18.2 The original and a copy of the Bid shall be typed or written in indelible ink and shall be signed by a person
or persons duly authorized to sign on behalf of the Bidder, pursuant to Sub-Clauses 4.3. All pages of the bid
where entries or amendments have been made shall be initialed by the person or persons signing the bid.
18.3 The Bid shall contain no alterations or additions, except those to comply with instructions issued by the
Employer, or as necessary to correct errors made by the bidder, in which case such corrections shall be
initialed by the person or persons signing the bid.
18.4 The Bidder shall furnish information as described in the Form of Bid on commissions or gratuities, if any,
paid or to be paid to agents relating to this Bid, and to contract execution if the Bidder is awarded the
contract
14 NCB.CW/W-1
D. Submission of Bids
19. Sealing and Marking of Bids
19.1 The Bidder shall seal the original and a copy of the Bid in separate envelopes, duly marking the envelopes
as "ORIGINAL" and "COPY". These envelopes (called as inner envelopes) shall then be put inside one
outer envelope.
19.2 The inner and outer envelopes shall
(a) be addressed to the Employer at the following address:
Principal, BVM College, Mota Bazar, Vallabh Vidyanagar, Anand
and
(b) bear the following identification:
- Bid for BVM-CW-Extension of Library Building
- Bid Reference No TEQIP-II/GJ/GJ1G02/250
- DO NOT OPEN BEFORE 16:30, 16.10.2014 [time and date for bid
opening, per Clause 23]
19.3 In addition to the identification required in Sub-Clause 19.2, the inner envelopes shall indicate the name and
address of the bidder to enable the bid to be returned unopened in case it is declared late, pursuant to Clause
21.
19.4 If the outer envelope is not sealed and marked as above, the Employer will assume no responsibility for the
misplacement or premature opening of the bid.
20. Deadline for Submission of the Bids
20.1 Bids must be received by the Employer at the address specified above no later than 16:00Hrs. 16.10.2014
*.
In the event of the specified date for the submission of bids being declared a holiday for the Employer, the
Bids will be received upto the appointed time on the next working day.
20.2 The Employer may extend the deadline for submission of bids by issuing an amendment in accordance with
Clause 10, in which case all rights and obligations of the Employer and the bidders previously subject to the
original deadline will then be subject to the new deadline.
21. Late Bids
21.1 Any Bid received by the Employer after the deadline prescribed in Clause 20 will be returned unopened to
the bidder.
22. Modification and Withdrawal of Bids
22.1 Bidders may modify or withdraw their bids by giving notice in writing before the deadline prescribed in
Clause 20.
22.2 Each Bidder's modification or withdrawal notice shall be prepared, sealed, marked, and delivered in
accordance with Clause 18 & 19, with the outer and inner envelopes additionally marked
"MODIFICATION" or "WITHDRAWAL", as appropriate.
22.3 No bid may be modified after the deadline for submission of Bids.
22.4 Withdrawal or modification of a Bid between the deadline for submission of bids and the expiration of the
original period of bid validity specified in Clause 15.1 above or as extended pursuant to Clause 15.2 may
result in the forfeiture of the Bid security pursuant to Clause 16.
* no later than 16:00 16.10.2014.
15 NCB.CW/W-1
22.5 Bidders may offer discounts to, or modify the prices of their Bids only by submitting Bid modifications in
accordance with this clause, or included in the original Bid submission.
E. Bid Opening and Evaluation
23. Bid Opening
23.1 The Employer will open all the Bids received (except those received late), including modifications made
pursuant to Clause 22, in the presence of the Bidders or their representatives who choose to attend at 16:30
hours on the date and the place specified in Clause 19. In the event of the specified date of Bid opening
being declared a holiday for the Employer, the Bids will be opened at the appointed time and location on
the next working day.
23.2 Envelopes marked "WITHDRAWAL" shall be opened and read out first. Bids for which an acceptable
notice of withdrawal has been submitted pursuant to Clause 22 shall not be opened. Subsequently all
envelopes marked ―Modification‖ shall be opened and the submissions therein read out in appropriate
detail.
23.3 The Bidders' names, the Bid prices, the total amount of each Bid and of any alternative Bid (if alternatives
have been requested or permitted), any discounts, Bid modifications and withdrawals, the presence or
absence of Bid security, and such other details as the Employer may consider appropriate, will be
announced by the Employer at the opening. No bid shall be rejected at bid opening except for the late bids
pursuant to Clause 21. Bids [and modifications] sent pursuant to Clause 22 that are not opened and read out
at bid opening will not be considered for further evaluation regardless of circumstances. Late and
withdrawn bids will be returned un-opened to bidders.
23.4 The Employer shall prepare minutes of the Bid opening, including the information disclosed to those
present in accordance with Sub-Clause 23.3.
24. Process to Be Confidential
24.1 Information relating to the examination, clarification, evaluation, and comparison of Bids and
recommendations for the award of a contract shall not be disclosed to Bidders or any other persons not
officially concerned with such process until the award to the successful Bidder has been announced. Any
effort by a Bidder to influence the Employer's processing of Bids or award decisions may result in the
rejection of his Bid.
25. Clarification of Bids
25.1 To assist in the examination, evaluation, and comparison of Bids, the Employer may, at his discretion, ask
any Bidder for clarification of his Bid, including breakdowns of unit rates. The request for clarification and
the response shall be in writing or by cable, but no change in the price or substance of the Bid shall be
sought, offered, or permitted except as required to confirm the correction of arithmetic errors discovered by
the Employer in the evaluation of the Bids in accordance with Clause 27.
25.2 Subject to sub-clause 25.1, no Bidder shall contact the Employer on any matter relating to its bid from the
time of the bid opening to the time the contract is awarded. If the Bidder wishes to bring additional
information to the notice of the Employer, it should do so in writing.
25.3 Any effort by the Bidder to influence the Employer in the Employer‘s bid evaluation, bid comparison or
contract award decisions may result in the rejection of the Bidders‘ bid.
26. Examination of Bids and Determination of Responsiveness
26.1 Prior to the detailed evaluation of Bids, the Employer will determine whether each Bid (a) meets the
eligibility criteria defined in Clause 3; (b) has been properly signed; (c) is accompanied by the required
securities and; (d) is substantially responsive to the requirements of the Bidding documents.
16 NCB.CW/W-1
26.2 A substantially responsive Bid is one which conforms to all the terms, conditions, and specifications of the
Bidding documents, without material deviation or reservation. A material deviation or reservation is one (a)
which affects in any substantial way the scope, quality, or performance of the Works; (b) which limits in
any substantial way, inconsistent with the Bidding documents, the Employer's rights or the Bidder's
obligations under the Contract; or (c) whose rectification would affect unfairly the competitive position of
other Bidders presenting substantially responsive Bids.
26.3 If a Bid is not substantially responsive, it will be rejected by the Employer, and may not subsequently be
made responsive by correction or withdrawal of the nonconforming deviation or reservation.
27. Correction of Errors
27.1 Bids determined to be substantially responsive will be checked by the Employer for any arithmetic errors.
Errors will be corrected by the Employer as follows:
(a) where there is a discrepancy between the rates in figures and in words, the rate in words will
govern; and
(b) where there is a discrepancy between the unit rate and the line item total resulting from multiplying
the unit rate by the quantity, the unit rate as quoted will govern.
27.2 The amount stated in the Bid will be adjusted by the Employer in accordance with the above procedure for
the correction of errors and, with the concurrence of the Bidder, shall be considered as binding upon the
Bidder. If the Bidder does not accept the corrected amount the Bid will be rejected, and the Bid security
may be forfeited in accordance with Sub-Clause 16.6 (b).
28. Deleted
29. Evaluation and Comparison of Bids
29.1 The Employer will evaluate and compare only the Bids determined to be substantially responsive in
accordance with Clause 26.
29.2 In evaluating the Bids, the Employer will determine for each Bid the evaluated Bid Price by adjusting the
Bid Price as follows:
(a) making any correction for errors pursuant to Clause 27; or
(b) making an appropriate adjustments for any other acceptable variations, deviations; and
(c) making appropriate adjustments to reflect discounts or other price modifications offered in
accordance with Sub Clause 22.5.
29.3 The Employer reserves the right to accept or reject any variation, deviation, or alternative offer. Variations,
deviations, and alternative offers and other factors which are in excess of the requirements of the Bidding
documents or otherwise result in unsolicited benefits for the Employer shall not be taken into account in Bid
evaluation.
29.4 The estimated effect of the price adjustment conditions under Clause 47 of the Conditions of Contract,
during the period of implementation of the Contract, will not be taken into account in Bid evaluation.
29.5 If the Bid of the successful Bidder is seriously unbalanced in relation to the Engineer's estimate of the cost
of work to be performed under the contract, the Employer may require the Bidder to produce detailed price
analyses for any or all items of the Bill of Quantities, to demonstrate the internal consistency of those prices
with the construction methods and schedule proposed. After evaluation of the price analyses, the Employer
may require that the amount of the performance security set forth in Clause 34 be increased at the expense
of the successful Bidder to a level sufficient to protect the Employer against financial loss in the event of
default of the successful Bidder under the Contract.
30. Deleted
17 NCB.CW/W-1
F. Award of Contract
31. Award Criteria
31.1 Subject to Clause 32, the Employer will award the Contract to the Bidder whose Bid has been determined to
be substantially responsive to the Bidding documents and who has offered the lowest evaluated Bid Price,
provided that such Bidder has been determined to be (a) eligible in accordance with the provisions of
Clause 3, and (b) qualified in accordance with the provisions of Clause 4.
31.2 If, pursuant to Clause 12.2 this contract is being let alongwith other contracts, the lowest evaluated Bid
Price will be determined when evaluating this contract in conjunction with other contracts to be awarded
concurrently, taking into account any discounts offered by the bidders for the award of more than one
contract.
32. Employer's Right to Accept any Bid and to Reject any or all Bids
32.1 Notwithstanding Clause 31, the Employer reserves the right to accept or reject any Bid, and to cancel the
Bidding process and reject all Bids, at any time prior to the award of Contract, without thereby incurring
any liability to the affected Bidder or Bidders or any obligation to inform the affected Bidder or Bidders of
the grounds for the Employer's action.
33. Notification of Award and Signing of Agreement
33.1 The Bidder whose Bid has been accepted will be notified of the award by the Employer prior to expiration
of the Bid validity period by cable, telex or facsimile confirmed by registered letter. This letter (hereinafter
and in the Conditions of Contract called the "Letter of Acceptance") will state the sum that the Employer
will pay the Contractor in consideration of the execution, completion, and maintenance of the Works by the
Contractor as prescribed by the Contract (hereinafter and in the Contract called the "Contract Price").
33.2 The notification of award will constitute the formation of the Contract, subject only to the furnishing of a
performance security in accordance with the provisions of Clause 34.
33.3 The Agreement will incorporate all agreements between the Employer and the successful Bidder. It will be
signed by the Employer and sent to the successful Bidder, or kept ready for signature of the successful
bidder in the office of employer (choose one alternative) within 28 days following the notification of award
along with the Letter of Acceptance. Within 21 days of receipt, the successful Bidder will sign the
Agreement and deliver it to the Employer.
33.4 Upon the furnishing by the successful Bidder of the Performance Security, the Employer will promptly
notify the other Bidders that their Bids have been unsuccessful.
34. Performance Security
34.1 Within 14 days of receipt of the Letter of Acceptance, the successful Bidder shall deliver to the Employer a
Performance Security in any of the forms given below for an amount equivalent to 5% of the Contract price
plus additional security for unbalanced Bids in accordance with Clause 29.5 of ITB and Clause 52 of
Conditions of Contract :
- a bank guarantee in the form given in Section 8; or
- Bank draft, in favour of Principal, BVM payable at Vallabh Vidyanagar
34.2 If the performance security is provided by the successful Bidder in the form of a Bank Guarantee, it shall be
issued either (a) at the Bidder's option, by a Nationalized/Scheduled Indian bank or (b) by a foreign bank
located in India and acceptable to the Employer .
18 NCB.CW/W-1
34.3 Failure of the successful bidder to comply with the requirements of sub-clause 34.1 shall constitute a breach
of contract, cause for annulment of the award, forfeiture of the bid security, and any such other remedy the
Employer may take under the contract, and the Employer may resort to awarding the contract to the next
ranked bidder..
35 Advance Payment and Security (deleted)
36. Adjudicator (deleted)
37. Corrupt or Fraudulent Practices
37.1 The Bank requires that Borrowers (including beneficiaries of Bank loans), as well as Bidders, Suppliers,
Contractors, and Consultants under Bank-financed contracts, observe the highest standard of ethics during
the procurement and execution of such contracts. In pursuit of this policy, the Bank:
(a) defines, for the purposes of this provision, the terms set forth below as follows:
(i) ―corrupt practice‖ means the offering, giving, receiving, or soliciting, directly or
indirectly, of anything of value to influence the action of a public official in the
procurement process or in contract execution;
(ii) ―fraudulent practice‖ means a misrepresentation or omission of facts in order to influence
a procurement process or the execution of a contract;
(iii) ―collusive practice‖ means a scheme or arrangement between two or more Bidders, with
or without the knowledge of the borrower, designed to establish bid prices at artificial,
non competitive levels; and
(iv) ―coercive practice‖ means harming or threatening to harm, directly or indirectly, persons
or their property to influence their participation in the procurement process or affect the
execution of a contract;
(b) will reject a proposal for award if it determines that the Bidder recommended for award has,
directly or through an agent, engaged in corrupt, fraudulent, collusive or coercive practices in
competing for the Contract in question;
(c) will cancel the portion of the loan allocated to a contract if it determines at any time that
representatives of the Borrower or of a beneficiary of the loan engaged in corrupt, fraudulent,
collusive or coercive practices during the procurement or the execution of that contract, without
the Borrower having taken timely and appropriate action satisfactory to the Bank to remedy the
situation;
(d) will sanction a firm or individual, including declaring them ineligible, either indefinitely or for a
stated period of time, to be awarded a Bank-financed contract if it at any time determines that they
have, directly or through an agent, engaged, in corrupt, fraudulent, collusive or coercive practices
in competing for, or in executing, a Bank-financed contract; and
(e) will have the right to require that a provision be included in Bidding Documents and in contracts
financed by a Bank loan, requiring Bidders, Suppliers, Contractors and Consultants to permit the
Bank to inspect their accounts and records and other documents relating to the bid submission and
contract performance and to have them audited by auditors appointed by the Bank.
37.2 Furthermore, Bidders shall be aware of the provision stated in sub-clause 59.2 of the Conditions of
Contract.
19 NCB.CW/W-1
SECTION 2: FORMS OF BID, QUALIFICATION INFORMATION
AND LETTER OF ACCEPTANCE
TABLE OF FORMS:
- CONTRACTOR’S BID
- QUALIFICATION INFORMATION
- LETTER OF ACCEPTANCE
- NOTICE TO PROCEED WITH THE WORK
- AGREEMENT FORM
20 NCB.CW/W-1
Contractor's Bid
Description of the Works: Enhancement of Reading and Stack room in BVM Library for better utilization
BID
To : Birla Vishvakarma Mahavidyalaya, Vallabh Vidyanagar [the Employer]
Address : Mota Bazar, Vallabh Vidyanagar, Anand
GENTLEMEN,
Having examined the bidding documents including addendum, we offer to execute the Works described above in
accordance with the Conditions of Contract, Specifications, Drawings and Bill of Quantities accompanying this Bid
for the Contract Price of [ ] ( ) [in letters].1
This Bid and your written acceptance of it shall constitute a binding contract between us. We understand that you are
not bound to accept the lowest or any Bid you receive.
We hereby certify that we have taken steps to ensure that no person acting for us or on our behalf will engage in
bribery.
We also undertake that, in competing for (and, if the award is made to us, in executing) the above contract, we will
strictly observe the laws against fraud and corruption in force in India namely ―Prevention of Corruption Act 1988‖.
Commissions or gratuities, if any, paid or to be paid by us to agents relating to this Bid, and to contract execution if
we are awarded the contract, are listed below :
Name and address of agent Amount Purpose of Commission or gratuity
------------------ ----- ------------------------------
----------------- ----- -------------------------------
(if none, state ―none‖)
We hereby confirm that this Bid complies with the Eligibility, Bid Validity and Bid Security required by the Bidding
documents.
Yours faithfully,
Authorized Signature:
Name & Title of Signatory: _________________________________________________________________
Name of Bidder : ______________________________________________
Address : __________________________________________________________________
3. To be filled in by the Bidder, together with his particulars and date of submission at the bottom of the Form
of Bid.
21 NCB.CW/W-1
Qualification Information
The information to be filled in by the Bidder in the following pages will be used for purposes of post qualification as
provided for in Clause 4 of the Instructions to Bidders. This information will not be incorporated in the Contract.
1. For Individual Bidders
1.1 Constitution or legal status of Bidder
[Attach copy]
Place of registration: _______________________________
Principal place of business: _______________________________
Power of attorney of signatory of Bid
[Attach copy]
1.2 Total value of Civil Engineering construction 2013-2014______________
work executed and payments received in the last five years** 2012-2013_____________
(in Rs. Million) 2011-2012______________
2010-2011______________
2009-2010______________
1.3 Work performed as prime contractor (in the same name) on works of a similar nature over the last five
years.**
Project
Name
Name of
Employer *
Descrip-
tion of
work
Contract
No.
Value of
contract
(Rs.
Million)
Date of
issue of
work order
Stipulated
period of
completion
Actual date of
completion *
Remarks
explaining
reasons for
delay and
work
completed
____________________________________________________________________________________________
____________________________________________________________________________________________
1.4 Information on Bid Capacity (works for which bids have been submitted and works which are yet to be
completed) as on the date of this bid.
* Attach certificate(s) from Engineer(s)-in-charge
** Immediately preceeding the financial year in which bids are received.
Attach certificate from Chartered Accountant
22 NCB.CW/W-1
(A) Existing commitments and on-going works:
_________________________________________________________________________________________
Description Place Contract No. Name Value of Stipulated Value of works* Anticipated
of & & Date and Contract period of remaining to be date of
Work State Address (Rs. million) completion completed completion
of Employer (Rs. million)
(1) (2) (3) (4) (5) (6) (7) (8)
_________________________________________________________________________________________
_________________________________________________________________________________________
(B) Works for which bids already submitted:
_________________________________________________________________________________________
Description Place Name and Estimated Stipulated Date when Remarks
of & Address of value of works period of decision is if any
Work State Employer (Rs. million) completion expected
(1) (2) (3) (4) (5) (6) (7)
* Attach certificate(s) from the Engineer(s)-in-Charge.
1.5 Proposed subcontracts and firms involved. [Refer ITB Clause 4.3 (j)]
______________________________________________________________________________
Sections Value of Sub-contractor Experience in
of the works Sub-contract (name and address) similar work
______________________________________________________________________________
* * * *
* *
* * * *
* *
* * * *
* *
______________________________________________________________________________
1.6 Financial reports for the last five years: balance sheets, profit and loss statements, auditors' reports (in case of
companies/corporation), etc. List them below and attach copies.
1.7 Deleted.
1.8. Name, address, and telephone, telex, and fax numbers of the Bidders' bankers who may provide references if
contacted by the Employer.
23 NCB.CW/W-1
1.9 Information on litigation history in which the Bidder is involved.
__________________________________________________________________________________
Other party(ies) Employer Cause of dispute Amount involved Remarks showing
present status
__________________________________________________________________________________
__________________________________________________________________________________
1.10 Statement of compliance under the requirements of Sub Clause 3.2 of the instructions to Bidders.
_______________________________________________________________________________________
_______________________________________________________________________________________
_______________________________________________________________________________________
24 NCB.CW/W-1
Letter of Acceptance
(letterhead paper of the Employer)
________________________[date]
To: _________________________________________________________________________[name and
address of the Contractor]
Dear Sirs,
This is to notify you that your Bid dated ____________ for execution of the
______________________________________________________________________________________ [name
of the contract and identification number, as given in the Instructions to Bidders] for the Contract Price of Rupees (
) [ ] [amount in words
and figures], as corrected and modified in accordance with the Instructions to Bidders1 is hereby accepted by our
Agency.
We note that as per bid, you do not intend to subcontract any component of work
[OR]
We note that as per bid, you propose to employ M/s. .......................................... as sub-contractor for
executing ...........................................
[Delete whichever is not applicable].
You are hereby requested to furnish Performance Security, plus additional security for unbalanced bids in
terms of ITB Clause 29.5, in the form detailed in Para 34.1 of ITB for an amount of Rs.————— within 21 days
of the receipt of this letter of acceptance valid upto 28 days from the date of expiry of Defects Liability Period i.e.
upto ............ and sign the contract, failing which action as stated in Para 34.3 of ITB will be taken.
Yours faithfully,
Authorized Signature
Name and Title of Signatory
Name of Agency
1 Delete "corrected and" or "and modified" if only one of these actions applies. Delete "as corrected and modified in accordance
with the Instructions to Bidders" if corrections or modifications have not been effected.
25 NCB.CW/W-1
Issue of Notice to proceed with the work
(letterhead of the Employer)
————— (date)
To
—————————————— (name and address of the Contractor)
——————————————
——————————————
Dear Sirs:
Pursuant to your furnishing the requisite security as stipulated in ITB Clause 34.1 and signing of the contract
agreement for the construction of —————— @ a Bid Price of Rs.——————, you are hereby instructed to
proceed with the execution of the said works in accordance with the contract documents.
Yours faithfully,
(Signature, name and title of
signatory authorized to sign on
behalf of Employer)
26 NCB.CW/W-1
Agreement Form
Agreement
This agreement, made the ___________________day of ______________19_______,
between______________________________________________________________________________________
_____________________________________[name and address of Employer]
(hereinafter called ―the Employer‖) of the one part and _____________________________________________
____________________________________________________________________________________________
____________________________________________________[name and address of contractor] (hereinafter
called ―the Contractor‖) of the other part.
Whereas the Employer is desirous that the Contractor execute _____________________________
____________________________________________________________________________________________
____________________________________________________________________________________[ name
and identification number of Contract] (hereinafter called ―the Works‖) and the Employer has accepted the Bid by
the Contractor for the execution and completion of such Works and the remedying of any defects therein at a
contract price of Rupees...............................
NOW THIS AGREEMENT WITNESSETH as follows:
1. In this Agreement, words and expression shall have the same meanings as are respectively assigned to them in
the Conditions of Contract hereinafter referred to, and they shall be deemed to form and be read and construed
as part of this Agreement.
2. In consideration of the payments to be made by the Employer to the Contractor as hereinafter mentioned, the
Contractor hereby covenants with the Employer to execute and complete the Works and remedy any defects
therein in conformity in all aspects with the provisions of the Contract.
3. The Employer hereby covenants to pay the Contractor in consideration of the execution and completion of the
Works and the remedying the defects wherein the Contract Price or such other sum as may become payable
under the provisions of the Contract at the times and in the manner prescribed by the Contract.
4. The following documents shall be deemed to form and be read and construed as part of this Agreement, viz:
i) Letter of Acceptance;
ii) Notice to proceed with the works;
iii) Contractor‘s Bid;
iv) Contract Data;
v) Conditions of contract (including Special Conditions of Contract);
vi) Specifications;
vii) Drawings;
viii) Bill of Quantities; and
ix) Any other document listed in the Contract Data as forming part of the contract.
27 NCB.CW/W-1
In witness whereof the parties thereto have caused this Agreement to be executed the day and year first before
written.
The Common Seal of ___________________________________________________________
was hereunto affixed in the presence of:
Signed, Sealed and Delivered by the said ___________________________________________________
_____________________________________________________________________________________
in the presence of:
Binding Signature of Employer _______________________________________________________
Binding Signature of Contractor _____________________________________________________
29 NCB.CW/W-1
Conditions of Contract
Table of Contents
A. General Page No. C. Quality Control Page No.
1. Definitions 31 33. Identifying Defects 37
2. Interpretation 32 34. Tests 37
3. Language and Law 33 35. Correction of Defects 38
4. Engineer's Decisions 33 36. Uncorrected Defects 38
5. Delegation 33
6. Communications 33
7. Subcontracting 33 D. Cost Control
8. Other Contractors 33 37. Bill of Quantities 38
9. Personnel 33 38. Changes in the Quantities 38
10. Employer‘s & Contractor's
Risks 34 39. Variations 38
11. Employer's Risks 34 40. Payments for Variations 38
12. Contractor‘s Risks 34 41. Cash Flow Forecasts 39
13. Insurance 34 42. Payment Certificates 39
14. Site Investigation Reports 34 43. Payments 39
15. Queries about the Contract 35 44. Compensation Events 39
Data 45. Tax 41
16. Contractor to Construct the 35 46. Currencies 41
Works 47. Price Adjustments
17. The Works to Be Completed by 35 48. Retention 41
the Intended Completion Date 49. Liquidated Damages 41
18. Approval by the Engineer 35 50. Bonus
51. Advance Payment
19. Safety 35 52. Securities 41
20. Discoveries 35 53. Dayworks
21. Possession of the Site 35 54. Cost of Repairs 42
22. Access to the Site 35
23. Instructions 36
24. Disputes 36 E. Finishing the Contract
25. Procedure for Disputes 36 55. Completion 42
26. Replacement of Adjudicator 56. Taking Over 42
57. Final Account 42
B. Time Control 58. Operating and Maintenance Manuals 42
27. Program 36 59. Termination 42
28. Extension of the Intended 36 60. Payment upon Termination 43
Completion Date 61. Property 43
29. Acceleration 62. Release from Performance 44
30. Delays Ordered by the 37 63. Suspension of World Bank Loan or
Engineer Credit 44
31. Management Meetings 37
32. Early Warning 37 F. Special Conditions of Contract 45-48
30 NCB.CW/W-1
Conditions of Contract
A. General
1. Definitions
1.1 Terms which are defined in the Contract Data are not also defined in the Conditions of Contract but
keep their defined meanings. Capital initials are used to identify defined terms.
Bill of Quantities means the priced and completed Bill of Quantities forming part of the Bid.
Compensation Events are those defined in Clause 44 hereunder.
The Completion Date is the date of completion of the Works as certified by the Engineer in
accordance with Sub Clause 55.1.
The Contract is the contract between the Employer and the Contractor to execute, complete and
maintain the Works. It consists of the documents listed in Clause 2.3 below.
The Contract Data defines the documents and other information which comprise the Contract.
The Contractor is a person or corporate body whose Bid to carry out the Works has been accepted by
the Employer.
The Contractor's Bid is the completed Bidding document submitted by the Contractor to the
Employer.
The Contract Price is the price stated in the Letter of Acceptance and thereafter as adjusted in
accordance with the provisions of the Contract.
Days are calendar days; months are calendar months.
A Defect is any part of the Works not completed in accordance with the Contract.
The Defects Liability Period is the period named in the Contract Data and calculated from the
Completion Date.
The Employer is the party who will employ the Contractor to carry out the Works.
The Engineer is the person named in the Contract Data (or any other competent person appointed and
notified to the contractor to act in replacement of the Engineer) who is responsible for supervising the
execution of the works and administering the Contract.
Equipment is the Contractor's machinery and vehicles brought temporarily to the Site to construct the
Works.
The Initial Contract Price is the Contract Price listed in the Employer's Letter of Acceptance.
The Intended Completion Date is the date on which it is intended that the Contractor shall complete
the Works. The Intended Completion Date is specified in the Contract Data. The Intended Completion
Date may be revised only by the Engineer by issuing an extension of time.
Materials are all supplies, including consumables, used by the contractor for incorporation in the
Works.
Plant is any integral part of the Works which is to have a mechanical, electrical, electronic or
chemical or biological function.
The Site is the area defined as such in the Contract Data.
31 NCB.CW/W-1
Site Investigation Reports are those which were included in the Bidding documents and are factual
interpretative reports about the surface and sub-surface conditions at the site.
Specification means the Specification of the Works included in the Contract and any modification or
addition made or approved by the Engineer.
The Start Date is given in the Contract Data. It is the date when the Contractor shall commence
execution of the works. It does not necessarily coincide with any of the Site Possession Dates.
A Subcontractor is a person or corporate body who has a Contract with the Contractor to carry out a
part of the work in the Contract which includes work on the Site.
Temporary Works are works designed, constructed, installed, and removed by the Contractor which
are needed for construction or installation of the Works.
A Variation is an instruction given by the Engineer which varies the Works.
The Works are what the Contract requires the Contractor to construct, install, and turn over to the
Employer, as defined in the Contract Data.
2. Interpretation
2.1 In interpreting these Conditions of Contract, singular also means plural, male also means female or
neuter, and the other way around. Headings have no significance. Words have their normal meaning
under the language of the Contract unless specifically defined. The Engineer will provide instructions
clarifying queries about the Conditions of Contract.
2.2 If sectional completion is specified in the Contract Data, references in the Conditions of Contract to
the Works, the Completion Date, and the Intended Completion Date apply to any Section of the Works
(other than references to the Completion Date and Intended Completion date for the whole of the
Works).
2.3 The documents forming the Contract shall be interpreted in the following order of priority:
(1) Agreement
(2) Letter of Acceptance, notice to proceed with the works
(3) Contractor‘s Bid
(4) Contract Data
(5) Conditions of Contract
(6) Specifications
(7) Drawings
(8) Bill of quantities and
(9) any other document listed in the Contract Data as forming part of the Contract.
32 NCB.CW/W-1
3. Language and Law
3.1 The language of the Contract and the law governing the Contract are stated in the Contract Data.
4. Engineer's Decisions
4.1 Except where otherwise specifically stated, the Engineer will decide contractual matters between the
Employer and the Contractor in the role representing the Employer.
5. Delegation
5.1 The Engineer may delegate any of his duties and responsibilities to other people except to the
Adjudicator after notifying the Contractor and may cancel any delegation after notifying the
Contractor.
6. Communications
6.1 Communications between parties which are referred to in the conditions are effective only when in
writing. A notice shall be effective only when it is delivered (in terms of Indian Contract Act).
7. Subcontracting
7.1 The Contractor may subcontract with the approval of the Engineer but may not assign the Contract
without the approval of the Employer in writing. Subcontracting does not alter the Contractor's
obligations.
8. Other Contractors
8.1 The Contractor shall cooperate and share the Site with other contractors, public authorities, utilities,
and the Employer between the dates given in the Schedule of Other Contractors. The Contractor shall
as referred to in the Contract Data, also provide facilities and services for them as described in the
Schedule. The employer may modify the schedule of other contractors and shall notify the contractor
of any such modification.
9. Personnel
9.1 The Contractor shall employ the key personnel named in the Schedule of Key Personnel as referred to
in the Contract Data to carry out the functions stated in the Schedule or other personnel approved by
the Engineer. The Engineer will approve any proposed replacement of key personnel only if their
qualifications, abilities, and relevant experience are substantially equal to or better than those of the
personnel listed in the Schedule.
9.2 If the Engineer asks the Contractor to remove a person who is a member of the Contractor‘s staff or
his work force stating the reasons the Contractor shall ensure that the person leaves the Site within
seven days and has no further connection with the work in the Contract.
10. Employer’s and Contractor's Risks
10.1 The Employer carries the risks which this Contract states are Employer‘s risks, and the Contractor
carries the risks which this Contract states are Contractor‘s risks.
11. Employer's Risks
11.1 The Employer is responsible for the excepted risks which are (a) in so far as they directly affect the
execution of the Works in the Employer‘s country, the risks of war, hostilities, invasion, act of foreign
enemies, rebellion, revolution, insurrection or military or usurped power, civil war, riot commotion or
disorder (unless restricted to the Contractor‘s employees), and contamination from any nuclear fuel or
nuclear waste or radioactive toxic explosive, or (b) a cause due solely to the design of the Works,
other than the Contractor‘s design.
33 NCB.CW/W-1
12. Contractor’s Risks
12.1 All risks of loss of or damage to physical property and of personal injury and death which arise during
and in consequence of the performance of the Contract other than the excepted risks are the
responsibility of the Contractor.
13. Insurance
13.1 The Contractor shall provide, in the joint names of the Employer and the Contractor, insurance cover
from the Start Date to the end of the Defects Liability Period, in the amounts and deductibles stated in
the Contract Data for the following events which are due to the Contractor‘s risks:
(a) loss of or damage to the Works, Plant and Materials;
(b) loss of or damage to Equipment;
(c) loss of or damage of property (except the Works, Plant, Materials and Equipment) in
connection with the Contract; and
(d) personal injury or death.
13.2 Policies and certificates for insurance shall be delivered by the Contractor to the Engineer for the
Engineer‘s approval before the Start Date. All such insurance shall provide for compensation to be
payable in the types and proportions of currencies required to rectify the loss or damage incurred.
13.3 If the Contractor does not provide any of the policies and certificates required, the Employer may
effect the insurance which the Contractor should have provided and recover the premiums the
Employer has paid from payments otherwise due to the Contractor or, if no payment is due, the
payment of the premiums shall be a debt due.
13.4 Alterations to the terms of an insurance shall not be made without the approval of the Engineer.
13.5 Both parties shall comply with any conditions of the insurance policies.
14. Site Investigation Reports
14.1 The Contractor, in preparing the Bid, shall rely on any site Investigation Reports referred to in the
Contract Data, supplemented by any information available to the Bidder.
15. Queries about the Contract Data
15.1 The Engineer will clarify queries on the Contract Data.
16. Contractor to Construct the Works
16.1 The Contractor shall construct and install the Works in accordance with the Specification and
Drawings, and as per instructions of Engineer.
17. The Works to Be Completed by the Intended Completion Date
17.1 The Contractor may commence execution of the Works on the Start Date and shall carry out the
Works in accordance with the program submitted by the Contractor, as updated with the approval of
the Engineer, and complete them by the Intended Completion Date.
34 NCB.CW/W-1
18. Approval by the Engineer
18.1 The Contractor shall submit Specifications and Drawings showing the proposed Temporary Works to
the Engineer, who is to approve them if they comply with the Specifications and Drawings.
18.2 The Contractor shall be responsible for design of Temporary Works.
18.3 The Engineer's approval shall not alter the Contractor's responsibility for design of the Temporary
Works.
18.4 The Contractor shall obtain approval of third parties to the design of the Temporary Works where
required.
18.5 All Drawings prepared by the Contractor for the execution of the temporary or permanent Works, are
subject to prior approval by the Engineer before their use.
19. Safety
19.1 The Contractor shall be responsible for the safety of all activities on the Site.
20. Discoveries
20.1 Anything of historical or other interest or of significant value unexpectedly discovered on the Site is
the property of the Employer. The Contractor is to notify the Engineer of such discoveries and carry
out the Engineer's instructions for dealing with them.
21. Possession of the Site
21.1 The Employer shall give possession of all parts of the Site to the Contractor. If possession of a part is
not given by the date stated in the Contract Data the Employer is deemed to have delayed the start of
the relevant activities and this will be Compensation Event.
22. Access to the Site
22.1 The Contractor shall allow the Engineer and any person authorized by the Engineer access to the Site,
to any place where work in connection with the Contract is being carried out or is intended to be
carried out and to any place where materials or plant are being manufactured / fabricated / assembled
for the works.
23. Instructions
23.1 The Contractor shall carry out all instructions of the Engineer which comply with the applicable laws
where the Site is located.
23.2 The Contractor shall permit the bank to inspect the Contractor‘s accounts and records relating to the
performance of the Contractor and to have them audited by auditors appointed by the Bank, if so
required by the Bank.
24. Disputes
24.1 If the Contractor believes that a decision taken by the Engineer was either outside the authority given
to the Engineer by the Contract or that the decision was wrongly taken, the decision shall be referred
to the Arbitrator within 28 days of the notification of the Engineer's decision.
25 Procedure for Disputes
25.1 deleted
25.2 deleted
25.3 The arbitration shall be conducted in accordance with the arbitration procedure stated in the Special
Conditions of Contract.
35 NCB.CW/W-1
26. Replacement of Adjudicator - deleted
B. Time Control
27. Program
27.1 Within the time stated in the Contract Data the Contractor shall submit to the Engineer for approval a
Program showing the general methods, arrangements, order, and timing for all the activities in the
Works, along with monthly cash flow forecast.
27.2 An update of the Program shall be a program showing the actual progress achieved on each activity
and the effect of the progress achieved on the timing of the remaining work including any changes to
the sequence of the activities.
27.3 The Contractor shall submit to the Engineer, for approval, an updated Program at intervals no longer
than the period stated in the Contract Data. If the Contractor does not submit an updated Program
within this period, the Engineer may withhold the amount stated in the Contract Data from the next
payment certificate and continue to withhold this amount until the next payment after the date on
which the overdue Program has been submitted.
27.4 The Engineer's approval of the Program shall not alter the Contractor's obligations. The Contractor
may revise the Program and submit it to the Engineer again at any time. A revised Program is to show
the effect of Variations and Compensation Events.
28. Extension of the Intended Completion Date
28.1 The Engineer shall extend the Intended Completion Date if a Compensation Event occurs or a
Variation is issued which makes it impossible for Completion to be achieved by the Intended
Completion Date without the Contractor taking steps to accelerate the remaining work and which
would cause the Contractor to incur additional cost.
28.2 The Engineer shall decide whether and by how much to extend the Intended Completion Date within
21 days of the Contractor asking the Engineer for a decision upon the effect of a Compensation Event
or Variation and submitting full supporting information. If the Contractor has failed to give early
warning of a delay or has failed to cooperate in dealing with a delay, the delay by this failure shall not
be considered in assessing the new Intended Completion Date.
29. Deleted
30. Delays Ordered by the Engineer
30.1 The Engineer may instruct the Contractor to delay the start or progress of any activity within the
Works.
31. Management Meetings
31.1 Either the Engineer or the Contractor may require the other to attend a management meeting. The
business of a management meeting shall be to review the plans for remaining work and to deal with
matters raised in accordance with the early warning procedure.
31.2 The Engineer shall record the business of management meetings and is to provide copies of his record
to those attending the meeting and to the Employer. The responsibility of the parties for actions to be
taken is to be decided by the Engineer either at the management meeting or after the management
meeting and stated in writing to all who attended the meeting.
32. Early Warning
36 NCB.CW/W-1
32.1 The Contractor is to warn the Engineer at the earliest opportunity of specific likely future events or
circumstances that may adversely affect the quality of the work, increase the Contract Price or delay
the execution of works. The Engineer may require the Contractor to provide an estimate of the
expected effect of the future event or circumstance on the Contract Price and Completion Date. The
estimate is to be provided by the Contractor as soon as reasonably possible.
32.2 The Contractor shall cooperate with the Engineer in making and considering proposals for how the
effect of such an event or circumstance can be avoided or reduced by anyone involved in the work and
in carrying out any resulting instruction of the Engineer.
C. Quality Control
33. Identifying Defects
33.1 The Engineer shall check the Contractor's work and notify the Contractor of any Defects that are
found. Such checking shall not affect the Contractor's responsibilities. The Engineer may instruct the
Contractor to search for a Defect and to uncover and test any work that the Engineer considers may
have a Defect.
33.2 The contractor shall permit the Employer‘s Technical auditor to check the Contractor‘s work and
notify the Engineer and Contractor of any defects that are found. Such a check shall not affect the
Contractor‘s or the Engineer‘s responsibility as defined in the Contract Agreement.
34. Tests
34.1 If the Engineer instructs the Contractor to carry out a test not specified in the Specification to check
whether any work has a Defect and the test shows that it does, the Contractor shall pay for the test and
any samples. If there is no Defect the test shall be a Compensation Event.
35. Correction of Defects
35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability
Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period
shall be extended for as long as Defects remain to be corrected.
35.2 Every time notice of a Defect is given, the Contractor shall correct the notified Defect within the
length of time specified by the Engineer‘s notice.
36. Uncorrected Defects
36.1 If the Contractor has not corrected a Defect within the time specified in the Engineer‘s notice, the
Engineer will assess the cost of having the Defect corrected, and the Contractor will pay this amount.
Note: Where in certain cases, the technical specifications provide for acceptance of works within specified
tolerance limits at reduced rates, Engineer will certify payments to Contractor accordingly.
D. Cost Control
37. Bill of Quantities
37.1 The Bill of Quantities shall contain items for the construction, installation, testing, and commissioning
work to be done by the Contractor.
37.2 The Bill of Quantities is used to calculate the Contract Price. The Contractor is paid for the quantity of
the work done at the rate in the Bill of Quantities for each item.
38. Changes in the Quantities
38.1 If the final quantity of the work done differs from the quantity in the Bill of Quantities for the
particular item by more than 25 percent provided the change exceeds 1% of Initial Contract Price, the
Engineer shall adjust the rate to allow for the change.
37 NCB.CW/W-1
38.2 The Engineer shall not adjust rates from changes in quantities if thereby the Initial Contract Price is
exceeded by more than 15 percent, except with the Prior approval of the Employer.
38.3 If requested by the Engineer, the Contractor shall provide the Engineer with a detailed cost breakdown
of any rate in the Bill of Quantities.
39. Variations
39.1 All Variations shall be included in updated Programs produced by the Contractor.
40. Payments for Variations
40.1 The Contractor shall provide the Engineer with a quotation (with breakdown of unit rates) for carrying
out the Variation when requested to do so by the Engineer. The Engineer shall assess the quotation,
which shall be given within seven days of the request or within any longer period stated by the
Engineer and before the Variation is ordered.
40.2 If the work in the Variation corresponds with an item description in the Bill of Quantities and if, in the
opinion of the Engineer, the quantity of work above the limit stated in Sub Clause 38.1 or the timing of
its execution do not cause the cost per unit of quantity to change, the rate in the Bill of Quantities shall
be used to calculate the value of the Variation. If the cost per unit of quantity changes, or if the nature
or timing of the work in the Variation does not correspond with items in the Bill of Quantities, the
quotation by the Contractor shall be in the form of new rates for the relevant items of work.
40.3 If the Contractor's quotation is unreasonable (or if the contractor fails to provide the Engineer with a
quotation within a reasonable time specified by the Engineer in accordance with Clause 40.1), the
Engineer may order the Variation and make a change to the Contract Price which shall be based on
Engineer‘s own forecast of the effects of the Variation on the Contractor's costs.
40.4 If the Engineer decides that the urgency of varying the work would prevent a quotation being given
and considered without delaying the work, no quotation shall be given and the Variation shall be
treated as a Compensation Event.
40.5 The Contractor shall not be entitled to additional payment for costs which could have been avoided by
giving early warning.
41. Cash flow forecasts
41.1 When the Program is updated, the contractor is to provide the Engineer with an updated cash flow
forecast.
42. Payment Certificates
42.1 The Contractor shall submit to the Engineer monthly statements of the estimated value of the work
completed less the cumulative amount certified previously alongwith details of measurement of the
quantity of works executed in a tabulated form as approved by the Engineer.
42.2 The Engineer shall check the Contractor‘s monthly statement and within 14 days certify the amount to
be paid to the Contractor.
42.3 The value of work executed shall be determined by the Engineer after due check measurement of the
quantities claimed as executed by the contractor.
42.4 The value of work executed shall comprise the value of the quantities of the items in the Bill of
Quantities completed.
42.5 The value of work executed shall include the valuation of Variations and Compensation Events.
42.6 The Engineer may exclude any item certified in a previous certificate or reduce the proportion of any
item previously certified in any certificate in the light of later information.
43. Payments
38 NCB.CW/W-1
43.1 Payments shall be adjusted for deductions for advance payments, retention, other recoveries in terms
of the contract and taxes, at source, as applicable under the law. The Employer shall pay the
Contractor the amounts certified by the Engineer within 28 days of the date of each certificate. If the
Employer makes a late payment, the Contractor shall be paid interest on the late payment in the next
payment. Interest shall be calculated from the date by which the payment should have been made upto
the date when the late payment is made at 8% per annum.
43.2 If an amount certified is increased in a later certificate or as a result of an award by an Arbitrator, the
Contractor shall be paid interest upon the delayed payment as set out in this clause. Interest shall be
calculated from the date upon which the increased amount would have been certified in the absence of
dispute.
43.3 Items of the Works for which no rate or price has been entered in will not be paid for by the Employer
and shall be deemed covered by other rates and prices in the Contract.
44. Compensation Events
44.1 The following are Compensation Events unless they are caused by the Contractor:
(a) The Employer does not give access to a part of the Site by the Site Possession Date stated in the
Contract Data.
(b) The Employer modifies the schedule of other contractors in a way which affects the work of the
contractor under the contract.
(c) The Engineer orders a delay or does not issue drawings, specifications or instructions required
for execution of works on time.
(d) The Engineer instructs the Contractor to uncover or to carry out additional tests upon work
which is then found to have no Defects.
(e) The Engineer unreasonably does not approve for a subcontract to be let.
(f) Ground conditions are substantially more adverse than could reasonably have been assumed
before issuance of Letter of Acceptance from the information issued to Bidders (including the
Site Investigation Reports), from information available publicly and from a visual inspection of
the Site.
(g) The Engineer gives an instruction for dealing with an unforeseen condition, caused by the
Employer, or additional work required for safety or other reasons.
(h) Other contractors, public authorities, utilities or the Employer does not work within the dates
and other constraints stated in the Contract, and they cause delay or extra cost to the Contractor.
(i) Deleted.
(j) The effect on the Contractor of any of the Employer‘s Risks.
(k) The Engineer unreasonably delays issuing a Certificate of Completion.
(l) Other Compensation Events listed in the Contract Data or mentioned in the Contract.
44.2 If a Compensation Event would cause additional cost or would prevent the work being completed
before the Intended Completion Date, the Contract Price shall be increased and/or the Intended
Completion Date is extended. The Engineer shall decide whether and by how much the Contract Price
shall be increased and whether and by how much the Intended Completion Date shall be extended.
44.3 As soon as information demonstrating the effect of each Compensation Event upon the Contractor's
forecast cost has been provided by the Contractor, it is to be assessed by the Engineer and the Contract
Price shall be adjusted accordingly. If the Contractor's forecast is deemed unreasonable, the Engineer
39 NCB.CW/W-1
shall adjust the Contract Price based on Engineer‘s own forecast. The Engineer will assume that the
Contractor will react competently and promptly to the event.
44.4 The Contractor shall not be entitled to compensation to the extent that the Employer's interests are
adversely affected by the Contractor not having given early warning or not having cooperated with the
Engineer.
45. Tax
45.1 The rates quoted by the Contractor shall be deemed to be inclusive of the sales and other taxes that the
Contractor will have to pay for the performance of this Contract. The Employer will perform such
duties in regard to the deduction of such taxes at source as per applicable law.
46. Currencies
46.1 All payments shall be made in Indian Rupees.
47. Price Adjustment - deleted
48. Retention
48.1 The Employer shall retain from each payment due to the Contractor the proportion stated in the
Contract Data until Completion of the whole of the Works.
48.2 On Completion of the whole of the Works half the total amount retained is repaid to the Contractor
and half when the Defects Liability Period has passed and the Engineer has certified that all Defects
notified by the Engineer to the Contractor before the end of this period have been corrected.
48.3 On completion of the whole works, the Contractor may substitute retention money with an ―on
demand‖ Bank guarantee.
49. Liquidated Damages
49.1 The Contractor shall pay liquidated damages to the Employer at the rate per day stated in the Contract
Data for each day that the Completion Date is later than the Intended Completion Date (for the whole
of the works or the milestones as stated in the Contract Data). The total amount of liquidated damages
shall not exceed the amount defined in the Contract Data. The Employer may deduct liquidated
damages from payments due to the Contractor. Payment of liquidated damages does not affect the
Contractor's liabilities.
49.2 If the Intended Completion Date is extended after liquidated damages have been paid, the Engineer
shall correct any overpayment of liquidated damages by the Contractor by adjusting the next payment
certificate. The Contractor shall be paid interest on the over payment calculated from the date of
payment to the date of repayment at the rates specified in Sub Clause 43.1.
50. Deleted
51. Advance Payment Deleted
52. Securities
40 NCB.CW/W-1
52.1 The Performance Security shall be provided to the Employer no later than the date specified in the
Letter of Acceptance and shall be issued in an amount and form and by a bank or surety acceptable to
the Employer, and denominated in Indian Rupees. The Performance Security shall be valid until a date
28 days from the date of expiry of Defects Liability Period and the additional security for unbalanced
bids shall be valid until a date 28 days from the date of issue of the certificate of completion.
53. Deleted
54. Cost of Repairs
54.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and
the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost
if the loss or damage arises from the Contractor's acts or omissions.
E. Finishing the Contract
55. Completion
55.1 The Contractor shall request the Engineer to issue a Certificate of Completion of the Works and the
Engineer will do so upon deciding that the Work is completed.
56. Taking Over
56.1 The Employer shall take over the Site and the Works within seven days of the Engineer issuing a
certificate of Completion
57. Final Account
57.1 The Contractor shall supply to the Engineer a detailed account of the total amount that the Contractor
considers payable under the Contract before the end of the Defects Liability Period. The Engineer
shall issue a Defect Liability Certificate and certify any final payment that is due to the Contractor
within 56 days of receiving the Contractor's account if it is correct and complete. If it is not, the
Engineer shall issue within 56 days a schedule that states the scope of the corrections or additions that
are necessary. If the Final Account is still unsatisfactory after it has been resubmitted, the Engineer
shall decide on the amount payable to the Contractor and issue a payment certificate within 56 days of
receiving the Contractor‘s revised account.
58. Operating and Maintenance Manuals
58.1 If ―as built‖ Drawings and/or operating and maintenance manuals are required, the Contractor shall
supply them by the dates stated in the Contract Data.
58.2 If the Contractor does not supply the Drawings and/or manuals by the dates stated in the Contract
Data, or they do not receive the Engineer‘s approval, the Engineer shall withhold the amount stated in
the Contract Data from payments due to the Contractor.
59. Termination
59.1 The Employer or the Contractor may terminate the Contract if the other party causes a fundamental
breach of the Contract.
59.2 Fundamental breaches of Contract include, but shall not be limited to the following:
(a) the Contractor stops work for 28 days when no stoppage of work is shown on the current
Program and the stoppage has not been authorized by the Engineer;
(b) the Engineer instructs the Contractor to delay the progress of the Works and the instruction is
not withdrawn within 28 days;
41 NCB.CW/W-1
(c) the Employer or the Contractor is made bankrupt or goes into liquidation other than for a
reconstruction or amalgamation;
(d) a payment certified by the Engineer is not paid by the Employer to the Contractor within 56
days of the date of the Engineer's certificate;
(e) the Engineer gives Notice that failure to correct a particular Defect is a fundamental breach of
Contract and the Contractor fails to correct it within a reasonable period of time determined by
the Engineer;
(f) the Contractor does not maintain a security which is required;
(g) the Contractor has delayed the completion of works by the number of days for which the
maximum amount of liquidated damages can be paid as defined in the Contract data; and
(h) if the Contractor, in judgment of the Purchaser engaged in fraud and corruption, a defined in
GCC Clause 64, in competing for or in executing the Contract.
59.3 When either party to the Contract gives notice of a breach of contract to the Engineer for a cause other
than those listed under Sub Clause 59.2 above, the Engineer shall decide whether the breach is
fundamental or not.
59.4 Notwithstanding the above, the Employer may terminate the Contract for convenience.
59.5 If the Contract is terminated the Contractor shall stop work immediately, make the Site safe and secure
and leave the Site as soon as reasonably possible.
60. Payment upon Termination
60.1 If the Contract is terminated because of a fundamental breach of Contract by the Contractor, the
Engineer shall issue a certificate for the value of the work done less advance payments received up to
the date of the issue of the certificate, less other recoveries due in terms of the contract, less taxes due
to be deducted at source as per applicable law and less the percentage to apply to the work not
completed as indicated in the Contract Data. Additional Liquidated Damages shall not apply. If the
total amount due to the Employer exceeds any payment due to the Contractor the difference shall be a
debt payable to the Employer.
60.2 If the Contract is terminated at the Employer's convenience or because of a fundamental breach of
Contract by the Employer, the Engineer shall issue a certificate for the value of the work done, the
reasonable cost of removal of Equipment, repatriation of the Contractor's personnel employed solely
on the Works, and the Contractor's costs of protecting and securing the Works and less advance
payments received up to the date of the certificate, less other recoveries due in terms of the contract,
and less taxes due to be deducted at source as per applicable law.
61. Property
61.1 All materials on the Site, Plant, Equipment, Temporary Works and Works are deemed to be the
property of the Employer, if the Contract is terminated because of a Contractor‘s default.
42 NCB.CW/W-1
62. Release from Performance
62.1 If the Contract is frustrated by the outbreak of war or by any other event entirely outside the control of
either the Employer or the Contractor the Engineer shall certify that the Contract has been frustrated.
The Contractor shall make the Site safe and stop work as quickly as possible after receiving this
certificate and shall be paid for all work carried out before receiving it and for any work carried out
afterwards to which commitment was made.
63. Suspension of World Bank Loan or Credit
63.1 In the event that the World Bank suspends the Loan or Credit to the Employer, from which part of the
payments to the Contractor are being made:
(a) The Employer is obligated to notify the Contractor of such suspension within 7 days of having
received the World Bank‘s suspension notice.
(b) If the Contractor has not received sums due to it upon the expiration of the 28 days for payment
provided for in Sub-Clause 43.1, the Contractor may immediately issue a 14-day termination
notice.
64. Fraud and Corruption
64.1 The Bank requires that Borrowers (including beneficiaries of Bank loans), as well as Bidders,
Suppliers, Contractors, and Consultants under Bank-financed contracts, observe the highest standard of
ethics during the procurement and execution of such contracts. In pursuit of this policy, the Bank:
(a) defines, for the purposes of this provision, the terms set forth below as follows:
(i) ―corrupt practice‖ means the offering, giving, receiving, or soliciting, directly or
indirectly, of anything of value to influence the action of a public official in the
procurement process or in contract execution;
(ii) ―fraudulent practice‖ means a misrepresentation or omission of facts in order to influence
a procurement process or the execution of a contract;
(iii) ―collusive practice‖ means a scheme or arrangement between two or more Bidders, with
or without the knowledge of the borrower, designed to establish bid prices at artificial,
non competitive levels; and
(iv) ―coercive practice‖ means harming or threatening to harm, directly or indirectly, persons
or their property to influence their participation in the procurement process or affect the
execution of a contract;
(b) will cancel the portion of the loan allocated to a contract if it determines at any time that
representatives of the Borrower or of a beneficiary of the loan engaged in corrupt, fraudulent,
collusive or coercive practices during the procurement or the execution of that contract, without
the Borrower having taken timely and appropriate action satisfactory to the Bank to remedy the
situation;
(c) will sanction a firm or individual, including declaring them ineligible, either indefinitely or for a
stated period of time, to be awarded a Bank-financed contract if it at any time determines that they
have, directly or through an agent, engaged, in corrupt, fraudulent, collusive or coercive practices
in competing for, or in executing, a Bank-financed contract; and
43 NCB.CW/W-1
(d) will have the right to require that Contractors to permit the Bank to inspect their accounts and
records and other documents relating to the bid submission and contract performance and to have
them audited by auditors appointed by the Bank.
44 NCB.CW/W-1
F. Special Conditions of Contract
1. LABOUR :
The Contractor shall, unless otherwise provided in the Contract, make his own arrangements for the
engagement of all staff and labour, local or other, and for their payment, housing, feeding and transport.
The Contractor shall, if required by the Engineer, deliver to the Engineer a return in detail, in such form and at
such intervals as the Engineer may prescribe, showing the staff and the numbers of the several classes of labour
from time to time employed by the Contractor on the Site and such other information as the Engineer may
require.
2. COMPLIANCE WITH LABOUR REGULATIONS :
During continuance of the contract, the Contractor and his sub contractors shall abide at all times by all
existing labour enactments and rules made thereunder, regulations, notifications and bye laws of the State or
Central Government or local authority and any other labour law (including rules), regulations, bye laws that
may be passed or notification that may be issued under any labour law in future either by the State or the
Central Government or the local authority. Salient features of some of the major labour laws that are
applicable to construction industry are given below. The Contractor shall keep the Employer indemnified in
case any action is taken against the Employer by the competent authority on account of contravention of any of
the provisions of any Act or rules made thereunder, regulations or notifications including amendments. If the
Employer is caused to pay or reimburse, such amounts as may be necessary to cause or observe, or for non-
observance of the provisions stipulated in the notifications/bye laws/Acts/Rules/regulations including
amendments, if any, on the part of the Contractor, the Engineer/Employer shall have the right to deduct any
money due to the Contractor including his amount of performance security. The Employer/Engineer shall also
have right to recover from the Contractor any sum required or estimated to be required for making good the
loss or damage suffered by the Employer.
The employees of the Contractor and the Sub-Contractor in no case shall be treated as the employees of the
Employer at any point of time.
SALIENT FEATURES OF SOME MAJOR LABOUR LAWS APPLICABLE TO
ESTABLISHMENTS ENGAGED IN BUILDING AND OTHER CONSTRUCTION WORK.
a) Workmen Compensation Act 1923: The Act provides for compensation in case of injury by accident
arising out of and during the course of employment.
b) Payment of Gratuity Act 1972: Gratuity is payable to an employee under the Act on satisfaction of
certain conditions on separation if an employee has completed 5 years service or more or on death the
rate of 15 days wages for every completed year of service. The Act is applicable to all establishments
employing 10 or more employees.
c) Employees P.F. and Miscellaneous provision Act 195: The Act Provides for monthly contributions by
the employer plus workers @ 10% or 8.33%. The benefits payable under the Act are :
(i) Pension or family pension on retirement or death as the case may be.
(ii) Deposit linked insurance on the death in harness of the worker.
(iii) payment of P.F. accumulation on retirement/death etc.
d) Maternity Benefit Act 1951 :- The Act provides for leave and some other benefits to women
employees in case of confinement or miscarriage etc.
45 NCB.CW/W-1
e) Contract Labour (Regulation & Abolition) Act 1970: The Act provides for certain welfare measures
to be provided by the Contractor to contract labour and in case the Contractor fails to provide, the
same are required to be provided, by the Principal Employer by Law. The principal Employer is
required to take Certificate of Registration and the Contractor is required to take license from the
designated Officer. The Act is applicable to the establishments or Contractor of Principal Employer if
they employ 20 or more contract labour.
f) Minimum Wages Act 1948: The Employer is supposed to pay not less than the Minimum Wages fixed
by appropriate Government as per provisions of the Act if the employment is a scheduled
employment. Construction of Buildings, Roads, Runways are scheduled employment.
g) Payment of Wages Act 1936: It lays down as to by what date the wages are to be paid, when it will be
paid and what deductions can be made from the wages of the workers.
h) Equal Remuneration Act 1979: The Act provides for payment of equal wages for work of equal nature
to Male and Female workers and for not making discrimination against Female employees in the
matters of transfers, training and promotions etc.
i) Payment of Bonus Act 1965: The Act is applicable to all establishments employing 20 or more
workmen. The Act provides for payments of annual bonus subject to a minimum of 8.33% of wages
and maximum of 20% of wages to employees drawing Rs.3500/- per month. or less. The bonus to be
paid to employees getting Rs.2500/- per month or above upto Rs.3500/- per month. shall be worked
out by taking wages as Rs.2500/- per month only. The Act does not apply to certain establishments.
The newly set-up establishments are exempted for five years in certain circumstances. Some of the
State Governments have reduced the employment size from 20 to 10 for the purpose of applicability
of the Act.
j) Industrial Disputes Act 1947: The Act lays down the machinery and procedure for resolution of
Industrial disputes, in what situations a strike or lock-out becomes illegal and what are the
requirements for laying off or retrenching the employees or closing down the establishment.
k) Industrial Employment (Standing Orders) Act 1946: It is applicable to all establishments employing
100 or more workmen (employment size reduced by some of the States and Central Government to
50). The Act provides for laying down rules governing the conditions of employment by the Employer
on matters provided in the Act and get the same certified by the designated Authority.
l) Trade Unions Act 1926: The Act lays down the procedure per registration of trade unions of workmen
and employers. The Trade Unions registered under the Act have been given certain immunities from
civil and criminal liabilities.
m) Child Labour (Prohibition & Regulation) Act 1986: The Act prohibits employment of children below
14 years of age in certain occupations and processes and provides for regulations of employment of
children in all other occupations and processes. Employment of Child Labour is prohibited in Building
and Construction Industry.
n) Inter-State Migrant workmen‘s (Regulation of Employment & Conditions of Service) Act 1979 :- The
Act is applicable to an establishment which employs 5 or more inter-state migrant workmen through
an intermediary (who has recruited workmen in one state for employment in the establishment situated
in another state). The Inter-State migrant workmen, in an establishment to which this Act becomes
applicable, are required to be provided certain facilities such as Housing, Medical-Aid, Travelling
expenses from home upto the establishment and back etc.
o) The Building and Other Construction workers (Regulation of Employment and Conditions of Service)
Act 1996 and the Cess Act of 1996: All the establishments who carry on any building or other
construction work and employs 10 or more workers are covered under this Act. All such
establishments are required to pay cess at the rate not exceeding 2% of the cost of construction as may
be modified by the Government. The Employer of the establishment is required to provide safety
measures at the Building or construction work and other welfare measures, such as Canteens, First-
Aid facilities, Ambulance, Housing accommodations for workers near the work place etc. The
46 NCB.CW/W-1
Employer to whom the Act applies has to obtain a registration certificate from the Registering Officer
appointed by the Government.
p) Factories Act 1948: The Act lays down the procedure for approval at plans before setting up a factory,
health and safety provisions, welfare provisions, working hours, annual earned leave and rendering
information regarding accidents or dangerous occurrences to designated authorities. It is applicable to
premises employing 10 persons or more with aid of power or 20 or more persons without the aid of
power engaged in manufacturing process.
3. SUB-CONTRACTING (GCC Clause 7)
Please add the following as Clause 7.2:
The contractor shall not be required to obtain any consent from the employer for:
a) the sub-contracting of any part of the Works for which the Sub-contractor is named in the contract;
b) the provision of labour; and
c) the purchase of materials which are in accordance with the standards specified in the Contract.
Beyond this if the contractor proposes sub-contracting any part of the work during execution of works,
because of some unforeseen circumstances to enable him to complete the work as per terms of the contract,
the Engineer will consider the following before according approval:
- The contractor shall not sub-contract the whole of the Works.
- The contractor shall not sub-contract any part of the Work without prior consent of the Engineer. Any
such consent shall not relieve the contractor from any liability or obligations under the contract and he
shall be responsible for the acts, defaults and neglects of any sub-contractor, his agents or workmen as
fully as if they were the acts, defaults or neglects of the contractor, his agents or workmen.
- The Engineer should satisfy whether (a) the circumstances warrant such sub-contracting; and (b) the
sub-contractors so proposed for the Work possess the experience, qualifications and equipment
necessary for the job proposed to be entrusted to them in proportion to the quantum of work to be sub-
contracted.
- If payments are proposed to be made directly to that sub-contractor, this should be subject to specific
authorization by the prime contractor so that this arrangement does not alter the contractor's liability or
obligations under the contract.)
4. ARBITRATION (GCC Clause 25.3)
The procedure for arbitration will be as follows :
25.3 (a) In case of Dispute or difference arising between the Employer and a domestic contractor relating
to any matter arising out of or connected with this agreement, such disputes or difference shall
be settled in accordance with the Arbitration and Conciliation Act, 1996. The arbitral tribunal
shall consist of 3 arbitrators one each to be appointed by the Employer and the Contractor. The
third Arbitrator shall be chosen by the two Arbitrators so appointed by the Parties and shall act a
presiding arbitrator. In case of failure of the two arbitrators appointed by the parties to reach
upon a consensus within a period of 30 days from the appointment of the arbitrator appointed
subsequently, the Presiding Arbitrator shall be appointed by the * Indian Council of
Arbitration/President of the Institution of Engineers (India)/The International Centre for
Alternative Dispute Resolution (India).
____________________________________ (Note: 1. All bidders are expected to indicate clearly in the bid, if they proposed sub-contracting parts of the works amounting to more than 20 percent
of the Bid Price. For each such proposal the qualification and the experience of the identified sub-contractor in the relevant field should be furnished
alongwith the bid to enable the employer to satisfy himself about their qualifications before agreeing for such sub-contracting and include it in the
contract. In view of the above, normally no additional sub-contracting should arise during execution of the contract.)
2. However, [a] sub contracting for certain specialized elements of the work is not unusual and acceptable for carrying out the works more
effectively; but vertical splitting of the works for subcontracting is not acceptable [b] In any case, proposal for sub-contracting in addition to
what was specified in bid and stated in contract agreement will not be acceptable if the value of such additional sub-contracting exceeds 25%
of value of work which was to be executed by Contractor without sub-contracting.
3. Assignment of the contract may be acceptable only under exceptional circumstances such as insolvencies/liquidation or merger of
companies etc.
47 NCB.CW/W-1
(b) In the case of dispute with a Foreign contractor the dispute shall be settled in accordance with
provisions of UNCITRAL (United Nations Commission on International Trade Law) Arbitration
Rules. The Arbitral Tribunal shall consist of three Arbitrators one each to be appointed by the
Employer and the Contractor. The third Arbitrator shall be chosen by the two Arbitrators so
appointed by the Parties, and shall act a presiding arbitrator. In case of failure of the two
arbitrators appointed by the parties to reach upon a consensus within a period of 30 days from
the appointment of the arbitrator appointed subsequently, the Presiding arbitrator shall be
appointed by the * Indian Council of Arbitration/President of the Institution of Engineers
(India)/The International Centre for Alternative Dispute Resolution (India).
(c) If one of the parties fails to appoint its arbitrator in pursuance of sub-clause (a) and (b) above
within 30 days after receipt of the notice of the appointment of its arbitrator by the other party,
then the * Indian Council of Arbitration/President of the Institution of Engineers (India)/The
International centre for Alternative Dispute Resolution (India), both in cases of the Foreign
Contractor as well as Indian Contractor, shall appoint the arbitrator. A certified copy of the
order of the *Indian Council of Arbitration/President of the Institution of Engineers (India)/The
International Centre for Alternative Disputes Resolution (India), making such an appointment
shall be furnished to each of the parties.
(d) Arbitration proceedings shall be held at Anand, Gujarat, India, and the language of the
arbitration proceedings and that of all documents and communications between the parties shall
be English.
(e) The decision of the majority of arbitrators shall be final and binding upon both parties. The cost
and expenses of Arbitration proceedings will be paid as determined by the arbitral tribunal.
However, the expenses incurred by each party in connection with the preparation, presentation,
etc. of its proceedings as also the fees and expenses paid to the arbitrator appointed by such
party or on its behalf shall be borne by each party itself.
(f) In the event value of the contract is upto Rs.50 millions, the disputes or differences arising shall
be referred to the Sole Arbitrator. The Sole Arbitrator should be appointed by agreement
between the parties, failing such agreement by the appointing authority, i.e. the *Indian Council
of Arbitration/President of the Institution of Engineers (India)/The International Centre for
Alternative Disputes Resolution (India).
(g) Performance under the contract shall continue during the arbitration proceedings and payments
due to the contractor by the owners shall not be withheld, unless they are the subject matter of
the arbitration proceedings.
5. PROTECTION OF ENVIRONMENT:
Add the following as GCC Clause 16.2:
The contractor shall take all reasonable steps to protect the environment on and off the Site and to
avoid damage or nuisance to persons or to property of the public or others resulting from pollution,
noise or other causes arising as a consequence of his methods of operation.
During continuance of the contract, the contractor and his sub-contractors shall abide at all times by all
existing enactments on environmental protection and rules made thereunder, regulations, notifications
and bye-laws of the State or Central Government, or local authorities and any other law, bye-law,
regulations that may be passed or notification that may be issued in this respect in future by the State
or Central Government or the local authority.
Salient features of some of the major laws that are applicable are given below :
* Choose one alternative. Insert Chairman of the executive Committee of the Indian Roads Congress
(for highway project) or any other appropriate institutions (for other types of works).
48 NCB.CW/W-1
The Water (Prevention and Control of Pollution) Act, 1974, This provides for the prevention and
control of water pollution and the maintaining and restoring of wholesomeness of water. 'Pollution'
means such contamination of water or such alteration of the physical, chemical or biological
properties of water or such discharge of any sewage or trade effluent or of any other liquid, gaseous or
solid substance into water (whether directly or indirectly) as may, or is likely to, create a nuisance or
render such water harmful or injurious to public health or safety, or to domestic, commercial,
industrial, agricultural or other legitimate uses, or to the life and health of animals or plants or of
aquatic organisms.
The Air (Prevention and Control of Pollution) Act, 1981, This provides for prevention, control and
abatement of air pollution. 'Air Pollution' means the presence in the atmosphere of any 'air pollutant',
which means any solid, liquid or gaseous substance (including noise) present in the atmosphere in
such concentration as may be or tend to be injurious to human beings or other living creatures or
plants or property or environment.
The Environment (Protection) Act, 1986, This provides for the protection and improvement of
environment and for matters connected therewith, and the prevention of hazards to human beings,
other living creatures, plants and property. 'Environment' includes water, air and land and the inter-
relationship which exists among and between water, air and land, and human beings, other living
creatures, plants, micro-organism and property.
The Public Liability Insurance Act, 1991, This provides for public liability insurance for the purpose
of providing immediate relief to the persons affected by accident occurring while handling hazardous
substances and for matters connected herewith or incidental thereto. Hazardous substance means any
substance or preparation which is defined as hazardous substance under the Environment (Protection)
Act 1986, and exceeding such quantity as may be specified by notification by the Central
Government.
[Employers should note that the Loan Agreement between IBRD and the borrowing country may
establish specific measures to be taken during construction of the Works for the protection of the
environment. Sub-clause 16.2 should be modified/expanded to take into account such specific
measures or other measures considered appropriate by the Employer]
6. LIQUIDATED DAMAGES:
Sub-clause 49.1:
Please substitute the last sentence with the following:
―Time is the essence of the contract and payment or deduction of liquidated damages shall not relieve
the contractor from his obligation to complete the work as per agreed construction program and
milestones or from any other of the contractor‘s obligations and liabilities under the contract.‖
50 NCB.CW/W-1
Contract Data
Items marked "N/A" do not apply in this Contract.
The following documents are also part of the Contract: Clause Reference
· The Schedule of Operating and Maintenance Manuals [58]
· The Schedule of Other Contractors [8]
· The Schedule of Key Personnel [9]
· The Methodology and Program of Construction [27]
· The Schedule of Key and Critical equipment to be deployed [27]
on the work as per agreed program of construction
· Site Investigation reports [14
The Borrower is Government of India / .............................................. [1.1]
[name of Borrower and statement of relationship with the Employer, if
different from the Borrower].
The World Bank means ____________________________ [1.1]
________________________________________________
[insert ”International Bank for Reconstruction and Development (IBRD)” or
International Development Association (IDA), “as appropriate] ,
and loan refers to an __________________
[insert “IBRD Loan” or “IDA Credit”, as appropriate]
The above insertions should correspond to the information provided in the Invitation for Bids.
The Employer is :
Name: Birla Vishvakarma Mahavidyalaya, Vallabh Vidyanagar (1.1)
Address: Mota Bazar, Vallabh Vidyanagar, Anand-388120
Name of authorized Representative: __________________________
The Engineer is [1.1)
Name: ______________________________________________
Address: ________________________________________________
Name of Authorized Representative: __________________________
The name and identification number of the Contract is
________________________________________________________________________________________
[insert name and number as indicated in the Invitation for Bids (or Prequalification, if any]. [1.1]
The Works consist of ---------------------------------------------------------------
[brief summary, including relationship to other contracts under the Project].
The start date shall be the date of issue of notice to proceed with the work. (1.1)
51 NCB.CW/W-1
The intended completion Date for the whole
of the work is PLACE HOLDER Work CompletionDate
The following documents also form part of the Contract: [2.3]
______________________________________________________
______________________________________________________
______________________________________________________
The Contractor shall submit a revised Program for the Works (in such form and
detail as the engineer shall reasonably prescribe) within 14 days of delivery
of the Letter of Acceptance. [27]
The Site Possession Date is: [21]
2
The Defects Liability Period is 365 days from the date of certification of completion of works (where sectional
completion certificate is issued this will apply from those dates for those sections). [35]
Insurance requirements are as under: [13]
Minimum Cover
for Insurance
Maximum deductible
for Insurance
(i) Works and Plant and
Materials
(ii) Loss or damage to
Equipment
(iii) Other Property
(iv) Personal injury or death
insurance:
a) for other people;
b) for Contractor‘s
Employees
In accordance with the statuary requirements
applicable to India
The following events shall also be Compensation Events: [44] [44]
1. ____________________________________________________
2. ____________________________________________________
3. ____________________________________________________
4. ____________________________________________________
The period between Program updates shall be ________ days. [27]
The amount to be withheld for late submission of an updated
Program shall be _________________________________________ [27]
The language of the Contract documents is English [3]
The law which applies to the Contract is the laws of Union of India [3]
The currency of the Contract is Indian Rupees. [46]
The proportion of payments retained (retention money) shall be 6% from
52 NCB.CW/W-1
each bill subject to a maximum of 5% of final contract price [48]
The liquidated damages for the whole of the works are
Rs. (amount) per day (49)
[To be fixed at not less than 0.01% per day of contract value]
The maximum amount of liquidated damages for the whole of the works [49]
is 10% of final contract price.
The Securities shall be for the following minimum amounts equivalent as a [52]
percentage of the Contract Price:
Performance Security for 5 per cent of contract price plus Rs. ..................... as additional
security in terms of ITB Clause 29.5.
The standard form(s) of Performance Security acceptable to the Employer shall be an [52]
unconditional Bank Guarantee of the type as presented in Section 8 of the Bidding Documents.
The amount to be withheld for failing to supply ―as built‖ drawings and/or operating and maintenance [58]
manuals* by the date required is Rs._______________________________________
The following events shall also be fundamental breach of the contract : [59.2]
1. The contractor has contravened Sub-clause 7 of GCC read with SCC and Clause 9 of GCC.
2. The contractor does not adhere to the agreed construction program (Clause 27 of GCC) and also fails to
take satisfactory remedial action as per agreements reached in the management meetings (Clause 31) for a
period of 60 days.
3. The contractor fails to carry out the instructions of Engineer within a reasonable time determined by the
Engineer in accordance with GCC Clause 16.1 and 23.1.
The percentage to apply to the value of the work not completed representing the Employer's [60]
additional cost for completing the Works shall be 20 percent.
54 NCB.CW/W-1
SPECIFICATIONS
SPECIFICATIONS OF WORKMANSHIP AND MATERIALS
Information, details, dimensions, etc. given in ‘Bill of Quantity’ shall supersede information
given in these specifications.
SPECIFICATION 1.00 ‘EARTHWORK’
SCOPE
This section covers the works specification of earthwork in excavation in all kinds of soils
including morum, hard morum, soft rock (without blasting), earth and sand filling in plinth,
rubble soling, etc.
Applicable Codes
The following Bureau of Indian Standard Codes, unless otherwise specified herein, shall be
applicable. In all cases, the latest revision of the codes shall be referred to.
IS – 4081 Safety code for blasting and related drilling operations.
IS – 1200 Method of measurement of building works.
IS - 3764 Safety code for excavation work.
IS – 3385 Code of practice for measurement of Civil Engineering works.
IS – 2720 Part II Determination of moisture content.
Part VIII Determination of moisture content dry density relation using light
compaction.
Part XXVIII Determination of dry density of soils, in-place by the sand
replacement method.
Part XXIX Determination of dry density of soils, in-place, by the core cutter
method.
Drawings
Engineer will furnish all necessary drawings showing the areas to be excavated, filled, sequence
of priorities etc. Contractor shall follow strictly such drawings.
General
Contractor shall provide all tools, plants, instruments, qualified supervisory personnel, labour,
materials, and temporary works, consumables, any and everything necessary, whether or not
such items are specifically stated herein, for completion of the Work.
Contractor shall carry out the survey of the site before excavation and set properly lines and
55 NCB.CW/W-1
establish levels for various works such as earthwork in excavation for levelling, basement,
foundations, plinth filling, roads, drains, cable trenches, pipelines etc. Such survey shall be
carried out by taking accurate cross sections of the area perpendicular to established reference /
grid lines at 5 m intervals or nearer as determined by Engineer based on ground profile. These
shall be checked by Engineer and thereafter properly recorded.
The area to be excavated /filled shall be cleared of fences, trees, plants, logs, slumps, bush,
vegetation's, rubbish slush etc. and other objectionable matter. If any roots or stumps of trees are
found during excavation, they shall also be removed. The material so removed shall be burnt or
disposed off as directed by Engineer. Where earth-fill is intended, the area shall be stripped of all
loose/soft patches, top soil containing deleterious matter / materials before fill commences.
Relics, Objects of Antiquity, Etc.
All gold, silver, oil minerals archaeological and other findings of importance, all precious stones,
coins, treasures, relics, antiquities and other similar things which may be found in or upon the
site shall be the property of owner and Contractor shall dully preserve the same to the satisfaction
of Owner and from time to time deliver the same to such person' or persons as Owner may from
time to time authorize or appoint to receive the same.
1.01 Earth work in excavation up to 1.50 M from existing Ground Level
a) Classification
Any earthwork will be classified under any of the following categories:
i) All kind of Soils: These shall include all kinds containing kankar, sand, silt, murum and
/ or shingle, gravel, clay, loam peat, ash, shale etc. which can generally be excavated by
spade, pick-axe and shovel and which is not classified under soft and decomposed rock,
and hard rock defined below. This shall also include embedded rock boulders not bigger
than 1 meter in any dimension and not more than 200 mm in anyone of the other two
dimensions.
ii) Soft Rock: This shall include rock, boulders, slag, chalk, slate, hard mica schist, laterite
etc. which are to be excavated with or without blasting or could be excavated with
picks, hammer, crow bars, wedges. This shall also include excavation in macadam and
tarred roads and pavements. This shall also include rock boulders not bigger than 1
meter in any dimension and not more than 500 mm in anyone of the other two
dimensions Rubble masonry to be dismantled will also be measured under this item.
b) The materials which are not usable for masonry shall be disposed off within the site as
decided by Employer / Architect. No extra shall be payable on this account.
c) The earth work in excavation shall be done as per the Architect and structural consultant's
drawings up to required depths and levels and alignments in all sorts of soils. The depth of the
foundation will be as per the Engineer's instructions. The lining work should be done by the
Contractor. Roots or trees met with during the excavation shall be cut and smeared with coal tar.
Excavated earth shall be stacked at least 3 m away from the trenches or as per the Engineer's
instructions, so that it may not damage the sides of the excavated trenches. The sides of the
56 NCB.CW/W-1
excavated trenches shall be vertical and in straight line and bottom uniformly leveled watered,
consolidated and ready for termite treatment. The maximum lead for stacking the earth shall be
100 m, unless otherwise categorically specified in the item description.
d) In firm soil if the excavation is deeper than 2 m the sides of the trenches shall be made bigger
by allowing steps of 50 cm on either side so as to keep the slope 0.25 to 1.0 loose soft or slushy
soil the width of the step shall be suitably increased or the sides sloped or shoring and strutting
may be done as per the Engineer's instructions.
e) For excavation for drain work, the sides and the bottoms should be to the required slope,
shape and gradient. The cutting shall be done from top to bottom. Under no circumstances shall
undermining or under cutting be allowed. The final surface shall be neatly leveled and well
compacted. The earth from the cutting shall be directly used for filling either in plinth or on
grounds.
f) For excavation in trenches for pipes nothing extra shall be payable for the lift irrespective of
the depth unless specifically mentioned otherwise in the Schedule of Quantities.
g) If the trenches are made deeper than specified level due to oversight or negligence of the
Contractor the extra depth shall be filled up by lean concrete of mix 1:5: 10(1 cement; 5 coarse
sand and 10 coarse aggregate of nominal size 40mm) and if the trench is made wider than shown
in the drawings the Contractor has to make good at his own cost. The foundation trenches shall
be free from water and muck, while the foundation work is in progress.
h) The trenches which are ready for concreting shall be got approved by the Engineer.
i) The excavated stacked earth shall be refilled in the trenches and sides of foundation in 150
mm layers and the balance surplus shall be first filled in layers in plinth and the remaining
surplus shall be disposed off by uniform spreading within the site/ outside the site as directed by
the Engineer.
j) Adequate protective measures shall be taken by the Contractor to see that the excavation for
the building foundation does not affect the adjoining structure's stability and safety. Contractor
will be responsible if he has not taken precaution for the safety of the people, property or
neighbor's property caused by his negligence during the constructional operations.
k) To the extent available, selected surplus spoils from excavated materials shall be used as
backfill. Fill material shall be free from clods, salts, sulfates, organic & other foreign material.
All clods of earth shall be broken or removed. Where excavated material is mostly rock, the
boulders shall be broken into pieces not larger than 150 mm size, mixed with properly graded
fine material consisting of murum or earth to fill up the voids and the mixture used for filling.
l) As soon as the work in foundations has been accepted and measured, the spaces around the
foundations, structures, pits, trenches etc. shall be cleared of all debris and filled with earth in
layers 15 cm to 20 cm ,each layer being watered, rammed and properly consolidated before the
succeeding one is laid. Each layer shall be consolidated to the satisfaction of Engineer.
57 NCB.CW/W-1
m) Mode of measurement for Earth work in excavation including back filling:
1) Lead: Lead for deposition/ disposal of excavated material, shall be as specified in the
respective item of work. If the lead is not specified in the respective term, a basic lead of 100 m
shall be considered for quoting rates. Only leads beyond 150m shall be considered as extra lead
and the Contractor shall be compensated for the same. For the purpose of measurement of lead
the area to be excavated or filled or area on which excavated material is to be deposited /
disposed off shall be divided into suitable blocks and for each of the blocks, the distance
between center lines shall be taken as the lead which shall be measured, as far as practically
possible, by the shortest straight line route on the plan and not the actual route taken by
Contractor. No extra compensation is admissible on the grounds that the lead including that for
borrowed materials had to be transported over marshy or katcha land/ route.
2) All excavation shall be measured net. Dimensions for purpose of payment shall be reckoned
on the horizontal area of the excavation at the base for foundations of the walls, columns,
footings, tanks, rafts or other foundations structure to be built, multiplied by the mean depth
from the surface of the ground in accordance with the drawings. Excavation inside slopes shall
not be paid for. Contractor may make such allowances in his rates to provide for excavation in
side slopes keeping in mind the nature of the soil and safety of excavation. In soft / slushy soil or
in firm soil if the excavation is deeper than 2m the sides of the trenches shall be made bigger by
allowing steps of 50cm on either side so as to keep slope 0.25:1. This shall be paid as per
original tender rate. However, if concreting is proposed against the additional / extra excavation
made by the Contractor shall be made good by the Contractor with concrete of the same class as
in the foundations at his own cost.
3) Backfilling as per specification the side of foundations of columns, footings, structures,
basement plinth, walls, tanks rafts, trenches etc. with excavated materials will not be paid for
separately. It shall be clearly understood that the rate quoted for excavation including backfilling
shall include stacking of excavated material as directed, excavation / and shifting the selected
stacked material (earth), conveying it to the place of final backfill, consolidation compaction
using plate compactor etc. as specified. As a rule material to be back filled shall be stacked
temporarily within the basic lead of 100 meters unless otherwise specified in the item.
4) The rates quoted shall also include for dumping of excavated materials in regular heaps,
bunds, riprap with regular slopes as directed by Engineer within the lead specified and leveling
the same so as to provide natural drainage. Rock / soil excavated shall be stacked properly as
directed by Engineer. As a rule, all softer material shall be laid along the centre of the heaps, the
harder and more weather resisting materials forming the casing on the sides and the top.
Excavated soft rock or hard rock shall be stacked separately.
5) The bailing out of water shall also be executed by the Contractor at his own cost.
6) The cost of shoring and strutting as demanded by the site conditions and as instructed by the
Engineer, is deemed to be included in quoted rate.
58 NCB.CW/W-1
1.03 Supplying the chemicals and carrying out pre-construction Anti-termite treatment.
a) Supplying the chemicals and carrying out pre-construction Anti-termite treatment at the various
stages of construction as per I.S. and as recommended by the chemical manufacturer to safeguard
the building against termite including execution and submission of guarantee for a period of 10
years. This work is to be got executed through Pest Control (India) Ltd as per their specifications
or an approved equivalent specialized agency.
b) For anti termite treatment chemicals used - CHLOROPYRIPHOS 20 EC @ 1 % concentration
in aqueous emulsion. At DPC level (if DPC is done) or over masonry course, 5 liter per Sq.M.
emulsion to be applied. The junction of wall and plinth (after completion of each filling) to be
done @ 1 liter per R.mt. including rodding for better spreading.5 liter per sqm emulsion to be
applied over filling after compaction. Finally the earth around the external perimeter of building
up to depth of 30 cm shall be treated @ 5 liters per R.mt. including making holes and forcing
liquid. Critical areas such as openings around pipes, cable trench etc to be soaked with chemical
emulsion.
Note: Contractor shall submit detailed specification of the chemical and application procedure
along with their offer.
c) Mode of measurement:
Building area in plan shall be measured in Sq.m. Based on the treatment provided. (No co-
efficient shall be applied) No storey (floors) calculation shall be done but guarantee shall be valid
for all the stories of the building.
SPECIFICATION 2.0 ‘CONCRETE AND ALLIED WORKS’
Applicable Codes
The following codes and standards are made a part of the Specifications. All standards, codes of
practices referred to herein shall be the latest edition including all applicable official
amendments and revisions.
In case of discrepancy between this specification and those referred to herein, his specification
shall prevail.
A) MATERIAL
IS 269 Specification for ordinary, rapid hardening and low heat Portland cement.
IS 1489 Specification for Portland-Pozzuolana cement. IS 4031 Methods of physical tests for hydraulic cement.
IS 650 Specification for standard sand for testing of cement.
IS 383 Specification for standard sand for testing of cement.
IS 2386 Methods of test for aggregates for concrete. (Parts I to VIII)
59 NCB.CW/W-1
IS 516 Methods of test for strength of concrete.
IS 1199 Methods of sampling and analysis of concrete. IS 1199 Methods of sampling and analysis of concrete.
IS 516 Methods of test for strength of concrete.
IS 1199 Methods of sampling and analysis of concrete. IS 1199 Methods of sampling and analysis of concrete. IS 3025 Methods of sampling and Test (water used in industry)
IS 432 Specification for mild steel and medium tensile steel bars and hard drawn
steel wire for concrete reinforcement.
The above mode of measurement is applicable only if it is not given specifically in the tender
document.
General
The quality of materials, method and control of manufacture and transportation of all concrete
work irrespective of mix, whether reinforced or otherwise shall conform to the applicable
portions of this specification.
Engineer shall have the right to inspect the source/ s of material/ s, the layout and operation of
procurement and storage of materials, the concrete batching and mixing equipment, and the
quality control system. Such an inspection shall be arranged and engineer's approval obtained,
prior to starting of concrete work.
Materials
The ingredients to be used in the manufacture of standard concrete shall consist solely of standard
type Portland cement, clean sand, natural coarse aggregate, clean water and admixtures.
1) Cement
a) If the Contractor is instructed to supply cement, then the following points shall be applicable:
i) Unless otherwise specified the cement shall be ordinary Portland cement in 50 kg bags. The
use of bulk cement will be permitted only with the approval of Engineer.
ii) A certified report attesting to the conformance of the cement to IS specifications by the
cement manufacturer's chemist shall be furnished to engineer if demanded.
iii) Cement held in storage for a period of Ninety (90) days or longer shall be tested. Should at
any time Engineer have reasons to consider that any cement is defective, then irrespective of its
origin, and/ or manufacturers test certificate, such cement shall be tested immediately at
contractor's cost at a National Test Laboratory / approved laboratory and until the results of such
tests are found satisfactory, it shall not be used in any work. Contractor shall not be entitled to
any claim of any nature on this account.
iv) A cement stores shall be constructed and maintained as detailed under (b) (i) here under for
storing specified quantity of cement for the project.
60 NCB.CW/W-1
v) If the cement is supplied by the OWNER
Contractor will have to make his own arrangements for the storage of minimum 250MT of
cement. If supplies are arranged by OWNER, cement will be issued in quantities to cover work
requirements of one month or more, as deemed fit by Engineer and it will be the responsibility of
contractor to ensure adequate and proper storage. Cement in bulk may be stored in bins or silos,
which will provide complete protection from dampness contamination and minimize taking and
false set. Cement bags shall be stored in a dry enclosed shed (storage under tarpaulins will not be
permitted), well away from the outer walls and insulated from the floor to avoid contract with
moisture from ground and so arranged as to provide ready access damaged or reclaimed or partly
set cement w n: not be permitted to be used and shall be removed from the site. The storage bins
and storage arrangements shall be such that there is no dead storage. Not more than 12 bags shall
be stacked in any tier. The storage arrangement shall be approved by Engineer. Consignments of
cement shall be stored as received and shall be consumed in the order of their delivery.
2) Aggregates
a) Aggregate in general designates both fine and coarse inert materials used in the manufacture of
concrete. Fine aggregate is aggregate all of which passes through 4.75 mm IS sieve. Coarse
aggregate is aggregate most of which is retained on 4.75 mm sieve
b) All fine and coarse aggregates proposed for use in the work shall be subject to Engineer's
approval and after specific materials have been accepted, the source of supply of such materials
should not be changed without prior approval of Engineer.
c) Aggregates shall, except as noted above, consist of natural sands, crushed stone and gravel
from a source known to produce satisfactory aggregate for concrete and shall be chemically inert,
strong, hard, durable against weathering, of limited porosity and free from deleterious materials
that may cause corrosion of the reinforcement or may impair the strength and/or durability of
concrete. The grading of aggregates shall be such as to produce dense concrete of specified
strength and consistency that will work readily into position without segregation and shall be
based on the mix design and preliminary tests on concrete specified later.
d) Sampling and testing
Samples of the aggregates for mix design and determination of suitability shall be taken under
the supervision of Engineer and delivered to the laboratory, well in advance of the scheduled I.
placing of concrete. Records of tests, which have been made on proposed aggregates and on
concrete made from this source of aggregates, shall be furnished to Engineer in advance of the
work for use in determining aggregate suitability. The costs of all such tests, sampling etc. shall
be borne by contractor.
e) Storage of Aggregates
All coarse and fine aggregates shall be stacked in stock separately in stock piles in the material
yard near the work site in bins properly constructed to avoid inter mixing of different aggregates.
Contamination with foreign materials and with earth during storage and while heaping the
61 NCB.CW/W-1
materials shall be avoided. The aggregate must be of specified quality not only at the time of
receiving at site but more so at the time of loading into mixer. Rackers shall be used for lifting
the coarse aggregates from bins or stockpiles. Coarse aggregate shall be piled in layers not
exceeding 1.20 meters in height to prevent coning or segregation. Each layer shall cover the
entire area of the stockpile before succeeding layers are started. Aggregates that have become
segregated shall be rejected.
f) Specific Gravity
Aggregate except as noted above and. for other than lightweight concrete shall consist of
natural or crushed sand shall conform to IS 383. The sand shall be clean sharp, hard, strong
and durable and shall be free from dust, vegetable substances, adherent coating, clay, alkali,
organic matter, mica, salt or o.ther deleterious substances, which can be injurious to the
setting qualities/ strength/ durability of concrete.
3) Machine Made Sand
If Locally available river sand is not available then, Machine made sand will be acceptable,
provided the constituent rock / gravel composition shall be sound, hard dense, non-organic
uncoated and durable against weathering.
a) Screening and Washing (both natural or machine made)
Sand shall be prepared for use for such screening or washing, or both, as necessary, to remove all
objectionable foreign matter while separating the sand grains to the required size fractions.
b) The percentages of deleterious substances in sand delivered to the mixer shall not exceed the
following:
1 Material finer than 75 Micron IS sieve 3.00 15.00
2 Shale 1.00 --
3 Coal and Lignite 1.00 1.00
4 Clay Lumps 1.00 1.00
5 Total of all above substances
including items (1) to (iv) for
uncrushed sand and items iii)
and (iv) for crushed sand
5.00 2.00
c) Gradation
Unless otherwise directed or approved, the grading of sand shall be within the limits indicated
hereunder:
Percentage passing for
IS Sieve Grading Grading Grading Grading
Designation Zone I Zone II Zone III Zone IV
10mm 100 100 100 100
4.75 mm 90-100 90-100 90-100 95-100
2.36 mm 60-95 75-100 85-100 95-100
1.18 mm 30-70 55-90 75-100 90-100
62 NCB.CW/W-1
600 micron 15-34 35-59 60-79 80-100
300 micron 5-20 8-30 12-40 15-50
150 micron 0-10 0-10 0-10 0-15
Where the grading falls outside the limits of any particular grading zone of sieves other than 600
micron IS sieve, by total amount not exceeding 5%, it shall be regarded falling within that
grading zone. This tolerance shall not be applied to percentage passing the 600 micron IS sieve
or to percentage passing any other sieve on the coarser limit of grading zone I or the finer limit of
grading zone IV.
d) Fineness Modulus
The sand shall have a fineness modulus of not less than 2.2 or more than 3.2. The fineness
modulus is determined by adding the cumulative percentages retained on the following IS sieves
sizes 4.75mm, 2.36 mm, 1.18 mm 600 micron, 300 micron and 150 micron and dividing the sum
by 100.
4) Coarse Aggregate
a) Coarse aggregate for concrete, except as noted above and for other than lightweight concrete
shall conform to IS 383. This shall consist of natural or crushed stone and gravel and shall be
clean and free from elongated, flaky or laminated pieces adhering 4 coatings, clay lumps, coal
residue, clinkers slag, alkali, mica, organic matter or other deleterious matter.
b) Screening and Washing
Natural gravel and crushed rock shall be screened and/or washed for the removal of dirt or dust
coating, if so demanded by Engineer.
c) Grading
Coarse aggregate shall be graded in both cases the grading shall be within the following limits.
IS Sieve
Designation
% passing for single sized
aggregate of nominal size mm
% passing for graded aggregate
of nominal Size mm
40 20 16 12. 10 40 20 16 12.
5 5
63mm 100 - - - - 100 - - -
40mm 85 100 - - - 95 100 - -
100 100
20mm 0- 85- 100 - - 30- 95- 100 -
20 100 70 100
16mm - - 85- 100 - - - 90 -
100 100
12.5mm - - - 85- 100 - - - 90-
100 100
10mm 0.5 0- 0- 0- 85- 10- 25- 30- 40-
20 30 45 100 35 55 70 85
4.75mm - 0-5 0-5 0- 0- 0-5 0-10 0- 0-
63 NCB.CW/W-1
10 20 10 10
2.36m - - - - 0-5 - - - -
The pieces small be angular in shape and shall have granular or crystalline surfaces, Friable,
flaky and laminated pieces, mica and shale, if present, shall be only in such quantities that will
not, is the opinion of Engineer affect adversely the strength and/ or durability of concrete. The
maximum size of coarse aggregate shall be '1b mm for class concrete 40-mm for class B concrete
and 20mm for class C concrete. The maximum size of coarse aggregate shall be the maximum
size specified above, but in no case greater than 1/4 of the minimum thickness of the member,
provided that the concrete can be placed without difficulty so as to surround all reinforcement
thoroughly and fill the corners of the form. Plums above 150 mm and up to any reasonable size
can be used in plain very concrete work of large dimensions up to a maximum limit of 200/0 of
volume of concrete when specifically approved by Engineer. For heavily reinforced concrete
members the nominal maximum size of the aggregate shall be 5 mm less than the minimum clear
distance between the reinforcing main bars or 5mm less than the minimum cover to the
reinforcement whichever is smaller. The amount of fine particles occurring in the free state or as
loose adherent shall not exceed 1 % when determined by laboratory sedimentation tests as per IS
2386. After 24 hours immersion in water, a previously dried sample shall not have gained more
than 10% of its oven dry weight in air, as determined by IS 2386.
d) Foreign Materials Limitations
The percentages of deleterious substance in the coarse aggregate delivered to the mixer shall not
exceed the following:
Percentage by Weight
Uncrushed Crushed
i) Material finer than 75 micron IS sieve 3.00 3.00
ii) Coal and Lignite 1.00 1.00
iii) Clay lumps 1.00 1.00
iv) Soft fragments 3.00 --
v) Total of all the above substances 5.00 5.00
5) Water
a) Water used for both mixing and curing shall be free from injurious amounts of deleterious
materials. Potable waters are generally satisfactory for mixing and curing concrete.
b) In case of doubt, the suitability of water for making concrete shall be ascertained by the
compressive strength and initial setting time test specified in IS-456 -2000. The sample of water
taken for" testing shall be typical of the water proposed to be used for concreting, due account
being paid to seasonal variation. The sample shall not receive any treatment before testing other
than that envisaged in the regular supply of water proposed for use in concrete. The sample shall
be stored in a clean container previously rinsed out with similar water.
64 NCB.CW/W-1
c) Average 28 days compressive strength of at least three 15 cm concrete cubes prepared with
water proposed to be used shall not be less than 90% of the average strength of three similar
concrete cubes prepared with distilled water.
d) The initial setting time or test block made with the appropriate set cement and the water
proposed to be used shall not be less than 30 minutes and shall not differ by more than plus
minus 30 seconds form the initial setting time of control test block prepared with the appropriate
test cement and distilled water. The test blocks shall be prepared and tested in accordance with
the requirements of IS 4031.
e) Where water can be shown to contain an excess of acid, alkali sugar or salt, engineer may
refuse to permit its use. As a guide, the following concentrations represent the maximum
permissible values:
i) To neutralize 100 ml sample of water, using phenolphthalein as indicator, it should not require
more than 5 ml of 0.2 normal NaOH. The details of test shall be as given in IS 3025 (part 22).
ii) To neutralize 100 ml sample of water using Mix Indicator as an indicator, it should not require
more than 25 ml of 0.02 normal H2So4. The details of test shall be given in IS 3025 (part 23).
iii) Percentage of solids when tested in accordance with the method indicated below shall not
exceed the following:
Percent Test as per
Organic 200 mg/L IS 3025-1964 ( part 18 )
Inorganic 3000mg/ L -Do-
Sulphate
(as S04 Alkali) 400 mg/ L IS 3025-1964 ( part 24 )
Chlorides (as CI) 2000 mg/L IS 3025-1964 ( part 32 )
Suspended matter 2000 mg/L IS 3025-1964 ( part 17 )
6) Brick Aggregates
The brickbats shall be of new bricks well burnt, hard, durable and broken to sizes, well graded. It
shall be free from dust; the size shall be of 37mm and down. It shall be free from earth and other
impurities.
7) Reinforcement Steel
a) Reinforcement bars, if supplies are arranged by contractor, shall be either plain round mild
steel bars grade I as per IS 432 (part I) or medium tensile steel bar as per IS 432 (Part I) or hot
rolled mild steel and medium tensile steel deformed bars as per IS 1139 or cold twisted steel bars
as per IS 1786, as shown and specified on the drawings. Wire mesh or fabric shall be in
accordance with IS 1566. Substitution of reinforcement will not be permitted except upon written
approval from Engineer.
b) Plain round mild steel bars grade II as per IS:432 (part I) may be used with prior approval of
Engineer in writing and with 10% ; increase in the reinforcement area but its use shall not be
permitted in structures located in earthquake zones subjected to severe damage (as per IS: 1895)
65 NCB.CW/W-1
and for structures subject to dynamic loading (other than wind loading), such as frames
supporting rotary or reciprocating machinery etc.
c) All reinforcement shall be clean, free from grease, oil, paint, loose: mill scale, loose rust, dust,
bituminous material or any other .j substances that will destroy or reduce the bond. All rods shall
be thoroughly cleaned before being fabricated. Pitted and defective rods shall not be used.
2.02 Providing and laying Plain Cement concrete in 1:4:8
a) (As per item for 1:4:8 Brickbat cement concrete.) Providing and laying plain cement concrete
1:4:8 (1 cement: 4 coarse sand: 8 graded stone aggregate of nominal size 37 mm and down)
b) Mode of Measurement
This shall be measured in cum and part thereof. The bed concrete provided for flooring / below
foundation or as specified shall be paid for under this item. The rate shall include cost the
shuttering to be provided.
2.03 Providing and Laying RCC of 1:1.5:3 for Foundation & Super Structure
a) All concrete works shall be carried out as per ‗Volumetric Proportion‘ only. The proportion
shall be 1 part cement, 1.5 part sand, 3 part aggregate of 20mm and down grade.
b) MINIMUM COMPRESSIVE STRENGTH OF 15 CM CUBES AT 7 AND 28 DAYS
AFTER MIXING, CONDUCTED IN ACCORDANCE WITH IS :516.
c) It shall be very clearly understood that whenever the class of concrete such as M 20 is
specified it shall be the Contractor's responsibility to ensure that minimum crushing strength
stipulated' for the respective class of concrete is obtained at works. The ~ maximum total
quantity of aggregate per 50 Kg 9f cement shall not exceed 450 Kg except when otherwise
specifically approved by Engineer.
d) To fix the grading of aggregates, water cement ratio, workability and the quantity of cement
Class
Preliminary test
(N/sq.m)
Work Test N/sq.m. Max. size
of
aggregate
mm
Minimum
Cement
Content
per Cu.M.
At 7 days At 28 days At 7 days
At 28
days
M40 35.0 54.0 27.0 46.0 20 550 Kg
M35 31.0 45.0 23.5 39.0 20 470 Kg
M30 28.0 42.0 20.0 33.0 40 or 20 420 Kg
M25 23.5 35.0 17.0 28.0 40 or 20 370 Kg
M20 19.4 29.0 13.5 22.0 40 or 20 320 Kg
M 15 14.0 17.0 10.0 16.0 40 or 20 300 Kg
66 NCB.CW/W-1
required giving preliminary and works cubes of the minimum strength specified, the proportions
of the mix shall be determined by weight/volume. Adjustment of aggregate proportions due to
moisture present in the aggregate shall be made. Mix proportioning shall be carried out
according to Indian Standard Specifications.
e) Whenever there is a change either in required strength of concrete or water cement ratio or
workability or the source of Aggregates: and/ or cement, preliminary tests shall be repeated to
determine I, the revised proportions, of the mix to suit the altered conditions.
f) While fixing the value for water cement ratio for preliminary mixes, assistance may be
derived from the graph (appendix IS 456 showing the relationship between the 28' day
compressive strengths of concrete mixes with different water cement ratios and the 7 days
compressive .strength of cement tested in accordance with IS 269.
g) Contractor shall not allow using Ready Mix Concrete (RMC).
Preliminary Tests
a) Test specimens shall be prepared with at least two different water / cement ratios for each class
of concrete, consistent with workability required for the nature of the work. The materials and
proportions used in making preliminary tests shall be similar in all respects to those to be actually
employed in the works as the object of these tests is to determine the proportions of cement,
aggregates and water necessary to produce concrete of required consistency and to give the
specified strength. It will be the Contractor's sole responsibility to carry out these tests and he
shall therefore furnish to Engineer a statement of proportions proposed to be used for the various
concrete mixes.
b) Materials shall be brought to the room temperature and all materials shall be in a dry
condition. The quantities of water, cement and aggregates for each mix shall be determined by
weight/volume to an accuracy of 1part in 1000 parts.
c) Mixing shall be done by a mixer machine as per IS 516 in such a manner as to avoid loss of
water. The cement and fine aggregate shall first be mixed dry until the mixture is uniform in
colour. The coarse aggregate shall then be added, mixed and, water added and mixed thoroughly
for a period of not less than 3 minutes until the resulting concrete is uniform in appearance. Each
mix of concrete shall be of such a quantity as to leave about 10% excess concrete after moulding
the desired number of test specimens.
d) The consistency of each mix of concrete shall be measured immediately after mixing, by the
slump test in accordance with IS 1199. If in the slump test, care is taken to ensure that no water
or other materials is lost, the materials used for the slump test may be remixed with the reminder
of the concrete for making the specimen test cubes. The period of re-mixing shall be as short as
possible yet sufficient to produce a homogeneous mass.
e) Compression tests of concrete cubes shall be made as per IS 516 on 15 cm cubes. Each mould
shall be provided with a metal base having a plane surface to support the mould during filling
without leakage. The base plate shall be preferably attached to the mould by springs or screws.
67 NCB.CW/W-1
The parts of the mould when assembled shall be positively and rigidly held together. Before
placing, concrete the mould and base plate shall be cleaned and oiled. The dimensions and
internal faces of the mould shall be accurate within the following limits:
Height and distance between the opposite faces of the mould shall be of specified size plus minus
0.2mm. The angle between the adjacent internal faces and between internal faces and top and
bottom planes of mould shall be 90 Deg. plus/minus 5 Deg. The interior faces of the mould shall
be plane surfaces with a permissible variation 0.03mm.
f) Concrete test cubes shall be moulded by placing fresh concrete in the mould and compacted as
specified in IS 516.
g) Curing shall be as specified in IS 516. The cubes shall be kept in moist air of at least 90%
relative humidity at a temperature of 27 Deg. Cent. Plus-minus two Deg. Centigrade for 24 hours
plus minus, half hour from the time of adding water to the dry ingredients. Thereafter they shall
be removed from the moulds, kept immersed in clean fresh water, and kept at 27 Deg. Centigrade
plus minus 2 Deg. Centigrade temperature until required for test. Curing water shall be renewed
every seven days. A record of maximum arid minimum temperatures at the place of storage of
the cubes shall be maintained during the period they remain in storage.
h) Testing of specimens
The strength shall be determined based on not less than five cubes test specimens for each age
and each water cement ratio. All these laboratory test results shall be tabulated and furnished to
Engineer. The test result shall be accepted by Engineer if the average compressive strengths of
the specimens are tested subject to the condition that only one out of the five consecutive test
may give a value less than the specified strength for that age. The Engineer may direct the
Contractor to repeat the tests if the results are not satisfactory and to n1ake such changes, as he
considers necessary to meet the requirements specified. All these preliminary tests shall be
conducted by the Contractor at his own cost in an approved laboratory.
Proportioning consistency, batching and mixing of concrete Proportioning
a) Aggregate:
The proportions, which shall be decided by conducting preliminary test, shall be by volume.
These proportions of cement, fine and coarse aggregates shall be maintained during subsequent
concrete mixing. The supply of properly graded aggregate of uniform quality shall be
maintained over the period of work, the grading of aggregates shall be controlled by obtaining
the coarse aggregate in different sizes and blending them in the right proportions. The different
sizes shall be stocked in separate stockpiles. The grading of coarse and fine aggregate shall be
checked as frequently as possible as determined by Engineer, to ensure maintaining of grading
in accordance with the samples used in preliminary mix design. The material shall be stock
piled well in advance of use.
b) Cement:
The cement shall be measured by volume.
c) Water
68 NCB.CW/W-1
Only such quantity of water shall be added to the cement and aggregates in the concrete mix as
to ensure dense concrete, specified surface finish, satisfactory workability, consistent with the
strength stipulated for each class of concrete. The water added to the mix shall be such as not to
cause segregation of material or the collection of excessive free water on the surface of the
concrete.
The water cement (w/c) ratio is defined as the volume of water in the mix (including the surface
moisture of the aggregates) divided by the volume of cement in the mix. The actual water
cement ratio to be adopted shall be determined in each instance by the Contractor and approved
by the Engineer.
d) Proportioning by Water /Cement Ratio (w/c)
The w/c ratio specified for use by Engineer shall be maintained. The Contractor shall determine
the water content of the aggregates as frequently as directed by Engineer as the work progress
and as specified in IS 2386. (Part-III) and the amount of water added at the mixer shall be
adjusted as directed by Engineer so as to maintain the specified w/c ratio. To allow for the
variation in volume of aggregates due to variation in their moisture content suitable adjustments
in the volume of aggregates shall also be made.
e) Consistency and slump
Concrete shall be of a consistency and workability suitable for the conditions of the job. After the
amount of water required is determined, the consistency of the mix shall be maintained
throughout the progress of the corresponding parts of the work ~ and approved tests e.g. slump
tests, compacting factor tests, in accordance with IS 1199 shall be conducted from time to time to
ensure the maintenance of such consistency.
The following tabulation gives a range of slumps, which shall generally be used for various types
of construction unless otherwise instructed by the Engineer.
SLUMPS FOR VARIOUS TYPES OF CONSTRUCTION
Only sufficient quantity of water shall be added to concrete during mixing to produce a mix of
sufficient workability to enable it to be well consolidated to be worked in to the corners of the
shuttering :1 and around the reinforcement, to give the specified surface finish, 1 and to have the
specified surface strength. The following slumps shall be adopted for different kinds of works:
Name of Work
When vibrator used When vibrator not
used
Mass concrete In foundations, footings
retaining walls and pavements.
10mm to 25mm 50 mm to 75mm
Thin sections of floors of less than 75mm thick 25mm to 40mm 75 mm to 100 mm
For reinforced cement concrete work:
Mass concreting in foundations, footings, retaining
wall and pavements
10mm to 25 mm 80 mm
Beams, slabs, columns
25mm to 40 mm 100mm to 125
mm
69 NCB.CW/W-1
Thin shells, folded plates
40mm to 50mm 124mm to 150
mm
The concrete mix shall be in the proportion as arrived at as per the mix design and all the
ingredients to be measured by weight (i.e. by weigh batching) .All concrete work shall be carried
by weigh batching only. In case if it is approved by the Engineer, the equivalent volume of coarse
and fine aggregates based on the bulk density can be adopted. Contractor shall make available
weigh scale of appropriate capacity at site for intermittent checking the weight of ingredients so
measured by volume during the concreting operation.
Sampling and testing concrete in the field
a) Facilities required for sampling materials and concrete in the field shall be provided by the
Contractor at no extra cost. The following equipment with operator shall be made available at
Engineer's request (all must be in serviceable condition):
i) One concrete cube testing machine suitable for 15 cm machine suitable for 15 cm cubes, of
100 MT capacity with proving calibration ring. The machine should be calibrated and
certification of calibration shall be produced, by the contractor.
ii) Fifteen cast iron cube moulds of 15 cm size.
iii) One set of sieves for coarse and fine aggregates.
iv) Laboratory balance to weigh up to 5 kg with sensitivity of 10gm.
v) One set of slump cone complete with tamping rod.
vi) A set of measures from 5 litre to 0.1 litre.
vii) One electric oven with thermostat up to 120 Deg. Cent.
viii) One flakiness gauge
ix) One elongation index gauge
x) One sedimentation pipette
xi) One Pyconometer
xii) Two calibrated glass jar of 1 litre capacity
The above list of the facility is an indicative and is not limiting. The contractor shall arrange
necessary laboratory equipment / glassware etc as may be required as per relevant IS
specification / code of practice or as advised by the Structural Consultants.
Arrangement can be made by the contractor to have the cubes 1 tested in an approved laboratory
in lieu of a testing machine at site' at his expense, with the prior consent of the Engineer.
b) At least six test cubes of each class of concrete shall be made for every 15.0 cum. of concrete
or part thereof. Such samples shall be drawn on each day for each type of concrete. Of each set of
6 cubes, three shall be tested at 7 days age and three at 28 days age. The laboratory test results
shall be tabulated and furnished to Engineer. Engineer will pass the concrete if average strength
of the specimens tested is not less than the strength specified, subject to the condition that only
one out of three consecutive tests may give a value less than the specified strength but this shall
not be less than 90% of the specified strength. The cubes shall be tested on 7th and 28th day from
the day of casting of the cubes.
70 NCB.CW/W-1
The requirement of number of samples shall be determined by the Engineer and as such 1 sample
for quantity of concrete up to 5 Cum 2 samples for quantity from 6 to 14 Cum to be taken.
An additional set of test cube if asked by the Engineer shall be cast and taken by the contractor
which may be kept for record verification at later date.
Admixtures
a) Admixtures may be used in concrete only with the approval of Engineer based upon evidence
that, with the passage of time, neither the compressive strength nor its durability reduced.
Calcium chloride shall not be used for accelerating setting of the cement for any concrete
containing reinforcement, or embedded steel parts. When calcium chloride is permitted to be
used, such as in mass concrete works, it shall be dissolved in water and added to the mixing
water in an amount not to exceed 1.5% of the volume of the cement in concrete. When
admixtures are used, the designed concrete mix shall be corrected accordingly. Admixtures shall
be used as per manufacturer's instructions, in the manner, and with the control specified by
Engineer.
b) Air entertaining agents
Where specified and approved by Engineer, neutralized vinyl resin or any other approved air-
entraining agent may be used to produce the specified amount of air in the concrete mix and these
agents shall conform to the requirements of ASTM standard 6260, air entraining admixtures for
concrete. The recommended total air content of the concrete is 4% plus minus 1%. The method
of measuring air content shall be as per IS:1199.
c) Water reducing admixtures
Where specified and approved by Engineer water reducing Lignosulfonate mixture shall be added
in quantities specified by Engineer. The admixtures shall be added in the form of a solution.
d) Retarding admixtures
Where specified and approved by Engineer, retarding agents shall be added to the concrete mix
in quantities specified by Engineer.
e) Water-proofing agents
Where specified and approved by Engineer, water proofing agent conforming to IS: 2645 shall
be added in quantities specified by Engineer.
Optional Tests
Engineer may order tests to be carried out on cement, sand, coarse aggregate and water in
accordance' with the relevant Indian Standards. Tests on cement shall include (i) fineness test
(ii) test for normal consistency (iii) test for setting time (iv) test for soundness (v) test for tensile
strength (vi) test for compressive strength (vii) test for 4eat of hydration by experiment and by
calculations in accordance with IS: 269. Tests on sand shall include (i) sieve test (ii) test for
organic impurities (iii) decapitation test for determining clay and silt content (iv) specific gravity
71 NCB.CW/W-1
test (v) test for unit weight and bulkage factor. Tests on coarse aggregate shall include (i) test for
sieve analysis (ii) specific gravity and unit weight of dry loose and rodded aggregate (iii)
soundness and alkali aggregate reactivity (iv) pertrographic examination (v) deleterious
materials and organic impurities (vi) test for aggregate crushing value. Any or all these tests
would normally be ordered to be carried out only if Engineer feels the materials are not in
accordance with the specifications OF if the specified concrete strengths are not obtained, and
shall be performed by contractor at site or at an approved test laboratory. If the tests are
successful, OWNER shall pay for all such optional tests on production of testing fees bills
otherwise the Contractor shall have to pay for them.
b) If the works cubes do not give the stipulated strengths Engineer reserves the right to ask
contractor to dismantle such portions of the work, which in his opinion are unacceptable and re-
do the work to the standard stipulated at contractor's cost.
In such case when the concrete fail to pass the routine tests the Engineer can order the contractor
to undertake non distractive tests like Rebound Hammer test. The field test to be carried out in
accordance with procedure described in IS 13311 (Part II). When making rebound hammer test
each result should be the average of at least 12 readings. The readings shall be taken and as per
the procedure in the relevant IS 13311 (Part II) and calibration charts available from manufacturer
to be used for interpretation. This non-distractive test shall be carried out through an approved
agency at contractors cost.
c) Load test on members or any other tests
i) In case - of any work being suspected of faulty material or workmanship or both, Engineer
requiring its removal and reconstruction may order the contractor that it should be load tested in
accordance with the following provisions.
ii) The test load shall be 125 % of the maximum superimposed load for which the structure was
designed. Such test load shall not be applied before 56 days after the effective hardening of the
concrete. During the test, struts strong enough to take the load shall be placed in position leaving
a gap under the members. The test load shall be maintained for 24 hours before removal.
iii) If within 24 hours of the removal of the load, the structure dose not show a recovery of at least
75 percent of the maximum deflection shown during the 24 hours under load the test loading
shall be repeated after a lapse of at least 72 hours. The structure shall be considered to have failed
to pass the test if the recovery after the second test is not at least 75 percent of the maximum
deflection shown during the second test. If the structure is certified as failed by Engineer, the cost
of the load test shall be borne by the contractor.
iv) If the maximum deflection in mm, shown during 24 hours under load is less than 40 (LxL)/D,
where L is the effective span in M ; and D, the overall depth of the section in mm, it is not
necessary for recovery to be measure and recovery provisions of (iii) shall not apply. This will be
governed by relevant IS.
v) Any other tests e.g. taking out in approved manner concrete cores examination and tests on
72 NCB.CW/W-1
such cores removed from such parts of the structure as directed by Engineer, Non destructive
testing etc. shall be carried out by contractor if so directed.
vi) Should the results of any test prove unsatisfactory, or the structure shows signs of weakness,
undue deflection or faulty construction the contractor shall remove and rebuild the member or
members involved or carry out such other remedial measures as may be required by Owner. the
Contractor shall bear the cost of so doing, unless the failure of the member or members to fulfil
the test conditions is proved to be solely due to faulty design.
Concrete in alkali soils and alkaline water
Where concrete is liable to attack from alkali salts or alkaline water, special cements containing
low amount of tricalcium aluminate shall be used, if so specified in the drawings. Such concrete
shall have a minimum 28 days compressive strength of 250 kg per sq.cm and shall contain not
less than 370 kg of cement per cubic meter. of concrete in place. If specified, additional
protection shall be obtained by the use of a chemically resistant, stone facing or a layer of plaster
of Paris covered with suitable fabric, such as jute thoroughly impregnated with tar.
Preparation prior to concrete placement
a) Before the concrete is actually placed in position, the insides of the formwork shall be
inspected to see that they have been cleaned and oiled. Temporary openings shall be provided to
facilitate inspection, especially at bottom of columns and walls forms to permit removal of saw
dust, wood shavings, binding wire, rubbish dirt etc. Openings shall be placed or holes drilled so
that these materials and water can be removed easily. Such openings/holes shall be later suitably
plugged.
b) The various agencies shall be permitted ample time to install drainage and plumbing lines in
floor and trench drains, electrical conduits, hangers, anchors, inserts, sleeves, bolts, frames and
other miscellaneous embedment to be cast in the concrete as indicated on the drawings or as is
necessary far the proper execution of the work Contractor shall cooperate fully with all such
agencies and shall permit the use of scaffolding form work etc. by other agencies at no extra
cost.
c) All embedded parts, inserts etc. supplied by Owner or Contractor shall be correctly positioned
and securely held in the forms to prevent displacement during depositing and vibrating of
concrete.
d) Anchor bolts shall be positioned and kept in place with the help of proper manufactured
templates. The use of all such templates fixture etc. shall be deemed included in the rates.
e) Slots, openings, holes, pockets etc. shall be provided in the concrete work in the positions indicated in the drawings or as .j directed by Engineer.
f) Prior to concrete placement all work shall be inspected and ~ approved by Engineer and if found
unsatisfactory, concrete shall not be poured until after all defects have been corrected at
Contractor's cost. Cat ladders shall be provided on the reinforcement to facilitate labourur
movement.
73 NCB.CW/W-1
g) Approval by Engineer for all materials and work as required herein shall not relieve contractor
from his obligation to produce finished concrete in accordance with the drawings and
specifications.
h) No concrete shall be placed in wet weather or on water covered surface. Any concrete that has
been washed by heavy rains, the work shall be entirely removed, if there is any sign of cement and
sand having been washed from the concrete mixture. To guard against damage, which may be
caused by rains, the works shall be covered with tarpaulins immediately after the concrete has been
placed and compacted. Any water accumulating on the surface of the newly placed concrete shall
be removed by approved means and no further concrete shall be placed thereon until such water is
removed. To avoid flow of water over / around freshly placed concrete, suitable drains and sumps
shall be provided.
i) Immediately before concrete placement begins, proposed surfaces except framework, which will
come in contract with the concrete to be placed, shall be covered with a bonding mortar.
Transportation
a) All buckets, containers or conveyors used for transporting concrete shall be mortar tight.
Irrespective of the method of transportation adopted, concrete shall be delivered with the
required consistency and plasticity without segregation or loss of slump. However, chutes shall
not be used for transport of concrete without the written permission of Engineer and concrete
shall not be re handled before placing.
b) Concrete must be placed in its final position before it becomes too stiff to work. On no
account, water shall be added after the initial mixing concrete that has become stiff or has been
contaminated with foreign materials shall be rejected and disposed off as directed by Engineer.
c) All equipment used for mixing, transporting and placing of concrete shall be maintained in
clean condition. All pans, bucket. Hoppers, chutes, pipelines and other equipment shall be
thoroughly cleaned after each period of placement.
d) Except when otherwise approved by Engineer, concrete shall be placed in shovels or other
approved implements and shall not be dropped from a height more than 1M or handled in a
manner which will cause segregation.
e) The following specification shall apply when placing of concrete by use of mechanical
equipment is specifically called for while inviting bids or is warranted considering the nature of
work involved. The control of placing shall begin at the mixer discharge, concrete shall be
discharged by a vertical drop into the middle of the bucket or hopper and this principle of a
vertical discharge of concrete shall be adhered to thoroughly all stages of delivery until the
concrete comes to rest in its final position.
f) Central bottom dump buckets of a type that provides for positive, regulation of the amount and
rate .of deposition of concrete in all dumping position shall be employed.
74 NCB.CW/W-1
g) In placing concrete in large open areas, the bucket shall be spotted directly over the position
designated and than lowered for dumping. The open bucket shall clear the concrete already in
place and the height of drop shall not exceed 1 M. The bucket shall be opened slowly to avoid
high vertical bounce. Dumping of I buckets on the swing or in any manner, which results in
separation of ingredients or disturbance of previously placed concrete, will not be permitted.
h) Concrete placed in restricted forms by wheel barrows, buggies, cars, short chutes or hand
shoveling shall be subject to the requirement for vertical delivery of limited height to avoid
segregation and shall be deposited as nearly as practicable in its final position.
i) Where it is necessary to use transfer chutes, specific approval of Engineer must be obtained to
the type, length, slopes, baffles, vertical terminals and timing of operations, the discharge and
without segregation. To allow for the loss of mortar against the sides of the chutes, the first mix
shall have less coarse aggregate. During cleaning of chutes, the wastewater shall be kept clear of
the forms. Concrete shall not be permitted to fall from the end of the chutes by more than 1 M.
Chutes when approved for use shall have slopes not flatter than 1: 3 and steeper than 1: 2 chutes
shall be of metal or metal lined and of rounded cross section. The slopes of all chutes sections
shall be approximately the same. The discharge end of the chutes shall be maintained above the
surface of the concrete in the forms.
j) Concrete may be conveyed and placed by mechanically operated equipment e.g. pumps or
pneumatic placers only with the written permission of Engineer. The slump shall be held to the
minimum, necessary for conveying concrete by this method.
k) When pumping is adopted, before pumping of concrete is started, the pipeline shall be
lubricated with one or two batches of mortar composed of one part cement and two parts sand.
The concrete mix shall be specially designed to suit pumping. Care shall be taken to avoid
stoppages in work once pumping has started.
l) When pneumatic placer is used, the manufacturer's advice on layout of pipeline shall be
followed to avoid blockages and excessive wear. Restraint shall be provided at the discharge box
to cater for the reaction at this end. Manufacturer's advice shall be followed regarding concrete
quality and all other related matters when pumping or pneumatic placing equipment is used.
m) Concreting, once started, shall be continuous until the pour is completed. Concrete shall be
placed in successive horizontal layers of uniform thickness ranging from 15 to 90 mm as
directed by Engineer. These shall be placed as rapidly practicable to prevent the formation of
cold joints or planes of weakness between each succeeding layer within the pour. The thickness
of each layer shall be such that it can be deposited before the previous layer has stiffened. The
bucket loads or other units of deposit shall be spotted progressively along the face of the layer
with such overlap as well facilitate spreading the layer to uniform depth and texture with a
minimum of shoveling. Any tendency to segregation shall be corrected by shoveling stones into
mortar rather than mortar on to stones. Such a condition shall be corrected by redesign of mix or
other means, as directed by Engineer.
n) The top surface of each pour and bedding planes shall be approximately horizontal unless
75 NCB.CW/W-1
otherwise instructed.
o) Compaction
i) Concrete shall be compacted during placing the approved vibrating equipment until the
concrete has been consolidated to the maximum practicable density, is free of pockets of coarse
aggregate and fits tightly against all form surfaces, reinforcement and embedded fixtures.
Particular care shall be taken to ensure that all concrete placed against the forms faces and into
corners of forms or against hardened concrete at joints is free from voids or cavities. The use of
vibrators shall be consistent with the concrete mix and caution exercised not to over vibrate the
concrete to the point those segregation results.
ii) Vibrators shall conform to BIS / IS specifications. Type of vibrator to be used shall depend on
the structure where concrete is to be placed. Shutter vibrators to be effective, shall be firmly
secured to the formwork which must be sufficiently rigid to transmit the vibration and strong
enough not to be damaged by it. Immersion vibrators shall have no load frequency, amplitude
and acceleration as per IS 2505 depending on the size of vibrator. Immersion: vibrators in
sufficient numbers and each of adequate size shall be used to properly consolidate all concrete.
Tapping or external vibrating of forms by hand tools or immersion vibrators will not be
permitted.
iii) The exact manner of application and the most suitable machines for the purpose must be
carefully considered and operated by experienced men. Immersion vibrators shall be inserted
vertically at points not more than 450 mm apart and withdrawn when air bubbles cease to
come to the surface. Immersion vibrators shall be withdrawn very slowly. In no case shall
immersion vibrators be used to transport concrete inside the forms. Particular attention shall
be paid to vibration at the top of a lift e.g. in a column or wall.
iv) When placing concrete in layers, which are advancing horizontally as the work
progresses, great care shall be exercised to ensure adequate vibration, blending and mixing
of the concrete between the succeeding layers.
v) The immersion vibrator shall penetrate the layer being placed and also penetrate the layer
below with the under layer is still plastic to ensure good bond and homogeneity between the
two layers and prevent the formation of cold joints.
vi) Care shall be taken to prevent contact of immersion vibrators against reinforcement steel.
Immersion vibrators shall not be allowed to come in contact with reinforcement steel after
start of initial set. They shall also not be allowed to come in contact with forms or finished
surfaces.
vii) Form attached vibrators shall be used only with specific authorization of Engineer.
viii) The surface vibrators will not be permitted under normal conditions. However, for thin
slabs vibration by specially designed vibrators may be permitted upon approval of Engineer.
Where as for cement concrete pavements appropriate surface vibrator shall be used in addition to
76 NCB.CW/W-1
immersion vibrator approved by the engineer.
ix) The formation of stone pockets or mortar bondage's in corner and against faces of forms shall
not be permitted. Should these occur, they shall be dug out, reformed and refilled to sufficient
depth and shape for through bonding, as directed by Engineer.
q) Placement Interval
Except when placing with slip forms each placement of concrete in multiple lift work, shall be
allowed to set for at least 24 hours after the final set of concrete and before the start of a
subsequent placement.
r) Special Provision in Placing
When placing concrete in walls with openings and in floors of integral slab and beam
construction and other similar conditions, the placing shall stop when the concrete reaches the
top of the opening in walls and bottom horizontal surface of the slab, as the case may be placing
shall be resumed before the concrete in place takes initial set, but not until it has time to settle as
determined by Engineer.
s) Placing Concrete through reinforcement Steel
When placing concrete through reinforced steel, care shall be taken to prevent segregation of the
coarse aggregate. When the congestion of .steel makes placing difficult, it may be necessary to
temporarily move the top steel aside to get proper placement and restore reinforcing steel to
design position.
t) Bleeding
Bleeding of free water, on top of concrete being deposited, in to the forms shall be caused to
stop the concrete pour. The conditions causing this defect corrected before any further
concreting is resumed.
Curing, protecting, repairing and finishing
a) Curing
i) All concrete shall be cured by keeping it continuously damp for the period required for
complete hydration and hardening to take place shall cure all concrete. Preference shall be given
to the use of continuous sprays or ponded water continuously saturated covering of sacks,
canvas, Hessian or other absorbent materials, Or approved effective curing compounds applied
with spraying' equipment capable of producing a smooth, even textured coat. Extra precautions
shall be exercised in curing concrete during cold and hot water as outlined hereinafter. The
quality of curing water shall be the same as that used for mixing concrete.
ii) Certain types of finish or preparation for overlaying concrete must be done at certain stage of
the curing process and special, treatment may be required for specific concrete surface finish.
iii) Curing of concrete made of high alumna cement and super sulphate cement shall be carried
out as directed by Engineer.
iv) Fresh concrete shall be kept continuously wet for a minimum period of 10 days from the date
of placing of concrete following a lapse of 12 to 14 hours after laying of concrete. The curing of
77 NCB.CW/W-1
horizontal surfaces exposed to the drying winds shall however begin immediately the concrete
has hardened. Water shall be applied uniformly to concrete surfaces within 1 hour after concrete
has set. Water shall be applied to formed surfaces immediately upon removal of forms quantity of
water applied shall be controlled to prevent erosion of freshly placed concrete.
v) Curing shall be assured by use of an ample water supply under pressure in pipes with all
necessary appliance of hose, sprinklers and spraying devices. Continuous fine mist spraying or
sprinkling shall be used, unless otherwise specified or approved by Engineer.
vi) Whenever, by the judgment of Engineer, it may be necessary to omit the continuous spray
method, a covering of clean sand or other approved means such as wet gunny bags, which will
prevent loss of moisture from the concrete, may be used. No type of covering will be approved
which would stain or damage the concrete during or after the curing period. Covering shall be
kept continuously wet during the curing period.
vii) For curing of concrete in pavements, sidewalks floors, flat roofs or other level surfaces, the
ponding method of curing is preferred. The method of containing the ponded water shall be
approved by Engineer. Special attention shall be given to edges and comers of the slabs to ensure
proper protection to these areas. The ponded area shall be kept continuously filled with water
during the curing period.
viii) Surface coating type compounds shall be used only by special permission of Engineer;
curing compounds shall be liquid type white pigmented. Other curing compounds shall be used
on surfaces where future blending with concrete, water or acid proof membrane or painting is
specified.
ix) All equipment and materials required for curing shall be on hand and ready for use before
concrete is placed.
b) Protecting fresh concrete
Fresh concrete shall be protected from defacements and damage due to construction operation by
leaving forms in place for an ample period as specified later in this specification. Newly placed
concrete shall be protected by approved means such as tarpaulins from rain, sun and winds. Steps
as approved by Engineer shall also be taken to protect immature concrete from damage by debris,
excessive loading, vibration, abrasion or contact with other materials etc that may impair the
strength and / or durability of the concrete. Workmen shall be warned against and prevented from
disturbing green concrete during it setting period. If it is necessary that workmen enter the area of
freshly placed concrete, Engineer may require that bridges be placed over the area.
c) Repair and replacement of unsatisfactory concrete:
i) Immediately after the shuttering is removed, the surface of concrete shall be very carefully
inspected and all defective areas called to the attention of Engineer who may permit patching of
the defective areas or also reject the concrete unit either partially or entirely. Rejected concrete
shall be removed and replaced by contractor at no additional expense to owner. Holes left by
from bolts etc. Shall be filled up and made good with mortar composed of one part of cement to
78 NCB.CW/W-1
one and half parts of sand passing 2.36 mm IS sieve after removing any loose stones adhering to
the concrete shall be finished as described under the particular items of work.
ii) Superficial honey combed surfaces and rough patches shall be similarly made good
immediately after removal of shuttering in the presence of Engineer and superficial water and air
holes shall be filled in. The mortar shall be well worked into the surface with a wooden float.
Excess water shall be avoided. Unless instructed otherwise by Engineer the surface of the
exposed concrete placed against shuttering shall be rubbed down immediately on removal of
shuttering to remove fine or other irregularities and necessary care being taken to avoid damage to
the surface. Surface irregularities shall be removed by grinding.
iii) If reinforcement is exposed or the honeycombing occurs at vulnerable positions e.g. ends of
beams or columns it may he necessary to cut out the member completely or in part and
reconstruct. The decision of Engineer shall be final in this regard. If only patching is necessary,
the defective concrete shall be cut out till solid concrete is reached (or to a minimum depth of
25mrn) the edges being cut perpendicular to the affected surface or with small under cut if
possible. Anchors, tees or dovetail slots shall be provided whenever necessary to attach the new
concrete securely' in place an area extending several centimeters beyond the edges, and the
surfaces of the prepared voids shall be saturated with' water for 24 hours immediately before the
patching material is placed.
iv) The use of epoxy for bonding fresh concrete used for repairs will be permitted upon written
approval of Engineer. Epoxy shall be applied in strict accordance with the instructions of the
manufacturer.
v) Small size holes having surface dimensions about equal to the depth of the hole, holes left after
removal of form bottom, grout insert holes and slots cut for repair of cracks shall be repaired as
follows. The hole to be patched shall be roughened and thoroughly soaked with water until
absorption stops.
A 5mm thick layer of grout of equal parts of cement and sand shall be well brushed into the
surface to be patched, followed immediately by the patching concrete, which shall be well
consolidated with a wooden float. The concrete patch shall be built up in 10 mm thick layers.
After an hour or more, depending upon weather conditions, it shall be worked off flush with a
wooden float and smooth finish obtained by wiping with Hessian; a steel trowel shall be used for
this purpose. The mix for patching shall be of same material and in the same proportions as that
used in the concrete being repaired, although some reduction in the maximum size of the coarse
aggregates may be necessary and the mix shall be kept as dry as possible.
Mortar filling by air pressure (guniting) shall be used for repairing of areas too large and/ or too
shallow for patching with mortar. Patched surfaces shall be given a final treatment to match the
colour and texture of the surrounding concrete. While cement shall be substituted for ordinary
cement, if so directed by Engineer, to match the shade of the patch with original concrete.
vii) The patched area shall be covered immediately with an approved non-staining water
saturated material such as gunny bag which shall be kept continuously wet and protected against
sun and wind for a period of 24 hours. Thereafter, the patched area shall be kept wet
continuously by fine spray of sprinkling for not less than 10 days.
79 NCB.CW/W-1
viii) Any minor cavity in the element or water pass through a joint, the affected area shall be
grouted with an approved means as approved by the Engineer. This will not however applicable
to any defect which is in case established during testing.
ix) All materials, procedures and operations used in the repairing of concrete and also the
finished repair work shall be subject to the approval of Engineer. All fillings shall be tightly
bonded to the concrete and shall be sound, free from shrinkage cracks after the fillings have been
cured and finished.
d) Finishing
i) The type of finish for formed concrete surface shall be as follows, unless, other wise specified
by the Engineer.
For surfaces against which backfill or concrete is to be placed, no treatment is required except
repairing of defective areas.
For surface below grade, which will receive, waterproofing treatment the concrete shall be free of
surface irregularities, which would interfere with proper application of the waterproofing
material which is specified for use.
Unless specified, surfaces which will be exposed when the structure is in service shall receive no
special finish, except repairing of damage or defective concrete removal of fins and abrupt
irregularities, fillings of holes left by form ties and rods and clean up of loose or adhering debris.
ii) Surfaces which will be exposed to the weather and which would normally be level shall be
sloped for drainage. Unless the drawing specifies such as stair treads, walls shall be sloped across
the width approximately 1 in 30 broader surface such as walkways. roads, parking areas and
platforms shall be sloped about 1 in 50. Surfaces that will be covered by backfill or concrete sub
floors to be covered either concrete topping, terrazzo or quarry tile and similar surfaces shall be
smoothing screeded and leveled to produce even surfaces. Surface irregularities shall not exceed
6mm. Surfaces which will not be covered by backfill, concrete or tile toppings such as outside
decks, floors of galleries and sumps parapets, gutters, sidewalks floors and slabs shall be
consolidated screeded and floated. Excess water and laitance shall be removed before finishing.
Floating may be done with hand or power tools and started as the screeded surface has attained a
stiffness to permit finishing operation and these shall be the minimum required to produce a
surface uniform in texture and free from screed marks or other imperfections. Joints edge panels
and forms linings shall be of uniform size and are as large as practicable and installed with closed
joints. Upon removal of forms the joint marks shall be smoothed off and all blemishes, .1
projections etc; removed leaving the surfaces reasonably smooth and unmarred.
iv) Integral cement concrete finish
When specified on the drawings and integral cement concrete finish of specified thickness for
floors and slabs shall be applied either monolithic or bonded as specified on the drawing as per
80 NCB.CW/W-1
IS:2571. The surface shall be compacted and than floated with a wood float or power floating
machine. The surface shall be tested with a straight edge and any high and low pots eliminated.
Floating or toweling of finish shall be permitted only after all surfaces water has evaporated. Dry
cement or a mixture of dry cement and sand shall not be sprinkled directly on the surface of the
cement finish to absorb moisture or to stiffen the mix.
Mode of Measurement
i) The unit rate for concrete work under various categories shall be all inclusive and no claims for
extra payment on account of such items as leaving holes, embedding inserts etc. shall be
entertained unless separately provided for in the schedule of quantities. No extra claim shall also
be entertained due to change in the number, position end/ or dimensions of holes soils or
openings sleeves, inserts or on account of any increased lift or scaffolding etc. All these factors
should be taken into consideration while quoting the unit rates.
ii) Payments of concrete will be made on the basis of unit of the respective item specified in the
Schedule of Quantities. No deduction in the concrete quantity will be made for reinforcements,
inserts etc. and opening less than 0.05cu.m. Where concrete is measured in cu.m. Where no such
deduction for concrete is made, payment for shuttering work provided for such holes, pockets
etc. will not be made.
Providing and erecting formwork for structure up to plinth level
(No extra cost shall be given for Formwork/shuttering. Contractor shall quote price of any
type of concrete work with its shuttering at any level of respective work. This content for
‘shuttering’ is mentioned here for its detail specification only)
a) The formwork shall consist of shores, bracings, sides of beams and columns, bottom of slabs
etc, including ties anchors, hangers inserts etc, complete which shall be properly designed and
planned for the work. False work shall be so constructed that necessary adjustment can be made
to compensate for take up and settlements. Wedge may be used at the top or bottom of timber
shores but not at both ends to facilitate vertical adjustment or dismantling of the formwork.
b) Design of formwork
The design of the formwork as well as its construction shall be the responsibility of Contractor.
If so instructed, the drawings and/or calculation for the design for the formwork shall be
submitted to Engineer for approval before proceeding with work, at no extra cost. Engineer's
approval shall not however relieve Contractor of the full responsibility for the design and
construction of the formwork. The design shall take into account the entire load vertical and
lateral that the forms will be carrying live and vibration loadings.
c) Type of formwork
Formwork may be of timber, plywood metal, plastic or concrete. For special finishes the
formwork may be lined with plywood, steel sheets oil tempered hard board etc. Sliding forms
and slip forms may be used with the approval of Engineer.
81 NCB.CW/W-1
d) Form work requirements
i) Forms shall conform to the shapes, lines, grades and dimensions including camber of the
concrete as called for on the drawings. Ample studs, braces, ties, straps, etc. shall be used to
hold the forms in proper position without any distortion whatsoever until the concrete is set
sufficiently to permit removal of forms. Forms shall be strong enough to permit the use of
immersion vibrators. In special cases form vibrators may also be used. The shuttering shall be
close boarded. Timber shall be well seasoned, free from sap, shakes, loose knots, worm holes,
warps or other surface defects in contact with concrete. Faces coming in contact with the
concrete shall be free from adhering grout, plaster, and paint, projecting nails, splits or other
defects. Joints shall be sufficiently tight to prevent loss of water or any fine material from
concrete.
ii) Plywood shall be used for exposed concrete surfaces where called for. Sawn and wrought
timber may be used for unexposed surfaces. Inside faces of forms for concrete surfaces, these
are to be rubbed finished shall be planed to remove irregularities or uneven ness in' the face.
Formwork with linings shall be permitted.
iii) All new and used form timber shall be maintained in a good condition with respect to shape,
strength, rigidity, water tightness, smoothness and cleanliness of surfaces. Form timber
unsatisfactory in any respect shall not be used and if ejected by Engineer shall be removed from
the site.
iv) Shores supporting successive members shall be placed directly over those below or be so
designed and placed that the load will be transmitted directly to them. Trussed supports shall be
provided for shores that cannot be secured on adequate foundations.
v) Formwork, during any stage of construction showing signs of distortion or distorted to such a
degree that the intended concrete work will not conform to the exact contours indicated on the
drawings, shall be repositioned and strengthened. Poured concrete affected by the faulty
formwork, shall be removed completely and the formwork be corrected prior to placing of new
concrete.
vi) Excessive construction camber to compensate for shrinkage, settlement may impair the
structural strength of members and shall not be permitted.
vii) Forms shall be so designed that their removal will not damage the concrete. Face formwork
shall provide true vertical and horizontal joints, conform to the architectural features of the
structure as to location of joints and be as directed by engineer.
viii) Where exposed smooth or rendered concrete finishes are required the forms shall be
constructed with special care so that the resulting concrete surfaces require a minimum finish.
e) Formwork for Slope Surfaces
82 NCB.CW/W-1
i) Forms for sloped surfaces shall be built so that the formwork can be placed board-by-board
immediately ahead of concrete placement so as to enable ready access for placement, vibration
inspection and repair of the concrete.
ii) The formwork shall also be built so that the boards can be removed one by one form the
bottom up as soon as the concrete has attained sufficient stiffness to prevent sagging. Surfaces of
construction joints and finished surfaces with slopes steeper than 4 horizontal: 1 vertical shall be
formed as required herein.
f) Formwork for Curved Surfaces
i) The contractor shall interpolate intermediate sections as necessary and shall construct the
forms so that the curvature will be continuous between sections. Where necessary to meet
requirements for curvature, the form timber shall be built up of laminated spleens cut to make
tight, smooth form surfaces.
ii) After the forms have been constructed, all surface imperfections shall be corrected and all
surface irregularities at matching faces of form material shall be dressed to the specified
curvature.
g) Bracing struts and propos
i) Shuttering shall be braced, strutted, propped and so supported that it shall not deform under
weight and pressure of the concrete and also due to the movement of men and other materials.
Bamboos shall not be used as props or cross bearers.
ii) The shuttering for beams and slabs shall be so erected that the shuttering on the sides of the
beams and under the soffit of slabs can be removed without disturbing the beam bottoms. Re--
propping of beams shall not be done except when props have to be reinstated to take care of
construction loads anticipated being in excess of the design load. Vertical props shall be
supported on wedges or other measures shall be taken whereby the props can be gently lowered
vertically while striking the shuttering. If the shuttering for a column is erected for the full height
of the column, one side shall be left open and built up in sections as placing of concrete from the
sides to limit the drop of concrete to 3M or as directed by engineer.
h) Mould Oil
Care shall be taken to see that the faces of form wok coming in contact with concrete are
perfectly cleaned and two coats of mould oil or any other approved material applied before fixing
reinforcement and placing concrete. Such coating shall be insoluble in water, non-staining and
not injurious to the concrete. It shall not become flaky or be removed by rain or wash water.
Reinforcement and/ or other items to be cast in the concrete shall not be placed until coating of
the forms is complete adjoining concrete surface shall also be protected against contamination
from the coating material.
j) Chamfers and Fillets
83 NCB.CW/W-1
All corners and angles exposed in the finished structure shall be formed with moldings to form
chamfers or fillets on the finished concrete. The standard dimension of chamfers and fillers,
unless otherwise specified shall be 20 mm x 20 mm. Care shall be exercised to ensure accurate
moldings. The diagonal face of the moldings shall be planned or surfaced to the same texture as
the forms to which it is attached.
k) Wall Tiles
Wire ties passing through the walls shall not be allowed. In their place bolts through sleeves are
used.
l) Reuse of Forms
Before reuse, all forms shall be thoroughly scraped, cleaned, nails removed, holes that may leak
suitably plugged and joints examined and when necessary, repaired and the inside retreated to
prevent adhesion to the satisfaction of Engineer. Warped lumber shall be resized. Contractor
shall equip himself with enough shuttering material to complete the job in the stipulated time.
m) Removal of forms
i) Contractor shall record on the drawings and in a special register the date upon which the
concrete is placed in each part of the work and the date on which the shuttering is removed there
from. The Contractor shall remove the shuttering after obtaining the approval of the Engineer.
ii) In no circumstances shall forms be struck until the concrete reaches strength of at least twice
the stress due to self weight and any construction/erection loading to which the concrete may be
subjected at the time of striking formwork.
iii) In normal circumstances (generally where temperatures are above 20 Deg. Cent.) forms may
be removed after expiry of the following periods:
Items Ordinary Portland cement concrete.
(Engineers instruction shall be
considered as priority instruction then
mentioned.
a) Walls columns and vertical sides of
Beams
24 hrs or directed by the Engineer.
b) Soffit formwork to slabs propos to be
re-fix immediately after removal of
formwork
3 days or –do-.
c) Beams soffit with propos left under
beams
7 days or –do-.
d) Removal of propos to slab
i) Spanning up to 4.5 mtr. 7 days or –do-.
ii) Spanning over 4.5 mtr. 14 days or –do-.
84 NCB.CW/W-1
e) Removal of props to Beams and arches
i) Spanning up to 4.5 mtr. 14 days
ii) Spanning over 4.5 mtr. 21 days
For other cements and lower temperature, the stripping time recommended above shall be
suitably modified by the Engineer in conformity with the relevant code of practice or
recommendations by the manufacturer.
iv) Striking shall be done slowly with utmost care to avoid damage to arises and projections and
without shock or vibration, by gently easing the wedges. If after removing the formwork, it is
found that timber has been embedded in the concrete, it shall be removed and made good as
specified earlier.
v) Reinforced temporary openings shall be provided as directed by Engineer to facilitate removal
of formwork which otherwise may be inaccessible.
vi) Tie rods, clamps, form bolts etc. which must be entirely removed from walls or similar
structures shall be loosened not sooner than 24 hours nor later than 40 hrs. After the concrete has
been deposited, ties, except those required to hold forms in place, may be removed at the same
time. Ties, withdrawn from walls and grade beams shall be pulled towards the inside face cutting
ties back from the faces of walls and grade beams will not be permitted.
vii) For liquid retaining structures no sleeves for through bolts shall be used nor shall through
bolts be removed as indicated above. The bolts, in this case, shall be cut at 25 mm depth from the
surface and then the hole shall be made good by polymer modified cement mortar of the same
proportions as the concrete just after striking the formwork.
Necessary approach / staging for ease of the access of .workmen, inspection and supervision
staff, in accordance with safety requirements and as per the instructions of the Engineer to be
provided for all types of formwork for all the elements at all the depth / heights the cost of such
arrangements detailed here above shall be deemed to be included in the quoted unit price of the
item.
Mode of Measurement
No payment shall be done as extra for this item. Contractor shall quote for RCC item with cost of
shuttering only.
2.06A Providing, fabricating and placing in position Reinforcement Steel
The quality of the steel shall be as mentioned in the materials section. The bars shall be
fabricated as per the drawings. Laps and splices for reinforcement shall be as shown on the
drawings. Engineer shall approve splices in adjacent bars. The bars' shall not be lapped unless the
length required exceeds the maximum available lengths of bars at site.
85 NCB.CW/W-1
Bending
a) Reinforcing bars supplied bent or in coils, shall be straightened before they are cut to size.
Straightening of bars shall be done in cold and without damaging the bars. This is considered as a
part of reinforcement bending fabricating work.
b) All bars shall be accurately bent according to the sizes and shapes shown on the detailed
working drawings/bar bending schedules. They shall be bent gradually by machine or other
approved means. Reinforcing bars shall not be straightened and bend in a manner that will injure
the material, bars containing cracks or splits shall be rejected. They shall be bent cold, except
bars of over 32mm in diameter that may be bent hot if specifically approved by Engineer. Bars
bent hot shall not be heated beyond cherry red colour (not exceeding 845 deg. centigrade and
after bending shall be allowed to cool slowly without quenching. Bars incorrectly bent shall be
used only if the means used for straightening and re-bending shall not injure the material. No
reinforcement shall be bent when in position in the work without approval whether or not it is
partially embedded in hardened concrete. Bars having kinks or bends other than those required by
design shall not be used.
Fixing
a) Reinforcement shall be accurately fixed by any approved means and maintained in the
correct position shown in the drawings by the use of block, spacers and chairs as per IS 2502
to prevent displacement during placing and compaction of concrete. Bars intended to be in
contact at crossing points shall be strongly bound together at all such points with two
numbers 16 to 18 gauge annealed soft iron wire or GI wire as specified in the tender. The
vertical distance required between successive layers of bar in beams or other members shall
be maintained by providing of mild steel spacer bars at such intervals that the main bars do
not perceptibly sag between adjacent spacer bars.
Cover
a) Nominal cover is the design depth of concrete cover to all steel reinforcement, including
links. Unless indicated otherwise on the drawings, clear concrete cover for reinforcement
(exclusive of plaster or other decorative finish) shall be as follows:
i) At each end of reinforcing bar, not less than 25 mm or not less than twice the diameter of
the bar whichever is less.
ii) For a longitudinal reinforcing bar in a column, not less than 40mm, or less than the
diameter of such bar. In case of columns of minimum dimensions of 20 cm or under, whose
reinforcing bars do not exceed 12 mm, a nominal cover of 25 mm may be used.
iii) For longitudinal reinforcing bars in a beam 25 mm or not less than the diameter of the bar.
iv) For tensile, compressive, shear, or other reinforcement in a slab or wall not less than
20mm or not less than the diameter of such reinforcement.
86 NCB.CW/W-1
v) For footings minimum cover of shall be 50 mm. Incase concrete is deposited on prepared
ground surface other than PCC the cover shall be to the bottom reinforcement shall be 75 mm.
vi) For concrete surfaces exposed to the weather or the ground after removal of forms, such as
retaining walls, footing sides and top etc. not less than 50 mm for bars larger than 16 mm dia
and not less than 40 mm for bars 16 mm diameter or smaller.
vii) Increased cover thickness shall be provided, as indicated on the drawings, for surfaces
exposed to the action of harmful chemicals (or exposed to earth contaminated by such
chemical, acid, alkali, saline atmosphere, sulphurous smoke, etc.
viii) For reinforced concrete members, totally or periodically immersed in sea water or subject to
sea water spray, the cover of concrete shall be 50mm more than those specified in (i) to (v)
above.
ix) For liquid retaining structures the minimum cover to all steel shall be 40mm or the diameter
of the main bars, whichever is greater. In the presence of sea water and soils and waters of a
corrosive character the cover shall be increased by 10 mm.
x) Protection to reinforcement in case of concrete exposed to harmful surroundings may also be
given by providing dense impermeable concrete with. approved protective coatings, as specified
by the Engineer.
xi) Concrete / Cement mortar cover blocks of same strength or PVC cover blocks of approved
quality shall be provided to maintain the correct cover. Concrete / PVC cover blocks to be tied /
fixed with reinforcement steel bars to ensure the bar remains in position. The use of pebbles or
stones shall not be permitted.
Inspection
Erected and secured reinforcement shall be inspected, jointly measured and recorded and
approved by Engineer prior to placement of concrete.
Mode of Measurement
Lengths of reinforcement steel shall be measured to the nearest centimeter. Spacers and chairs
shall be measured and & converted to weight using IS coefficients. The actual quantity of steel
embedded in concrete as calculated and approved by Engineer, irrespective of the level or the
height at which the work is done shall be taken. The unit rate for reinforcement shall include all
wastages, binding wire, cover blocks etc. for which no separate payment shall be made. Laps as
shown in drawings or as approved by Engineer and minimum number of chairs and spacer bars
required to keep the reinforcement in position shall be paid for.
No wastage or rolling margin for over weight shall however be payable when steel is supplied by
the contractor whereas for under weight it should be paid at actual if allowed to use.
87 NCB.CW/W-1
SPECIFICATION 3.00 ‘MASONARY WORKS’
a) The following codes, standards and specifications are made a part of this specification. All
standards, tentative specifications, codes of practices referred to herein shall be the latest edition
including all applicable official amendments and revisions.
IS 1077 For Common Burnt Clay Bricks.
IS 3102 Classification of Burnt Clay Bricks.
IS 2180 Burnt Clay building bricks, heavy duty.
IS 3495 Method of Sampling and testing for clay building bricks
IS 2691 Burnt clay facing bricks
IS 2221 Code of Practice for Brick Work
IS 2185 Load bearing hollow concrete blocks
IS 5498 Lime cement cinder hollow concrete blocks
IS 3115 Lime cement cinder solid blocks
IS 1597 Code practice for construction of stone masonry
3.01 Providing and constructing brick masonry in CM in foundation and up to plinth level
a) Bricks used in works shall be bricks of specified crushing strength as described in the
schedule of Quantities. They shall have the following general properties:
They shall be sound, hard, and homogenous in texture, well burnt in kiln without being vitrified,
table moulded, deep red, cherry or copper coloured, of regular shape and size and shall have
sharp and square edges and paralleled faces. The bricks shall be free from pores, chips, flaws or
humps of any kind. Bricks containing ungrounded particles and which absorb water more than
1/ 5th of their weight when soaked in water for twenty-four hours shall be rejected. Over burnt
or under burnt bricks shall be liable to rejection. These bricks shall give a clear ringing sound
when struck.
b) Samples of bricks shall be submitted before starting the brickwork to the Engineer for
approval. Bricks supplied shall conform to these approved samples. Brick sample shall be got
tested as per IS 3495 by Contractor at no extra cost. Bricks rejected by Engineer shall be removed
from the site of works within 24 hours.
b) Mortar
i) Mix for cement mortar shall be as specified in the respective items of work. Gauge boxes for
sand shall be of such dimensions that one complete bag of cement containing 50 kgs of cement
forms one unit. The sand shall be free from clay shale, loam, alkali, and organic matter and of
sound, hard, clean and durable particles. Sand shall be approved by the engineer. If so directed
by the engineer sand shall be thoroughly washed till it is free of any contamination.
ii) For preparing cement mortar the ingredients shall first be mixed thoroughly in dry condition.
Water shall then be added and mixing continued to give a uniform mix of required consistency.
Cement mortar shall preferably be machine mixed, through mixing in a thorough manner may be
88 NCB.CW/W-1
allowed. The mortar so mixed shall be used within 30 minutes of mixing. Mortar left unused in
the specified period shall be rejected.
iii) The Contractor shall arrange for test on mortar samples if so directed by the engineer re-
tempering of mortar shall not be permitted.
d) Workmanship
i) All bricks shall be thoroughly soaked in clean water for at least one hour immediately before
being laid. The cement mortar for brick masonry work shall be as specified in the respective item
of work. Brick work 230 mm thick and over shall be laid in English bond unless otherwise
specified. While laying bricks shall be pressed in to the mortar and shoved into final position so
as to embed the brick fully, in mortar. Bricks shall be laid with frogs uppermost.
ii) All brickwork shall be plumb, square and true to dimensions. Vertical joints in alternate
courses shall come directly one over the other and be in line. Horizontal courses shall be levelled.
The thickness of brick courses shall be kept uniform. For walls of thickness greater than 230 mm
both faces shall be kept in vertical planes. No broken bricks shall be used except as closures. Care
shall be taken that the bricks forming the top corners and ends of the wall shall be properly
radiated and keyed into position. Holes kept in masonry for scaffolding shall be closed before
plastering. All interconnected brickwork shall be carried out at nearly one level (so that there is
uniform distribution of pressure on the supporting structure) and no portion of the work shall be
left more than one course lower than the adjacent work where this is not possible, the work shall
be raked back accordingly to bond (and not saw toothed) at an angle not exceeding 45 degree.
iii) Bricks shall be so laid that all joints are well filled with mortar. The thickness of joints shall
not be less than 6mm and not more than 10 mm. The face joint shall be raked to a minimum
depth of 12mm by raking- tools daily during the progress of work when the mortar is still green
so as to provide a proper key for the plaster or pointing to be done. Where plastering or pointing
is not required to be done the joints shall be uniform in thickness and be struck flush and
finished at the time of lying. The face of brickwork shall be cleaned daily and all mortar
droppings removed. The surface of each course shall be thoroughly cleaned of all dirt before
another course is laid on top. If the mortar in the lower course has begun to set the joints shall be
raked out to a depth of 12 mm before another course is laid.
iv) All brickwork shall be built tightly against columns, floor slabs or other structural member.
v) Where drawings. Indicate that structural steel columns are to be fireproofed with brickwork
the brick shall be built closely against all flanges and webs with all spaces between the steel and
bricks works filled solid with mortar. Steel member's partly embedded in brickwork and not
indicated to be fireproofed with concrete shall be covered with not less than 12mm thick mortar
unless directed otherwise by engineer.
vi) The work shall be cured for 15 days.
a) Miscellaneous inserts in masonry e.g. sleeves, wall ties, anchors, conduits, structural sheet,
89 NCB.CW/W-1
steel lintels etc. shall be installed by the Contractor. Furnishing fixing of any of these inserts by
the Contractor will be paid for separately under steelwork. Openings, arches, etc. shall be
provided as shown on the drawings, chasses, pockets etc. shall be provided as shown on the
drawings to receive rain water pipes etc. Wall ties and flashing shall be built into the brickwork in
accordance with the drawings and specifications.
f) Mode of Measurement
i) Brick work of thickness one brick i.e. 230 mm and above shall be paid in units of cum.
In all cases, the quantities measured shall be executed after making necessary deductions for
openings etc. as given below:
No deductions shall be done for openings up to 1000 sq. cm., ends of dissimilar materials,
drainage holes, window/door holdfasts, concrete lintel bearings, landing slab bearing, beam
bearing, chimney flues, cut-outs, iron fixtures, pipes up to 30cm dia.
ii) It shall be clearly understood that the rates quoted by Contractor include leaving openings,
cutting chases brickwork as per drawings/ instructions of the Engineer.
iii) The rate includes necessary single or double scaffolding, centering, soaking of bricks, raking
out joints and curing the work all complete.
3.02 Providing and brick work in CM in super structure at all levels
The general specification is same as per item (of Brickwork below plinth) above including
scaffolding, staging etc. as required.
Mode of Measurement
Same as above item of Brickwork below plinth.
3.03 Providing and constructing 115 mm brick masonry in partition at all levels in CM
The bricks shall be laid with stretchers. The proportion of the mortar shall be as specified in the
item description. The quality of the bricks shall be as specified in the item 3.01. Two nos. of 6mm
dia MS bars or 25mm x 1.2 mm deep iron band kept at every fourth course as specified in BOQ.
Mode of Measurement
The brick work shall be measured in sq.m. The deductions shall be as specified in the item 3.01.
The rate includes necessary single or double scaffolding, centering, soaking of bricks, providing
and placing of 2 nos. of 6 mm dia MS bars or 25mm x 1.2 mm thick iron band, raking out joints
and curing the work all complete.
90 NCB.CW/W-1
SPECIFICATION 4.00 ‘DOORS, WINDOWS, VENTILATION WORK’
Applicable Codes
IS: 4021 Timber Doors, windows, ventilator frames.
IS:2202 Wooden flush door shutters (solid core type) part I
IS:1003 Timber panel and glazed shutter (Part I & II).
IS:4020 Method of tests for wooden doors.
IS:1948 Aluminum doors, windows and ventilations.
IS:1949 Aluminum windows for Industrial Building.
4 WOOD WORK
4.01 Providing and Fixing For Fully glazed windows / ventilations including frames, hinges,
Aluminium anodised fixing of glazed with transparent frosted or figured glass clips, putty
fixtures, fittings. Necessary iron fastening, fixtures, handles, stoppers with primer coat of
approved quality and two coats of enamel/oil paint etc.
This shall confirm to i.s. 1038. And no sections shall be less then specified in ls.1038. The
members shall be electrically flash butt welded. This item includes all types of window such as
fixed, partially fixed and partially hinged side hung, bottom hung, top hung centre hung etc. or
composition of any two or more and all other windows types as specified and sized in engineer
drawings. The necessary accessories such as handles, stays. Stoppers etc. Shall be provided as
per the directions of engineer,
The wood shall be pucca Sal wood of approved quality as per general specification of materials
For window frame and shall be of 12.5cms x 7.0cms.size The window shutter frame size shall be
10 cm x 3.7cms to 4cms.of pucca teak wood Necessary holes for housing the holdfasts shall be
made. The frame shall be made in true line, level and in plumb, the house shall be grouted with
cement mortar 1:4 and surface finished of smooth, windows shall be glazed with either
transparent. Frosted or figured glass as approved by the engineer. Glazing shall confirm to the
relevant specification. Glass shall not be less than or 4 mm.thick glass including necessary
cutting of glass etc. & shall be fixed by putty, wood bids or aluminium bead as directed by the
engineer. Windows shall be painted with approved primer and make surface enamel painted two
coats. M.S.round bright bar of12 mm dia & m.s.flat 32 x 6 mm should be provided at required
spacing in windows as per direction of engineer.
Rate include all as above including glazing materials all labour and shall be paid per Smt of clear
opening of masonry gap i.e. out to out of frame.
1 but for louvered item no.1.3 ventilation having wooden frame size 12.5 x 7.0 cm. With 4 mm
th. & 100 mm. Wide bajari glass fitted in slanty grooves in wooden frame and fixed with 25 mm
x 20mm. t.w.bettens all around including approved quality of primer and two coats of oil. Paint,
91 NCB.CW/W-1
4.02: Providing and fixing in position partly panelled partly glazed doors as per design
including necessary aluminium anodised or iron anodised fittings and fixtures. One coat of
wood primer and two coats of approved quality enamel paint etc. Complete as directed.
The work for doors shall be carried out as per relevant specifications of p.w.d. Hand book vol.1
and as per drawings and instructions of engineer in charge during execution of work. The wood
for frame shall be pucca sal wood of approved quality as per general specifications of
materials, the frame shall be 127mm x 65mm.( Sal wood for frame only).the Door shutter shall
be 10cms to 12.5cms x 4.0 cms. Thick. The door bottom rail and middle rail. Shall be 15cms x
4.0 cms. thick top rail 10cms to 12.5cms. Size: the scantlings for the pucca teak wood 40mm
door shutter shall be as under.the styles and rails shall be provide as per detailed drawing
supplied by the engineer. The panels shall be 19mm thick B.C.T.wood or as approved by the
engineer. The teak wood scantlings shall be prepared from the best quality of pucca teak and
shall generally be free from any defects like loose. Knots. Cracks, wraping etc. And relevant
specifications shall be followed from specifications of material.Aluminium anodised fixture like
handles,tower bolt hinge's door catcher, aldrop etc. of approved make shall be provided as per
details or instruction of the engineer. All fixtures and fastenings shalt bf fixed with galvanised
nattlfold (or equivellent) screws for glazing work specification refer the item of fully glazed
window.
The wood work shall be painted with one: coat of primer and two coats of synthetic enamel paint
of approved make shade. the surface after final coat painted shall give even shade and wood base
shall not be visible on surface the contractor shall have to apply further Coats of paints without
any cost so as to bring finished surface even in texture and without appearance of wood base and
1nster marks. The width shall be measured from out to out of frames and height shall be
measured from flooring. The clearance between bottom of shutter and floor shall not be more
than half centimetre the rate include cost of all materials and necessary labour as above and also
include all lead and lifts.
The payment shall be made on Smt Basis.
SPECIFICATION 5.0 ‘FINISHING WORKS (PLASTER WORKS)’
Applicable Codes
IS:2394 Code of Practice for application for Lime plaster
IS:1477 Code of Practice for Painting Ferrous metals in Buildings and allied finishes
IS:427 Distemper, dry colour as required
IS:2395 Code of practice for Painting concrete, masonry and plaster surfaces.
IS:428 Distemper, oil emulsion, colour as required.
92 NCB.CW/W-1
5.01 Providing and applying Cement Plaster (12mm minimum thickness)
(Application for internal & external walls, ceiling, chhajja, etc. on brickwork or RCC work)
The surface to be plastered shall be washed with fresh clean water free from all dirt, loose
material grease etc. and thoroughly wetted for 6 hours before plastering work is commenced.
Concrete surfaces to be plastered will however be kept dry. The wall should not be too wet but
only damp at the time of plastering the damping shall be uniform to get uniform bond between
the plaster and the wall. The junction between the brickwork and RCC should be fixed with
chicken wire mesh/PVC strip as directed before plaster.
The proportion of the mortar shall be as specified under the respective items of work. Cement
shall be mixed thoroughly in dry condition and then just enough water added to obtain a
workable consistency. The quality of water, sand and cement shall be as mentioned in the
Specifications for Concrete & allied works. The mortar thus mixed shall be used immediately and
in no case shall the mortar be allowed to stand for more than 30 minutes after mixing with water.
The plaster shall be laid in a single coat. The mortar shall be splashed on the prepared surface
with a trowel and finished smooth by trowelling. The plastered surface shall be rubbed with iron
plate till the surface shows cement paste. Then pure (neat) cement paste made with ‗water of
lime‘ or plain water as directed by engineer shall be applied on cement plaster. The paste shall be
then rubbed with metal trowel with enough pressure so that air bubble should not be formed. The
work shall be in required line, level and plumb including cutting and providing grooves of
20mmx6mm or as per the details for rain water drips. Undulation shall not be more then 1.00 mm
in 1.0 mtr. length of plaster. Curing of plaster shall be started as soon as the applied plaster has
hardened enough so as not to be damaged. Curing shall be done by continuously applying water
in a fine spray and shall be carried out for at least 7 days. Contractor shall not add neeru, lime
paste into the plaster.
The plaster shall be carried out on jambs, lintel and sill faces top and undersides, etc. as shown in
the drawing or as directed by the engineer.
Contractor shall make water drips, rain water moulds/ cornices etc. on all weather shed, beams,
lintels, etc. (where water is likely to penetrate/surface drained into the building) free of cost.
Mode of Measurement
The quantity of work to be paid for under this item shall be calculated by taking the projected
surface of the area plastered after making necessary deductions for openings, doors, windows etc.
as given below:
i) No deductions shall be made for opening or end steel joints, beams, post girders etc. up to 0.5
sqm area. No addition shall be made for joints, soffits and sills of such openings. This is
applicable to both the sides of the wall.
93 NCB.CW/W-1
ii) Where opening exceeds 0.5 sqm. but does not exceed 3 sqm and also when only one side of
the wall is treated and other side is not treated, deduction shall be made if the width of the reveal
on the treated sides is less than that on the untreated side but if the width of the reveal is more
then no deduction nor addition shall be made for reveals for jambs, soffits, sills etc.
iii) For openings more than 0.5sqm but not exceeding 3 sqm and also when both the sides of the
wall is plastered with the similar plaster, deduction shall be made for one face only. But when
both the sides treated with different plaster, then deduction shall be made from the side on which
the reveal is less and no deduction on the other side.
iv) For openings whose respective areas exceed 3 sqm deductions shall be made for the full
opening of the wall treatment on both faces while at the same time jambs, sills and soffits shall be
measured in sq.m. for payment. In measuring the jambs deduction shall not be made for the area
in contact with the frames of doors, windows etc.
v) If the average thickness of the plaster is more than the specified thickness due to any account
nothing extra shall be paid for the same.
vi) Nothing extra shall be paid for double scaffolding and the rate is applicable for work at all
levels. All levels mean on floor height, generally for 3.65mtrs.
It shall be measure in sq.mtrs.
SPECIFICATION 6.00 ‘FLOORING WORK’
Applicable codes
IS: 1443 Code of practice for laying and finishing of cement concrete flooring tiles.
IS: 777 Glazed earthenware tiles
6.01 Providing and fixing pre-cast Mosaic Tile Flooring
The type, quality, size, thickness, colour etc. of the tiles for flooring shall, be as per the item
description given in the Schedule of Quantities and of best quality. Generally total thickness of
the tile shall not be less then 25mm. The tile shall be factory made under pressure process with
backing layer of cement to aggregate proportion of 1:3 and wearing layer of minimum 8 mm
conforming to approved sample / manufacturer. The contractor shall provide the Engineer with
necessary sample for approval.
Before the tiling work is commenced, the sub-surface shall be thoroughly cleaned and washed of
all loose material, dirt, and scum and then shall be wetted without forming water pools on the
surface. The tiles shall be laid on cement mortar (in CM 1:7) bedding of 50mm minimum
thickness and proportion as specified in the item description. The mortar shall be evenly spread
on the sub-floor. Over this mortar bed, 4.4 kg of cement per sq.m of floor area shall be spread.
The tiles shall be fixed on this bed one after another. Each tile being gently tapped with a
wooden mallet till it is properly bedded and in level with the adjoining tiles. The joints shall be
94 NCB.CW/W-1
perfectly straight and uniform in thickness. The tiles shall be laid perfectly in level unless
otherwise specified by the Engineer. After laying the tiles the joints shall be cleaned with wire /
coir brush and finished with cement slurry of matching colour with addition of pigment as
specified / directed.
Floor tiles laid adjoining the wall shall project 12mm or as specified under the plaster, skirting or
dado as directed by the Engineer. Half tiles and pieces shall be avoided as far as possible. After
laying the tiles, it shall be cured for at least 14 days. About a week after laying the tiles each and
every tile shall be lightly tapped with a small wooden mallet to find out if it gives a hollow
sound, if it does, such tiles along with any other cracked or broken tiles shall be removed and
replaced with a new tile to proper line and level. The same procedure shall be followed again
after the tiles are finally polished. For the purpose of ensuring that such replaced tiles match with
those earlier laid it is necessary that the Contractor order enough extra tiles from the factory to
meet this contingency.
After the joints have attained sufficient strength, the floors shall be machine polished using
carboroundum stone of No. 60, followed by 120, 150 and final coat with 320 Grit stone to the
desired finish approved by the Engineer. Sufficient quantity of water shall always be used during
polishing to prevent scratches. After each coat of polish with grit No. 60, 120 / 150 the surface to
be applied with cement slurry of matching shade and cured before next polish is taken up. After
final polish with No. 320 stone, the surface to be cleaned with water and dried Oxalic acid shall
then be dusted over the surface @ 33 gms sprinkled with water and rubbed hard with Namadah
blocks with machine.
Wax polishing shall be carried out as specified in the item specification by applying wax over the
cleaned surface and sprinkling dry saw dust when the wax is set and then polish with machine
fitted with Namadah or woolen rags block. The used saw dust shall then be swept to get polished
surface. Care should be taken that the saw dust used is free from dust particles or any impurities.
The final surface should not show any trace of wax when polished.
The final polished surface shall be mopped with wet cloth every day at. least for 10 days.
Mode of Measurement
Unit of measurement for floor tiling shall be sq.m or part thereof of the superficial area. Actual
quantity of tiling work carried out shall be measured and paid for after making deductions for
openings etc. The rate shall include embedding of tile below wall plaster / skirting.
The rate quoted for flooring and dado work shall be inclusive of angles and corner pieces, cutting
tiles for water points, such away that the point is in the junction of four tiles, electrical points etc.
Providing & fixing pre-cast Mosaic tiles in skirting, dado and risers
Quality of tile shall conform to same as specified in item 5.01 and of thickness not less than 25
mm. For dado and skirting work, the vertical surface shall be thoroughly cleaned, scraped
dismantled so as to provide the face of the skirting / dado in desired plane and wetted. Thereafter
it shall be evenly and uniformly covered with about 12mm thick 1:3 cement mortar. For this
work the tiles as obtained from the factory shall be of the size required and practically fully
95 NCB.CW/W-1
polished. The back of each tile to be fixed shall be covered with a thin layer of neat cement paste
and the tile shall then be gently tapped against the wall with a wooden mallet. This shall be done
from the bottom of the surface upwards. The joints shall be as close as possible and the work
shall be truly vertical and flush. The tiles shall be fixed flush with the plaster or projected as
specified by the Engineer. The junction of the plaster and the skirting or dado shall be neatly
finished. The joints shall be cleaned and filled with cement with or without pigment to match the
shade of tile. After the tile has set and cured the same to be polished with machine / hand with
carborundum stones as detailed in item no. 5.01 so that the surface attains a glossy finish.
Corners and junctions are finished true.
Mode of measurement
Skirting, dado or risers shall be measured in sq.m. The rate shall include providing tiles including
wastage, laying as per specifications, filling joints, curing, rubbing and polishing etc. all
complete.
6.02 Providing and laying polished green kota stone flooring
Stones shall be of selected quality, hard, sound, dense and homogenous In texture free from
cracks, decay of weathering and flaws and of approved quality, size and uniform thickness as
specified in the item specification, edges shall be machine cut and the top surfaces shall be
machine polished with joints running true and parallel from side to side. The sides (edges) shall be
table rubbed with coarse sand or machine rubbed before paving. Stones should be laid on a bed of
cement mortar of specified mix and thickness. The pattern of the flooring shall be as per the
Architect's drawing or as directed by the Engineer. Thickness of mortar bedding shall be of 1:7 in
CM mortar, however thickness any place shall not be less then 50mm. The stone slabs shall be
thoroughly wetted with clean water. Mortar of the specified mix shall be spread under the area of
each slab in accordance with the overall slope, roughly to the average thickness as specified in
item. It shall be pressed tapped with wooden mallet and brought to the level. The stone to be lifted
and laid aside. The top surface of the mortar to be corrected by adding fresh mortar at hollows.
The mortar is allowed to harden a bit and cement slurry of honey like consistency shall be spread
over the same @ 4.4 Kg per Sqm. The edges of the slabs already paved to be buttered with cement
with or without pigment. The slab to be tapped to desired level with a fine joint. The surplus
cements slurry to be cleaned.
Care should be taken so that the stone slab is set over the bed and fixed over cement slurry
without any hollow pocket. There should be no voids left underneath. The joints should be struck
smooth cleaned with wire / coir brush and grouted with cement slurry of matching colour. If
specified terrazzo filling of specified thickness or strips of different stone strip shall be provided
in the joints between the kota stone slabs. The floor should be kept covered with damp sand or
water for a week. The stone flooring shall be machine polished as item no: 5.01and then cleaned
with oxalic acid as specified as specified in item of Mosaic Tile flooring and wax polished as
specified in the item specification. The finished floor shall be mopped with water mixed with
kerosene as directed by the Engineer for 10 times in next 7 to 10 days.
The general slope for any area as per the drawing / directions of the Engineer shall be provided in
sub base / PCC and or the grade slab as the case may be. Excess thickness of bedding mortar in
96 NCB.CW/W-1
the event of failure of maintaining necessary slope shall not be paid .The contractor should mark
the levels well in advance and preceding course should be laid accordingly. The contractor should
also make level marks as per the final finished floor level before taking up the flooring work.
Mode of Measurement
This shall be measured in sq.m. The rate shall include providing and laying, curing, machine
polishing, cleaning etc. all complete. The rate quoted for flooring and dado work shall be
inclusive of angles and corner pieces, cutting tiles for water points, such away that the point is in
the junction of four tiles, electrical points etc.
Providing and laying kota stone in skirting and dado.
The stone shall be of required sizes and the thickness shall be as mentioned in the item
specification. The stones shall be pre-polished and machine cut. The thickness of the exposed
edges shall be uniform and polished smooth before fixing. The stone's edges shall be dressed fine
true, straight and at right angles to each other. The stones shall be fixed over cement mortar bed
1:4 : (1 cement; 4 coarse sand) when dried with the help of cement slurry The joints are filled with
cement with addition of pigment: to match the shade and machine / hand polished washed as per
previous item and wax polished as specified in the item specification. The joint between the top
of skirting/ dado and plaster shall be finished properly. The joints in the flooring shall be
continued in the skirting/dado also. The work shall be cured properly.
Skirting shall be of varying height where slopes are provided in the floor. The top of skirting /
dado should be made in horizontal and in level to receive dado of glazed / ceramic tiles as per the
approved scheme / drawing where finished surface shall be maintained in one plane. Cutting of
masonry wall to the required depth keeping in view the finished wall treatment is included in this
item.
Mode of Measurement
As per item of Mosaic tile skirting.
6.03 Providing and laying Indian Water proofing on terraces, sunken slabs, etc.
Waterproofing treatment shall be as specified in the schedule of items over RCC terrace slabs,
chajjas and sloping roof with or without cut-outs, openings, inverted beams, ducts, vents, pipe
lines etc. All proprietary material shall be laid to manufacturer's specifications and proportions
but in no case less than the specifications and proportions as detailed in the following
paragraphs. The contractor shall issue to the Employer a performance guarantee certificate for
ten years period for water tightness of the treatment 'from the date of completion of maintenance
period of the building and shall be submitted in the proforma prescribed by the Department
before the final bill is paid.
The RCC and other surfaces should be cleaned of all foreign materials such as loose mortar,
concrete, local humps, bare pieces and other unwanted materials. The surface to be treated shall
be hacked with, ‗tancha‘ to remove loose mortar scaling and roughened. The surface should be
97 NCB.CW/W-1
rubbed vigorously to remove all dust and with the help of wire brush/brooms. The surface shall
be cleaned to have proper bond with the waterproofing treatment The surface thus prepared shall
then be washed with clean potable water before laying the waterproofing treatment. The
construction joints, cracks, honey combing, if any, should be located and treated with
waterproofing compound, injection, grouting etc. to seal off the cracks, air holes, honey combing
etc. to the entire satisfaction .of the Engineer or his authorised representative. The terrace is then
subjected to terrace method of waterproofing treatment as per manufacturer's specification.
The prepared terrace shall be then watered again thoroughly and cement slur)' shall be spread
over the surface along with the waterproofing/damp proofing compounds, if any, as per
manufacturer's specifications. The brick bats of required size and shape shall be then laid to
proper levels and slope not flatter than 1 in 100, over cement mortar bedding 25mm thick in
C.M. 1:4 mix with waterproofing in specialised manner with brick bats partly projected above
the mortar bedding and fully secured at bottom with at least 15mm gap between the brick bats.
The brick bats so laid should be allowed to set for at least one week and kept under water. Any
seepage I dampness notices under side the ceiling should be treated again as detailed above.
The 'finishing layer shall be of cement mortar 1:4 with waterproofing compound not less than 1
% of weigh of cement, should be added and this layer is laid to desired slope and levels. The
layer so laid should be joint less, well compacted and toweled vigorously till it becomes hard.
This surface so prepared is then marked with false squares of 300 x 300mm or left smooth as
directed by the Engineer-in-Charge.
This treatment shall be continued along the inner sides of parapets, jointing walls up to a height
of 300mm to 375mm in the shape of parabolic vata. The construction joints shall be taken at
ridges and should be made properly watertight and monolithic. The total thickness of the
treatment shall be average 115mm thick with at least 50mm thickness at drain points. Any
additional brick bat coba laid for attaining desired levels and. slope will be measured and paid
under separate item. However, the treatment remains to be the same for the entire work.
The terrace shall be tested for water tightness after the treatment is completed by ponding after
on the terrace and any defects noticed shall be attended to immediately to the entire satisfaction
of the Engineer.
Mode of Measurement
The measurement shall be for the area covered by the treatment. The length/height and breadth
shall be measured along the untreated surfaces. Area of all openings, cut-outs, pipe crossings
shall be deducted and shall be treated well free of cost.
SPECIFICATION 7:00 ‘PAINT WORK’
Applicable Codes
IS: 348 French Polish
IS: 427 Distemper, (dry), colour as required
IS: 428 Distemper, (Oil emulsion), colour as required.
IS: 1477 Codes of Practice for painting of ferrous metals in Buildings (I & II)
IS: 2338 Codes of practice for finishing of wood and wood based materials (I &/1)
98 NCB.CW/W-1
IS: 2339 Aluminium Paints for general purposes, in dual containers.
IS: 2395 Code of Practice for painting concrete, masonry and plaster surface (1&11)
IS: 2932 Enamel, synthetic, exterior, type-I.
IS: 2933 Enamel, synthetic, exterior, type -II.
IS: 5410 Cement paint, colour as required.
IS: 428 Distemper, (Oil emulsion), colour as required.
IS: 1477 Codes of Practice for painting of ferrous metals in Buildings (I & II)
IS: 2338 Codes of practice for finishing of wood and wood based materials (I &/1)
IS: 2339 Aluminium Paints for general purposes, in dual containers.
IS: 2395 Code of Practice for painting concrete, masonry and plaster surface (1&11)
IS: 2932 Enamel, synthetic, exterior, type-I.
IS: 2933 Enamel, synthetic, exterior, type -II.
IS: 5410 Cement paint, colour as required.
7.01 Providing and applying synthetic water-resistant distemper paint
Distemper shall be of approved make. It shall be applied by a broad stiff brush in two coats over
a coat of primer. The first coat with brush shall be applied only after the primer coat has
thoroughly dried. The first coat shall be of a lighter tint. The second shall be applied with roller
or brush after first coat is completely dried. If required putty filling shall be done in damaged area
before application of second coat. The shade of the distemper shall be got approved by the
Engineer. The third coat shall be finishing coat and shall be applied with roller after virtual
finishing of civil works. If required and work is not satisfactory in finishing contractor shall
apply more then three coats without any extra charges. Water bound and oil bound distemper
shall conform to the requirements of IS: 427 and IS 428 respectively.
Total thickness of three coats shall not be less then 150 microns.
Mode of Measurement
It shall be measured in sq.m.
7.02 Providing and applying Acrylic based, Anti fungus exterior paint.
-Do - as per item providing and applying 2 coats of acrylic based, anti fungus exterior paint of
approved shade and make like on smooth or sand face plaster finish as per as specified in the
schedule of quantities, over a coat of same paint in base white colour as a primer in accordance
with the manufacturers specifications etc complete. The cost shall include scaffolding system, all
tools & tackles, and working at any height of the building.
Mode of Measurement
It shall be measured in sq.m.
99 NCB.CW/W-1
7.03 Providing and applying synthetic enamel / flat paint
-do- as distemper but for synthetic enamel / flat paint. This paint shall be applied on walls and
shall be satin or matt finish.
Mode of Measurement
It shall be measured in sq.m.
9.0 DISMANTLING BRICK MASONARY AND/OR RCC WORK
Walls and partitions, plastered or unplastered as per instruction including stacking of
serviceable materials and disposal of unserviceable materials with all leads and lifts in lime
mortar \ in cement mortar, finishing the broken surface to match with the surrounding. Removing
the debris as directed upto a lead of 150m cutting the reinforcement if any etc. Comp. As directed
by site engineer. And carting away same including at site,
The rate shall include cost of all labour involved and tools used in demolishing and dismentalling
including scaffolding. The rate shall also include the charges for separating out and stacking
serviceable materials properly and disposing the unserviceable materials with all leads and lifts.
the rate also includes for temporary showing for the safety of the portion not required to be
pulled down or of adjoining property and providing temporary enclosures or partitions where
considered necessary.
Measurements should be taken in cubic meters for the walls and independent piers or columns of
bricks or stone masonary etc. all copings corbels, cornices and other projections shall be
included in wall measurements. In measuring thickness of plastered walls the thickness of plaster
shall be included. The unserviceable materials shall be disposed of with all lead and lift.
The rate is exclusive of bricks or stones. honey comb works or RCC walling shall be measured as
solid. The rate shall be for a unit of one cubic meter.
Transportation and disposal as directed by the site engineer.
Demolition including stacking of serviceable materials and disposal of unserviceable
materials with all leads and lifts for R.C.C. beams, slabs, lintels, columns etc. The relevant
specification of item no. 9. Shall be followed except that the demolition of reinforced concrete
structure. The unserviceable materials shall be disposed of at all leads and lifts. The rate excludes
scrapping, strengthening of reinforcement but includes cutting of reinforcement. The rate shall be
for a unit of one cubic meter.
100 NCB.CW/W-1
APPROVED COMPANY LIST OF CIVIL, SANITARY, PLUMBING, ETC. ITEMS
Only one of the under mentioned makes of equipment and materials will be acceptable.
Although the acceptable makes are given, the Contractor shall submit samples of all
materials other than heavy equipment and obtain prior approval of the Architect
Consultants (whose decisions shall be binding) for the make of each item before
ordering the same. This condition is also applicable to all items of equipment and
material for which makes are not given in these specifications:
Note:
Tender prices shall be based on the 'make' of equipment materials indicated first in the
list. However, in the event of non-availability, while procuring the equipment materials,
the selected Contractor may choose any other make in this list subject to any rebate
available being passed on to the Owner. Selection of equipment / material before
procurement shall be got approved from the Owner / Consultant.
1. Cement (53 grade opc)
a. L & T (Ultratech)
b. Gujarat Ambuja
c. Elephant
d. Lotus (kamal)
2. Steel (TOR-TMT – MS)
a. Barnala
b. Electrotherm
c. Kamdhenu
3. Water proofing & Building chemicals, Plasticiser, Grouts, Silicon Sealants.
a. Roffee
b. Sica
c. Dr. Back
d. Fosroc
e. G E
4. Interior, Exterior, Enamel, Epoxy paint
a. Asian
b. ICICI
c. Nerolac
5. Marble Mosaic Tile
a. Baroda Mosaic, Baroda
b. Akira Tiles, V. U. Nagar.
c. Dave Tiles, V.U. Nagar
6. Ceramic, Glazed & Vitrified Tile
a. SPL
b. Kajaria
c. Nitco
d. Oreva
e. Euro
7. Aluminum Sections
a. Banco
b. Jindal
8. Glass
a. Modi (GGL)
b. Saint Gobain
101 NCB.CW/W-1
9. Pre-laminated Sheets & Boards
a. Novapan
b. Bakelite Hylam
c. Formica
10. Hardware
a. Ebco
b. Diamond
11. G I / MS Pipes
a. Tata
12. G. I. Fittings
a. ‗R‘ Brand (Rajshree Malleable Ltd)
13. PVC Pipes
a. Supreme
b. Kisan
14. CPVC Pipes
a. Astral
b. Ajay
15. Sanitary ware
a. Hindustan
b. Cera
16. Cast Iron Pipes
a. Nico (centri series/sand casted)
b. BIC (sand casted)
17. Sanitary Fittings
a. Ark (Supreme)
b. Jaquar (Continental)
c. Aquel
18. Aluminium Gaskets
a. Minimum 10% EPDM
19. White Cement
a. Birla White
b. JK white
107 NCB.CW/W-1
Summary of Quantities
Sr.
No.
Item Rate Amount
1 Earth work
2 Concrete work
3 Masonary work
4 Door, window, ventilators wood work
5 Plastering work
6 Flooring work
7 Paint work
8 Plumbing & Sanitation work
9 Demolition & Dismentalling
Total Civil work cost (1 to 9)
10 Add Electrical work cost@-------% of Total
Tender cost (1 to 9)
Total Tender Cost
108 NCB.CW/W-1
Bill of Quantities
ITEM NO:-1. EARTH WORK
SR.
NO S.O.R. NO QTY
UNIT DESCRIPTION RATE AMOUNT
Rs.
1.01 0.00b EXCAVATION FOR FOUNDATION
IN ALL TYPES SOIL FOR WALLS,
COLUMNS, PLINTH BEAMS,
BASEMENT, RAFT DUCTS, PIPE
TRENCHES, ETC. INCLUDING
BACKFILLING THE SAME TO
TRENCHES SFTER COMPLITION
OF FOOTINGS INCLUDING
SOARING, STRUTTING, BAILING
OUT SURFACE WATER PUMPING
OFF IF REQUIRED, REMOVING
AND STACKING ADDITIONAL
EXCAVATED EARTH WHERE
GUIDED WITHIN CAMPUS AREA
ETC COMP - FROM EXISTING
GROUND AT THE SPOT TO 1.50
M.BELOW.
Rs.
1.01
A
0.00b 115.35 CMT -DO- AS ITEM NO.1.01 IN
YELLOW SOIL OR DENSE OR
HARD SOIL BEYOND 1.50 M. BUT
NOT EXCEEDING 3.00 MT (AS PER
STRUCTURAL DEATIL) BELOW
THE GROUND LEVEL.
Rs.
1.02 CMT EARTH FILLING IN FOUNDATION
PIT, SIDE TERNCHES, PLINTH,
SITE DEVELOPMENT ETC WITH
SELECTED EXCAVATED EARTH
IN LAYERS 15CMS TO 20CMS.
INCLUDING WATERING TO
OPTIMUM MOISTURE CONTENT,
RAMMING AND COMPACTING
USING MECHANICAL VIBRO -
ROLLER COMPLETE AS
DIRECTED INCLUDING COST OF
TRANSPORTATION ETC.IF ANY.
(MESUREMENT AFTER
COMPLETE CONSOLIDATION
WILL BE CONSIDERED FOR
PAYMENT)
1.02
A
4.12 60.00 CMT -DO- AS ITEM NO.1.02BUT WITH
AVAILABLE SELECTED EARTH
FROM SITE.
Rs.
1.02
B
4.24 148.24 CMT -DO- AS ITEM NO.1.02BUT WITH
SELECTED YELLOW SOIL
BROUGHT FROM OUT SIDE
INCLUDING FREIGHT
TRANSPORTATION, LOADING
UNLOADING, TAXES, ROYALTY,
SCREENING ETC.
(MESUREMENT AFTER
COMPLETE CONSOLIDATION
Rs.
109 NCB.CW/W-1
WILL BE CONSIDERED FOR
PAYMENT)
1.03 348.56 SMT PROVIDING & SPREADING
ANTITERMITE CHEMICAL
TREATMENT FOR FOOTINGS &
FLOORINGS WITH PRESSURE
PUMPS, FOR SPREADING
OPERATIONS TO FACILITATE
PROPER PENETRATION OF
CHEMICALS INTO THE EARTH
WITH THE HELP OF CHEMICALS
CONCENTRATIONS & DOSAGES
THROUGH REPUTED AGENCY
PEST CONTROL OF INDIA (PCI) . (
MEASUREMENTS WILL BE ON
PLINTH AREA BASIS)
Rs.
1.04 34.1 CMT PROVIDING AND FILLING CLEAN
LOCAL FINE SAND FOR FILLING
IN PLINTH, TRENCHES, UNDER
FLOORS AND SURROUNDING
AREAS INCLUDING WATERING,
RAMMING, CONSOLIDATING, IN
LAYERS OF 200MM INCLUDING
ALL TAXES AND ROYALIES,
LEAD AND LIFT ETC. COMPLETE
AS DIRECTED. (MESUREMENT
AFTER COMPLETE
CONSOLIDATION WILL BE
CONSIDERED FOR PAYMENT)
Rs.
ITEM NO:-2. CONCRETE WORK
SR.
NO S.O.R. NO QTY
UNIT DESCRIPTION RATE AMOUNT
Rs.
2.01 5.3.3 30.00 CMT PROVIDING AND LAYING
MACHINE MIXED B.B.C.C.
VOLUMETRIC PROPORTION
1:4:8 WITH 37 MM DOWN SIZE
BRICKBATS OF SPECIFIED
THICKNESS, MIX & GRADATION
OF THE AGGREGATES
EXCLUDING THE DISMANTLED
DEBRIS INCLUDING CENTERING
& SPREADING, RAMMING,
CONSOLIDATING AS DIRECTED
FOR FOUNDATION AND
FLOORING.
Rs.
2.02 5.3.3
PROVIDING AND LAYING
MACHINE MIXED PLAIN
CEMENT CONCRETE IN
VOLUMETRIC PROPORTION 1 : 4
: 8 WITH 37 MM AND DOWN
STONE AGGREGATES OF
SPECIFIED THICKNESS, MIX AND
GRADATION INCL. CENTERING,
SHUTTERING IF REQUIRED,
LAYING, SPREADING, RAMMING
CONSOLIDATING.
2.02 9.38 CMT -DO- AS PER ITEM NO. 2.02 Rs.
110 NCB.CW/W-1
(A) FOR FOUNDATION.
2.02
(B)
3.6 CMT -DO- AS PER ITEM NO. 2.02 FOR
GROUND BEAM.
Rs.
2.03 PROVIDING AND LAYING IN
POSITION MACHINE MIXED &
MACHINE VIBRATED CEMENT
CONCRETE OF M20
GRADE(DESIGN OF CONCRETE
MIX WILL BE DONE BY
CONTRACTOR) WITH MINIMUM
350 KG OF CEMENT
CONSUMPTION PER CUBIC
METRE OF CONCRETE (BY
WEIGHT BATCHING/BY VOLUME
BATCHING ) FOR REINFORCED
CEMENT CONCRETE
STRUCTURAL ELEMENTS. FOR
FOUNDATIONS TO ANY
HEIGHTS FOR PROPOSED WORK.
VIZ. FOUNDATION, BEAMS,
ARCH SLABS ON DEFINED
LEVEL, PLINTH BEAM ETC. IN
THE BASEMENT AND THE SLAB,
BEAMS, SLAB BEAM ETC @
PLINTH LEVEL PLINTH BEAM
LEDGES, WINDOW SILLS,
COPING, WALLS, PARAPETS
BOXES, FOLDED PLATES,
CHHAJJAS, MULLIONS,
RETAINING WALLS FINS,
STAIRCASES, OVERHEAD AND
UNDERGROUND WATER TANKS
IN ANY SHAPE all AS PER
STRUCTURAL DESIGN AND AS
DIRECTED IN SPECIFIED
COMPRESSIVE STRENGTH AT 28
DAYS AS PER I.S.456 1978 USING
20 MM. MAXIMUM SIZE
AGGREGATE INCLUDING
DESIGN OF CONCRETE
MIXES.WEIGHT BATCHED
PROPORTIONING NECESSARY
LIFT AND LEAD AS SPECIFIED
FINISHING CONCRETE
SURFACES, CENTERINGAT
DOUBLE HEIGHT/ TRIPLE
HEIGHT SHUTTERING, CURING
ETC. COMPLETE. AND KEEPING
IN VIEW WITH CONTROLLED
WATER FOR ALL FLOORS
FOR ALL FLOORS.
2.03
A
b0.0iii 33.04 CMT -DO- AS PER ITEM NO. 2.03 FOR
R.C.C COLUMN FOOTING,
PADESTALS,WALL, RETAINING
WALL, RAFT, BASE SLAB OF
UNDERGROUND WATER TANK,
RAMP, TRENCHES ETC.
111 NCB.CW/W-1
2.03
B
11.93 CMT -DO- AS PER ITEM NO. 2.03 R.C.C.
COPING, PLINTH BEAM,
GROUND BEAM ETC
Rs.
2.03
C
b0.0iii 9.66 CMT -DO- AS PER ITEM NO. 2.03 FOR
R.C.C. COLUMN
Rs.
2.03
D
a330.0iii 30.64 CMT -DO- AS PER ITEM NO. 2.03 FOR
R.C.C. BEAMS, BRACKETS
LINTELS, CILLS, CORNICE ETC.
& BED BLOCK BEAM ETC
Rs.
2.03
E
24.5.8.2 75.00 CMT -DO- AS PER ITEM NO. 2.03 FOR
R.C.C. SLABS, SUNK SLAB OF
TOILETS, R.C.C. LOFT AND
WEATHERSHED , BALCONY,
PORCH/CANOPY SLAB, STAIR
RISER & TREAD, LANDING
WATER TANK SLAB, ANY SLAB
ETC.
Rs.
2.06 PROVIDING, FABRICATING IF
NEEDED , WELDING THE
LAPPING OF REINFORCEMENT
BAR WHERE REQUIRED ,
REBARING TO EXISTING
STRUCTURE IF NEEDED AND
LAYING POSITION STEEL
REINFORCEMENT FOR R.C.C.
STRUCTURES AS PER DESIGN
INCLUDING BASIC COST OF
THE STEEL/OR STORE AT THE
SITE & INCIDENTAL CHARGES
FOR HANDLING
CUTTING,BENDING,BINDING
WITH 16 GAUGE WIRES ETC
COMPLETE
2.06
A
14a5.4.11 11.00 TON -DO- AS PER ITEM NO. 2.06 FOR
TMT BARS FOR R.C.C. WORK
Rs.
ITEM NO:- 3. MASONARY WORK
SR.
NO S.O.R. NO QTY
UNIT DESCRIPTION RATE AMOUNT
Rs.
3.01 6.13C 12.60 CMT PROVIDING AND LAYING
BRICK MASONARY IN C.M . 1:6 ( 1
CEMENT AND 6 COARSE SAND)
KEEPING ITS FROG ON TOP
INCLUDING
SCAFFOLDING,RACKING OUT
THE JOINTS, CURING ETC.
COMP. AS DIRECTED FOR
FOUNDATIONS TO HIGHEST
PLINTH LEVEL.
Rs.
3.02 6.13C 30.00 CMT PROVIDING AND LAYING
BRICK MASONARY IN C.M . 1:6 ( 1
CEMENT AND 6 COARSE SAND)
KEEPING ITS FROG ON TOP
INCLUDING
SCAFFOLDING,RACKING OUT
THE JOINTS, CURING ETC.
COMP. AS DIRECTED FOR SUPER
STRUCTURE THREE UPPER
FLOORS.
Rs.
112 NCB.CW/W-1
3.03 6.13C 15.00 CMT PROVIDING AND LAYING
BRICK MASONARY IN C.M . 1:6 ( 1
CEMENT AND 6 COARSE SAND)
KEEPING ITS FROG ON TOP
INCLUDING
SCAFFOLDING,RACKING OUT
THE JOINTS, CURING ETC.
COMP. AS DIRECTED FOR
PARAPET WALL.
Rs.
3.04 6.30C 30.00 SMT PROVIDING AND
CONSTRUCTING 115MM B.B.
MASONARY PARTITION FOR
SUPERSTRUCTURE IN C.M. 1:4 ( 1
CEMENT AND 4 COARSE SAND )
OR THE BRICK ON EDGE
PARTITION INCLUDING
SCAFFOLDING, RACKING OUT
THE JOINTS REINFORCEMENT
OF 2NOS. 6MM DIA. BARS AT
EVERY FOURTH LAYER. FOR
ALL FLOORS.
Rs.
ITEM NO:- 4. DOOR, WINDOW,
VENTILATORS WOOD WORK
SR.
NO S.O.R. NO QTY
UNIT DESCRIPTION RATE AMOUNT
Rs.
4.01
4.02
4.03
10.13 SMT PROVIDING AND FIXING 35MM
THICK SHUTTERS FOR DOORS,
WINDOWS AND CLEARESTORY
WINDOWS INCLUDING BLACK
ENAMELLED M.S. BUTT HINGS
WITH NECESSARY SCREWS (A)
INDIAN TEAK WOOD
30.00 SMT (I) FULLY PANELLED Rs.
SMT (II) FULL GLAZED
55.00 SMT (III) PARTLY PANELLED AND
PARTLY GLAZED
Rs.
ITEM NO:- 5 PLASTER WORK
SR.
NO S.O.R. NO QTY
UNIT DESCRIPTION RATE AMOUNT
Rs.
5.01 17.60ii 1072.00 SMT PROVIDING AND APPLYING
MINIMUM 12MM THICK CEMENT
PLASTER IN CEMENT MORTAR
1:4 (1 CEMENT 2 FINE SAND AND
2 COARSE SAND) TO THE WALLS,
BEAMS,CEILINGS, STAIRS,
COLUMNS, PARDI, BENDS,
MOULDS, FORMING MAKING
VATA FOR PARAPET GROOVES,
BENDS, VERTICAL HORIZONTAL,
OR OBLIQUE GROOV FOR ALL
LEVELS INCLUDING FINISH
COAT IN NEAT CEMENT .
Rs.
113 NCB.CW/W-1
5.02 17.61iii 294.00 SMT PROVIDING AND APPLYING
DOUBLE COAT ROUGH PLASTER
(IN CM 1:4) FOR MINIMUM 19
MM THICK SAND FINISH
PLASTER FOR WALL, MEMBER
OF VERTICAL AND HORIZONTAL
RCC WORK AND SEPARATE
MEMBER OF RCC WORK.
Rs.
ITEM NO:- 6. FLOORING WORK
QTY UNIT DESCRIPTION RATE AMOUNT Rs.
6.01
510.00 SMT PROVIDING AND LAYING 40 MM
THICK MARBLE CHIPS
FLOORING RUBBED AND
POLISHED (I.E. TERRAZO) TO
GRANOLITHIC FINISH WITH
UNDER LAYER 30 MM THICK
CEMENT CONCRETE 1:2:4 (1
CEMENT : 2 COURSE SAND : 4
GRADED STONE AGGREGATE 10
MM AND DOWN GUAGE) AND
TOP LAYER 10 MM THICK WITH
WHITEBLACK OR WHITE AND
BLACK MARBLE CHIPS OF
REQUIRED SIZES FROM 1 MM TO
4 MM NOMINAL SIZE LAID IN
CEMENT MARBLE POWDER MIX
3:1 (3 CEMENT : 1 MARBLE
POWDER BY WEIGHT) IN
PROPORATION OF 4:7 (4 CEMENT
MARBLE POWDER MIX : 7
MARBLE CHIPS BY VOLUME)
Rs.
6.02 35.00 SMT PROVIDING & FIXING 30MM TO
37MM GREEN POLISHED KOTA
STONE OF ONE SIDE PRE-
POLISHED OF UNIFORM TINT
FOR FLOORING & OF SIZE
600MM X 600MM OR 450MM X
600MM ON MAXIMUM CEMENT
MORTAR BED 1:6 IN PROPER
SLOPE INCLUDING DRESSING
THE STONES, RUBBING THE
EDGE ON MS GRINDERS,
FILLING THE JOINTS WITH
CEMENT SLURRY & OF
APPROPRIATE SHADE OF GREEN
COLOUR. RATE INCLUDES
CURING, POLISHING WITH
MACHINE / MANUALLY AS
REQUIRED, CLEANING WITH
ACID, WAX POLISHING ETC
COMP AT ALL LEVELS &
HEIGHTS AS DIRECTED.
Rs.
6.03 285.00 SMT PROVIDING AND LAYING
TYPICAL 115MM THICK INDIAN
WATER PROOFING ON
TERRACE INCL. CLEANING THE
SURFACE OF SLAB WITH WATER
AND THEN LAYING OF P.C.C.
BED (1 CEMENT : 3 SAND : 3
Rs.
114 NCB.CW/W-1
GRIT) , AVERAGE 115 MM. TH.
BRICK BATS COBA, LAYING IN
PROPER SLOPE TO DRAIN THE
RAIN WATER PIPE, FILLING THE
JOINTS WITH THE SAME,
FINISHING THE SURFACE IN
SMOOTH BY MAKING PATTERN
STONE, GIVING 10 YEARS
GAURANTEE FOR THE WORK
DONE .
ITEM NO:- 7. PAINT WORK
SR.
NO S.O.R. NO QTY
UNIT DESCRIPTION RATE AMOUNT
Rs.
7.01 18.88 1800.00 SMT DISTEMPERING (TWO COATS)
WITH OIL BOUND DISTEMPER
OF APPROVED BRAND AND
MANUFACTURE AND OF
REQUIRED SHADE ON WALL
SURFACE TO GIVE AN EVEN
SHADE OVER AND INCLUDING A
PRIMING COAT WITH
DISTEMPER PRIMER OF
APPROVED BRAND AND
MANUFACTURE AFTER
THROUGHLY BRUSHING THE
SURFACE FREE FROM MORTAR
DROPPING AND OTHER
FOREIGN MATTER AND ALSO
INCLUDING PREPARING THE
SURFACE EVEN AND SAND
PAPERED SMOOTH.
Rs.
7.02 18.57 650.00 SMT PROVIDING & APPLYING APEX -
EXTERIOR PAINT ON WALL
SURFACE ON TEXTURED
PLASTER WORK (TWO OR MORE
COATS) TO GIVE AS EVEN SHADE
INCLUDING THOROUGHLY
BROOMING.THE SURFACE TO
REMOVE ALL DIRT, DUST,
MORTAR DROPS AND OTHER
FOREIGN MATERIAL.
Rs.
7.03 19.71
85.00 SMT PAINTING TWO COATS
(EXCLUDING PRIMING COAT) ON
NEW WOOD AND WOOD BASED
SURFACES WITH ENAMEL
PAINT, INTERIOR TO GIVE AN
EVEN SHADE INCLUDING
CLEANING THE SURFACE OF
ALL DIRT AND OTHER FOREIGN
MATTER SAND PAPERING AND
STOPPING
Rs
85.00 SMT EXTRA OVER ITEMS 7.03 FOR
EVERY SUBSEQUENT COAT OF
PAINT.
Rs
115 NCB.CW/W-1
ITEM NO:-8 PLUMBING &
SANITATION WORK
SR.
NO S.O.R. NO QTY
UNIT DESCRIPTION RATE AMOUNT
Rs.
8.01 PROVIDING AND FIXING ON
WALL FACE P.V.C. RAIN WATER
PIPE OF SPECIFIED DIA. ( 6
KG. / SCM PRESSURE) WITH I.S.I.
MARK INCLUDING NECESSARY
FITTINGS LIKE BEND, SHOE
BEND ETC. WITH 16 TO 18
GAUGE G. I.CLAMPS AT EVERY
1.8 MT. INCLUDING FILLING THE
JOINTS ETC COMP.
RMT -DO- AS PER ITEM NO. 8.01 FOR
100MM DIA.
35.00 RMT -DO- AS PER ITEM NO. 8.01 FOR
150MM DIA.
Rs.
RMT -DO- AS PER ITEM NO. 8.01 FOR
200MM DIA.
ITEM NO 9 DEMOLITION AND
DISMENTALLING
SR.
NO S.O.R. NO QTY
UNIT
DESCRIPTION RATE AMOUNT
Rs.
9.01 20.10 DEMOLITION AND DISPOSAL OF
UNSERVICEABLE MATERIALS
WITH ALL LEAD AND LIFT.
Cu. m (I) LIME CONCRETE
10.00 Cu. m (II) UNREINFORCED CEMENT
CONCRETE
Rs.
9.02 20.30 DEMOLITION INCLUDING
STACKING OF SERVICEABLE
MATERIALS AND DISPOSAL OF
UNSERVICEABLE MATERIALS
WITH ALL LEAD AND LIFT
8.00 Cu. m (I) R.C.C. WORK Rs.
9.03 20.11 Cu. m DEMOLITION OF BRICK WORK
AND STONE MASONARY
INCLUDING STACKING OF
SERVICEABLE MATERIALS AND
DISPOSAL OF UNSERVICEABLE
MATERIALS WITH ALL LEAD
AND LIFT
Cu. m (I) IN LIME MORTAR
25.00 Cu. m (II) IN CEMENT MORTAR Rs.
TOTAL Rs.
Note:
(1) Item for which no rate or price has been entered in will not be paid for by the Employer when executed
and shall be deemed covered by the other rates and prices in the Bill of Quantities (refer: ITB Clause 13.2
and GCC Clause 43.3).
116 NCB.CW/W-1
(2) Unit rates and prices shall be quoted by the bidder in Indian rupee [ITB Clause 14.1].
(3) Where there is a discrepancy between the rate in figures and words, the rates in words will govern.
[ITB Clause 27.1(a)]
(4) Where there is a discrepancy between the unit rate and the line item total resulting from multiplying the unit
rate by quantity, the unit rate quoted shall govern [ITB Clause 27.1 (b)].
(5) Electrical work cost is about on % basis of Total civil works. Contractor has to fill Compulsory this
amount, if it is not filled than the tender can be liable for reject.
(6) For any extra items which are not indicated in the tender, contractor must have to take permission
from BOG before the execution of that extra item.
(7) In case of any discrepancy regarding any specifications, items or any clause of tender, decision of BOG
will be considered as final.
118 NCB.CW/W-1
Forms of Securities
Acceptable forms of securities are annexed. Bidders should not complete the Performance and Advance
Payment Security forms at this time. Only the successful Bidder will be required to provide Performance and
Advance Payment Securities in accordance with one of the forms, or in a similar form acceptable to the Employer.
Annex A: Bid Security (Bank Guarantee)
Annex B: Performance Bank Guarantee
Annex C: Deleted
Annex D: Bank Guarantee for Advance Payment
119 NCB.CW/W-1
Annex A
BID SECURITY (BANK GUARANTEE)
WHEREAS, _______________________ [name of Bidder] (hereinafter called "the Bidder") has submitted his Bid
dated _______________________ [date] for the construction of _____________________________________
[name of Contract] (hereinafter called "the Bid").
KNOW ALL PEOPLE by these presents that We ______________________________ [name of bank]
of____________________________ [name of country] having our registered office at
___________________________________ (hereinafter called "the Bank") are bound unto
______________________________[name of Employer] (hereinafter called "the Employer") in the sum of
___________________1 for which payment well and truly to be made to the said Employer the Bank binds itself, his
successors and assigns by these presents.
SEALED with the Common Seal of the said Bank this_________ day of __________ 19____.
THE CONDITIONS of this obligation are:
(1) If after Bid opening the Bidder withdraws his bid during the period of Bid validity specified in
the Form of Bid;
or
(2) If the Bidder having been notified of the acceptance of his bid by the Employer during the
period of Bid validity,
(a) fails or refuses to execute the Form of Agreement in accordance with the Instructions
to Bidders, if required; or
(b) fails or refuses to furnish the Performance Security, in accordance with the
Instruction to Bidders; or
(c) does not accept the correction of the Bid Price pursuant to Clause 27,
we undertake to pay to the Employer up to the above amount upon receipt of his first written demand, without the
Employer having to substantiate his demand, provided that in his demand the Employer will note that the amount
claimed by him is due to him owing to the occurrence of one or any of the three conditions, specifying the occurred
condition or conditions.
This Guarantee will remain in force up to and including the date ____________________2 days after the deadline
for submission of Bids as such deadline is stated in the Instructions to Bidders or as it may be extended by the
Employer, notice of which extension(s) to the Bank is hereby waived. Any demand in respect of this guarantee
should reach the Bank not later than the above date.
DATE _______________ SIGNATURE OF THE BANK _________________________
WITNESS ____________ SEAL _______________________________________
_________________________________________________________________
[signature, name, and address]
____________________________
1 The Bidder should insert the amount of the guarantee in words and figures denominated in Indian Rupees.
This figure should be the same as shown in Clause 16.1 of the Instructions to Bidders.
2 45 days after the end of the validity period of the Bid.
120 NCB.CW/W-1
Annex B
PERFORMANCE BANK GUARANTEE
To: Birla Vishvakarma Mahavidyalaya, Vallabh Vidyanagar [name of Employer]
Mota Bazar, Vallabh Vidyanagar, Anand [address of Employer]
WHEREAS _________________________ [name and address of Contractor] (hereinafter called "the
Contractor") has undertaken, in pursuance of Contract No. _____ dated ________________ to execute
__________________________ [name of Contract and brief description of Works] (hereinafter called "the
Contract");
AND WHEREAS it has been stipulated by you in the said Contract that the Contractor shall furnish you
with a Bank Guarantee by a recognized bank for the sum specified therein as security for compliance with his
obligations in accordance with the Contract;
AND WHEREAS we have agreed to give the Contractor such a Bank Guarantee;
NOW THEREFORE we hereby affirm that we are the Guarantor and responsible to you, on behalf of the
Contractor, up to a total of ____________________ [amount of guarantee] 1___________________________ [in
words], such sum being payable in the types and proportions of currencies in which the Contract Price is payable,
and we undertake to pay you, upon your first written demand and without cavil or argument, any sum or sums within
the limits of ____________________ [amount of guarantee]1 as aforesaid without your needing to prove or to show
grounds or reasons for your demand for the sum specified therein.
We hereby waive the necessity of your demanding the said debt from the Contractor before presenting us
with the demand.
We further agree that no change or addition to or other modification of the terms of the Contract or of the
Works to be performed thereunder or of any of the Contract documents which may be made between you and the
Contractor shall in any way release us from any liability under this guarantee, and we hereby waive notice of any
such change, addition or modification.
This guarantee shall be valid until 28 days from the date of expiry of the Defects Liability Period.
Signature and seal of the guarantor _____________________________
Name of Bank ____________________________________________
Address ____________________________________________
Date ____________________________________________
__________________
1 An amount shall be inserted by the Guarantor, representing the percentage of the Contract Price specified in
the Contract including additional security for unbalanced Bids, if any and denominated in Indian Rupees.
121 NCB.CW/W-1
Annex - D
BANK GUARANTEE FOR ADVANCE PAYMENT
To: Birla Vishvakarma Mahavidyalaya, Vallabh Vidyanagar [name of Employer]
Mota Bazar, Vallabh Vidyanagar, Anand-388120 [address of Employer]
___________________________________________[name of Contract]
Gentlemen:
In accordance with the provisions of the Conditions of Contract, subclause 51.1 ("Advance Payment") of
the above-mentioned Contract, ________________________________ [name and address of Contractor]
(hereinafter called "the Contractor") shall deposit with ________________________ [name of Employer] a bank
guarantee to guarantee his proper and faithful performance under the said Clause of the Contract in an amount of
_____________ [amount of guarantee] 1_________________________________ [in words].
We, the ____________________ [bank or financial institution], as instructed by the Contractor, agree
unconditionally and irrevocably to guarantee as primary obligator and not as Surety merely, the payment to
____________________ [name of Employer] on his first demand without whatsoever right of objection on our part
and without his first claim to the Contractor, in the amount not exceeding ____________________ [amount of
guarantee]1 __________________________________ [in words].
We further agree that no change or addition to or other modification of the terms of the Contract or of
Works to be performed thereunder or of any of the Contract documents which may be made between
_____________________ [name of Employer] and the Contractor, shall in any way release us from any liability
under this guarantee, and we hereby waive notice of any such change, addition or modification.
This guarantee shall remain valid and in full effect from the date of the advance payment under the Contract
until _________________________ [name of Employer] receives full repayment of the same amount from the
Contractor.
Yours truly,
Signature and seal: _______________________________
Name of Bank/Financial Institution: _________________
Address: _______________________________________
Date: ____________________
__________________________
1 An amount shall be inserted by the bank or financial institution representing the amount of the Advance
Payment, and denominated in Indian Rupees.
NR/ls Tuesday, October 26, 2004
m:\pdat\sbd\works\doc\w1.doc