DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Title Page
Southern California Edison CompanyTariff Title: Rate SchedulesTariff Record Title: Rate Schedule FERC No. XXX
FERC FPA Electric Tariff
AGREEMENT FOR INTERCONNECTION OF THE ELDORADO -
HARRY ALLEN 500 KV TRANSMISSION LINE TO THE ELDORADO
500 KV SWITCHYARD
AMONG
DEPARTMENT OF WATER AND POWER OF THE CITY OF LOS
ANGELES, SOUTHERN CALIFORNIA EDISON COMPANY, NEVADA
POWER COMPANY d/b/a NV ENERGY
AND
DESERTLINK, LLC
Tariff Record Proposed Effective Date: 10/1/2018Version Number; 0.0.0
Option Code: A
Contract Effective Date: 10/1/2018 XXX.0.0Contract #:OTH-010
DocuSign Envelope ID: F9382259-74BCM8DB-BF91-ACE86028A4CE
Page 1
TABLE OF CONTENTS
31. PARTIES
32. RECITALS
43. SECTION HEADING AND DEFINITIONS
12EFFECTIVE DATE AND TERMINATION4.
135. RESERVED...:
PERMISSION TO INTERCONNECT ... 136.
137. CONNECTING FACILITIES
158. OWNERSHIP
9. RESERVED 16
1610. AFFECTED SYSTEMS
1711. CAPITAL ADDITIONS
12. POTENTIALLY-REFUNDABLE PAYMENTS FOR THE CONNECTING
18FACILITIES
13. COST ALLOCATION. 20
14. STATUS REPORTS 21
15. REMOVAL COST 22
2316, OPERATING AND OWNERSHIP PRINCIPLES
2517. TAXES
3018. INSURANCE
3619. INDEMNITY
DocuSign Envelope ID: F9382259-74BCM8DB-BF91-ACE86028A4CE
Page 2
20. CONSEQUENTIAL DAMAGES 39
21. DEFAULT 40
22. UNCONTROLLABLE FORCE 41
23. RELATIONSHIP OF THE PARTIES 41
24. SUCCESSORS AND ASSIGNS 42
4225. RESERVATION OF RIGHTS
26. NONDEDICATION OF FACILITIES 43
REGULATORY APPROVALS27. 43
GOVERNING LAW AND VENUE 4328.
MUTUAL COOPERATION 4329.
30. DISPUTE RESOLUTION 44
4631. NOTICES
GENERAL PROVISIONS32. 47
33. ATTACHMENT REVISIONS. 48
34. AUDIT 49
EXECUTION BY COUNTERPARTS35, 50
SIGNATURE CLAUSE36. 51
ATTACHMENT A - ELDORADO SUBSTATION ONE-LINE DIAGRAM
ATTACHMENT B - COST RESPONSIBILITY RATIOS
ATTACHMENT C - ADDRESSES FOR NOTICES
ATTACHMENT D - NOT USED
ATTACHMENT E - SCOPE OF WORK AND COSTS
ATTACHMENT F - MILESTONES
DocuSign Envelope ID: F9382259-74BC48DB-BF91-ACE86028A4CE
Page 3
AGREEMENT FOR THE INTERCONNECTION OF THE ELDORADO-HARRY
ALLEN 500 KV TRANSMISSION LINE TO THE ELDORADO 500 KV
SWITCHYARD
I. PARTIES
The parties to this Agreement for the Interconnection of the Eldorado-Harry
Allen 500 kV Transmission Line to the Eldorado 500 kV Switchyard
(“Agreement”) are: (i) DEPARTMENT OF WATER AND POWER OF THE
CITY OF LOS ANGELES (“LADWP”), a department organized and existing
under the charter of the City of Los Angeles, a municipal corporation of the
State of California; SOUTHERN CALIFORNIA EDISON COMPANY
(“SCE”), a California corporation, and NEVADA POWER COMPANY,
doing business as NV ENERGY (“NV Energy” and with LADWP and SCE
the “Eldorado Co-Owners”); and (ii) DesertLink, LLC, a Delaware limited
liability company, and the party requesting connection to the Eldorado 500 kV
Switchyard (the “Connecting Customer”). The parties to this Agreement are
individually referred to as “Party” and collectively as “Parties.”
2., RECITALS
This Agreement is made with reference to the following facts, among others:
The Eldorado Co-Owners jointly own, as tenants-in-common, the
Eldorado Substation pursuant to the Eldorado Co-Tenancy and
Operating Agreement, as defined in Section 3.26 of this Agreement.
Eldorado Substation is within the metered boundary of the CAISO’s
Balancing Authority Area.
SCE serves as the Operating Agent for the Eldorado Substation on
behalf of the Eldorado Co-Owners.
2.1.
2.2.
2.3.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 4
2.4. Connecting Customer has requested interconnection of the Eldorado-
Harry Allen 500 kV Transmission Line to the jointly-owned Eldorado
500 kV Switchyard.
The Parties desire to have 1) Connecting Customer finance, design,
engineer, procure and construct the Additional Towers, 2) Connecting
Customer make potentially-refundable payments for, and SCE design,
engineer, procure, construct and own the Connecting Facilities other than
the Additional Towers, 3) Connecting Customer transfer ownership of the
Additional Towers to SCE prior to energization at no cost to SCE, and pay
all taxes due thereon.
By this Agreement, the Parties desire to provide (i) for the
Interconnection of the Eldorado-Harry Allen 500 kV Transmission
Line to the jointly-owned Eldorado 500 kV Switchyard; and (ii) for the
construction, ownership, operation, maintenance, liability, cost
. responsibility, and use of the Connecting Facilities and of the
Additional Towers.
2.5.
2.6.
. 3. SECTION HEADING AND DEFINITIONS
Section headings in this Agreement are for convenience only and are not to
be construed to define, limit, expand, interpret, or amplify the provisions of
this Agreement. When initially capitalized in this Agreement, or amendments
hereto, the following words or phrases whether in the singular or plural, shall
have the meanings specified: -
Accounting Practices - Generally accepted accounting principles and
practices, in accordance with FERC Accounts applicable to electric utility
operations.
Additional Towers - Three transmission line towers (identified on
Attachment A as towers A, B and C) including insulators, ground wire,
fiber optic cable, conductors and all appurtenant equipment as further
described in Attachment E, to be installed on the current Eldorado right-
3.1.
3.2.
DocuSign Envelope ID; F938225&-74BC-48DB-BF91-ACE86028A4CE
Page 5
of-way between the Last Structure and a location to be designated by
Operating Agent for installation of tower A, approximately 1,800 feet
southeast of McCullough Pass Road and approximately 1,500 feet west of
the Eldorado Substation south entrance. The Additional Towers also
include any Capital Additions to the Additional Towers.
Affected System - An electric system other than the Eldorado Substation
that may be affected by the proposed interconnection, including, but not
limited to SCE, NV Energy and LADWP’s electric systems that are not
part of the Eldorado System.
Applicable Reliability Council - The Western Electricity Coordinating
Council or its successor.
Applicable Reliability Criteria - The reliability standards and reliability
criteria established by NERC and WECC and local reliability criteria, as
amended from time to time, including any requirements of the NERC.
Applicable Reliability Standards - Any applicable regulation, rule, order,
law, standard, procedure or requirement issued by any local, state,
regional or federal entity with jurisdiction over the operation, ownership
and maintenance of the Eldorado System and/or the Eldorado-Harry
Allen 500 kV Transmission Line, including the Applicable Reliability
Council and NERC; and applicable procedures and/or protocols of the
Balancing Authority; and any standard, procedure or other requirement
adopted by the Eldorado Co-Owners in writing with Connecting
Customer’s written consent (which consent shall not be unreasonably
withheld) pursuant to any provision of the Eldorado Co-Tenancy and
Operating Agreement and in conformance with Good Utility Practice; in
each case as amended from time to time and whether now existing or
hereafter imposed or arising. .
APSA - The First Amended & Restated Approved Project Sponsor
Agreement between Connecting Customer and CAISO, dated January 11,
2017, as may be amended from time to time.
3.3.
3.4.
3.5.1
3.6.
3.7.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 6
Balancing Authority - The responsible entity that integrates resource
plans ahead of time, maintains load-interchange-generation balance
within a Balancing Authority Area, and supports interconnection
frequency in real time. The CAISO is the Balancing Authority for the
Eldorado Substation, the Connecting Facilities, and the Line Segment,
provided however, that the Balancing Authority may be changed by the
Eldorado Co-Owners in accordance with die Eldorado Co-Tenancy and
Operating Agreement, as defined in Section 3.26 of this Agreement.
Balancing Authority Area - The collection of generation, transmission
and loads within the metered boundaries of a Balancing Authority. The
Eldorado Substation, the Connecting Facilities and the Line Segment are
within the metered boundary of the CAISO Balancing Authority Area.
Breach - The failure of a Party to perform or observe any material term or
condition of the Agreement.
Breaching Party - A Party that is in Breach of the Agreement.
Business Day - Any day other than a Saturday, a Sunday, or a holiday on
which the Federal Reserve Bank of New York is not open for business.
CAISO - The California Independent System Operator Corporation, a
California nonprofit public benefit corporation organized and existing
Under the laws of the State of California with operational control of,
among others, the Eldorado-Harry Allen 500 kV Transmission Line and
SCE’s ownership share of the Eldorado 500 kV Switchyard. 1
Calendar Day - A single calendar day; provided, however, that if any
period of Calendar Days referred to in this Agreement shall end on any
day that is not a Business Day, then the expiration of such period shall be
automatically extended until the end of the next Business Day.
Capital Additions — After the Commercial Operation Date, 1) any Units
of Property which are added to the Connecting Facilities or Eldorado
Substation; 2) the enlargement or betterment of any Units of Property
constituting apart of the Connecting Facilities or Eldorado Substation;
3.8.
3.9.
3.10.
3.11.
3.12.
3.13.
3.14.
3.15*
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 7
and 3) the replacement of any Units of Property constituting a part of the
Connecting Facilities or Eldorado Substation, irrespective of whether
such replacement constitutes an enlargement or betterment of that which
it replaces, which additions, betterments, enlargements, and replacements
in accordance with Accounting Practices would be capitalized.
3.16. Capital Expenditure Budget - The budget, prepared by the Operating
Agent and approved by the E&O Committee, for all current and future
Capital Additions to the Eldorado System including Capital Additions to
the Connecting Facilities.
3.17. Commercial Operation Date - The date on which the Line S egment
commences CAISO operational control as agreed to by the Connecting
Customer, the Operating Agent and the CAISO.
3.18. Components of the Eldorado System - Any of the components of the
Eldorado System as defined in the Eldorado Co-Tenancy and Operating
Agreement.
3.19. Connecting Customer DesertLink, LLC, or any successor or permitted
assignee thereof.
3.20. Connecting Facilities - All the facilities and equipment between the Point
of Change of Ownership and the Point of Interconnection, including any
modification, additions or upgrades that are necessary to physically and
electrically interconnect the Line Segment to the Eldorado 500 kV
Switchyard. Such Connecting Facilities include the Additional Towers as
shown in Attachment A and the scope of work for SCE as described in
Attachment E, including but not limited to, dead-end structures, 500 kV
circuit breakers 8162 and 9162, disconnect switches associated with such
circuit breakers, associated metering, relay protection devices located at
Eldorado 500 kV Switchyard providing transmission line protection for
the Eldorado-Harry Allen 500 kV Transmission Line, surge arrestors, line
reactors, and appurtenant facilities. The Connecting Facilities also
include any Capital Additions to the Connecting Facilities.
I
DocuSign Envelope ID: F93B2259-74BC-48DB-BF91-ACE86028A4CE
Page 8
Cost Responsibility Ratios - The ratios of responsibility for costs
associated with the General Facilities and the Eldorado 500 kV
Switchyard, as described in Section 13 of the Agreement and shown in
Attachment B.
Default - The failure of a Breaching Party to cure its Breach in
accordance with the Agreement.
Disputing Party - Any Party who disputes, or asserts a claim that arises
out of, or in connection with this Agreement.
Effective Date - As defined in Section 4.1 of this Agreement.
Eldorado 500 kV Switchyard — The jointly-owned 500 kV switchyard of
the Eldorado Substation as shown in Attachment A, attached hereto.
Eldorado Co-Tenancy and Operating Agreement — The Amended and
Restated Eldorado System Co-Tenancy and Operating Agreement among
the Eldorado Co-Owners effective January 1,2017 providing for, among
other things, the ownership, governance, operation, maintenance, and cost .
responsibility for the Eldorado System, as it may be amended or restated
from time to time, or replaced in accordance with Section 4.5.
Eldorado-Harry Allen 500 kV Transmission Line - The 500 kV
transmission line between the Eldorado 500 kV Switchyard and Harry
Allen Substation including the Additional Towers and series capacitor,
but excluding other Connecting Facilities.
Eldorado Substation - The 500/220 kV substation located in Boulder
City, Nevada, jointly owned by the Eldorado Co-Owners.
Eldorado System — As defined in the Eldorado Co-Tenancy and
Operating Agreement. ’
Engineering and Operating Committee (“E&O Committee”! —The committee
established pursuant to the Eldorado Co-Tenancy and Operating Agreement
that meets periodically (quarterly, or as otherwise agreed by the E&O
Committee) to review, among other things, the current and future Capital
Expenditure Budget, and budget for operation and maintenance.
3.21.
3.22.
3.23.
3.24.
3,25.
3.26.
3.27.
3.28.
3.29.
3.30.
DocuSign Envelope ID: F9382259-74BC-46DB-BF91-ACE86023A4CE
Page 9
3.31. FERC — The Federal Energy Regulatory Commission, or its regulatory
successor.
FERC Accounts - FERC’s “Uniform System of Accounts Prescribed for
Public Utilities and Licensees,” subject to the provisions of the Federal
Power Act in effect as of the date of this Agreement, and as such system of
accounts may be in effect from time to time. Reference in this Agreement
to any specific FERC Account number shall mean the FERC Account
number in effect as of the date of this Agreement or any successor FERC
Account.
Function — Each connection to the Eldorado Substation through circuit
breakers or disconnect switches, such as line connections, generator
connections, or transformer connections.
General Facilities - As defined in the Eldorado Co-Tenancy and
Operating Agreement.
Good Utility Practice - Any of the practices, methods and acts engaged in
or approved by a significant portion of the electric utility industry during
the relevant time period, or any of the practices, methods and acts which,
in the exercise of reasonable judgment in light of the facts known at the
time the decision was made, could have been expected to accomplish the
desired result at a reasonable cost consistent with good business practices,
reliability, safety and expedition. Good Utility Practice is not intended to
be any one of a number of the optimum practices, methods, or acts to the
exclusion of all others, but rather to be acceptable practices, methods, or
acts generally accepted in the region.
Governmental Authority - Any federal, state, local or other
governmental regulatory or administrative agency, court, commission,
department, board, or other governmental subdivision, legislature,
rulemaking board, tribunal, or other governmental authority having
jurisdiction over the Parties, their respective facilities, or the respective
services they provide, and exercising or entitled to exercise any
3.32.
3.33.
3.34.
3.35.
3.36.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 10
administrative,.executive, police, or taxing authority or power; provided,
however, that such term does not include Interconnection Customer,
Interconnection Provider, or any affiliate thereof.
3.37. Harry Allen Substation - The NV Energy-owned 525/345/230 kV
Substation in Clark County, Nevada.
3.38. Interconnection Handbook — A handbook, developed by SCE and posted
on SCE’s web site or otherwise made available by SCE, describing .
interconnections to SCE's electrical system, as such handbook may be
modified or superseded from time to time. SCE’s standards contained in
the Interconnection Handbook shall be deemed consistent with Good
Utility Practice and Applicable Reliability Standards. In the event of a
conflict between the terms of this Agreement and the terms of SCE’s
Interconnection Handbook, the terms in this Agreement shall apply.
3.39. ITCCf Income Tax Component of Contribution! - The incremental
payment to reimburse SCE for any income taxes associated with
payments made to SCE by Connecting Customer with respect to the
Connecting Facilities (if such payments are not refunded by SCE) and
the transfer of ownership of the Additional Towers by Connecting
Customer to SCE pursuant to this Agreement. The ITCC amount is
calculated pursuant to Section 17 of the Agreement.
3.40. Last Structure -The last Connecting Customer-owned transmission
structure for the Line Segment located at a position directly outside of,
and nearest to, the current Eldorado Substation right-of-way boundary,
depicted in Attachment A as structure #D,
3.41. Line Segment - The portion ofthe Eldorado-Harry Allen 500 kV
Transmission Line from the Harry Allen Substation to the Point of
Change of Ownership. .
3.42. NERC — North American Electric Reliability Corporation or its
successor organization.
I(
\
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 11
3.43. Notice of Dispute A written notice, provided pursuant to Section 30 of
the Agreement, of a dispute or claim by the Disputing Party that arises
out of, or in connection with, this Agreement.
Operating Agent - SCE, or its successor, as so appointed under the
Eldorado Co-Tenancy and Operating Agreement, with such additional
rights, duties, and obligations as explicitly provided in this Agreement,
Operating Emergency - An unplanned event or circumstance which
reduces or may reduce the amount of transmission capacity for the
Eldorado System, any Components of the Eldorado System, or the
Connecting Facilities that would otherwise be available to the Parties
under normal operating conditions.
Point of Change of Ownership - The end of the insulators at their
connection points to the Last Structure as shown in Attachment A.
Point of Interconnection — The point(s) where the Connecting Facilities
connect to the Eldorado 500 kV Switchyard as shown in Attachment A.
Remedial Action Scheme (“RAS”) - A system that reduces or trips
generation or transmission facilities under contingency outages to
maintain system stability or to limit overloads on electric system
facilities.
Reasonable Efforts - With respect to an action required to be attempted
or taken by a Party under this Agreement, efforts that are timely and
consistent with Good Utility Practice and are otherwise substantially
equivalent to those a Party would use to protect its own interests.
Removal Cost ~ The actual cost SCE incurs for the removal of the
Connecting Facilities, which is calculated as the amount, if positive, of
the costs of removal minus the salvage value of the Connecting Facilities.
Transmission Owner Tariff - SCE’s Tariff designated as FERC Electric
Tariff, Volume No. 6, as such tariff may be amended or superseded.
Transfer Date - As defined in Section 18.1 of this Agreement.
3.44.
3.45.
3.46.
3.47.
3.48.
3.49.
3.50.
3.51.
3.52.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 12
3.53. Units of Property - Units of property as described in FERC ’ s “List of
Units of Property for Use in Connection with Uniform System of
Accounts Prescribed for Public Utilities and Licensees” in effect as of the
date of this Agreement, and as such list may be amended from time to
time.
3.54. WECC the Western Electricity Coordinating Council, or its successor,
in its role as the compliance enforcement authority designated by NERC
to enforce the Applicable Reliability Standards applicable to SCE as the
registered transmission operator, and SCE as the registered transmission
owner of the Connecting Facilities.
4. EFFECTIVE DATE AND TERMINATION
4.1. This Agreement shall become effective on October 1,2018 (“Effective
Date”), subject to the execution of the Agreement by all the Parties and
the acceptance of the Agreement by FERC.
This Agreement shall remain in effect unless terminated by either party
following the earliest of: (i) Default pursuant to Section 21 of the
Agreement; (ii) termination of the Eldorado Co-Tenancy and Operating
Agreement or (iii) Ninety (90) Calendar Days advance written notice
from the Connecting Customer to Operating Agent to terminate this
Agreement. Notwithstanding anything to the contrary herein, no
termination hereunder shall become effective until notice of termination
of this Agreement is filed with FERC and FERC has accepted such notice
of termination.
Prior to termination of this Agreement pursuant to clause (ii) of Section
4.2 above, the Eldorado Co-Owners agree to negotiate in good faith with
Connecting Party and to proceed with due diligence to develop a
replacement agreement which provides similar benefits to Connecting
Customer under substantially the same terms and conditions as this
Agreement. The Operating Agent will provide written notification to
4.2.
4.3.
DocuSign Envelope ID: F9382259-74BCM8DB-BF91-ACE86028A4CE
Page 13
Connecting Customer within five (5) Business Days following the filing
with FERC of any proposed or actual amendment or replacement of the
Eldorado Co-Tenancy and Operating Agreement.
RESERVED
In the event that the Eldorado Co-Tenancy and Operating Agreement is
amended, or replaced with a new governing agreement, and such
amended or replaced agreement contains provisions that are inconsistent
with this Agreement, the Parties agree to negotiate in good faith to
proceed with due diligence to develop an amendment or replacement to
this Agreement that provides similar benefits to Connecting Customer
under substantially the same terms and conditions as this Agreement.
4.4.
4.5.
RESERVED5.
6. PERMISSION TO INTERCONNECT
The Eldorado Co-Owners hereby grant Connecting Customer permission to
connect the Eldorado-Harry Allen 500 kV Transmission Line to the Eldorado
500 kV Switchyard, subject to the terms and conditions of this Agreement.
CONNECTING FACILITIES7.
7.1. Connecting Customer is hereby granted reasonable and appropriate
ingress/egress rights on property relating to and outside the fence line of
the Eldorado Substation that is part of the Eldorado System for
Connecting Customer to design and construct the Additional Towers;
provided, that Connecting Customer shall coordinate with the Operating
Agent regarding the exercise of such rights and shall comply with
reasonable limitations on such exercise provided in advance by the
Operating Agent to Connecting Customer. Such rights to ingress/egress
shall also include, subject to Connecting Customer obtaining approvals
from other underlying property owners (e.g., U.S.A., Boulder City, etc.) if
DocuSign Envelope ID: F9382259-74BC48DB-BF91-ACE8602SA4CE
Page 14
required, the right to perform surveys, tests, soil samples, borings, and
similar activities to support the design and permitting of the Additional
Towers, and the right to construct roads and tower foundations, erect
towers, string wire, and associated construction and commissioning
activities required for the Additional Towers.
[Reserved].
Connecting Customer shall submit to SCE specifications and technical
drawings for the Additional Towers by the date specified in Attachment
F, Table FI. ■'
SCE will review the specifications submitted pursuant to Section 7.3 of
the Agreement, and may; 1) request additional information, or 2) suggest
revisions to the design of the Additional Towers, by the date specified in
Attachment F, Table Cl; provided, that all decisions regarding the design
and specifications of the Additional Towers shall ultimately be
determined by Connecting Customer in its reasonable discretion!
[Reserved].
Upon completion of construction of the Additional Towers, but prior to
energization of the Additional Towers, Connecting Customer shall
transfer sole ownership of the Additional Towers to SCE. Connecting
Customer will also transfer all existing labor and material warranties for
the Additional Towers to SCE at such time. Connecting Customer will
use commercially reasonable efforts to obtain warranties in respect of the
Additional Towers with minimum terms of one year for labor and two
years for equipment.
On or before the date one (1) year following termination of this
Agreement, Operating Agent shall notify the Connecting Customer
whether Operating Agent intends to physically remove the Connecting
Facilities or any part thereof. If Operating Agent intends to physically
remove the Connecting Facilities within two (2) years from the date of
notification of intent, the Connecting Customer shall pay the Removal
7.2.
7.3.
7.4.
7.5.
7.6.
i
7.7.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 15
Cost in accordance with Sections 4.4 and 15.1 of the Agreement. If
Operating Agent does not intend to physically remove the Connecting
Facilities or any part thereof, then the Connecting Customer shall have no
obligation to pay such Removal Cost.
8. OWNERSHIP
8.1. Connecting Customer shall own, operate, and maintain the Line Segment.
SCE shall own1, and SCE as the Operating Agent shall operate and
maintain the Connecting Facilities from the Point of Change of
Ownership to the Eldorado 500 kV Switchyard including the insulators
and conductors that are used to attach the Connecting Facilities and the
Additional Towers to the Last Structure.
Connecting Customer has no ownership interest in any facilities or
equipment inside the fence line of the Eldorado Substation, and after
Connecting Customer designs, constructs and transfers to SCE the
Additional Towers, will have no ownership interest in any facilities or
equipment inside the Eldorado Substation right-of-way boundary.
Pursuant to the terms of this Agreement, Connecting Customer shall at
Connecting Customer’s sole cost design, engineer, procure and construct
the Additional Towers.
Connecting Customer shall make potentially-refiindable payments for and
Operating Agent shall design, engineer, procure and construct the
Connecting Facilities other than the Additional Towers as described in
Attachment E, and interconnect the Eldorado - Harry Allen 500 kV
Transmission Line to the Eldorado 500 kV Switchyard.
The Eldorado Substation and any Capital Additions thereto shall continue
to be owned by, and remain the property of the Eldorado Co-Owners.
8.2.
8.3.
8.4.
8.5.
8.6.
1 With respect to the Additional Towers, SCE ownership begins upon transfer of ownership from Connecting Customer,
DocuSign Envelope ID: F9382259-74BC-48.DB-BF91-ACE86028A4CE
Page 16
9. RESERVED
10. AFFECTED SYSTEMS
10.1. If at any time Operating Agent or Affected System operators determine
that upgrades are required to an Affected System, solely as a result of
system issues resulting from changes to the Line Segment, if such
upgrades are required to Affected Systems, Connecting Customer shall
enter into agreements with the Affected System operators) to mitigate
such impacts at Connecting Customer’s sole costs, unless some other
financial arrangement is made with the Affected System operator,
10.2. Operating Agent is under no obligation to energize the Connecting
Facilities in the event that Operating Agent and the Connecting Customer
receives reasonable advance written notice from an Affected System
operator (other than an Eldorado Co-Owner) that (i) its electrical system
is an Affected System and is negatively impacted by the energization of
' the Connecting Facilities, (ii) it requires upgrades to mitigate the negative
impact of such energization, and (iii) describes such negative impact in
reasonable detail to permit a full investigation and analysis of such
impact. Additionally, Operating Agent is under no obligation to energize
the Connecting Facilities until the situation is resolved to Operating
Agent’s reasonable satisfaction if LADWP notifies the Operating Agent
in writing (with concurrent copy to Connecting Customer) that (a) the
short circuit duty issues at Marketplace and McCullough substations
(identified in the Final Report of the System Impact Study For an
Affected System, Harry Allen-Eldorado 500kV Transmission Project
(HAETP) dated August, 2018) have not been resolved, (b) upgrades are
required to mitigate the negative impact of such energization, and (c)
includes a reasonably detailed description of such negative impact so as
to permit a full investigation and analysis of such impact; provided,
however, that if temporary mitigation measures approved by LADWP can
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 17
be implemented to relieve such short circuit duty issues at Marketplace
and McCullough substations, Operating Agent will proceed to energize
the Connecting Facilities.
11. CAPITAL ADDITIONS
11.1. If at any time Capital Additions are required for the Connecting
Facilities, as a result of system conditions and/or Applicable Reliability
Standards compliance issues attributable solely to the Eldorado System,
Operating Agent shall construct the Capital Additions. SCE will be
responsible for such costs. Such Capital Addition shall be the property of
SCE.
11.2. If at any time that Capital Additions are required for the Eldorado
Substation as a result of system conditions and/or Applicable Reliability
Standards compliance issues attributable solely to the Connecting
Facilities, SCE as the Operating Agent shall construct such Capital
Additions and SCE will be responsible for such costs, including, but not
limited to, costs for construction work, and operation and maintenance
work thereto. Such Capital Addition shall be the property of SCE and/or
the Eldorado Co-Owners pursuant to the Eldorado Co-Tenancy and
Operating Agreement.
If at any time that Capital Additions are required for the Connecting
Facilities and/or the Eldorado Substation, as a result of CAISO approved
transmission projects, Operating Agent shall construct such Capital
Additions, and the costs of the Capital Additions will be paid for by SCE,
including, but not limited to, construction work, and operation and
maintenance thereto. Such Capital Addition shall be the property of SCE
and/or the Eldorado Co-Owners as applicable pursuant to the terms of the
Eldorado Co-Tenancy and Operating Agreement.
i
11.3.
s
DocuSign Envelope ID: F9382259-74BC48DB-BF91-ACE86028A4CE
Page 18
11.4. If at any time that Capital Additions are required for the Connecting
Facilities and/or the Eldorado Substation as a result of changes on a
system outside of the CAISO’s operational control, Operating Agent shall
construct such Capital Additions, and the costs of the Capital Additions
will be paid for by the entity responsible for such changes including, but
not limited to, construction work, and operation and maintenance thereto.
Such Capital Addition shall be the property of SCE and/or the Eldorado
Co-Owners as applicable pursuant to the terms of the Eldorado Co
Tenancy and Operating Agreement.
11.5. If at any time an Affected System or the Eldorado System is negatively
impacted by system issues resulting from changes to the Line Segment, the
Connecting Customer shall be responsible for the costs of mitigation and/or
upgrades required on such Affected Systems or the Eldorado System.
11.6. Operating Agent will provide at least sixty (60) Calendar Days advance
written notification to the Connecting Customer prior to commencing
work on Capital Additions to the Connecting Facilities, except that
Operating Agent may commence the work on the Capital Additions to the
Connecting Facilities, with either shorter advance written notification or
written notification after the work has commenced, at Operating Agent’s
sole discretion, if Operating Agent determines that the Capital Additions
to the Connecting Facilities are required to comply with safety or
regulatory requirements or to preserve system integrity or reliability. Any
such written notification will include the estimated cost of the Capital
Additions to the Connecting Facilities required to be paid by the
Connecting Customer, which is sufficient to cover the costs for
constructing, procuring and installing the Capital Additions to the
Connecting Facilities.
POTENTIALLY-REFUNDABLE PAYMENTS FOR THE CONNECTING12.
FACILITIES
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 19
12.1. The Connecting Customer shall submit payment in support of the
Connecting Facilities in the amounts, and on the dates as listed in the
table below, to cover SCE’s costs for design, engineering, procuring and
installing the Connecting Facilities, plus ITCC (calculated in accordance
with the methodology set forth in Section 17 of this Agreement and
which for purposes of the chart below is calculated assuming a rate of
24%, which may change in the future). Operating Agent shall issue an
invoice for each milestone payment no less than thirty (30) days prior to
the due date.
Schedule of Potentially-Refundable Payments
ConnectingFacilitiesPayment
Corresponding Estimated
ITCC Payment
Connecting Facilities
Payment + ITCC
Total Potentially- Refundable AmountDue Date
aojjafpftiiiExecution of
JWGjMfc ISSSililS. J ^rn 3^9
IIIIiSlffippmx ft.
mpp*. ...i IS mmm Mmm0su. . 5Ss®&W •5 ft &! m tX F ■a
Agreementi ? &
,830 'mm $260,189ft#1;>:
1$4,807,0101/1/2019 $1,153,682 $5,960,692 $6,220,821
6/1/2019 $6)6,Q9i;6§0.,;; -©»S3^S»S(®iSSSS.«5... -
..‘ liS8MUa?3V
$14,416^884* ’4.'*m mQQ3t iff: SMt •ft
1/1/2020 $6,031,480 $1,447,555 $7,479,035 $21,895,919$17,658,000Total $4,237,919 $21,895,919
12.2. Any amounts initially paid by Connecting Customer which SCE elects
to refund, including ITCC, in support of the Connecting Facilities
pursuant to this Article 12 shall be repaid in full by SCE to Connecting
Customer no later than thirty (30) Calendar Days after the Commercial
Operation Date. If repayment in full by SCE occurs prior to the final
milestone payment (due on January 1, 2020), then no lurther amounts
shall be paid by Connecting Customer.
Termination of this Agreement prior to the Commercial Operation
Date pursuant to Section 4.2 of the Agreement shall relieve SCE of its
12.3.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 20
obligation to make repayments in accordance with Section 12.2 for any
amounts actually incurred by SCE, plus ITCC. To the extent this
Agreement is terminated prior to the Commercial Operation Date and the
aggregate payments made pursuant to Section 12.1 exceed SCE’s costs
incurred, or irrevocably committed to be incurred, in association with the
construction of the Connecting Facilities (including any Removal Costs
or for irrevocably committed cancellation costs associated with orders or
contracts for the construction of the Connecting Facilities and any
associated equipment), as of the effective date of termination of this
Agreement, SCE shall remit to the Connecting Customer any excess
amounts received, plus associated ITCC. In the event that SCE
determines that the amounts identified herein will not cover its expected
costs to be incurred for the construction of the Connecting Facilities, it
will notify Connecting Customer in writing, together with reasonably
detailed supporting documentation, and submit an invoice for the other
amounts needed for SCE to cops tract the Connecting Facilities. Any
such invoices submitted for undisputed amounts shall be paid by
Connecting Customer within thirty (30) days after receipt thereof.
i13. COST ALLOCATION
13.1. The Cost Responsibility Ratios in Attachment B shall be re-calculated by
the Operating Agent, if necessary, upon the addition or removal of any
Function, subject to the agreement of the Eldorado Co-Owners.
Operating Agent shall notify the Parties of any such changes pursuant to
Section 31 of the Agreement. Any re-calculated Cost Responsibility
Ratio shall be effective upon the in-service or removal date of such
Function.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028MCE
Page 21
Costs for the operation and maintenance, or an Operating Emergency, of
General Facilities shall be allocated in accordance with the applicable
Cost Responsibility Ratio as set forth in Attachment B.
Costs for the operation and maintenance, or an Operating Emergency, of
the Eldorado 500 kV Switchyard shall be allocated in accordance with the
applicable Cost Responsibility Ratio as set forth in Attachment B.
Costs for the operation and maintenance, or an Operating Emergency, for
the Connecting Facilities shall be allocated entirely to SCE.
13.2.
13.3.
13.4.
14. STATUS REPORTS
14.1. Every ninety (90) Calendar Days from the Effective Date until the Line
Segment and the Connecting Facilities are energized and under CAISO
Operational Control, Operating Agent shall provide to the CAISO and
Connecting Customer a Connecting Facilities status report. Such status
report shall include project schedule; permit and license status, including
environmental, state, and local permits and licenses; right-of-way
acquisition status, if required; land acquisition status, if required; design
and engineering status; status of contracts for project work, including
land, procurement, and staffing; construction status; testing status; events
creating risks and obstacles to project completion; and project budget,
including actuals, estimate to complete, and contingency. The format for
the report shall be in accordance with CAISO’s Business Practice Manual
for the Transmission Planning Process.
14.2. Connecting Customer submits a development progress status report on
the Line Segment and Additional Towers to CAISO every ninety (90)
Calendar Days. CAISO and/or Connecting Customer shall forward
Connecting Customer’s report to Operating Agent.
14.3. Connecting Customer and Operating Agent shall conduct periodic
conference calls and/or meetings to review the status reports delivered
pursuant to Sections 14.1 and 14.2 of the Agreement and to coordinate
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 22
upcoming activities and discuss project concerns as required to ensure the
project remains on schedule. Frequency of such calls and/or meetings
shall be agreed upon by the Parties, but shall be no less frequent than
every ninety (90) Calendar Days. Operating Agent will update the
Eldorado Co-Owners on the status updates provided on the periodic
conference calls. !
14.4. CAISO plans to initiate periodic conference calls with Operating Agent
from time to time to review the status reports delivered pursuant to
Sections 14.1 and 14.2 of the Agreement. Operating Agent shall
■ reasonably cooperate and participate upon CAISO’s request.
15. REMOVAL COST
15.1. If, in accordance with Section 4.4 of the Agreement, Operating Agent
decides to physically remove the Connecting Facilities, Operating Agent
shall render a bill to the Connecting Customer for the Removal Cost. The
Connecting Customer shall pay the Removal Cost in accordance with this
Section 15 of the Agreement. Such billing shall be initially based on
Operating Agent’s estimate of the Removal Cost. Within three (3)
months following the removal of the Connecting Facilities, Operating
Agent shall determine the recorded Removal Cost and provide the
Connecting Customer with a final invoice. ,
If the amount paid for the Removal Cost is less than the amount due for
the Removal Cost as determined from the actual recorded Removal Cost,
Operating Agent will bill the Connecting Customer for the difference
between the amount previously paid by the Connecting Customer and the
amount which would have been paid based on actual recorded costs,
without interest, within twenty (20) Calendar Days of the date of such
invoice.
Using the Accounting Principles as defined in Section 3.1, if the amount
paid for the Removal Cost is greater than the amount due for the Removal
15.2.
j
15.3.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACES6028A4CE
Page 23
Cost as determined from the actual recorded Removal Cost, Operating
Agent will refund the Connecting Customer the difference between the
amount previously paid by the Connecting Customer and the amount
which would have been paid based on actual recorded costs, without
interest, within twenty (20) Calendar Days of determining the recorded
Removal Cost in accordance with Section 15.
16. OPERATING AND OWNERSHIP PRINCIPLES
The Eldorado-Harry Allen 500 kV Transmission Line, including the
Connecting Facilities, will be within the CAISO’s Balancing Authority
Area.
Connecting Customer shall be entitled to use the total capacity of the Line
Segment and the Connecting Facilities, subject to CAISO deliverability
and congestion management protocols, applicable mles, standards, tariffs
and regulations, to transmit power to or from the Eldorado 500 kV
Switchyard. Connecting Customer understands and agrees that if
upgrades are made to the Line Segment that necessitates upgrades to the
Connecting Facilities, Connecting Customer may not be allocated
additional capacity from the Connecting Facilities, until Capital Additions
are done to the Connecting Facilities and/or the Eldorado Substation
pursuant to Section 11.3 of the Agreement (if necessary).
Capacity in the Eldorado 500 kV Switchyard shall be determined by
Operating Agent and allocated in accordance with the Eldorado Co
Tenancy and Operating Agreement.
Connecting Customer shall cause the Eldorado-Harry Allen 500 kV
Transmission Line to be tested, operated and maintained in accordance
with Applicable Reliability Standards and Good Utility Practice.
The Connecting Customer shall be required to, in coordination with
Operating Agent and CAISO, cause the Eldorado-Harry Allen 500 kV
Transmission Line to participate in any RAS required by CAISO to
16.1.
16.2.
16.3.
16.4.
16.5.
DocuSign Envelope ID: F9382259-74BCM8DB-BF91-ACE86028A4CE
Page 24
prevent negative effects such as thermal overloads, transient and voltage
instability resulting from contingency conditions (system outages) or
other conditions (e.g., sub-synchronous resonance). Such participation
shall be in accordance with Applicable Reliability Standards and
Applicable Reliability Criteria. The Connecting Customer will not be
entitled to any compensation from Operating Agent, the CAISO, or the
Eldorado Co-Owners, for loss of transmission capacity when: (i)
Eldorado-Harry Allen 500 kV Transmission Line capacity is reduced or
tripped off-line due to implementation of the CAISO-required RAS; or
(ii) such transmission capacity is restricted in the event the CAISO-
required RAS becomes inoperable. Pursuant to Good Utility Practice,
Operating Agent will provide the Connecting Customer advance notice of
any CAISO-required RAS.
16.6. Following outages of the Connecting Facilities or the Eldorado-Harry
Allen 500 kV Transmission Line, the Connecting Customer shall not
energize the Eldorado-Harry Allen 500 kV Transmission Line for any
reason without specific permission from Operating Agent. Such
permission shall not be unreasonably withheld. Notwithstanding the
foregoing, the Eldorado Co-Owners acknowledge that operational control
of the Eldorado-Harry Allen 500 kV Transmission Line will reside with
CAISO, not Connecting Customer, and the Eldorado Co-Owners
acknowledge and agree that nothing herein shall be deemed to impose
any liability or responsibility on Connecting Customer for the actions or
inactions of CAISO.
16.7. The Connecting Customer or its designee shall maintain operating
communications with Operating Agent’s designated switching center.
The operating communications shall include, but not be limited to, system
parallel operation or separation, scheduled and unscheduled outages,
equipment clearances, protective relay operations, and levels of operating
voltage and reactive power.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 25
16.8. Connecting Customer shall comply with Applicable Reliability Standards
and Good Utility Practice for ownership and operation of the Line
Segment.
[RESERVED].
16.10. RESERVED.
16.11. Operating Agent shall comply with Applicable Reliability Criteria,
Applicable Reliability Standards and Good Utility Practice for the
ownership? operation, and maintenance of the Connecting Facilities and
Capital Additions..
16.12. Operating Agent shall coordinate with Connecting Customer, CAISO,
and any affected entity any scheduled outage of facilities required for
maintenance of the Eldorado 500 kV Switchyard, the Connecting
Facilities, or for the making of Capital Additions. Decisions regarding
outages for the Connecting Facilities or the Eldorado 500 kV Switchyard
shall be made by Operating Agent in accordance with the Eldorado Co
Tenancy and Operating Agreement, Applicable Reliability Standards and
Good Utility Practice; provided, however, without first obtaining
Connecting Customer’s prior written consent (which consent shall not be
unreasonably withheld), the Connecting Facilities and the Eldorado 500
kV Switchyard shall not he taken out of service during the term of this
Agreement except on a non-permanent basis for purposes of maintenance,
repair, relief of a transmission constraint, emergency, or replacement in
accordance with Good Utility Practice.
16.9.
17. TAXES
17.1. Connecting Customer shall use Reasonable Efforts to have any taxing
authority imposing any property taxes or other taxes (excluding any sales
or use taxes) or assessments on the Additional Towers, impose such taxes
or assessments directly upon the Connecting Customer rather than on
DocuSign Envelope ID: F9382259-74BC48DB-BF91-ACE86028A4CE
Page 26
SCE and/or the other Eldorado Co-Owners until transfer of ownership of
the Additional Towers.
17.2. All taxes and assessments levied against any Party shall be the sole
responsibility of the Party upon whom said taxes and assessments are
levied, unless such taxes and assessments are levied directly upon an
individual Party on behalf of any or all of the other Parties.
17.3. Notwithstanding Section 17.2 of the Agreement* Connecting Customer
shall protect, indemnify and hold harmless SCE and/or the other Eldorado
Co-Owners fibm any income tax liability incurred or imposed against it
as the result of the transfer of the Additional Towers to SCE by
Connecting Customer pursuant to the terms of this Agreement, as well as
any interest and penalties, other than interest and penalties attributable to
any delay caused by Operating Agent or SCE.
17.4. Connecting Customer's indemnity obligation set forth in Section 17.3 of
the Agreement shall be calculated on a fully grossed-up basis. Except as
may otherwise be agreed to by the parties, this means that Connecting
Customer will pay the ITCC to SCE, in addition to Connecting Customer
paying for the cost of designing, engineering, procuring and constructing
the Additional Towers (the “AT Construction Cost”). The ITCC shall be
equal to (1) the current taxes imposed on SCE (“Current Taxes”) on the
excess of (a) the gross income realized as a result of the transfer of
ownership of the Additional Towers by Connecting Customer to SCE
under this Agreement (the “Gross Income Amount”), which amount shall
be equal to the AT Constmction Cost, over (b) the present value of future
tax deductions for depreciation that will be available as a result of such
transfer (the “Present Value Depreciation Amount”), plus (2) an
additional amount sufficient to permit SCE to receive and retain, after the
payment of all Current Taxes, the net amount described in clause (1).
17-5. For this purpose, (i) Current Taxes shall be computed based on SCE’s
composite federal and state tax rates at the time the payments or property
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 27
transfers are received and at the highest marginal rates in effect at that
time (the “Current Tax Rate”), and (ii) the Present Value Depreciation
Amount shall be computed by discounting the anticipated tax
depreciation deductions as a result of such transfer by SCE’s current
weighted average cost of capital. Thus, the ITCC formula is calculated as
follows: (Current Tax Rate x Gross Income Amount - Present Value
Depreciation Amount))/(l — Current Tax Rate).
17.6. Private Letter Ruling or Change or Clarification of Law.
At Connecting Customer’s request and expense, SCE shall
file with the IRS a request for a private letter ruling as to whether any
property transferred or sums paid, or to be paid, by Connecting
Customer to SCE under this Agreement are subject to federal income
taxation (including with respect to amounts paid by Connecting
Customer for Connecting Facilities other than the Additional Towers).
Connecting Customer may prepare the initial draft of the request for a
private letter ruling, and will certify under penalties of peijury that all
facts represented in such request are true and accurate to the best of
Connecting Customer’s knowledge. SCE approval of the facts as
described in the ruling request is required before the ruling request can
be submitted to the IRS. SCE and Connecting Customer shall
cooperate in good faith with respect to the submission of such request.
SCE shall keep Connecting Customer fully informed of the status of
such request for a private letter ruling and shall execute either a
privacy act waiver or a limited power of attorney, in a form acceptable
to the IRS, that authorizes Connecting Customer to participate in all
discussions with the IRS regarding such request for a private letter
ruling. SCE shall allow Connecting Customer to attend all meetings
with IRS officials about the request and shall permit Connecting
Customer to prepare the initial drafts of any follow-up letters in
connection with the request. SCE represents that SCE has and will
17.6.1.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 28
maintain the full authority to carry out the provisions of this Section
17.6.1.
17.6.2. In the event that (A) a private letter ruling is issued to SCE
which holds that any amount paid or the value of any property
transferred by Connecting Customer to SCE under the terms of this
Agreement is not subject to federal income taxation, (B) any
legislative change or administrative announcement, notice, ruling or
other determination makes it reasonably clear to SCE in good faith that
any amount paid or the value of any property transferred by
Connecting Customer to SCE under the terms of this Agreement is not
taxable to SCE, (C) any abatement, appeal, protest, or other contest
results in a determination that any payments or transfers made by
Connecting Customer to SCE are not subject to federal income tax, or
(D) if SCE receives a refund from any taxing authority for any
overpayment of tax attributable to any payment or property transfer
made by Connecting Customer to SCE pursuant to this Agreement,
SCE shall promptly refund to Connecting Customer the following: (i)
any payment made by Connecting Customer under this section for
taxes that is attributable to the amount determined to be non-taxable,
together with interest thereon, (ii) interest on any amounts paid by
Connecting Customer to SCE for such taxes which SCE did not submit
to the taxing authority, calculated in accordance with the methodology
set forth in FERC’s regulations at 18 C.F.R. § 35.19a from the date
payment was made by Connecting Customer to the date SCE refunds
such payment to Connecting Customer, and (iii) with respect to any
such taxes paid by SCE, any refund or credit SCE receives or to which
it may be entitled from any Governmental Authority, interest (or that
portion thereof attributable to the payment described in clause (i),
above) owed to SCE for such overpayment of taxes (including any
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 29
reduction in interest otherwise payable by SCE to any Governmental
Authority resulting from an offset or credit); provided, however, that
SCE will remit such amount promptly to Connecting Customer only
after and to the extent that SCE has received a tax refund, credit or
offset from any Governmental Authority for any applicable
overpayment of income tax related to any amounts paid to SCE by
Connecting Customer with respect to the Connecting Facilities or the
transfer of the Additional Towers to SCE by Connecting Customer
under this Agreement. The intent of this provision is to leave the
Parties, to the extent practicable, in the event that no taxes are due with
respect to any amounts paid to SCE by Connecting Customer with
respect to the Connecting Facilities or the transfer of the ownership of
the Additional Towers to SCE by Connecting Customer, in the same
position they would have been in had no such tax payments been
made.
17.7. Any Party exempted from any taxes assessed against any or all of the
other Parties shall be given credit for such exemption by Operating
Agent upon the provision of satisfactory proof of exemption from the
operative taxing authority.
17.8. Within thirty (3 0) Calendar Days following transfer of ownership of
the Additional Towers, Connecting Customer shall remit to SCE the
ITCC payment; provided that no ITCC payment shall be due if the
Operating Agent or SCE determine in good faith that the transfer of
ownership of the Additional Towers to SCE is not taxable to SCE
(whether such determination is the result of updated legislative
guidance or otherwise). The table below sets forth an estimate of the
ITCC payment (which is based on SCE’s estimate of the AT
Construction Cost). The actual ITCC payment shall be based on the
actual AT Construction Cost incurred by Connecting Customer.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 30
Estimated ITCC for Additional Towers (AT)
$8,331,632Estimated AT Construction Cost
$1,999,592Estimated ITCC Payment
17.9. Any payments of ITCC associated with the potentially refundable
payments for the Connecting Facilities shall be subject to a final true-
up adjustment based on the applicable Current Tax Rate and tax
depreciation laws for the year in which the Connecting Facilities
1 Payment is included in SCE’s applicable federal or state income tax
return. If a refund is due to the Connecting Customer as a result of an
over collection of such ITCC, such refund shall be paid to Connecting
Customer no later than November 30 of the calendar year following
the year in which such Connecting Facilities Payment was reported on
SCE’s income tax return. If additional amounts are owed to SCE, such
amounts shall be paid within 30 days of the. receipt of an invoice from
SCE to Connecting Customer calculating the additional amounts due.
18. INSURANCE
18.1. The Operating Agent’s insurance obligations with regard to the
Connecting Facilities are governed by the Eldorado Co-Tenancy and
Operating Agreement. As indicated below, Connecting Customer
shall, at its own expense, maintain in force throughout the period
commencing with the beginning of any construction activities for the
Additional Towers and ending on the effective date of the transfer of
ownership of the Additional Towers to SCE (the “Transfer Date”), the
following minimum insurance coverages, with insurers rated no less
than A-VII) by A.M. Bests’ Key Ratings Guide and authorized to do
business in the state where the Point of Interconnection is located,
except in the case of any insurance required to be carried by the
CAISO, the State of California:
DocuSign Envelope ID: F9382259-74BC 48DB-Br91-ACE86028A4CF
Page 31
Workers' Compensation and Employer's Liability Insurance. The
Connecting Customer shall maintain such coverage from the
commencement of any Construction Activities through the Transfer
Date providing statutory benefits for workers compensation coverage
and coverage amounts of no less than One Million Dollars
($1,000,000) for employer’s liability in accordance with the laws and
regulations of the state in which the Point of Interconnection is
located.
Commercial General Liability Insurance. Connecting Customer shall
maintain commercial general liability insurance commencing within
thirty (30) days of the effective date of the Agreement through three
years after the Transfer Date, including coverage for premises and
operations, bodily injury, personal injury, property damage,
contractual liability, products and completed operations explosion,
collapse and underground hazards, sudden and accidental pollution to
the extent normally available, punitive damages to the extent normally
available and insurable, and a cross liability or separation of insured
clause or endorsement with minimum limits of One Million Dollars
($1,000,000) per occurrence/One Million Dollars ($1,000,000)
aggregate. If the activities of the Connecting Customer are being
conducted through the actions of an affiliate, then the Connecting
Customer may satisfy the insurance requirements of this Section 18.3
by providing evidence of insurance coverage carried by such affiliate
and showing both the Eldorado Co-Owners and the Operating Agent
as an additional insured, under the affiliates’ General Liability
insurance policy, together with the Connecting Customer’s written
representation to Operating Agent that the insured affiliate is
conducting all of the necessary pre-construction work. Within thirty
(30) days prior to the entry of any person on behalf of the Connecting
Customer onto any construction site to perform work related to the
18.2.
18.3.
DocuSign Envelope ID: F9382259 74BC-48DB-BF91-ACE86028A4CE
Page 32
Additional Towers, the Connecting Customer shall replace any
evidence of affiliate Insurance with evidence of such insurance carried
by the Connecting Customer, naming both the Eldorado Co-Owners
and the Operating Agent as additional insured as required under
Section 18.7 of the Agreement.
Business Automobile Liability Insurance. Prior to the entry of any
such vehicles on any construction site in connection with work done
by or on behalf of Connecting Customer and through the Transfer
Date, Connecting Customer shall provide evidence of coverage of
owned and non-owned and hired vehicles, trailers or semi-trailers
designed for travel on public roads, with a minimum, combined single
limit of One Million Dollars ($1,000,000) per occurrence for bodily
injury, including death, and property damage.
Excess or Umbrella Liability Insurance. Commencing at the time of
entry of any person on its behalf upon any construction site for the
Connecting Facilities, Eldorado Substation, or Line Segment,
Connecting Customer shall maintain through three years after the
Transfer Date excess or umbrella liability insurance over and above
the Employer's Liability, Commercial General Liability and Business
Automobile Liability Insurance coverage, with a minimum limit of
Twenty Million Dollars ($20,000,000) per occurrence/Twenty Million
Dollars ($20,000,000) aggregate. The requirements of Sections 18.3
and 18.5 of the Agreement may be met by any combination of general
and excess or umbrella liability insurance.
Builder’s Risk Insurance. Commencing within fifteen (15) days after
Connecting Customer notifies SCE in writing that it will construct the
Additional Towers and through the Transfer Date, Connecting
Customer will obtain and maintain in force Builder’s Risk Insurance,
covering the Additional Towers, including all supplies, materials, and
other property intended to be permanently incorporated into the
18.4.
18.5,
S
18.6.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91 ACEB6023A4CE
Page 33
Additional Towers. Connecting Customer shall have risk of loss for
the Additional Towers from the commencement of construction until
the transfer of ownership of the Additional Towers to SCE. The
Builder’s Risk Policy shall name Connecting Company, SCE, and
contractors and subcontractors of any tier as named insureds. Coverage
shall be on an “all risk” basis, and shall not be less than 100% of the
replacement cost value of the Additional Towers for physical damage,
loss, or destruction. Coverage shall apply to such Project property
while it is located at the job site or located at temporary off-site
storage or staging areas, or while in land-based transit to the job site
within the continental United States, and shall include expediting
expense coverage. Connecting Customer and SCE shall be named as
loss payee, subject to compliance with lender covenants, and the
policy shall include a non-vitiation clause or endorsement. Connecting
Customer and SCE agree to waive all rights of recovery against each
other, and contractors and subcontractors for damages covered by and
to the extent paid by the Builder’s Risk Policy. Connecting Customer
shall cause the Builder’s Risk insurer to waive all rights of subrogation
against SCE, and shall cause contractors and subcontractors to waive
all rights of recovery against SCE to the extent claims are paid by the
Builder’s Risk Policy. SCE shall have the right to review the Builders
Risk Policy including with respect to covered property, limits and sub
limits, exclusions, and coverage extensions, to ensure that the policy
adequately insures the Additional Towers. Such acceptance of terms
shall not be unreasonably withheld.
18.7. For the insurance policies under Sections 18.3,18.4 and 18.5 above,
Connecting Customer shall name both the Eldorado Co-Owners, its
parents, associated and affiliate companies and their respective
directors, officers, agents, servants and employees ("Other Party
Group"), and the Operating Agent, as additional insured. All
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 34
insurance policies above shall contain provisions whereby the insurers
waive all rights of subrogation in accordance with the provisions of the
Agreement against the both Eldorado Co-Owners and the Operating
Agent. Connecting Customer shall provide thirty (30) Calendar Days
advance written notice to the Operating Agent of cancellation in
coverage. If Connecting Customer can reasonably demonstrate that
coverage policies containing provisions for insurer waiver of
subrogation rights are not available on commercially reasonable terms,
then the Connecting Customer and Operating Agent shall meet and
confer and mutually determine to (i) establish replacement or
equivalent terms in lieu of subrogation or notice or (ii) waive the
requirements that coverage(s) include such subrogation provision.
The insurance policies under Sections 18.3,18.4, and 18.5 above shall
contain provisions that specify that the policies are primary and non
contributory to any insurance or self-insurance the Operating Agent
maintains. The insurance policy under 18.3 shall contain a cross
liability, severability of interest or separation of insureds clause.
Connecting Customer shall be responsible for their respective
deductibles or retentions.
The insurance policies under Sections 18.2, 18.3, 18.4 and 18.5 above,
if written on a Claims First Made Basis, shall be maintained in full
force and effect for two (2) years after termination of the Agreement,
which coverage may be in the form of tail coverage or extended
reporting period coverage if agreed by the Connecting Customer and
Operating Agent.
The requirements contained herein as to the types and limits of all
insurance to be maintained by the Connecting Customer are not
intended to and shall not in any manner, limit or qualify the liabilities
and obligations assumed by the Connecting Customer under the
Agreement.
18.8.
18.9.
18.10.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 3 5
18.11. Within ten (10) Calendar Days following execution of the Agreement,
and as soon as practicable after the end of each fiscal year or at the
renewal of the insurance policy and in any event within ninety (90)
Calendar Days thereafter, Connecting Customer shall provide
certification of all insurance required under the Agreement, executed
by each insurer or by an authorized representative of each insurer.
18.12. Notwithstanding the foregoing, Connecting Customer may self-insure
to meet the insurance requirements of Section 18.2 through 18.9 of the
Agreement, to the extent that it maintains a self-insurance program
that is a qualified self-insurer within the state in which the Point of
Interconnection is located, under the laws and regulations of such
state; and to meet the minimum insurance requirements of Sections
18.2 through 18.9 of the Agreement to the extent it maintains a self
insurance program; provided that, (i) Connecting Customer’s or if
applicable its Parent Guarantor maintains (a) Credit Ratings of at least
“A-” by S&P, “A-” by Fitch and “A3” by Moody’s, if such entity is
rated by the Ratings Agencies; (b) if such entity is rated by only two of
the three Ratings Agencies, a Credit Rating from two of the three
Ratings Agencies of at least ”A-” by S&P, if such entity is rated by
S&P, “A-” by Fitch, if such entity is rated by Fitch, and “A3” by
Moody’s, if such entity is rated by Moody’s; or (c) a Credit Rating of
at least ”A-” by S&P or “A3” by Moody’s, or “A-” by Fitch if such
entity is rated by only one Ratings Agency, and (ii) its self-insurance
program meets the minimum insurance requirements of Sections 18.2
through 18.7 of the Agreement. For any period of time that the
Connecting Customer or if applicable its Parent Guarantor fails to
maintain Credit Ratings specified in (a), (b) or (c), the Connecting
Customer shall comply with the insurance requirements applicable to
it under Sections 18.2 through 18.9 of the Agreement. For purposes of
this section, the following definitions apply. “Credit Rating” means
!
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 36
with respect to any entity, the rating then assigned to such entity’s
unsecured, senior long-term debt obligations (not supported by third
party credit enhancements) or if such entity does not have a rating for
its senior unsecured long-term debt, then the rating then assigned to
such entity as an issuer rating by the Ratings Agencies. “Ratings
Agency” means any of S&P, Moody’s, and Fitch (collectively the
‘Ratings Agencies’). “Fitch” means Fitch Ratings Ltd. or its successor.
“Moody’s” means Moody’s Investor Services, Inc. or its successor,
“S&P” means the Standard & Poor’s Rating Group (a division of
McGraw-Hill, Inc.) or its successor. “Parent Guarantor” means
Connecting Customer’s corporate parent which has provided a parent
guaranty acceptable to Operating Agent, in its sole discretion.
In the event that Connecting Customer is permitted to self-insure
pursuant to this Section 18.12, Connecting Customer shall notify the
Operating Agent that it meets die requirements to self-insure and that
its self-insurance program meets the minimum insurance requirements
in a manner consistent with that specified in Section 18.1 throughl 8.9.
18.13. The Connecting Customer agrees to report to Operating Agent in
writing as soon as practical all accidents or occurrences resulting in
injuries to any person, including death, and any property damage
arising out of the Agreement.
19. INDEMNITY
Operating Agent shall indemnify, defend and hold harmless
Connecting Customer, and Connecting Customer’ s directors, officers,
employees, agents, assigns, and successors in interest (collectively,
“Indemnitees”), from and against any and all third-party claims,
demands, liabilities, costs, damages, fees or expenses (including
without limitation attorneys’ fees and court costs) which may be
19.1.
DocuSign Envelope ID: F9382259-74BC48DB-BF91-ACE86028A4CE
Page 37
imposed on or asserted against any Indemnitee for any and all injury,
damage or loss of any kind or nature whatsoever, direct or indirect,
suffered by any person or property to the extent arising out of, caused
by, or resulting from Operating Agent’s, its employees’, agents’,
representatives’ or subcontractors’, actions or inactions pursuant to
this Agreement, except to the extent attributable to the negligence or
willful misconduct of the Connecting Customer. In the event of a
claim by Connecting Customer for indemnity by the Operating Agent
under this Section 19.1, responsibility for any such claims as between
the Operating Agent and the Eldorado Co-Owners will, in turn, be
governed by the applicable provisions of the Eldorado Co-Tenancy
and Operating Agreement.
Connecting Customer shall indemnify, defend and hold
harmless the Operating Agent and the Eldorado Co-Owners, and
Operating Agent’s and the Eldorado Co-Owners’ directors, officers,
employees, agents, assigns, and successors in interest, from and
against any and all third-party claims, demands, liabilities, costs,
damages, fees or expenses (including without limitation attorneys’
fees and court costs) which may be imposed on or asserted against the
Operating Agent and any of the Eldorado Co-Owners for any and all
injury, damage or loss of any kind or nature whatsoever, direct or
indirect, suffered by any person or property to the extent arising out
of, caused by, or resulting from Connecting Customer’s, its
employees’, agents’, representatives’, or subcontractors’ actions or
inactions pursuant to this Agreement, except to the extent attributable
to the negligence or willful misconduct of the Operating Agent or
Eldorado Co-Owners.
19.3. Indemnified Party.
19.3.1. If an indemnified person is entitled to indemnification
under this Section 19 as a result of a claim by a third party,
19.2.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 38
and the indemnifying Party fails, after notice and reasonable
opportunity to proceed under Section 19.1, to assume the
defense of such claim, such indemnified Party may at the
expense of the indemnifying Party contest, settle or consent
to the entry of any judgment with respect to, or pay in full,
such claim.
19.3.2. If an indemnifying Party is obligated to indemnify and
hold any indemnified Party harmless under this Section 19,
the amount owing to the indemnified Party shall be the
amount of such indemnified Party’s actual loss, net of any
insurance or other recovery.
19.4, Indemnity Procedures
19.4.1. Promptly after receipt by an indemnified Party of any
claim or notice of the commencement of any action or
administrative or legal proceeding or investigation as to
which the indemnity provided for in Section 19 may apply,
the indemnified Party shall notify the Indemnifying Party of
such fact Any failure of or delay in such notification shall
not affect a Party's indemnification obligation unless such
failure or delay is materially prejudicial to the indemnifying
Party.
19.4.2. The indemnifying Party shall have the right to assume the
defense thereof with counsel designated by such
indemnifying Party and reasonably satisfactory to the
indemnified Party. If the defendants in any such action
include one or more indemnified Parties and the
indemnifying Party and if the indemnified Party reasonably
concludes that there may be legal defenses available to it
and/or other indemnified Parties which are different from or
additional to those available to the Indemnifying Party, the
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 39
indemnified Party shall have the right to select separate
counsel to assert such legal defenses and to otherwise
participate in the defense of such action on its own behalf.
In such instances, the indemnifying Party shall only be
required to pay the fees and expenses of one additional
attorney to represent an indemnified Party or indemnified
Parties having such differing or additional legal defenses.
19.4,3. The indemnified Party shall be entitled, at its expense, to
participate in any such action, suit or proceeding, the defense
of which has been assumed by the indemnifying Party.
Notwithstanding the foregoing, the indemnifying Party (i)
shall not be entitled to assume and control the defense of any
such action, suit or proceedings if and to the extent that, in
the opinion of the indemnified Party and its counsel, such
action, suit or proceeding involves the potential imposition
of criminal liability on the indemnified Party, or there exists
a conflict or adversity of interest between the indemnified
Party and the indemnifying Party, in such event the
indemnifying Party shall pay the reasonable expenses of the
indemnified Party, and (ii) shall not settle or consent to the
entry of any judgment in any action, suit or proceeding
without the consent of the indemnified Party, which shall not
be unreasonably withheld, conditioned or delayed.
20. CONSEQUENTIAL DAMAGES
In no event shall any Party be liable under any provision of this
Agreement for any losses, damages, costs or expenses for any special,
indirect, incidental, consequential, or punitive damages, including but
not limited to loss of profit or revenue, loss of the use of equipment,
cost of capital, cost of temporary equipment or services, whether
20.1.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 40
based in whole or in part in contract, in tort, including negligence,
strict liability, or any other theory of liability; provided, however, that
damages for which a Party may be liable to another Party under
another agreement will not be considered to be special, indirect,
incidental, or consequential damages hereunder.
21. DEFAULT
General. No Default shall exist where such failure to discharge an
obligation (other than the payment of money) is the result of
Uncontrollable Force as defined in this Agreement or the result of an
act or omission of the other Party. Upon a Breach, the affected non
Breaching Party(ies) shall give written notice of such Breach to the
Breaching Party. The Breaching Party shall have thirty (30) Calendar
Days from receipt of the Breach notice within which to cure such
Breach; provided however, if such Breach is not capable of cure
within thirty (30) Calendar Days, the Breaching Party shall
commence such cure within thirty (30) Calendar Days after notice and
continuously and diligently complete such cure within ninety (90)
Calendar Days from receipt of the Breach notice; and, if cured within
such time, the Breach specified in such notice shall cease to exist.
Right to Terminate. If a Breach is not cured as provided in Section 21.1
of the Agreement, or if a Breach is not capable of being cured within the
period provided for herein, the affected non-Breaching Party(ies) shall
have the right to declare a Default and terminate the Agreement by
written notice at any time that such Default remains uncured, and be
relieved of any further obligation hereunder, with the exception of the
provision in Section 4.4 of the Agreement and, all other damages and
remedies to which it is entitled at law or in equity. Notwithstanding the
foregoing, if a declared Default has been disputed by the Breaching Party,
termination of this Agreement on account of such Default may not occur
21.1.
21.2.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 41
absent a decision by an arbitrator, or a court of competent authority
having jurisdiction, making a determination of said Default. The
provisions of Section 4.4 of the Agreement and Section 17 of the
Agreement will survive termination of the Agreement.
22. UNCONTROLLABLE FORCE
22.1. No Party shall be considered to be in default in the performance of its
obligations hereunder (other than obligations of said Party to make
payment of bills rendered hereunder) when a failure of performance
shall be due to an Uncontrollable Force. The term "Uncontrollable
Force" means any cause beyond the reasonable control of the Party
affected, including but not restricted to failure of or threat of failure of
facilities, flood, earthquake, storm, fire, lightning, epidemic, war, riot,
civil disturbance or disobedience, labor dispute, labor or material
shortage, sabotage, restraint by court order or public authority, which
by exercise of due diligence such Party could not reasonably have
been expected to avoid and which by exercise of due diligence it shall
be unable to overcome. Nothing contained herein shall be construed
so as to require a Party to settle any strike or labor dispute in which it
may be involved. Any Party rendered unable to fulfill any of its
obligations hereunder by reason of an Uncontrollable Force shall give
prompt written notice of such fact to the other Parties and shall
exercise due diligence to remove such inability with all reasonable
dispatch.
22.2. Economic hardship shall not be an Uncontrollable Force.
s1
l
23. RELATIONSHIP OF THE PARTIES
Except as provided for in the Eldorado Co-Tenancy and Operating
Agreement, the covenants, obligations, and liabilities of the Parties are
intended to be several and not joint or collective, and nothing herein
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE36028A4CE
Page 42
contained shall ever be construed to create an association, joint venture,
trust, or partnership, or to impose an association, joint venture, trust, or
partnership covenant, obligation, or liability on or with regard to any one or
more of the Parties. Each Party shall be individually responsible for its
own covenants, obligations, and liabilities as herein provided, No Party or
group of Parties shall be under the control of or shall be deemed to control
any other Party or the Parties as a group. No Party shall be the agent of or
have a right or power to bind any other Party without its express written
consent, except as expressly provided in this Agreement.
24. SUCCESSORS AND ASSIGNS
This Agreement shall be binding upon and inure to the benefit of the
respective successors and assigns of the Parties.
Any successor or assignee shall notify the remaining Parties of such
succession or assignment in accordance with Section 31.
No assignment or transfer of interest hereunder shall relieve the
assigning or transferring Party from Ml liability and financial
responsibility for performance, after any such assignment or transfer,
of ail obligations and duties incurred, under the terms and conditions
of the Agreement, by such Party prior to such assignment or transfer
unless and until the assignee or transferee shall agree in writing with
all the remaining Parties to assume all obligations and duties imposed
under the terms and conditions of the Agreement, upon the assigning
or transferring Party after such assignment or transfer.
24.1.
24.2.
24.3.
I
25. RESERVATION OF RIGHTS
25.1. The Eldorado Co-Owners and the Connecting Customer shall each
have the right to make a unilateral filing with FERC to seek to modify
this Agreement pursuant to Section 205, Section 206, or any other
applicable provision of the Federal Power Act and FERC’s rules and
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 43
regulations thereunder, provided that each Party shall have the right to
protest any such filing by another Party and to participate fully in any
proceeding before FERC in which such modifications may be
considered. Nothing in this Agreement shall limit the rights of the
Parties or of FERC under Sections 205 or 206 of the Federal Power
Act and FERC’s rules and regulations thereunder, except to the extent
that the Parties otherwise mutually agree as provided herein.
26: NONDEDICATION OF FACILITIES
The Parties do not intend to dedicate, and nothing in this Agreement shall be
construed as constituting a dedication by any Party of its properties or
facilities, or any part thereof, to any other Party or to the customers of anyiParty.
27. REGULATORY APPROVALS
The Parties agree to cooperate to obtain any state or federal regulatory
approval necessary for the full participation of any Party in the rights and
obligations of the Agreement 1\
28. GOVERNING LAW AND VENUE
This Agreement shall be interpreted in accordance with the substantive and
procedural laws of the State of Nevada, notwithstanding any Nevada conflict
of laws provisions to the contrary. Any court action arising under this
Agreement shall be initiated and prosecuted in a state or federal court in Clark
County, Nevada or in a state or federal court within the territory of the Federal
District Court for the Southern District of California.
29. MUTUAL COOPERATION
DocuSign Envelope ID: F9382259-74BCM8DB-BF91-ACE86028A4CE
Page 44
Operating Agent, SCE in its capacity as owner of the Connecting Facilities, or
the Connecting Customer shall, within 10 Calendar Days of the receipt of any
notice of alleged violation (“NOAV”) from a regulatory agency pertaining to
the Connecting Facilities, provide the other Parties, with a copy of the NOAV.
Subject to applicable regulatory and legal requirements, protections for each
Party’s privileges and confidential information, and subject to the execution of
any necessary confidentiality and non-disclosure agreements, the Parties agree
to cooperate fully to provide each other the information, documentation and
assistance necessary to demonstrate compliance with their respective
obligations. Unless otherwise agreed, the Parties agree that upon thirty (30)
days of receipt of a written notice from the Party requesting the information,
the Party responsible for providing information shall timely deliver the
requested information. In the event the information is required by WECC,
NERC, or FERC in less than thirty (30) days, the appropriate Party will make
commercially reasonable efforts to provide information in any such requested
time.
!30. DISPUTE RESOLUTION
Disputes among the Eldorado Co-Owners will be handled pursuant to
the terms of the Eldorado Co-Tenancy and Operating Agreement.
In the event a Disputing Party has a dispute, or asserts a claim, that
arises out of or in connection with this Agreement, or their
performance, such Disputing Party shall provide the non-Disputing
Party with a Notice of Dispute.
Such dispute or claim shall be referred to a designated senior
representative of the non-Disputing Party for resolution on an
informal basis as promptly as practicable after receipt of the Notice of
Dispute.
In the event the designated representatives are unable to resolve the
claim or dispute through negotiations within thirty (30) Calendar
30.1.
30.2.
30.3.
30.4.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 45
Days of the non-Disputing Party's receipt of the Notice of Dispute,
such claim or dispute may, upon mutual agreement among the
Disputing Party and the non-Disputing Party, be submitted to either
non-binding or binding arbitration and resolved in accordance with
the arbitration procedures set forth below.
30.5. In the event the Disputing Party and the non-Disputing Party do not
agree to submit such claim or dispute to arbitration, each party may
exercise whatever rights and remedies it may have in equity or at law
consistent with the terms of the Agreement.
30.6. Any arbitration initiated under these procedures shall be conducted
before a single neutral arbitrator appointed by the Disputing Party and
the non-Disputing Party. If the parties fail to agree upon a single
arbitrator within ten (10) Calendar Days of the submission of the
dispute to arbitration, each party shall choose one arbitrator who shall
sit on a three-member arbitration panel. The two arbitrators so chosen
shall within twenty (20) Calendar Days select a third arbitrator to
chair the arbitration panel. In either case, the arbitrators shall be
knowledgeable in electric utility matters, including electric
transmission and bulk power issues, and shall not have any current or
past substantial business or financial relationships with any party to
the arbitration (except prior arbitration). The arbitrators) shall
provide each of the parties an opportunity to be heard and, except as
otherwise provided herein, shall conduct the arbitration in accordance
with the JAMS Arbitration Procedures; provided, however, in the
event of a conflict between the Arbitration Rules and the terms of
Section 28 of the Agreement, the terms of Section 28 of the
Agreement shall prevail.
30.7. Unless otherwise agreed by the Disputing Party and the non
Disputing Party, the arbitrator(s) shall render a decision within ninety
(90) Calendar Days of appointment and shall notify the parties in
j
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 46
writing of such decision and the reasons therefor. The arbitrators)
shall be authorized only to interpret and apply the provisions of this
Agreement Mid shall have no power to modify or change any
provision of the Agreement in any manner. If the parties have
mutually agreed to binding arbitration, the decision of the arbitrator(s)
shall be final and binding upon the Parties, and judgment on the
award may be entered in any court having jurisdiction. The decision
of the arbitrator(s) may be appealed solely on the grounds that the
conduct of the arbitrators), or the decision itself, violated the
standards set forth in the Federal Arbitration Act or the
Administrative Dispute Resolution Act. The final decision of the
arbitrator must also be filed with FERC if it affects jurisdictional
rates, terms and conditions of service or Connecting Facilities of those
Eldorado Co-Owners subject to such FERC jurisdiction.
30.8. Each party shall be responsible for its own costs incurred during the
arbitration process and for the following costs, if applicable: (i) the
cost of the arbitrator chosen by the party to sit on the three member
panel and one half of the cost of the third arbitrator chosen; or (ii) one
half the cost of the single arbitrator jointly chosen by the parties.
31. NOTICES
31.1. Except as set forth in Section 31.2 of the Agreement, any legal notice
or communication required by this Agreement shall be in writing and
shall be deemed received (i) upon delivery if delivered in person or by
electronic mail or (ii) five (5) Calendar Days after deposit in the mail
if sent by registered or certified first class United States mail, postage
prepaid, to the persons and addresses set forth in Attachment C
attached hereto.
DocuSign Envelope ID: F9382259-74BCM8DB-BF91-ACE86028A4CE
Page 47
31.2. Communications of a routine nature involving requests for funds and
related matters shall be given in such manner as the Parties shall
arrange.
31.3. Any Party may, at any time, by written notice to all other Parties,
designate different or additional persons or different addresses for the
giving of notices hereunder. Within thirty (30) Calendar Days of any
such change, Operating Agent shall provide each Party with a revised
Attachment C. Such revised attachment shall not require approval by
the Engineering and Operating Committee and shall not require a
formal amendment to this Agreement requiring signature by each
Party.
32. GENERAL PROVISIONS
32.1. In the event that any of the terms, covenants, or conditions of the
Agreement, or the application of any such term, covenant, or
condition, shall be held invalid as to any person or circumstance by
any court having jurisdiction in the premises, all other terms,
covenants, or conditions of this Agreement and their application shall
not be affected thereby, but shall remain in full force and effect.
Except as otherwise specifically provided in the Agreement, the
Parties do not intend to create rights in, or to grant remedies to, any
third party as a beneficiary of this Agreement or of any duty,
covenant, obligation, or undertaking established therein.
Any waiver at any time by any Party of its rights with respect to a
default or any other matter arising in connection with this Agreement
shall not be deemed a waiver with respect to any subsequent default
or matter whether of a similar or different nature.
With the exception of the right that each Party has to make a
unilateral filing as granted in Section 25 of the Agreement, and
32.2.
32.3.
32.4.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 48
pursuant to Section 31,3 of the Agreement, this Agreement shall be
modified only through written agreement signed by each Party.
32.5. Section headings in this Agreement are for convenience only and are
not to be construed to define, limit, expand, interpret, or amplify the
provisions of the Agreement.
32.6. If, after the Effective Date of this Agreement, FERC or any other
regulatory body, agency or court of competent jurisdiction determines
that all or any part of this Agreement, its operation or effect, is unjust,
unreasonable, unlawful, imprudent or otherwise not in the public
interest, each Party shall be relieved of any obligations hereunder to
the extent necessary to comply with or eliminate such adverse
determination. The Parties shall promptly enter into good faith
negotiations in an attempt to achieve a mutually agreeable
modification to this Agreement to address any such adverse
determination.
32.7. If, after the Effective Date of this Agreement, FERC or any other
regulatory body, agency or court of competent jurisdiction orders or
determines that this Agreement should be modified or significantly
extended in such a manner that any Party may be required to extend
its obligations under this Agreement to a third party, or to incur
significant new or different obligations to another Party or to Third
Parties not contemplated by this Agreement, then the Parties shall be
relieved of their obligations to the extent lawful and necessary to
eliminate the effect of that order or determination, and the Parties
shall attempt to renegotiate in good faith to modify the terms and
conditions of this Agreement to restore the balance of benefits and
burdens contemplated by the Parties prior to such order or
determination.
33. ATTACHMENT REVISIONS
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 49
Attachment A, ELDORADO-HARRY ALLEN 500 KV LINE
INTERCONNECTION TO ELDORADO SUBSTATION and
Attachment B, COST RESPONSIBILITY RATIOS shall be revised
by Operating Agent upon any change in the configuration of Eldorado
Substation; provided, that no such revision shall be applicable to
Connecting Customer without Connecting Customer’s prior written
consent if it could reasonably be anticipated to have an adverse effect
on Connecting Customer. Attachment C, ADDRESS FOR
NOTICES, shall be revised pursuant to Section 31.3.
The effective date of a revised Attachment A or Attachment B, as the
case may be, shall be the effective in-service date of the new facility
or the effective removal date of an existing facility, unless otherwise
determined by the Eldorado Co-Owners; provided, that no such
revision shall be applicable to Connecting Customer without
Connecting Customer’s prior written consent if it could reasonably be
anticipated to have an adverse effect on Connecting Customer. Such
revised attachment shall not be considered an amendment to this
Agreement requiring signature by each Party.
33.1.
33.2.
34. AUDIT
For two years following the in-service date of any Capital Additions in
accordance with Section 11 of the Agreement for which the Connecting
Customer is responsible hereunder, SCE shall maintain records and accounts
of such costs incurred in sufficient detail to allow verification of such costs
incurred, including, but not limited to, labor and associated labor burden costs,
material and supplies, outside services, and administrative and general
expenses. Connecting Customer shall have the right, upon reasonable notice,
at a reasonable time and place, and at its own expense, to audit SCE’s records
as necessary and as appropriate in order to verify such costs incurred by SCE.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 50
35. EXECUTION BY COUNTERPARTS
This Agreement may be executed in any number of counterparts, and upon
execution by all Parties, each executed counterpart shall have the same force
and effect as an original instrument and as if all Parties had signed the same
instrument. Any signature page of the Agreement may be detached from any
counterpart hereof without impairing the legal effect of any signature thereon
and may be attached to another counterpart of the Agreement identical in form
hereto but having attached to it one or more signature pages.
(SIGNATURES APPEAR ON NEXT PAGE)
!
\
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page 51
36. SIGNATURE CLAUSE
The signatories hereto represent that they have been appropriately
authorized to enter into this Agreement on behalf of the Party for whom they
sign.
NEVADA POWER COMPANY (d/b/a NV
Energy)
SOUTHERN CALIFORNIA EDISON
COMPANY 1
DocuSigned by: DocuSfgned by:
U&tfBy. By.■ 7CE3BF9CB7E6406... ■68804129BFFF46C...
Name Shahzad Lateef Name Robert Woods
Title Vice President - Transmission Title Managing Director T&D Asset Management & Ops Services
10/3/201810/3/2018Date Signed. Date Signed.
DEPARTMENT OF WATER AND POWER DESKRTLINK, LLC
OF THE CITY OF LOS ANGELES BY
BOARD OF WATER AND POWER
COMMISSIONERS
*-----DocuSfgned by;
( iWk. P. flfitkun/i.By: Bv•6F4C40E737394SB...
DAVID H . WRIGHT General Manager Name MarkMilbum
Date: Title Vice President
10/3/2018Date SignedAnd:
BARBARA E. MOSCHOS Board Secretary
J
Page 51
36. SIGNATURE CLAUSE
The signatories hereto represent that they have been appropriately
authorized to enter into this Agreement on behalf of the Party for whom they
sign.
NEVADA POWER COMPANY (d/b/a NV
Energy)
SOUTHERN CALIFORNIA EDISON
COMPANY
By.By.
Name Robert WoodsName Shahzad Lateef
Title Managing Director T&D Asset Management & Ops ServicesTitle Vice President - Transmission
Date SignedDate Signed
DESERTLINK, LLCDEPARTMENT OF WATER AND POWER
OF THE CITY OF LOS ANGELES BY
BOARD OF WATER AND POWER
COMMISSIONERS I
BvBy:MARTIN L. ADAMS
General Manager and Chief Engineer Name MarkMilbum
Date: Title Vice President
Date SignedAnd:
SUSAN A. RODRIGUEZ Secretary
APPROVED AS TO FORM AND LEGALITY MICHAEL N. FEUER, CITY ATTORNEY
UB 2 8 2019BY.
SYNQI DRISCOLL/ DEPUTY CITY ATTORNEY
i1
DocuSign Envelope ID; F9382259-74BC-48DB-BF91-ACE86028A4CE
Page A-l
ATTACHMENT A
Protected Materials: Contains Critical Energy Infrastructure Information
ELDORADO-HARRY ALLEN 500 KV LINE
INTERCONNECTION TO ELDORADO SUBSTATIONj
Detail of Last Structure (D)
To Harry Allen Substation
E3 E3 | E3 insulators
JChamteofOwnefthfe b where SCE’s
tosulators connect to Desartlinfc's Jumpers
and tower
OPGW Splice Box(SCE|
<>I
fInsdatws
Harry Allen
t.To Eldorado Substation
LAST STRUCTUREIdELDORADO SUBSTATION
ROW BOUNDARYC>
Mohave Lugo ^BMoenkopiMcCullough [*]aAddtfonal TowersELDORADO SUBSTATIONS FENCE UNE
16 Ur-M-fYmv11 151 2 6 12 13 143 4 5 7 8 9 10S
| M2 | | W | | 95?] I3962 992 $162jPoint of -
InterconnectionJOINTLY-OWNED ELDORADO S00 KV
SWITCHYARD
i862 81$872 882 L j■v
QtT] Q«] [t|] . 782 792N
3aa aAa aAa 4A*500/ 220 KV VW VW 500/ 220 KV
AAA 5AA VW 500/220 KV
LegendOwned by One or More of the
' Eldorado Co-Owners ■ Connecting Facilities (Owned by SCE)
-------- Owned by Connecting Customer
Last StructureN
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page B-l
ATTACHMENT BELDORADO GENERAL FACILITIES
NEW COST RESPONSIBILITY RATIOS
TERMINATIONS NVLADWP SCE 1Energy(in %)220 kV (in %) (in %)
Transformer No. 3AA - 220 kV 21.140 63.76015.10021.140Transformer No. 4AA - 220 kV 15.100 63.760
Eldorado-Mead No. 1 26.42518.875 54.700Eldorado-Mead No. 2 26.42518.875 54.700
Eldorado-Cima-Pisgah No. 1 0.000 100.0000.000Eldorado-Cima-Pisgah No. 2 0.0000.000 100.000
Eldorado-Merchant No. 1 0.000 100.0000.000Eldorado-Merchant No. 2 100.000 0.0000.000Eldorado-Magnolia 100.0000.000 0.000Eldorado-NSO 0.000 100.000 0.000220 kV Subtotal = 1000 67.950 395.130 536.920
500 kVTransformer No. 3AA - 500 kV 21.14015.100 63.760
Transformer No. 4AA - 500 kV 21.140 63.76015.100
21.140Eldorado-Mohave 45J00 33.560Eldorado-McCullough 0.000100.000 0.000
100.0000.000Eldorado-Lugo 0.000Eldorado-Moenkopi 0.000 100.0000.000 i
i0.000Transformer No. 5 AA 0.000 100.000
Eldorado-Harry Allen 0.0000.000 100.000
500 kV Subtotal 800 175.500 63.420 561.080TOTAL= 1800 458.550243.450 1098.000
Sum of Functions responsibilities:LADWP + NV Energy + SCE + Eldorado-Harry Allen Transmission Line (SCE responsible) = 243,450 + 458.550 + 998.000 + 100.000 = 1800.000 Calculation of Cost Responsibility Ratios:LADWP = (243.450/1800.000) x 100% = 13.525%
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page B-2
= 25.475% = 61.000% = 100.000%
NV Energy = (458.550/1800.000) x 100% = (1098.000/1800.000) x 100%SCE
Total
ELDORADO 500 KV SWITCHYARD
NEW COST RESPONSIBILITY RATIOS
TERMINATIONSLADWP
(in %)SCE
(in %)NV Energy
(in%)
Eldorado-Harry Allen 100.0000.000 0.000
Eldorado-Lugo 100.0000.000 0.000Eldorado-McCullough 100.000 0.000 0.000
Eldorado-Moenkopi 0.000 0.000 100.000
Eldorado-Mohave 33.56045.300 21.140
63.760Transformer No. 3AA 15.100 21.140
21.140Transformer No. 4AA 15.100 63.760
Transformer No. 5AA 100.0000.000 0.000
Total = 800.000 175.500 63.420 561.080
A. Sum of Functions responsibilities:
LADWP + NV Energy + SCE + Eldorado-Harry Allen Transmission Line (SCE
responsible) = 175.500 + 63.420 + 461.080 + 100 - 800.000
Calculation of Cost Responsibility Ratios:B.
= (175.500/800.000) x 100%
NV Energy =(63.420/800.000) x 100%
= (561.080/800.000) x 100%
21.9375%LADWP
7.9275%
70.135%
100.000%
SCE
Total
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page C-l
ATTACHMENT C
ADDRESSES FOR NOTICES
Department of Water and Power of the City of Los Angeles c/o Reiko A. Kerr, Senior Assistant General Manager — Power System111 North Hope Street, Room 921Los Angeles, CA 90012-2607Box 51111, Room 921Los Angeles, CA 90051-5700Fax: 213 367-0313E-mail: Reiko.Kerr@ladwp .com
Street address:
Mailing address:
Nevada Power Company d/b/a NV Energyc/o Manager, Transmission Business Services6100 Neil Road - M/S S3B40Reno, NV 89511P.O. Box 10100 - M/S S3B40Reno, NV 89520-0024E-mail: [email protected]
Street address:
Mailing address:
Southern California Edison Companyc/o Manager, Grid Contracts Management 2244 Walnut Grove Avenue Rosemead, California 91770 P.O. Box 800 Rosemead, CA 91770E-mail: [email protected]
Street address:
Mailing address:
DesertLink, LLCc/o Project Manager16150 Main Circle Drive, Suite 310Chesterfield, MO 63017E-mail: [email protected]
Mailing address:
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page E-2
ATTACHMENT E
SCOPE OF WORK AND COST
The Connecting Facilities described in this Attachment E to the Agreement are based on SCE’s preliminary engineering and design and are subject to modification to reflect the actual facilities that are constructed and installed following SCE’s final engineering and design, identification of field conditions, and compliance with applicable environmental and permitting requirements.
1. Connecting Customer’s Scope
The Connecting Customer shall:i. Install the Eldorado-Harry Allen 500 kV Transmission Line, a new 60-mile
single circuit 500 kV transmission line with three (3) 1590 kcmil 45/7 ACSR “lapwing” conductors per phase which shall include:
1. the Line Segment; and2. the Additional Towers.
ii. Design tower A (as identified in Attachment A) as a double circuit tower, subject to SCE review and approval, and install tower A with one circuit position remaining open without attached hardware, insulators or conductors.
iii. Install one (1) 48 fiber optical ground wire (“OPGW”) on the Eldorado-Harry Allen 500 kV Transmission Line to provide one of two telecommunication paths required for the line protection scheme and the remote terminal units (“RTUs”). A minimum of eight (8) strands within the OPGW shall be provided for SCE’s exclusive use into the Eldorado 500 kV Switchyard.
iv. Install one (1)7 strand EHS steel ground wire and/or Ibis wire to facilitate shielding between Harry Allen and Eldorado Substations.
v. Install appropriate single-mode fiber-optic cable and/or microwave bandwidth from Harry Allen Substation to a point designated by SCE near the Eldorado Substation to provide the second telecommunication path required for the line protection scheme. A minimum of eight (8) strands within the single-mode fiber optic cable shall be provided for SCE’s exclusive use. The telecommunication path shall meet the Applicable Reliability Standards and Applicable Reliability Criteria for diversity.
vi. Install a new series capacitor bank with rated continuous current of 3800 amp and 70% compensation and appurtenant equipment near Harry Allen Substation. The series capacitor bank shall be designed to automatically bypass the series capacitors due to faults in the series capacitors, and provide a means to isolate the series capacitors to facilitate maintenance. Install Forced- Triggered Bypass Gaps or Other Fast Bypass Devices in series capacitors which are programmed to bypass the series capacitors at least 10 ms prior to the current interruption of line circuit breakers).
vii. Install bypass switches on each series capacitor bank segment.
i
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page E-3
Own, operate and maintain the portion of the primary telecommunication path (including OPGW, any fiber-optic cables, and appurtenant facilities) that is located between the Point of Change of Ownership and the Harry Allen Substation, including a patch panel specified and installed by Connecting Customer on tower D. Connecting Customer shall install such telecommunication path between the Harry Allen Substation and tower A as shown in Attachment A, but the portion of such path located between the Point of Change of Ownership and tower A shall be transferred to SCE as part of the Additional Towers, and shall thereafter be operated and maintained by SCE.Own, operate and maintain, or otherwise lease the secondary telecommunication path (including OPGW, any fiber-optic cables, microwave facilities and appurtenant facilities) located between the Eldorado 500 kV Switchyard and the Harry Allen Substation. Connecting Customer shall coordinate with SCE to determine the interface, and if necessary a point of change of ownership, for the secondary path, whether for fiber or microwave, Allow SCE to review the Connecting Customer’s design for the Additional Towers and during construction to perform inspections to ensure compatibility with agreed transmission design and construction requirements; allow SCE to perform acceptance testing of the Additional Towers and the right to request correction of installation deficiencies.Allow SCE to review the Connecting Customer’s telecommunication equipment design and during construction to perform inspections to ensure compatibility with agreed terminal equipment and protection engineering requirements; allow SCE to perform acceptance testing of the telecommunication equipment and the right to request correction of installation deficiencies.Extend the OPGW for the primary telecommunication path to an SCE- specified patch panel provided and installed by Connecting Customer, to be located at Tower D, string the OPGW from Tower D to Tower A and provide sufficient quantity of OPGW coiled at Tower A to enable SCE to install the span from Tower A to the Point of Interconnection.Request NV Energy to install relay protection at Harry Allen Substation in accordance with specifications to be agreed upon by SCE and NV Energy to accommodate the relay protection used by NV Energy and SCE, in order to protect the Eldorado-Harry Allen 500 kV Transmission Line, as follows:
Two (2) SEL current differential relays via diversely routed dedicated digital communication channels to the Eldorado 500 kV Switchyard. The model of current differential relays will be specified via collaboration between SCE and NV Energy.Install disconnect facilities to comply with switching and tagging procedures as agreed by NV Energy.
Connecting Customer shall transfer the ownership of the Additional Towers within forty five (45) days following completion of construction of the Eldorado-Harry Allen 500 kV Transmission Line. SCE may not energize the
vin.
IX.
X.
XI.
XU.
i
xm.
1.
2.
XIV.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page E-4
Eldorado-Harry Allen 500 kV Transmission Line until Connecting Customer transfers the ownership of the Additional Towers to SCE.
2. Connecting Facilities (excluding Additional Towers)
SCE shall:a. Install facilities for a new 500 kV switchrack position to terminate the Eldorado-
Harry Allen 500 kV Transmission Line. This work includes the following:Install two (2) 90 foot by 108 foot high bus dead-end structure and foundations to extend the 500 kV bus.Install approximately 1,700 feet of 2156 kemil ACSR conductor to extend the 500 kV bus.Install twelve (12) bus insulator assemblies to extend the 500 kV bus.Install one (1) 90 foot wide by 108 foot high steel dead-end structure and foundation.Install two (2) 4000A, 63kA, 500 kV circuit breakers to be designated as #7102 and #9102.Install four (4) 4000A, horizontally mounted disconnect switches, leads and foundations. ' : ■Install one (1) grounding switch.Install thirty six (36) bus supports and foundations.Install approximately 4,000 feet of 2156 kemil ACSR conductor.Install approximately 500 feet of'cable trench.Install approximately 14,000 feet of control cable. ;Install three (3) 500 kV coupling capacitor voltage transformers (“CCVTs”) with steel pedestal support structures.Install appropriate seven (7) protective relays and appurtenant equipment as agreed upon by SCE.Install five (5) 28 inch racks.
l.
it.
in.IV.
V.
VI.
vu.Vlll.
IX.X. i
XI.XU.
XUl,
XIV.
b. Install a new 100 MVAR shunt line reactor and appurtenant equipment as follows:
i. Install one (1) 90 foot wide by 108 foot high steel dead-end structure andfoundation. .
ii. Install one (1) 4000A, 500 kV horizontally mounted disconnect switch, steelsupport structures and foundations. .
iii. Install one (1) set (3 single pole) 3000 A, 500 kV, synchronous circuit breaker and foundation.
iv. Install three (3) bus support structures, insulators and foundations.v. Install three (3) 500 kV lightning arresters on new foundations.
vi. Install three (3) 33.333 MVAR line reactors and foundations.vii. Install two (2) firewalls. , ,
viii. Install two (2) 18 foot high neutral bus structures and foundations.Install 1,000 feet of 2156 kemil ACSR conductor.Install 200 feet of 103 3 kemil ACSR conductor.
I
ix.x.
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page E-5
Install 200 feet of cable trench. Install 200 feet of control cable.
xt.xu.
Install all required lightwave, channel, and associated equipment (including terminal equipment), supporting protection, RTU and SCADA requirements for the interconnection of the Eldorado-Harry Allen 500 kV Transmission Line. Install appropriate length of fiber optic cable, including conduit and vaults, from a point designated by SCE to extend the OPGW into the communication room at the Eldorado 500 kV Switchyard as follows:
i. Install approximately 650 feet of 2-5 inch conduit.ii. Install one (1) four foot by four foot by six foot manhole. iiUnstall approximately 2,250 feet of fiber optic cable.
c.
d.
Install appropriate length of fiber optic cable, including conduit and vaults, to extend the Connecting Customer’s diverse telecommunications from the point designated by SCE near the Eldorado 500 kV Switchyard into the communication room at the Eldorado 500 kV Switchyard. The actual location and length of fiber optic cable and conduit, and location and number of vaults, will be determined during final engineering of SCE’s Connecting Facilities.
e.
f. RESERVED,]
Add RTU point additions to the existing RTU and updates to the EMS database, displays, and calculations as required to support the Eldorado-Harry Allen 500 kV Transmission Line.
g-
Provide mapping, survey, title work, land acquisition labor, licensing, and other activities related to substation, transmission line and telecom requirement.
h.
3. Estimated Cost of SCE’s Connecting Facilities and associated ITCC:
Connecting Facilities Estimated CostElement
Eldorado 500 kV Switchyard (within substation fence line) $ 7,829,000.00
$ 8,875,000.00Line Reactor$ 77,000.00Real Properties$ 877,000.00Telecommunications$ 17,658,000.00SCE Total
Additional Towers (outside substation fence line but within current Eldorado right-of-way) $8,331,632.00ITCC associated with transfer of Additional Towers $1,999,592
$10,331,224.00Connecting Customer Total
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page E-6
All amounts shown above are in nominal dollars and are estimates only. Actual costs and ITCC to be determined in accordance with Section 17.4 and 17.9 of this agreement.
!
DocuSign Envelope ID; F9382259-74BC-48DB-BF91-ACE86023A4CE
Page F-7
ATTACHMENT F
MILESTONES
1. Milestones: Table FI
Item Milestone Responsible Party Due DateConnecting Customer provides specifications and drawings of Additional Towers to SCE (“Additional Towers
On or before thirty (30) Calendar Days following the Effective Date
(a) Connecting Customer
Documentation”).SCE requests additional Within fifteen (15)
Calendar Days following receipt Additional Towers Documentation
information and/or suggests revisions to the Additional TowersDocumentation.
(b) SCE
Connecting Customer submits final Additional TowersDocumentation to SCE
Within thirty (30) Calendar Days following completion of milestone
(c)* Connecting Customer
(b)
SCE andrepresentatives of Boulder City,Nevada agree in principle on terms of secure long-term rights for all property within the current Eldorado right-of- way boundary that is required for the Additional Towers and is subject to the August 6, 2019 expiration of the
/
(d)** SCE July 1, 2019
DoouSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page F-8
BLM reservedcorridor (BLM serial number NVN-02655)ConnectingCustomerdemonstrates that it has secured all material permits, licenses, and property rights required for the construction of the Additional Towers
(e)* November 1, 2018Connecting Customer
and Line SegmentConnectingCustomerdemonstrates selection of Engineering, Procurement and Construction Contractor for the Additional Towers and Line Segment
(f)* Connecting Customer November 1, 2018
ConnectingCustomercommences construction of the Eldorado-Harry Allen 500 kV Transmission Line
(g)* Connecting Customer November 1, 2018
SCE begins design, engineering and procurement of the Connecting Facilities (excluding the Additional Towers)
Within thirty (30) Calendar Days following Effective Date
(h)** SCE
SCE submits toConnecting Customer the construction schedule for the Connecting Facilities per Article 5.5.2 oftheAPSA
Within sixty (60) Calendar Days following achievement of item (h)
0)** SCE
DocuSign Envelope ID: F9382259-74BC-48DB-BF91-ACE86028A4CE
Page F-9
Construction of the Connecting Facilities (other than the Additional
**(i) SCE August 1, 2019
Towers) beginsConstruction of theAdditional Towers and Line Segment is substantially complete_________
(k)* Connecting Customer March 1, 2020
Contingent on satisfactory and timely completion of milestones (g) and (k), the earlier of 1) twenty-seven (27) months from the Effective Date, or 2) March 1, 2020,________
Construction of the Connecting Facilities (other than the Additional Towers) is substantially complete.
SCE(1)*4=
Submit initial specifications for major equipment and/or materials for the Line Segment, including system protection facilities, to SCE and the CAISO per Article 5.4.1 oftheAPSA
At least thirty (30) Calendar Days prior to solicitations for major equipment and/or material
(m) Connecting Customer
Review and submit any comments on initial specifications per Article 5.4.1 of the APSA
Within fifteen (15) Calendar Days of submissions pursuant to milestone (m)
(n) SCE
i
Submit any updated specifications for major equipment and/or materials for the Line Segment, including system protection facilities, to SCE and the CAISO per Article 5.4.2 of the APSA
At least one hundred eighty (180) Calendar Days prior to Testing Commencement
(o) Connecting Customer
DocuSign Envelope ID: F9382259-74BCM8DB-BF91-ACE8602BA4CE
Page F-10
Review and submit any comments on the updatedspecifications per Article 5.4.2 of the APSA
Within thirty (30) Calendar Days of submissions pursuant to milestone (o)
(P) SCE
Submit final specifications for major equipment and/or materials for the Line Segment, including system protection facilities, to SCE and the CAISO per Article 5.4.2 of the APSA
At least ninety (90) Calendar Days prior to Testing Commencement
Connecting Customer(q)
Review and submit any comments on the final specifications per Article 5.4.2 of the APSA
Within thirty (30) Calendar Days of submissions pursuant to milestone (q)
(r) SCE
Notify CAISO in advance of commencement of testing per Article 6.2 of the APSA
At least fourteen (14) Calendar Days prior to the Testing Commencement
Connecting Customer and SCE(s)
Transfer ownership of Additional Towers to SCE
Prior to Commercial Operation DateConnecting Customer(t)
Provide written approval to the Connecting Customer and CAISO for initial energization of the Line Segment per Article 9.3 of the APSA
Prior to Testing Commencement(u) SCE
Initial Energization and Testing of the Connecting Facilities and the Line Segment in accordance with Article 6.1 of the
Within one (1) month following completion of milestones (k) and (1)
Connecting Customer and SCE(v)**
DocuSign Envelope ID: F9382259-74BC48DB-BF91-ACE86028A4CE
Page F-l 1
APSA (“Testing Commencement’ ’)Provide writtenapproval to the Connecting Customer and CAISO for the operation of the Line Segment per Article 6.1 of the APSA
No later than the Commercial Operation Date
(w)** SCE
CAISO’s and Connecting , Customer’s required Commercial
(x)** SCE May 1,2020
Operation DateSubmittal of “as-built” drawings, information and documents, including protection settings, for the Line Segment per Article 4.6.2 of the APSA
Within one hundred twenty (120) Calendar Days after Commercial Operation Date, unless otherwise agreed
(y) Connecting Customer
Notes:
Connecting Customer will use Reasonable Efforts to meet the milestones designated with in Table FI (as such milestones may be adjusted) by the applicable Due Dates. If the Connecting Customer is not current in meeting the milestones designated with in Table FI (as such milestones may be adjusted), the Connecting Customer shall provide written notice to SCE with the reasons for such failure to meet the identified milestones and shall undertake Reasonable Efforts to meet the earliest dates thereafter.
1.
SCE will use Reasonable Efforts to meet the milestones designated with Table FI by the applicable Due Dates. If SCE is not current in meeting its milestones designated asCustomer with the reasons for such failure to meet the identified milestones and shall undertake Reasonable Efforts to meet the earliest dates thereafter.
;2. m
in Table FI, SCE shall provide written notice to the Connecting
The Connecting Customer understands and acknowledges that such timelines are only an estimate and that equipment and material lead times, labor availability, outage coordination, regulatory approvals, right-of-way negotiations, or other unforeseen events could delay the actual in-service dates of the Connecting Facilities beyond those specified. SCE shall not be liable for any cost or damage incurred by the
3.
DocuSign Envelope ID: F9382259-74BCM8DB-BF91-ACE86028A4CE
Page F-12
Connecting Customer because of any delay in the work provided for in this Agreement. The Connecting Customer also understands and agrees that the completion timeline of the Connecting Facilities may be delayed if the Connecting Customer does not meet or satisfies the Connecting Customer’s milestones as outlined in this Attachment F, Table FL
4. Within five days after the Connecting Customer determines that the ConnectingCustomer’s milestones, Additional Towers, and/or the Line Segment may be delayed, the Connecting Customer shall give written notice to SCE that completion of the Line Segment or the milestones may be delayed. In such event the Parties shall negotiate in good faith to amend the milestones in Table Cl to synchronize the completion of the Line Segment, Additional Towers and the Connecting Facilities. However, if the Parties fail to reach agreement, the completion timeline of the Connecting Facilities may be delayed, and unless the Connecting Customer affirms in writing that the Connecting Customer is responsible for the costs of the Connecting Facilities pursuant to Section 4.4 of the Agreement, SCE has discretion to delay its construction, halt and cease progress towards SCE’s milestones.
i