Board of Directors’ Report
Board of Directors’ Reportand Consolidated Financial Statements
Annual Report
TECHINT E&C S.A.
Annual Report
For the year ended December 31, 2017 and December 31, 2016
2 TECHINT E&C S.A. Annual Report 2017
Contents
09
21
34
40
55
63
Overview of the year
TECHINT E&C subsidiaries’ activities for the fiscal year ended December 31, 2017
Ecuador
Engineering
Legal Information
Consolidated Statement of Comprehensive Income
46Social responsibility
Board of Directors’ Report
Consolidated Financial Statements
3
TECHINT E&C Equipment Division
12
21
36
43
56
64
Prospect for the Fiscal Year 2018
Africa
Europe and Commonwealth of Independent States (CIS)
Procurement
Independent Auditor’s Report
Consolidated Statement of Changes in Equity
47
15
22
37
44
60
68
Technology and IT Systems
Economic and Financial Information
Argentina
Mexico and North America
Consolidated Statement of Financial Position
Consolidated Statement of Cash Flows
48 49
20
33
38
46
Board of Directors’ Proposal
Board of Directors
TECHINT E&C in the world
Chile
Uruguay
Compliance and Internal Control
47
18
32
38
45
62
71
Human Resources
Major Works per Country
Brazil
Peru
Quality, Health, Safety and Environment (QHSE)
Consolidated Income Statement
Index to the Notes to the Consolidated Financial Statements
4 TECHINT E&C S.A. Annual Report 2017
The Company values internal and external transparency,
and considers its top management responsible
for fostering an environment of honesty and integrity,
with absolute fulfillment of the corresponding legal and
regulative requirements.
TECHINT E&C has gained strength from the synergies
resulting from the integration with the subsidiaries in America
and Europe, and it offers customized services in different
industrial sectors (such as oil & gas, energy, industrial plants,
mining and infrastructure) ensuring quality, reliability and
expertise to our customers in diversified markets.
For the purpose of providing its customers with
comprehensive solutions with a high added value, the
Company counts on highly qualified human resources,
various skills in engineering and construction, and the
know-how to efficiently manage the projects it develops.
Techint E&C S.A. (TECHINT E&C), is a holding company
of a group of subsidiaries which provide engineering,
procurement, construction, operation and management
services for large and challenging projects globally in the
segments of oil & gas, energy, industrial plants, oil refineries
and petrochemical plants, mining and infrastructure
and architecture civil works. TECHINT E&C, through its
subsidiaries, conducts activities mainly in the markets
of America, Europe, Africa and the Middle East. Any
references in this Report to “TECHINT E&C” or “the
Entity” or “the Company”, refer to Techint E&C S.A. and
its consolidated subsidiaries.
The Company develops highly complex ventures, from
design to commissioning and start-up, taking care
of the environment and the welfare of the communities
at the locations where it operates.
TECHINT E&C develops the projects, taking into account
the requirements of ISO 9001, ISO 14001 and OHSAS 18001,
and using methods that ensure the achievement of
the highest standards relating to quality, safety and health,
as well as environmental protection.
The Company
5Board of Directors’ Report
Dec 31, 2017
13,740 Dec 31, 2016
18,671
KEy FIguRES REvENuE By CouNTRy
PERSoNNEl
USD millionS
Revenue
EBITDA
EBITDA %
Profit
Profit / Revenue
Total equity
ROE
Dec 31, 2017
1,427.1
62.1
4%
16.6
1%
673.6
2.5%
1,283.8
104.3
8%
42.4
3%
645.2
6.7%
Dec 31, 2016
40% Argentina
1% Others
2% Uruguay
3%Peru
10%Ecuador
8% Europe, Middle East and Africa
26%Mexico
10%Brazil
6 TECHINT E&C S.A. Annual Report 2017
7Board of Directors’ Report
TECHINT E&C S.A.
For the year ended December 31, 2017 and December 31, 2016
Board of Directors’ Report
Board of Directors’ Report
8 TECHINT E&C S.A. Annual Report 2017
Ferro Carajás S11D Project, Brazil
9Board of Directors’ Report
TECHINT E&C recorded consolidated revenues for USD
1,427.1 million.
TECHINT E&C is currently developing activities, always in
accordance with the Company’s most outstanding values:
sustainability and safety, commitment to skills development,
transparency and passion for quality. TECHINT E&C´s focus
on the execution of businesses is consistent with the
Company’s mission: creating value for clients by means of
the ongoing search of project management streamlining,
assuring both quality and respect for scheduled terms, and
constantly paying special attention to workers’ safety.
In Argentina, through the subsidiary Techint Compañía
Técnica Internacional S.A.C.I. (TEARG), the activities were
developed under several types of contracts: engineering,
procurement and construction (EPC) and construction
management (EPCM), subject to several contract modalities
such as lump sum, unit prices, cost plus, etc.
In the energy sector, a contract was entered into with Pampa
Energía S.A. seeking to expand the installed capacity in the
Genelba Plus combined cycle of the Thermal Power Plant
located in Marcos Paz, Province of Buenos Aires. With respect
to works executed during the fiscal year for Empresa Provincial
Sociedad del Estado (EPSE) at the hydroelectric station El
Tambolar, the works for drilling and concrete lining of the river
sidetracking tunnel were completed, and excavation works
were started for the tunnel mouth. In addition, for the Client
General Electric International Inc. Sucursal Argentina (GE),
the YGEN II project was developed in El Bracho, Province of
Tucumán, for the assembly of an additional turbo generator that
will allow the delivery of additional 260 Mw to the Argentine
Interconnection System (SADI). Also, works were commenced
in Lima, Province of Buenos Aires, for completion of civil works
required for the assembly of the prototype reactor CAREM 25,
a project awarded to the Company by the Argentine Atomic
Energy Commission (Comisión Nacional de Energía Atómica).
For Central Costanera S.A., TEARG replaced two rotation filters
located at the cooling water intake of combined cycle II of the
plant located at Costanera Sur in the City of Buenos Aires.
In the iron & steel segment, the works were continued at
the plants of Siderca S.A.I.C. (Campana, Province of Buenos
Aires) and of Ternium Argentina S.A. (San Nicolás, Province
of Buenos Aires). The latter client also awarded to TEARG the
works for the assembly of the shed and electromechanical
works at the new Acid Regeneration Unit to be installed at its
plant located in Ensenada, Province of Buenos Aires.
In the infrastructure works segment, under the project for
Subway Line H Expansion, for the client Subterráneos de
Buenos Aires Sociedad del Estado (SBASE), during this fiscal
year TEARG obtained the Provisional Acknowledgements
of Receipt for the Córdoba, Santa Fe and Las Heras stations
(with the related tunnel), the Cordoba rectification sub-station
(“SER”), tunnel of C2 tranche up to post-Las Heras, Workshop
I and the parking space in a cave under Parque Patricios.
TEARG also obtained the Final Acknowledgement of Receipt
for Parque Patricios Workshop I and the Honda Building.
Works were continued in the execution of Facultad de Derecho
station and the respective tunnels.
In the mining area, the company Minera Argentina Gold S.A.
required engineering works within the maintenance plan of
the Veladero Mine facilities.
In the oil & gas segment, the contract executed with Tecpetrol
S.A. stands out, for the rendering of engineering, construction
and procurement services, among others, in the Fortín de Piedra
area, located in the Province of Neuquén, a project that is part of
the unconventional gas development in the zone of Vaca Muerta.
Overview of the year
10 TECHINT E&C S.A. Annual Report 2017
Also within the context of this development, TEARG entered
into a contract with YPF S.A. for construction of a 16" and
33.3 km gas pipeline, including the respective surface facilities
in the surroundings of Añelo, Province of Neuquén.
Besides, in the gas fields in the Magallanes area, TEARG
continued rendering services of detail engineering, procurement
management, construction, commissioning and start-up of
onshore works and the management of offshore works required
by Enap Sipetrol Argentina S.A. – YPF S.A. UTE (JV).
In Chile, during 2017 Techint Chile S.A. (TECHI) has obtained
great achievements with respect to the projects that were
executed. Firstly, the Mechanical Completion certificate was
received from the project of Escondida Water Supply (EWS),
executed in a consortium with Bechtel Chile Ltda., obtaining
the recognition of the BHP Client for the management of TECHI
both in terms of the quality of the works as to results in security.
On the other hand, the works executed for the client Anglo
American Sur S.A. in the Los Bronces mine were successfully
concluded, and thanks to the relationship and trust built as a
result of the execution of previous projects, in October this client
awarded a new contract in favor of the Company. This project
comprises the continuation of works for replacement of pipes,
now at the medium zone, for the mining tailings transportation
system, from the Ortiga Tunnel Portal to the Barros Negro
mountain area, and the contract amount is USD 28 million.
In Peru, during this fiscal year, Techint S.A.C. (TESAC)
continued working on the Camisea Pipeline Maintenance
Project for Compañía Operadora de Gas del Amazonas S.A.
through a joint venture with GyM S.A., and completed a
project as budgeted on the Norperuano Oil Pipeline for the
client Petroperu S.A., also under a joint venture with GyM S.A.
Besides, TESAC also worked on the Sagari Project, that
is a FEED contract for the client Repsol, and it provided
some engineering services for the clients Pluspetrol Peru
Corporation S.A. and CNPC Peru SAC.
In uruguay, Techint Compañía Técnica Internacional S.A.C.I.
(TEURU), TEI&C’s subsidiary, continued working on:
Maldonado Sewage System for Obras Sanitarias del Estado
(OSE) and Route 9 for Corporación Vial del Uruguay S.A.
During this fiscal year, the contract with Environmental Works
in Maldonado and Punta del Este for OSE was finished.
In Brazil, in 2017, the Company’s subsidiary Techint
Engenharia e Construção S.A. (TEBRA) completed 70 years
of continuous operation in Brazil. Throughout such period, it
has developed the most relevant infrastructure projects of the
country, taking part in the construction of all the refineries,
most large-sized pipelines currently in operation and the
largest projects of the energy sector. In every single market
in which TEBRA has been present, its clients, business
partners, insurance companies and financial developers
always recognize TEBRA as a company with technical and
financial capacity, high quality and a great performance. It
has continued working in the Modules for the Petrobras-76
(P-76) Platform for the client Petrobras Netherlands B.V.
On the other hand, TEBRA is still working with Vale in a
contract for a project involving the highest investment of
Vale in Brazil: S11D Ferro-Carajas. This contract consists in the
implementation of assembly of a Truckless Mining System,
which results in a reduction of both waste and costs, by using
movable equipment to replace iron ore transportation trucks.
In Ecuador, the Company, through its subsidiary,
Construcciones y Prestaciones Petroleras S.A. (CPP),
keeps on rendering specialized technical services of
engineering, procurement management and construction in
the Shushufindi-Aguarico field, Province of Sucumbíos, in
Eastern Ecuador, for the client Consorcio Shushufindi, a joint
venture currently formed by Schlumberger and Tecpetrol. In
addition, Schlumberger, through its subsidiary Shaya Ecuador
SA, has continued to rely on our services for the AUCA field,
located in the province of Orellana, which are similar to those
provided in the Shushufindi field. The main goal of the clients
is to increase crude oil production in the fields.
In Mexico, through the subsidiary Techint S.A. de C.V.
(TEMEX), the following works were carried out:
In Altamira (Tamaulipas), TEMEX started to work on the
Compressor Station Altamira for the client Infraestructura
Marina del Golfo, S. de R.L. de C.V.
11Board of Directors’ Report
TEMEX was awarded two new projects: the Central Combined
North III project for the client Abeinsa Juarez N III, S.A. of
C.V. and the project for the Internal Coal Handling System
Revamp (Repotenciamiento del Sistema Interno de Manejo de
Carbón (RSIMC)) for the client Greenfield SPV I S.A.P.I. of C.V.
In addition, works were continued at the plants of Ternium de
México S.A. de C.V. and Tubos de Acero de México S.A. de C.V.
In the united States, works were completed at the Tenaris
Bay City Project for the client Tenaris Bay City Inc.
During the fiscal year, the Company accompanied the gradual
completion of the Europe and Middle East sites and made
great efforts to promote the new services center, aimed at
both consolidated clients and new investors in emerging areas.
In Northern France, works are being developed for the
construction of one of the largest liquefied natural gas (LNG)
regasification plants in Europe, located in Dunkerque, for
Électricité de France (EDF).
In Egypt, the Company continued working in the Al Shabab
and West Damietta power projects, both for the East Delta
Electricity Production Company. Construction works are
almost finished and both projects are in the Commissioning
stage. The Company is currently working in the South
Helwan power project, a Supercritical Thermal Power
Plant for Upper Egypt Electricity Production Company.
During 2017, the Company also executed and completed a
brownfield project for Sidi Kerir Petrochemicals Company
(SIDPEC) in Alexandria.
As regards engineering services, the Company continued
with the works relative to concept, basic and detail
engineering mainly associated with the Company’s own
projects under execution and projects for external clients
who are provided this specific professional services. Besides,
the Company kept on providing assistance for development
of technical bidding terms and the assessment of several
investment projects.
All the operational activities conducted by TECHINT E&C
in the different geographical areas around the world were
carried out paying maximum attention to, and in furtherance
of, the regulations in terms of environmental sustainability
and the ongoing development of quality and safety aspects.
Techint E&C is participating in S11D, part of the largest investment project in the history of Vale mining company, located in Pará, Brazil.
12 TECHINT E&C S.A. Annual Report 2017
The Company aims at maintaining its primary role
as engineering company and general contractor in
the different product segments (energy, oil & gas,
petrochemical, infrastructure) and in the geographical areas
considered to be targets by TECHINT E&C (Africa, Middle
East, Europe and Latin America) taking into account a
market scenario for industrial plants posing ever-increasing
challenges. Our extensive deployment and the knowledge
of the needs of domestic clients and engineering and
construction practices will be a key and positive distinctive
factors for TECHINT E&C.
For the year to come, the Company expects to focus its
activities on key clients, providing a wider range of services.
The Entity foresees that the oil & gas, mining and power
generation industries will continue to be active, even
though with different degrees of intensity in each one of
such segments.
Thanks to the synergies between the subsidiaries in America,
Europe, Africa and the Middle East, TECHINT E&C is able
to offer its clients a wide range of diversified services in the
various core businesses of the Entity, specifically focusing
on the loyalty of major clients, the strengthening of a local
presence and the level of excellence in the services provided
to clients.
In Peru, the level of mining activity is expected to be
positive during 2018 regarding execution, exploration
and exploitation. Therefore, the Company is analyzing
to participate in different works related to the Mina
Justa Mine Project for the client Marcobre S.A.C.,
on the Corani Project for Bear Creek Mining, and on
the Quellaveco Project for Anglo American.
As from the end of 2017, some recovery has been evident
in the Chilean market, as a consequence of an increasing
confidence in such market by both local and foreign clients,
added to the worldwide context leading copper (the main
Chilean commodity for export) to reach higher prices than
in the past two years. All of this resulted in new positive
levels of growth for the country. Given the foregoing, it is
anticipated that during 2018 there will be several bidding
processes related to mining and energy infrastructure and
water supply projects. The Company will assess taking part
in such projects always giving priority to those in which it
may assert a differentiating value against other competitors,
based on the Company’s expertise, know-how or level of
confidence forged with clients.
As regards the oil & gas segment, TESAC has recently
submitted a bid for the client Sempra Energy Peru and
is studying the Norperuano Oil Pipeline. In addition, the
Company expects to take part in the Malvina Project for
Pluspetrol Perú Corporation S.A.
Finally, in the power generation market, the Company is
currently analyzing a high voltage network project, and
expects to be part of the hydroelectric generation projects in
which Sempra Energy Peru plans to invest during the current
fiscal year.
In Uruguay, Techint Compañía Técnica Internacional S.A.C.I.
(“TEURU”) will execute the extension of road works contracts.
The performance of the Brazilian economy is still uncertain,
but the forecast by the end of the year shows an
improvement in ratios. The private sector should drive the
major new investments in infrastructure and energy markets,
mainly transmission lines. Nevertheless, the Company
is taking measures to take advantage of all commercial
opportunities, which have risen in its traditional markets:
oil & gas, mining, steel and power plants, as well as new
segments and clients.
Prospects for the fiscal year 2018
13Board of Directors’ Report
In Europe, the Company has set the goal of expanding
its expertise to new sectors, such as environmental
engineering, renewable energy and new technologies,
in order to broaden the range of services being
offered to its clients and to increase opportunities for
market penetration.
For the year to come, the International Area’s main objective
is to continue strengthening the Company’s presence in
Egypt and to continue searching for business opportunities
in the power, petrochemical, oil & gas sectors with strategic
clients and partners in the EMEA area with the focus on
major pipeline projects.
In Argentina, there is an increased interest by investors and
we expect this may have a positive impact on the country’s
growth and may give rise to opportunities for the Company in
various business areas.
The Company shall continue working in projects involving
oil exploitation and production projects (upstream),
transportation and storage (midstream) and refining
(downstream). With respect to Vaca Muerta, the Company
shall continue developing the field by giving assistance to
Tecpetrol S.A. in Fortín de Piedra. On a supplementary basis,
the Company shall seek capitalizing the opportunities arising
in the oil sector within the Neuquén basin (unconventional
oil and gas) and works shall be executed with other clients
leveraging on the competitive advantages of having
established a permanent base of operations in the City of
Neuquén, using the experience and know-how developed
in this area during construction of facilities for oil and gas
processing and transportation.
In the mining segment, upon the increase of commodity
prices, a recovery is expected of certain projects
that were suspended in Argentina. TEARG is mostly
interested in projects associated with lithium mines in
the Northwestern region.
As regards infrastructure, it is estimated that projects under
PPP (Public Private Partnerships) shall derive in opportunities
for new challenges in all areas, from highways to subways,
railroads, water and sanitation, among others, in which the
Company is planning to be involved.
In the energy sector, the Company is working in projects
for generation of combined cycles closings and is waiting
for opportunities to develop new projects; having obtained
works for the expansion of the El Bracho plant for the
General Electric client. In the Nuclear sector, the Company
continues with the civil works related to the reactor
CAREM 25 for the Argentine Atomic Energy Commission
(CNEA), and expectations are focused on the future
evolution of new nuclear projects. In turn, the Company
is still interested in hydroelectricity projects in order to
continue with its operations in this sector, in which the
Company has been present on an uninterrupted basis for
several years now.
In Ecuador, the objectives for 2018 are to ratify the Contract
entered into with Shaya for the Auca Project and to continue
providing services for the Shushufindi-Aguarico field.
In the United States, Tenaris Bay City is bringing additional
opportunities to continue operating in the country. TEMEX
continues to seek EPCM and engineering projects. The
alliance with TENOVA on lithium plants enhances TEMEX’s
presence in the United States; in addition, some steel-related
clients that have shown their interest in forging a beneficial
relationship in ECPM projects.
In Mexico, the strong presence of TEMEX continues to
bring important opportunities in the oil & gas and the power
14 TECHINT E&C S.A. Annual Report 2017
sectors. Presidential elections to be held on July 1st entail
a slower pace of growth in this market, even though this is
temporary. In the private sector, Ternium sustained growth
in the country has brought important engineering and
manpower contracts. PPP projects seem to be the new
direction for our segments, and power initiatives with CFE
are already being explored and developed. The Nitrogen
Rejection project for PEMEX seems to be entering into its
final stage, where we will be competing strongly.
Mid-stream projects (fuel storage and transportation)
continue to move slowly, but high expectations will surely
turn into new business opportunities in the following
months, as the need for imported fuel continues to grow.
In Colombia, in a context where competition is increasingly
aggressive, TECHINT E&C has the purpose of returning
to the Colombian market. Projects are being evaluated
for the short and medium term such as electromechanical
assembly and the building of biofuel facilities, as well as
oil & gas projects.
15Board of Directors’ Report
SuMMARy oF CoNSolIDATED INCoME STATEMENT
Net income for the fiscal year was USD 16.6 million,
representing 1.2% of revenues.
Gross profit for this period was USD 156.9 million, accounting
for 11% of the revenues.
EBITDA for this period was USD 62.1 million, representing
4% on revenues.
General, administrative and selling expenses represented
10% of the revenues.
Financial results showed a gain of USD 2.3 million mainly
originated in the restatement and interest on claims, the
results from Techint Cía Técnica Internacional S.A.C.I.
Impregilo S.p.A. (suc. Arg.) Iglys S.A. - Unión Transitoria de
Empresas – Complejo Penitenciario Ezeiza, and the net
USD millionS
Revenues from construction contracts and other services
Cost of revenue
gross profit
General, administrative and selling expenses
Other operating results
Net financial result
Result from investments accounted for using the equity method
Income before income tax
Income tax expense
Net income
Attributable to:
Equity holders of the Company
Non-controlling interest
EBITDA (1)
EBITDA margin (% of revenues)
Dec 31, 2017
1,427.1
(1,270.2)
156.9
11%
(141.9)
(3.7)
2.3
3.4
17.0
(0.4)
16.6
1.2%
13.7
2.9
62.1
4%
1,283.8
(1,082.7)
201.1
16%
(138.9)
(17.3)
27.8
13.2
85.9
(43.5)
42.4
3.3%
38.5
3.9
104.3
8%
Dec 31, 2016
(1) EBITDA is equivalent to Gross profit plus General, administrative and selling expenses, Result from investments accounted for using the equity method, Other Operating results, minus depreciation and amortization.
Economic and financial information
16 TECHINT E&C S.A. Annual Report 2017
Equity at the end of the fiscal year amounted to USD 673.6
million with a Capital Stock of USD 877.5 million. The Equity
increased mainly due to the net income for the fiscal year, the
revaluation of PP&E and the capital contribution net of the
currency translation, the remeasurement of actuarial losses
and the changes in non-controlling interests.
Working capital as of December 31, 2017 was
USD 344.3 million.
foreign exchange transaction results, net of the interest and
indexation and commissions.
The other operating results showed a loss for USD 3.7 million,
mainly due to the results from the devaluation of other assets
and the claims, net of the sale of equipment and materials.
SuMMARy oF CoNSolIDATED STATEMENT oF FINANCIAl PoSITIoN
USD millionS
Assets
Non-current assets
Current assets
Total Assets
Equity
Majority Shareholders
Non-Controlling interest
Total Equity
liabilities
Non-current liabilities
Current liabilities
Total liabilities
Total equity and liabilities
Dec 31, 2017
488.4
1,316.0
1,804.4
668.8
4.8
673.6
159.1
971.7
1,130.8
1,804.4
529.8
1,052.8
1,582.6
639.3
5.9
645.2
173.3
764.1
937.4
1,582.6
Dec 31, 2016
17Board of Directors’ Report
SuMMARy oF CoNSolIDATED STATEMENT oF CASH FlowS
Cash and cash equivalents reaching USD 381.3 million at the
end of the fiscal year.
The Company generated operating funds for USD 193.5 million.
This generation of funds derived from the changes in trade and
other payables and tax liabilities, other liabilities and the result
of the fiscal year net of income tax payment and trade accounts
receivable and tax assets.
Among investment activities, mainly payment from the purchase
of PP&E net of proceeds from disposal of PP&E and dividend
collected, resulted in a cash decrease of USD 10.0 million.
Financing activities used funds for USD 39.2 million mainly
due to the cash flow for borrowings proceeds-repayment.
The effect of exchange rate changes were USD 8.1 million.
Some important ratios are the following:
USD millionS
Financial solvency (Assets / Liabilities)
Liquidity (Current Assets / Current Liabilities )
Indebtedness (Liabilities / Equity)
Solvency (Equity/Liabilities)
Immobilization of Capital (Non Current Assets / Assets)
Profitability (Net Income / Equity)
Cash and cash equivalents at the beginning of the year
Net cash generated by / (used in) operating activities
Net cash used in investing activities
Net cash used in financing activities
Net increase / (decrease) in cash and cash equivalents
Effect of exchange rates changes
Variation in cash due to Consolidation of Subsidiaries
Cash and cash equivalents at the end of the year
Dec 31, 2017
Dec 31, 2017
1.6
1.4
1.7
0.6
0.3
2%
226.6
193.5
(10.0)
(39.2)
144.3
8.1
2.3
381.3
1.7
1.4
1.5
0.7
0.3
7%
403.8
(138.0)
(8.9)
(20.8)
(167.7)
(9.5)
–
226.6
Dec 31, 2016
Dec 31, 2016
INDICAToRS
18 TECHINT E&C S.A. Annual Report 2017
AFriCA
Al Shabab – Combined Cycle Power Plant Phase II (Egypt)
West Damietta – Combined Cycle Power Plant Phase II (Egypt)
South Helwan – Supercritical Thermal Power Plant
ArgEnTinA
Subway Line H Expansion
Punta Negra Hydroelectric Power Station / Tambolar
GNEA
ENAP - Magallanes Area Incremental Project
Fortín de Piedra
Genelba Plus
CAREM 25
YGEN II – El Bracho
Works and Services in steel plants
BrAzil
Modules for P-76 Platform
Projet Ferro Carajás S-11D
ChilE
Escondida Water Supply (EWS) Project
Los Bronces Duct Replacement (High area)
Los Bronces Duct Replacement (Middle area)
Escondida Water Supply Expansion (EWSE)
East Delta Electricity Production Company (EDEPC)
East Delta Electricity Production Company (EDEPC)
Upper Egypt Electricity Production Company (UEEPC)
Subterráneos de Buenos Aires S.E. (SBASE) /
Ministerio de Desarrollo Urbano (MDU)
Energía Provincial S.E.
Energía Argentina Sociedad Anónima (ENARSA)
Enap Sipetrol Argentina S.A
Tecpetrol S.A.
Pampa Energía S.A.
Comisión Nacional de Energía Atómica (CNEA)
General Electric International Inc.
Planta Ternium Argentina S.A.- Planta Siderca S.A.I.C. -
Planta Regeneradora de Ácido Ternium S.A.
Petrobras Netherlands B.V.
VALE S.A.
Bechtel Chile Limitada
Anglo American Sur S.A.
Anglo American Sur S.A.
Minera Escondida Limitada
Contract Total Amount
(USD MILLION)
Country / Project Client
41
30
77
491
98
199
123
392
191
60
33
59
889
124
786
13
28
65
(a) Projects under a consortium/JV. The amount corresponds to total contract amount at 100%. See note 20 to the Consolidated Financial Statements. (b) The amount corresponds to annual revenues.
(a)
(a)
(a)
(b)
(a)
Major works per country
19Board of Directors’ Report
ECUADor
Shushufindi Services
Auca Services
EUroPE
Dunkerque LNG Fast Reloading
mExiCo
Combined Cycle Power Plant Norte III
Internal Coal Handling System Revamp (RSIMC)
Altamira Facilities Compressor Station
PErU
CAMISEA Pipeline Maintenance
UniTED STATES
Tenaris Bay City
UrUgUAy
Route 9
Maldonado Sewage System
Route 8
Consorcio Shushufindi
Shaya Ecuador
Électricité de France (EDF)
Abeinsa Juarez N III, S.A. de C.V.
Greenfield SPV I S.A.P.I. de C.V.
Infraestructura Marina del Golfo, S. de R.L. de C.V.
Compañía Operadora de Gas del Amazonas S.A. (COGA)
Tenaris Bay City Inc.
Corporación Vial del Uruguay S.A.
Obras Sanitarias del Estado (OSE)
Corporación Vial del Uruguay S.A.
Country / Project Client
65
79
35
574
39
87
260
46
44
70
10
MAjoR woRKS PER CouNTRy (cont’d.)
(a) Projects under a consortium/JV. The amount corresponds to total contract amount at 100%. See note 20 to the Consolidated Financial Statements. (b) The amount corresponds to annual revenues.
(b)
(b)
(a)
(a)
(a)
Contract Total Amount
(USD MILLION)
20 TECHINT E&C S.A. Annual Report 2017
During this period, the Company determined and carried out
different undertakings in the oil & gas field, pipelines as well as
infrastructure works for mining companies and other civil works.
Projects were developed from different offices around the world:
Mexico City
Quito
Regional Headquarter
Commercial & Operating Center
Engineering Center
Offshore Yard
Sao Paulo
Milan
Pontal do ParanaMontevideo
Buenos Aires
Lima
Santiago
Mumbai
Cairo
Techint E&C in the world
21Board of Directors’ Report
AFRICA
Al Shabab – Combined Cycle Power Plant - Phase II (Egypt) -
East Delta Electricity Production Company (EDEPC)
The contract includes the mechanical balance of plant for
conversion of the existing simple cycle to combined cycle
for the Al Shabab power plant, comprising two modules of
4 x 125 MW units, through the installation of heat recovery
boilers for the generation of steam and a steam turbine (250
MW) for each module.
The amount of the project is USD 41 million.
The Client is East Delta Electricity Production Company
(EDEPC), an affiliate company of the Egyptian Electricity
Holding Company.
The project was awarded in August 2015. As of December
31, 2017, the progress of works was approximately 99%. The
first unit was commissioned and the Taking Over Acceptance
Certificates (TOAC) of both units are expected to be released
by mid-2018.
Cost increases due to requests for changes by the Client,
delays in the schedule and the country’s economic crisis
(reflected in a sharp devaluation of the local currency in the
last quarter of 2017) have resulted in a deterioration of the
financials of the project. Negotiations are being held in order
to recover from impacts due to the country’s economic crisis.
west Damietta – Combined Cycle Power Plant – Phase II (Egypt) -
East Delta Electricity Production Company (EDEPC)
The contract includes the mechanical balance of plant for
conversion of the existing simple cycle to combined cycle for
the West Damietta power plant, comprising one module of 4 x
125 MW units, through the installation of heat recovery boilers
for the generation of steam and a steam turbine (250 MW).
The amount of the project is USD 30 million.
The Client is East Delta Electricity Production Company
(EDEPC), an affiliate company of the Egyptian Electricity
Holding Company.
The project was awarded in September 2015.
As of December 31, 2017, the progress of the works was
around 95% and the commissioning and release of the TOAC
is expected to occur by mid-2018.
Cost increases due to requests for changes by the client,
delays in the schedule and the country’s economic crisis
(reflected in a sharp devaluation of the local currency in the
last quarter) have resulted in a deterioration of the financials
of the project. Negotiations are being held in order to recover
from impacts due to the country’s economic crisis.
South Helwan - Supercritical Thermal Power Plant (Egypt)
The project involves construction works and the mechanical
balance of plant for the South Helwan supercritical
power plant, consisting of three units, with a capacity
of 650 MW each.
The project on which Techint Compagnia Tecnica Internazionale
S.p.A. is working is worth around USD 77 million.
The Client is Upper Egypt Electricity Production Company
(UEEPC), an affiliate company of the Egyptian Electricity
Holding Company. The construction activities are being
carried out at Beni Suef.
The project started in November 30, 2015 and works will be
completed by the end of 2018. The first unit is currently in
the commissioning process and the release of the third unit's
TOAC is expected to occur by the end of 2018.
As of December 31, 2017 the progress of the project was
approximately 81% for the construction of the three units.
For the fiscal year ended December 31, 2017
Techint E&C subsidiaries’ activities
22 TECHINT E&C S.A. Annual Report 2017
in Argentina, Techint E&C is in the final stages of the Subway line h Expansion project.
ARgENTINA
During the fiscal year, activities in Argentina were developed
by the argentinian subsidiaries TEARG, Sidernet S.A.
and Ferroexpreso Pampeano S.A. Concesionaria (FEPSA).
Subway line H Expansion - Subterráneos de Buenos Aires S.E.
(SBASE) / Ministerio de Desarrollo urbano (MDu)
On August 15, 2011, SBASE awarded to the Techint-Dycasa
S.A. Joint Venture (JV) (in which the Company holds a
60% participating interest) the integral construction and
commissioning in conditions of commercial exploitation of
the current Subway Line H of the City of Buenos Aires.
The project comprises civil and electromechanical works,
including tracks, power installations, pulling, signaling, commu-
nications, mechanical stairs, elevators and station equipment.
The suspension of works at Intendente Carlos María Alvear
Square (Plaza Francia Station), in addition to SBASE’s failure
to define certain aspects in the South tranche, have led
SBASE and the Joint Venture (JV) to execute a Memorandum
of Understanding (Acta Acuerdo) in December 2012. This
Memorandum of Understanding established a contractual
extension for an additional 24-month term (until April 2017),
and divided the works into two phases: Phase I until April
2015, including Córdoba, Santa Fe and Las Heras Stations
(with the related tunnel), Córdoba rectifier substation
(“SER”), C2 tranche tunnel up to post-Las Heras and
construction of a workshop in a cave under Parque Patricios;
Phase II, to be completed by April 2017, includes Plaza Francia
station (now, Facultad de Derecho station) and execution of
the post-Plaza Francia tunnel up to the end of C2 tranche,
Pompeya and Sáenz stations, with the respective tunnel, and
23Board of Directors’ Report
redetermination of prices performed in October 2017,
is equivalent to USD 491 million.
As of December 31, 2017, the project recorded 81%
progress.
Punta Negra Hydroelectric Power Station / Tambolar –
Energía Provincial S.E.
The contract was executed between Energía Provincial S.E.
(EPSE) and the Joint Venture (JV) formed by TEARG and
Panedile Argentina S.A., in which the Company holds a 75%
participating interest. This project is on the San Juan River,
20 km downstream Los Caracoles dam, and it is intended to
increase the regulation of this river, which is essential for San
Juan’s economy, and to add 65 MW to the generation system
of the Province.
In March 2015, an Addendum was executed to the Punta
Negra Contract for Works, whereby EPSE awarded the
Joint Venture (JV) formed by Techint Compañía Técnica
Internacional S.A.C.I. and Panedile Argentina S.A., the
preliminary works for the El Tambolar Hydroelectric Plant,
on the San Juan River, 25 km upstream Los Caracoles.
The scope of works includes basic and executive design
of the plant, settling of camp and construction site,
detail engineering and construction of tunnels for river
sidetracking and future bottom outlet. During this fiscal
year, the activities corresponding to drilling and concrete
lining of the river sidetracking tunnel were concluded.
Besides, the works for excavation of the mouth section of
such tunnel were commenced.
The updated contract amount is USD 98 million and the
works are scheduled to be completed in February 2019.
As of December 31, 2017, the works record a 83% progress.
y-gEN II – El BRACHo – general Electric International Inc.
The Project called Y-GEN II – El Bracho results from the
awarding of a contract by Compañía Administradora del
Mercado Mayorista Eléctrico S.A. (CAMMESA) to Y-GEN
(a Joint Venture between YPF S.A. and General Electric
the workshop-parking space in the alternative site located at
Av. Sáenz and Perito Moreno.
On December 23, 2016, a Memorandum of Understanding
(Acta Acuerdo) was executed to extend the term for
execution of the contract, not including the South Tranche
(A1), for an additional 20-month term (until December 2018).
In turn, on October 1, 2016, an Agreement for Provisional
Neutralization of Execution Terms Tranche A1 (Acta de
Neutralización Temporal de Plazos de Obra Tramo A1) was
executed (comprising Sáenz station with the respective
tunnel), effective until September 2017, in order to agree upon
the price and term of this project. As of the date of issue of
this annual report, there is a preliminary agreement as to the
price and term of the works but the Government of the City
of Buenos Aires (GCBA) requested the JV to seek financing
for execution, and the relevant actions are being currently
taken to such effect.
On the other hand, during this fiscal year, the Company obtained
the Provisional Acknowledgements of Receipt for Córdoba,
Santa Fe and Las Heras stations (with the related tunnel),
Córdoba rectifier substation (“SER”), C2 tranche tunnel up to
post-Las Heras, Workshop I and the Parking space in a cave
under Parque Patricios. In turn, the Final Acknowledgements of
Receipt were obtained for Parque Patricios Workshop I and the
Honda Building. As of the date of issue of this annual report,
the relevant steps are being taken for signature of the Final
Acknowledgments of Receipt for Córdoba, Santa Fe (partial)
and Las Heras stations with the related tunnels. In addition,
the applicable files were executed and approved for new prices
approved by SBASE, and for acknowledgement of longer of
permanence and additional works.
The Company continued with execution of Facultad de
Derecho station (and related tunnels), which replaces the
original Plaza Francia station, the Parque Patricios Workshop II
and the 40-meter Tranche A1 Pre-Hospitales.
The amount of the contract, including the above-stated
Memorandum of Understanding and based on the latest
24 TECHINT E&C S.A. Annual Report 2017
International Inc. Sucursal Argentina) for the assembly of
a turbo generator to be added to existing generators. This
project comprises civil works, electromechanical assembly
and pre-commissioning of both the power island and the
balance of plant. Such generator shall provide 260 Mw to the
Argentine Interconnection System (SADI).
On November 18, 2016, TEARG submitted an offer for
USD 26 million to General Electric International Inc.
Sucursal Argentina (GE) to execute the civil works and
electromechanical assembly of such facilities. The materials
and the engineering services were provided by GE. During
execution of the works, the Company received instructions
and changes with respect to the original project resulting
in an increase of the contract amount of USD 7 million.
Finally, the construction stage was completed in December
2017, and it is estimated that the Company shall continue
providing the client only with assistance for start-up. The
plant started to commercialize energy during January 2018.
As of December 31, 2017, the project recorded 100% progress.
gNEA - Energía Argentina Sociedad Anónima (ENARSA)
On August 5, 2014, the contract was executed between
Energía Argentina Sociedad Anónima (ENARSA) and the
Joint Venture (JV) Techint-Panedile Argentina S.A.I.C.F. e I.
(where the Company holds an 80% participating interest).
This project involved the execution of engineering,
equipment provision (except for piping) and construction
of Cycle 2 of the gas pipeline called Gasoducto Noreste
Argentino (GNEA).
The scope of the contract includes the installation of the
gas pipelines, approximately 303 km long, the provision and
installation of scraper traps, the provision and installation
of line block valves and by-passes to future compression
plants, the provision and installation of a measurement
and regulation station to supply the following locations:
Ing. Guillermo Juárez, Chiriguanos, Laguna Yema, Pozo del
Mortero, Juan G. Bazán, Las Lomitas, Pozo del Tigre and E.
del Campo, and the provision and laying of optic fiber.
The contract amount is around USD 199 million, according
to the latest redetermination of prices corresponding to
October 2016. As from November 2016, paid services
related to custody and basic maintenance of the facilities
started to be provided.
During this fiscal year, this project was completed and the
services related to custody are still to be concluded.
ENAP - Magallanes Area Incremental Project – Enap Sipetrol
Argentina S.A.
On March 31, 2016, Enap Sipetrol Argentina S.A. – YPF S.A.
UTE (JV), accepted the offer submitted by TEARG under
Bidding Process “AMBA 010/2015 PIAM”, the purpose of
which is to increase the extraction of gas from the fields
located in the south of the Republic of Argentina.
TEARG, subject to the framework of the contract awarded,
shall provide detail engineering, procurement management,
construction, commissioning and start-up services for the
onshore works, as well as the construction management for
the offshore works.
The most relevant onshore activities are as follows:
New compression plant.
Ancillary installation facilities required.
Revamping of the plant located at Cape Vírgenes lighthouse.
Battery-based fuel gas pipeline at the reception of Magallanes
Area (Magellan Area).
Gas pipeline for export and connection to the General San
Martin gas pipeline.
The offshore activities include, among others:
A 20-km pipelay of a 14" offshore gas pipeline.
Land/sea interface of the pipeline (shore approach).
As an additional work, the Project includes the sea layout of 6"
and 8" pipelines between sea platforms, along a length of 20 km.
The Client has estimated an investment of around USD 123
million for the execution of the works.
>
>
>
>
>
>
>
25Board of Directors’ Report
Techint E&C is working on Fortin de Piedra’s surface facilities, located in the Vaca muerta shale field for Tecpetrol.
As of December 31, 2017, the Project recorded around
100% progress, and for early 2018 the only works
pending were the ties in connections, the revamping
of the plant at the Cape Vírgenes lighthouse, and
demobilization.
Fortín de Piedra – Tecpetrol S.A.
On July 21, 2017, TEARG accepted the offer from Tecpetrol
S.A. for the rendering of engineering, construction and
procurement services, among other services, for the Fortín
de Piedra area, located in the Province of Neuquén. This
Project is part of the development of the Vaca Muerta area,
the second unconventional gas reservoir in the world. Works
comprise the design and construction of surface facilities for
extraction, treatment and evacuation of gas produced
by Tecpetrol S.A. These works would allow processing
16.5 million of cubic meters per day.
Works shall be performed on platforms and flowlines,
batteries, trunk lines, Early Process Facilities (EPF),
Central Process Facilities (CPF), export pipelines, water
intake, filtering, storage and injection well.
The main contractual challenge is the short term for
intermediate milestones since this is a fast-track project.
Therefore, within only six months, it was required to
increase the EPF capacity from 750 thousand to 1 million
cubic meters per day.
26 TECHINT E&C S.A. Annual Report 2017
The contract amount is approximately USD 392 million, and
completion is scheduled for February 2019.
As of December 31, 2017, the project recorded around 25%
progress out of the total works.
looP yPF – Rincón del Mangrullo – loma de la lata 16"
gas Pipeline
On May 15, 2017, TEARG entered into a contract with YPF
S.A. for construction of a 16” and 33.3 km gas pipeline,
including the related surface facilities. The project is carried
out in the surroundings of Añelo, Province of Neuquén,
and is part of the development of unconventional gas
projects in the Vaca Muerta area.
The contract amount is USD 11 million, and completion is
scheduled for January 2018.
As of December 31, 2017, the project recorded 89%
progress.
Carem25 – Comisión Nacional de Energía Atómica (CNEA –
Argentine Atomic Energy Commission)
This project called CAREM 25, is the result of the project
awarded by the Argentine Atomic Energy Commission
(CNEA) to TEARG for completion of the civil works necessary
for assembly of the prototype reactor CAREM 25 in Lima,
Province of Buenos Aires.
On July 10, 2017, a contract was executed for USD 60
million, for a term of 25 months which was extended
to 32 months due to delays by the client in the delivery
of some part of the site.
Completion of the project is scheduled for March 2020.
As of December 31, 2017, the project recorded 2% progress.
genelba Plus – Pampa Energía S.A.
On October 25, 2017, the contract was executed with Pampa
Energía for the project involving the expansion of installed
capacity in the Genelba Plus combined cycle of the Thermal
Power Plant located in Marcos Paz, Province of Buenos Aires.
Upon completion of the expansion, the power plan shall
go from an installed capacity of 178 Mw to 542 Mw. The
contract with the Company comprises detail engineering,
procurement for Balance of Plant, construction and assembly,
commissioning and start-up.
The works include the incorporation of a heat recovery steam
generator (HRSG) to the existing gas turbine, an additional
gas turbo generator with a power of 172 Mw, and the
respective HRSG, and a steam turbo generator with a power
of 192 Mw. Besides, the Company shall execute the Balance
of Plant facilities and supplementary works.
The contract amount is USD 191 million for a term of 32
months. Field works shall be commenced in February 2018,
with an intermediary milestone for start-up of the new gas
turbine in June 2019. It is estimated that 550 people shall
work during the peak of the works.
As of December 31, 2017, the project recorded 1% progress.
Rotating Filters Partial Rehabilitation Service – Central
Costanera S.A.
In August 2017, a contract was entered into between Central
Costanera S.A. and TEARG, for an amount of USD 1.5 million.
The scope of works contemplates the replacement of two
rotating filters at the intake of cooling water of combined
cycle II of the plant located at Costanera Sur of the City of
Buenos Aires, under an EPC contract.
Engineering works mainly include the design of routings for
new electricity ducts, changes of civil works to be executed
at the bases of existing filters, the design of a new electrical
box where dashboards shall be installed for operation
of new filters. Central Costanera S.A. shall be liable for
the supply of the main equipment (water filters). Other
materials required to complete the project shall be provided
by the Company (ducts, cables, materials for construction of
electrical box, etc.).
27Board of Directors’ Report
The company is working on a 33.3 km-long 16" gas pipeline for yPF S.A. in neuquén, Argentina.
At the end of the fiscal year, the works of the electrical box
and on the first filter were completed and in operation. The
duct works for the second filter are about to be finished, the
only pending works are the connections to equipments and
a minor duct that requires to stop the filter in order to be
executed. The project suffered some delays since the Client
did not release the second filter to execute the works which
were commenced on March 12, 2018.
The estimated date for completion of the project is April 2018.
As of December 31, 2017, the project recorded 79% progress.
Ternium Argentina S.A. (formerly known as Siderar S.A.I.C.)
(Plant San Nicolás)
The main works executed during 2017 include the following:
Works were executed in the Steel-making area in order
to reduce the emission of gases and particles to the
environment. Other works were also performed, such
as the following:
In Converters (Fluxing Revamping, vibros were replaced
and changes were made in the capacities
of the addition system; besides, progress is being
made in assembly of the equipment of the ferroalloy
addition system.
Improvements in operation and maintenance of sludge
separation.
In the Continuous Casting area, works comprised the
replacement and improvement of bridge cranes in
the Descaling Section and the assembly of the second
carrier in pantographs 1 and 3.
>
>
>
28 TECHINT E&C S.A. Annual Report 2017
In October 2017, the Plant Extraordinary Repair (REX) was
conducted in the Hot Rolling Mill area. The main works were
as follows: repair of walking beam of winder 1, replacement of
engines of F8, F9 and F10, replacement of drives of F8, F9 and
F10, installation of combibox of F8, installation of hardware,
changes of roughing and finishing mill pulpits, assembly of
drives in combustion fans and assembly of drive of furnace 5
cooling system, shutdown and start-up of heating furnaces.
Other projects were executed for improvement of
environmental and safety aspects at the plant:
Closing of gases washing circuit of Blast Furnace 2.
Evacuation of Sinter runoffs.
Installation of a gas extraction system by pouring remaining
slag in steel thermal wagons.
Total income of the fiscal year for these services amounted to
USD 29 million, with a total of 1,250,000 man-hours used.
Siderca S.A.I.C. (Plant Campana)
Fiscal year 2017 started with the Plant Extraordinary Repair
(REX), which works were executed during January and February.
Even though during 2016 the plant showed little activity in
production and investments, these REX works constituted
the starting point of several actions and repairs with a view
to a future increase in production.
In January and February 2017, 138,000 man-hours were
certified, a 97.5% increase against the same period of the
previous year.
in Argentina, Techint E&C executed TenarisSiderca’s annual Extraordinary repair (rEx).
>
>
>
29Board of Directors’ Report
The Company maintained and applied the action plan
agreed upon with Siderca S.A.I.C. in 2016, in order to
readjust costs and rates. This action plan to reduce fees
and rates included the following items:
Use of idle equipment at the plant rather than using the
Company´s own equipment.
Readjustment of supervision sale categories.
Increase of the chiefs/workers ratio, i.e. adopting a
scheme where every chief would have more people
reporting to him/her.
Streamlining of the support structure (reduction of houses
for people without a family, new supplier of packed food,
new health-care provider, etc.).
Tenders and works under lump sum modality were
conducted at the client’s request.
With the new scheme of fees and rates, the Company
executed maintenance and service tasks which gave rise to
a higher need of resources. Thus, we were able to recover
gradually the regular activity levels of the project.
Throughout the year, the level of activity was sustained,
with a distribution of works of 70% for maintenance and
services, and 30% for the engineering area.
Total income of the fiscal year was USD 11 million and
417,000 man-hours were used.
Acid Regeneration unit – Ternium Argentina S.A.
(Ensenada Plant)
On September 22, 2017, the Company was awarded by
Ternium Argentina S.A. the execution of the assembly
of shed and electromechanical works necessary for
connection to the existing stripping of the New Acid
Regeneration Unit to be installed at the plant located in
Ensenada, Province of Buenos Aires, of the company
Ternium Argentina S.A. The project includes pre-
commissioning and start-up assistance works.
The initial milestone of the project is the subcontract for
premanufactured piping and structures, followed by the
mobilization of personnel, equipment and installation
of working sites.
The execution of the works comprises the installation
of the following elements: 272 tons of equipment,
180 tons of refractory material, 855 tons of structures,
120 tons of piping and 42,000 m of wiring.
The total contract amount is USD 19 million. The
execution term is 18 months and, as of the end of the
fiscal year, the works recorded 4.1% progress.
veladero F2 Maintenance Project – Minera Argentina
gold S.A.
On February 27, 2014, a Service Master Agreement
was executed between Minera Argentina Gold S.A.
and Techint Compañía Técnica Internacional S.A.C.I.
for an 18-month term, for the provision of design,
engineering, procurement, construction, construction
management, pre-commissioning and other related
services within Veladero Mine, located in San Juan,
approximately 370 km away from the capital city of
such province.
In October 2016, an addendum was signed on the
same Service Master Agreement entered into in 2014,
extending it up to December 31, 2017. In that same
month, the Client requested a series of engineering
works, within its plan for maintenance of the facilities.
In July 2017, the Company was awarded by the Client
work orders for construction, which are in progress
at present, and they comprise the construction of the
pumping system Booster Barren II, the early works of
continuous retort and the disassembly and assembly of
the new silo Surge Bin.
At present, the Company is reviewing several minor
proposals made by the Client regarding engineering
and construction within the plan of maintenance and
improvement of processes currently in progress.
>
>
>
>
>
30 TECHINT E&C S.A. Annual Report 2017
SERVICES
Cargo Railway Transportation
Ferroexpreso Pampeano S.A. (FEPSA) Concession Company,
a firm under the control and corporate decision of the
Company through COINFER, is the holder of the cargo
railway transportation concession providing services towards
the ports of Bahía Blanca, Rosario, San Lorenzo and San
Martín to exporters, storage companies and large producers
of a vast area of the wet pampas region.
During the fiscal year started January 1st and ended
December 31, 2017, 3.5 million tons were transported,
accounting for a 17% decrease against the figures of 2016,
as a consequence of significant floods in the northeast of
Buenos Aires and south of Santa Fe, which affected the
railroad infrastructure.
On September 20, 2016, FEPSA exercised the option laid down
in the contract and requested the extension of the concession
for a 10-year period as from its completion in November
2021, and the Grantor had to resolve on such request within
a term of (1) year. Taking into account that Law 27132 and
its regulation are still being drafted, they would impact on
the terms of the concession contract in force, and by virtue
of the imminent due date for the term established for the
Grantor to make a resolution on the request for an extension,
on September 18, 2017, FEPSA entered into a Memorandum
of Understanding (Acta Acuerdo) with the Argentine Ministry
of Transportation, whereby the parties agreed to extend the
term contractually established for the Grantor to resolve on the
request of an extension made by FEPSA, which term shall be
deemed extended until the Argentine Executive had passed
the Regulatory Executive Order for Law 27132.
The Act on Railway Reactivation for Passenger and Cargo
Railroads (Law 27132) passed in April 2015, has not been
regulated yet. Based on the content of such Act and given
the fact that the definition of the regulatory framework is still
pending, the potential effects that these changes might have
are still uncertain. Notwithstanding the above, in our opinion,
there are no elements that need to be considered and
reflected in the Company’s Financial Statements.
Tecnología en Servicios urbanos TESuR S.A.
Tecnología en Servicios Urbanos – Tesur S.A. (TESUR) started
doing business in the 1990’s as one of the business units
of TEARG, which company holds an indirect participating
interest of 87.75% through Tefin S.A.
The sustained development of the telecommunications
area enabled TESUR to focus its specialization, taking part
in engineering, construction and management projects and
rendering integrated services of land telephone lines, optic
fiber networks, infrastructure for mobile phones, localization
and construction of communications sites, FTTH (fiber to
the home), Data Centers and development of Integrated
Communication Solutions.
In turn, for more than two decades, TESUR has developed
vast experience in projects comprising civil, railroad, power
and fresh water network projects, as well as repairs,
constructions and miscellaneous maintenance works.
In the telecommunications area, during this fiscal year,
TESUR completed the execution of a contract with Empresa
Argentina de Soluciones Satelitales S.A. (ARSAT) for
construction of the laying for optic fiber, and the Provisional
Acknowledgment of Receipt is currently in progress.
Under the master agreement with Telefónica Móviles
Argentina S.A. (Movistar), the Company continued civil and
electromechanical works inherent in the implementation of
new technologies for voice and data networks.
TESUR continued with the execution of the master
agreement for Telecom Argentina S.A. in the Province of
Córdoba, consisting in the construction of networks for optic
fiber, fiber to the home (FTTH), outside plant, installation of
clients and network expansion.
As regards civil and railroad works, TESUR is about to receive
from the Client the Final Acknowledgement of Receipt for
the works comprising the replacement of rails and sleepers
of Ferrocarril General Roca, Vivoratá-Mar del Plata, and
the construction of a new tracks between Camet and Mar
31Board of Directors’ Report
del Plata, under a Joint Venture (JV) with Panedile S.A. for
Administración de Infraestructuras Ferroviarias S.E. (ADIF).
Also in the railroad area, under a JV with Siemens S.A.,
TESUR was awarded the works corresponding to Bidding
Process BID 2982/oc-AR-O-LPI 02/2014, for the construction
of a substation, switching stations, self-transformation and
tele-command for Ferrocarril General Roca, Constitución
- La Plata branch, entrusted by the Central Execution Unit
(Unidad Ejecutora Central - UEC) of the Argentine Ministry of
Transportation.
The JV TESUR-Panedile was awarded the works
corresponding to Bidding Process LPI 01-ADIF-2016 called
for by ADIF, for the Project of Recovery and Improvement
of Ferrocarril General Belgrano – Total renewal of the
infrastructure of tracks in tranche 5, Sector “A” (km. 211,340
to km 275,479) and in National and International Public
Bid ADIF LP 49-2016 called for by ADIF, for the Project of
Recovery and Improvement of Ferrocarril General Belgrano –
Total renewal of the infrastructure of tracks in Sector B (km
37,900 to km 83,900) in the Province of Santa Fe.
Under a Joint Venture (JV) with Panedile S.A. and Siemens
S.A., TESUR was awarded the works for National and
International Public Bid ADIF 80/2016, for modernization,
renewal and expansion of the rail yard at Estación Retiro
of Ferrocarril General Mitre, and integration with Ferrocarril
General San Martín. The contract with the Client was entered
into on November 14, 2017.
The lP-80 project includes the redesign of the current railroad configuration to optimize operations at the head of line in retiro, the country’s busiest railway station.
32 TECHINT E&C S.A. Annual Report 2017
Impripost Tecnologías S.A.
Impripost Tecnologías S.A. (“IMPRIPOST”) provides
services of data processing, variable printing,
digitalization, finishing and distribution with a high
added valued for telecommunication and internet
companies, cable providers, utility companies, bank
entities and municipalities.
For the past 19 years, this company has been owned
by Techint on a 50/50 basis with Grupo Clarín, to
provide technological solutions in the document and
information market since it counts on professional,
technical and specialized human resources.
IMPRIPOST is one of the two absolute leaders in
this market.
BRAZIl
TEBRA and its subsidiaries perform activities related to
engineering, construction, erection, project management,
petrochemical facilities, offshore projects, power generation,
transmission and distribution, iron and steel units,
transportation systems and infrastructure works in general.
During the current year, works were performed in the
following projects:
Modules for P-76 Platform – Petrobras Netherlands B.v.
In April 2013, a contract was executed with Petrobras
Netherlands B.V. (PNBV) for the construction of modules and
integration of such modules for Platform FPSO Petrobras-76
(P-76) to be installed by the client in the Santos Basin off-
shore area, approximately 210 kms. from the brazilian shore,
in Brazil, the FPSo (Floating Production, Storage & offloading) P-76 project for Petrobras is reaching the end of the construction stage at the Techint offshore Unit.
33Board of Directors’ Report
with a production capacity of 150,000 barrels/day (oil) and 7
MM3/day (gas).
The contract modality is lump sum EPC Turn-key, and
includes FEED endorsement, detail engineering, supply of
materials and partial supply of equipment, manufacturing,
construction and assembly of the elements for the modules,
and integration of such modules to the hull. The contract also
includes conditioning and commissioning, inclination tests,
transportation from worksite to the entrance to Paranaguá
Bay, pre-operation, start-up and certification of the Platform.
In 2015 engineering and procurement works are carried
out in the city of Rio de Janeiro, and the construction
and integration works are executed at the yard owned by
TEBRA in Pontal do Paraná, State of Paraná, which was
properly conditioned for execution of this project.
In 2016, engineering and procurement works achieved 100%
progress, and were concluded. Construction and erection
works continued to be performed at the yard, in Pontal do
Paraná, with nearly 4,000 employees. In July 2016, the hull was
delivered by PNBV, and from September to December 2016,
the lifting of the modules was successfully performed, and
then, the integration phase of the Project was commenced.
Until May 2017, TEBRA was part of the TTP-76 JV with
Technip, with a 50% participating interest each partner,
under the leadership of Technip.
On June 1st, 2017, the Company signed a contract of
assignment of contractual position with Technip whereby
Technip ceded its interests, resulting a participation of 99%
to TEBRA and 1% to Techint Oil and Gas Ltda.
In 2017, the integration and commissioning phases continued
to be performed at the yard, in Pontal do Paraná. In June 2017,
an amendment to the main contract was executed, including
additional procurement, construction and assembly services
regarding the Hull remaining scope (Carry-over, Packages
1 and 2), which resulted in a change in both the contract
amount and its term.
In December 2017, the contract amount was USD 889 millon,
and it is estimated that works will be completed in 2019. As of
December 2017, the general progress of the project was 82%.
Projet Ferro-Carajas S11D – vAlE S.A.
This contract consists in implementing the assembling of
a Truckless Mining System, which results in a reduction of
waste and costs, by using movable equipment to replace iron
ore transportation trucks. Two packages have been tendered,
one inside the mine and the other outside the mine; the latter
is the one to be executed by the Company, and consists in
the provision of services for the electromechanical assembly
of several structures and equipment.
On April 17, 2015, TEBRA was awarded by VALE S.A. with the
contract for execution of electromechanical assembly regarding
the S11D Truckless System, areas 1082, 1083, 1084, 1085,
4000 and 4013, located in Canaã dos Carajas, State of Pará.
In 2016, the construction site had nearly 2,000 employees
working in the assembly of major conveyor belts and mobile
tripper spreaders. An important milestone was completed
in 2016: the conclusion of mechanical assembly and
commissioning activities of area 1085, Iron Ore System.
As of December 2017, the contract amount is USD 124 million
and the general progress is 100%.
CHIlE
Works have been executed in the following projects:
Escondida water Supply (EwS) Project – Betchtel Chile limitada
Bechtel Chile Limitada invited Techint Chile S.A. to participate
on a jointly basis in the construction of part of the project
called “Escondida Water Supply Project” (EWS Project), for
the client Minera Escondida Limitada. This project is managed
by Bechtel Chile Limitada. For such purposes, the companies
became associated, and TECHI holds a 40% participating
interest. In December 2013, two contracts were executed.
One construction contract for the execution of two parallel
42" water pipelines, 177 km long each one; three pumping
stations; three electric substations located at the site of each
34 TECHINT E&C S.A. Annual Report 2017
one of the three pumping stations; a 220 KV high voltage
line; two 36" water pipelines for distribution to the mine,
with a total length of 23 km; and a reservoir. The purpose
of the other contract is to provide engineering services,
procurement and other related services, including the sale
and lease of machinery, tools and equipment for the project.
As of December 31, 2017, the works had been completed
in full. Both contracts amounted to USD 786 million.
los Bronces Duct Replacement (High area) –
Anglo American Sur S.A.
In October 2016, Techint Chile entered into contract No.
P16.0050-1 “Assembly of Piping 16 – High Zone Tailing
Transportation System, with quality assurance”, with the client
Anglo American Sur S.A.
The work consists in replacement of 3.3 km of piping
from San Francisco Thickener to Ortiga Tunnel Exit, which
comprises 970 m. of buried piping in external platform and
2,400 m. in internal supports of the Tunnel and exit of the
Pressurized Distributor. The works will contemplate the
intervention of walls and anchor nipples, in addition to other
specific works such as road crossing, Confluence Bridge
crossing and removal of existing piping.
On October 26, 2017, the client executed the provisional
acknowledgement of receipt and, as of December 31, 2017,
the project was fully completed. The final contract amount
was USD 13 million.
los Bronces Duct Replacement (Middle area) –
Anglo American Sur S.A.
On October 23, 2017, the Company executed a lump sum
contract plus unit price (P17.0050-1), called “Assembly
of 11 km and 1.6 km of piping (16"/24") - Mining Tailings
Transportation System and SAR at Medium Zone, with quality
assurance” with Anglo American Sur S.A.
This project comprises the continuation of works for
replacement of pipes, now at the medium zone, for the
mining tailings transportation system, from the Ortiga Tunnel
Portal to the Barros Negro mountain area, with 16" piping
along 11 km and 24" piping along 1.6 km, in addition to
implementing a By Pass and interconnection of valves with
the Waste Water System lines.
As for December 2017, the project recorded a 10.4%
progress, and the contract amount was USD 28 million.
Escondida water Supply Expansion (EwSE) -
Minera Escondida limitada
It is reported that on March 8, 2018, the Company was
awarded by Minera Escondida Limitada the Construction
Contract CC002, “Water Conveyance Construction and
Assembly” No. 8500138203, which corresponds to one
of the 3 contracts that are part of the Escondida Water
Supply Expansion (EWSE) Project, owned by Minera
Escondida Limitada.
The EWSE Project is intended to increase the capacity
of the desalination plant and drive system that were part
of the Escondida Water Supply (EWS) Project concluded
by the end of 2016, in which the Company took part
under a consortium with Bechtel Chile for the construction
of part of such project.
The Construction Contract awarded to the Company
comprises the installation of 6 pumps at each one of
the existing pumping stations, a power transformer,
the expansion of the bay at the GIS of each Substation
and the construction of a 14-km long and 36" wide
distribution pipeline. The works shall be developed at the
pumping stations, the existing substations of the pumping
system and within the location of Minera Escondida, in
Region II of Antofagasta, at a site higher than 3,500 meters
above sea level.
The effective term of the Contract is 534 days as from
commencement, and the contract amount is USD 65 million.
ECuADoR
Shushufindi Services – Consorcio Shushufindi
The Company, through its subsidiary Construcciones y
35Board of Directors’ Report
Prestaciones Petroleras S.A. (CPP), renders specialized
technical services of engineering, procurement and
construction in the Shushufindi-Aguarico field, Province of
Sucumbíos, in Eastern Ecuador, for the client Consorcio
Shushufindi (a JV formed by Schlumberger, 75% and
Tecpetrol, 25%), a project that is intended to increase
production in the whole field.
During 2017, CPP has performed the following activities in
Shushufindi: construction of 5 km of 13.8 kVA electricity lines,
5 km of 34.5 kVA electricity lines, 4 km of 69 kV electricity
lines and 5 complementary projects for the improvement of
facilities in the main stations in the field. These works were
certified during this fiscal year for the sum of USD 65 million.
Auca Services – Shaya Ecuador
The Company, through its subsidiaries Construcciones
Globales Andinas CGA S.A. (CGA) and Construcciones y
Prestaciones Petroleras S.A. (CPP), renders specialized
technical services of engineering, procurement and
construction within the Auca Oil Fields (Bloque 61), Province
of Orellana, in Eastern Ecuador, for the client Shaya Ecuador
(a subsidiary of Schlumberger), a project that is intended to
increase production in the whole field.
During 2017, CGA and CPP have performed the following
activities in Bloque 61: construction of 1 new well platform,
and improvements in 15 well platforms, resulting in 35 new
producing wells in the field, execution of 4.2 km of intra-field
pipelines (diameters between 6” and 8”, for oil and water),
procurement of electrical equipment for existing platforms,
1 project for water injection facilities, and 9 complementary
projects for the improvement of facilities in the main stations
in the field and platforms, and some minor works and
engineering works for 2017 and 2018 projects.
These works were certified during this fiscal year for the sum
of USD 79 million.
Techint E&C is working on the replacement of pipelines at the Chilean los Bronces copper and molybdenum mine.
36 TECHINT E&C S.A. Annual Report 2017
EuRoPE AND CoMMoNwEAlTH oF INDEPENDENT
STATES (CIS)
Projects developed by Techint Compagnia Tecnica
Internazionale (TEMIL) and their subsidiaries:
Dunkerque lNg (France) - Électricité de France (EDF) -
Fast Reloading Project
On January 28, 2016 a contract was signed for the fast
Reloading at the LNG terminal in Dunkerque, France. This is
an engineering, procurement and construction (EPC) contract,
under an LSTK formula, for the expansion of the terminal,
which is in the final phases of completion, to increase the
LNG reloading capacity of the carriers from the current
4,000 cubic meters per hour to 8300 cubic meters per hour.
It mainly includes the installation of another Boil-Off Gas
Compressor and the replacement of the 8 low pressure
in-tank pumps in two of the three existing tanks, in addition
to the related ancillary services and utilities, and all the
necessary civil, mechanical and electrical works required.
The amount of the contract is USD 35 million, and as of
December 31, 2017, the progress of construction works was 56%.
The execution of the Electro-Mechanical Tie Ins is scheduled
to take place during the plant shutdown starting on August
4, 2018, simultaneously with shutdown needed to replace
the Flare. The Company is analyzing with its Partner
(Sener), the recognition of an incentive plan parallel to
the one signed with the end client for an amount equal
to USD 1.9 million.
Pursuant to the contract, the completion and the issue
of the Taking Over Certificate (TOC) are estimated to occur
in October 2018.
in mexico, the company has started to work on the Altamira Compression Station project.
37Board of Directors’ Report
MÉXICo AND NoRTH AMERICA
MEXICo
In this year, the Company’s subsidiary in Mexico, Techint S.A.
de C.V. jointly with its subsidiaries (TEMEX), has consolidated
its ongoing projects and continues working on the development
of new business lines.
The main projects executed during the period are the following:
Combined Cycle Power Plant Norte III - Abeinsa juarez N III,
S.A. de C.v.
This project includes engineering, construction, supply
management, procurement and commissioning of a
Combined Cycle power plant in two 2TGx1TV modules with a
minimum power of 906 MW in Ciudad Juárez, Chihuahua.
The contract amount for this project is around USD 574
million with a term of 27 months. As of December 31, 2017,
the overall progress of the project was 5%.
Internal Coal Handling System Revamp (RSIMC) -
greenfield SPv I S.A.P.I. de C.v.
The contract consists in the revamp of current facilities with
a view to increasing the coal transportation capacity from
1,300 ton/h to 1,800 ton/h in the President Plutarco Elías
Calles Power Plant. The scope includes engineering, supply
management, construction, commissioning and performance
testing of the new facilities.
The contract amount for this project is around USD 39 million
with a term of 17 months. As of December 31, 2017, the
overall progress of the project was 0%.
Altamira Facilities Compressor Station – Infraestructura Marina
del golfo, S. de R.l. de C.v.
The project consists in engineering, procurement and
construction works for a compressor station of 135,000 HP
(3+0) with a measuring station within the same location in
Altamira (Tamaulipas). This project is part of Gasoducto Marino
Sur de Texas. This contract was signed in November, 2016.
The contract amount for this project is around USD 87 million.
As of December 31, 2017, the overall progress of the project
was 42%.
Construction works - Ternium de México S.A. de C.v.
This contract comprises professional services for placement
of personnel and materials for the execution of construction
works (including civil and electromechanical works) and
structure mounting.
Additionally, TEMEX executed different works in Ternium
plants all over Monterrey city.
As of December 31, 2017, in this contract, TEMEX had around
678 people working on a direct basis.
Construction works – Tubos de Acero de México S.A. de C.v.
This contract comprises professional services for placement
of personnel and materials for the execution of construction
works (including civil and electromechanical works) and
structure mounting.
As of December 31, 2017, TEMEX had approximately 384
people working in this project on a direct basis.
Heavy Duty Cleaning Service – Tubos de Aceros de México S.A. de C.v.
The cleaning service has been provided through Sidernet S.A.
de C.V. since April 2005 and it comprises the reception of raw
materials in the scrap yard, transportation and processing of
slag, and the recovery, cutting and classification of metal junk.
As of December 31, 2017 TEMEX had approximately 153
people working in the project.
Petacalco Project, Maintenance and operation Contract -
Comisión Federal de Electricidad (CFE)
Carbonser, S.A. de C.V., 50% of which is owned by TEMEX,
was established on August 8, 1994, and its main activity is
to provide services for loading and transportation of coal
from Lázaro Cardenas port to President Plutarco Elías Calles
Power Plant, located in Petacalco, Guerrero.
During this fiscal year, the Company unloaded 7.0 million tons
of coal and delivered 6.6 million tons.
38 TECHINT E&C S.A. Annual Report 2017
uNITED STATES
Tenaris Bay City – Tenaris Bay City Inc.
The project is located in Bay City, in Matagorda County,
Texas, and comprises a seamless tubing manufacturing
facility for the fabrication of seamless tubes in the range
of 114.3 – 244.5 mm in diameter (4 ½" to 9 5/8"), and
wall thickness from 5.7 to 25.4 mm, with a capacity
to produce around 600,000 tons/year, for the Tenaris
OCTG line of products.
During the first quarter of 2014, the Company’s subsidiary
TEMEX was awarded a contract to participate in the
Tenaris Bay City project, providing key and specialized
personnel.
The total amount of the contract is USD 46 million and,
as of December 31, 2017, the overall progress was 100%.
PERu
Sales by TESAC, the Company’s subsidiary in Peru, have
gone down relative to previous periods.
The most outstanding project executed during the period
is the followings:
Camisea Pipeline Maintenance – Compañía operadora de gas
del Amazonas S.A. (CogA)
The maintenance service for this gas pipeline is provided
by the joint venture “Consorcio para la Atención y
Mantenimiento de Ductos del Peru” (AMDP Joint Venture)
formed by TESAC (50%) and GyM S.A. (50%).
This joint venture was set up on December 18, 2015 with the
exclusive purpose of negotiating, signing and executing the
contract with Compañía Operadora de Gas del Amazonas
S.A.C. (COGA) to provide the service and maintenance of the
natural gas (NG) and natural gas liquids (NGL) transportation
system. In December 2015, this contract was awarded to
ADMP Joint Venture for a period of 60 months and for an
amount of USD 213 million. Subsequently, the contract
amount was updated due to a reduction in scope to USD 210
million. However, additional works for USD 50 million were
included, thus increasing the total amount of the contract to
USD 260 million. The project recorded a 52% progress as of
December 31, 2017.
On March 13, 2018, the Company signed a contract of
assignment of contractual position with GyM S.A. whereby
GyM ceded 49% to Techint SAC and 1% to TEURU of its
participation in the ADMP Joint Venture.
uRuguAy
During the fiscal year, revenues increased if compared to
those of the previous fiscal year.
The works developed in road, water and civil projects were
as follows:
Maldonado Sewage System – obras Sanitarias del Estado (oSE)
The Company continued with the sanitation works under the
contract with OSE. This contract, executed under a JV formed
by TEURU, Techint Compañía Técnica Internacional S.A.C.I.
Uruguayan Branch (TEARG Uruguayan Branch), Montec and
Belfi (grouped under a typical JV structure), was divided into
two phases: (1) land works to be executed by the JV TEARG
Uruguayan Branch, 53%, and TEURU, 47% comprising:
35 km of pipes, 1 land outfall of 4 km and civil and architecture
works in 7 pumping stations, and (2) one off-shore outfall
to be executed by the JV Montec (50%) and Belfi (50%).
Each one of the Companies under the JV undertook total and
exclusive liability for execution of their portion of the works.
During 2016, works were resumed for Sanitation Maldonado
pursuant to the new extension of contract LPI 1393,
awarded under Board of Directors’ Resolution No. 1624 of
December 28, 2015. The amount of the extended works
reaches USD 8 million. Works focused on the extensions
for connection of the neighborhood La Capuera, consisting
in laying 15 km of tubing, and two pumping stations at La
Capuera and Solanas. In these works, TEURU holds a 99%
participating interest, and TEARG Uruguayan Branch holds a
1% participating interest.
39Board of Directors’ Report
The total amount of this project as of December 31, 2017,
is USD 70 million and works recorded 97% progress.
Route 9 – Corporación vial del uruguay S.A.
TEURU was awarded by Corporación Vial del Uruguay S.A.
with works for the Reinstatement and Maintenance by
service levels of Route 9, Pan de Azúcar – Rocha section. The
original contract was for USD 19 million, and such amount
was increased due to the awards of new works: in October
2016, the extended works reached USD 5.9 million. Such new
extension included works on Road 9, repair of the old bridge
over the Andreoni Channel, and construction of a new bridge.
In 2017, new extended works were added: on August 7, a
contract was executed for USD 17.6 million, including works
on Roads 9, 10 and 16, and on December 22, another
contract was executed for USD 1.5 million, comprising
works on Roads 9 and 10.
The total amount of the contract, including the extended
works, is USD 44 million. Works started in June 2014 and
as of December 31, 2017 works recorded 76% progress.
Route 8 – Corporación vial del uruguay S.A.
From the contract signed on February 28, 2014 for the
execution of Route 9, the Corporación Vial del Uruguay
S.A. awarded us an extension of USD 10 million for road
reconstruction works on Route 8, between the 152k100
to 184K000 progressives, which are planned to be
carried out in 2018.
Techint E&C managed the construction of the greenfield TenarisBayCity seamless pipe plant in BayCity, USA.
40 TECHINT E&C S.A. Annual Report 2017
The main engineering works performed are related to
projects under development and to others that have already
been completed, among which the following stand out:
CC genelba Plus (Argentina): Development of detail engineer-
ing for a 350 Mw Combined Cycle Power Plant. EPC contract
for Pampa Energy S.A., Province of Buenos Aires, Argentina.
CC Norte III (Mexico): Development of detail engineering
for a 915 Mw Combined Cycle Power Plant. EPC contract for
CFE, Ciudad Juarez, Mexico.
Shushufindi Field Project (Ecuador): Development of
engineering (basic and detail) in new facilities and/or plants,
or changes to existing facilities and/or plants, in relation to
hydrocarbon exploitation fields; preparation of documents
necessary for specification of equipment and materials, sub-
contracts for accessory/supplementary works and services
(civil, electricity, mechanical, etc.), and the relevant assembly.
REPSol FEED & EPmCm Sagari (Peru): Development of
detail engineering for two oil and gas platforms in Campo
Sagari and the flow lines necessary to send the production,
along with Kinteroni’s, to Nuevo Mundo’s facilities. The
engineering scope includes surface installations of flow lines
and the modifications required for Kinteroni’s facilities.
CENTENARIo lithium Project (Argentina): Detailed
Feasibility Study for ERAMET S.A.S. Development of
feasibility studies for detail engineering, CAPEX estimate
+/-10% for a production of 20 000 tons/year from the Lithium
Carbonate plant.
yPF Eolic Park (Argentina): Development of detail
engineering for a 50 MW wind farm located in Chubut with
the option to expand it to 100 MW. The project includes two
electrical substations, a high voltage transmission line (132 kV)
to connect them, and a medium voltage transmission line (35
kV) connecting the wind turbines to one of the substations.
DK Fast Reloading (France): Development of detail
engineering for additional facilities allowing for the increase of
reloading capacity of LNG from two LNG storage Tanks, 02T01
and 02T02 (out of three), to LNG carriers, through the existing
unloading / loading facilities, from 4000 m3/h to 8300 m3/h.
Cashiriari wellhead Compression Expansion (Peru):
Development of basic engineering for Pluspetrol for inlet gas
compression expansion at Malvinas Plant, adding two news
centrifugal compressors.
ToTAl Incahuasi –Phase 2 (Bolivia): Development of
extended basic engineering and debottlenecking for a CPF,
requested by Total E&P Bolivia.
ToTAl Río Cullen –Fenix on Shore (Argentina):
Development for TOTAL of basic engineering for a Río Cullen
gas Treatment Plant Expansion (on-shore) in order to receive
gas from a new Fenix off-shore platform, Tierra del Fuego,
Argentina.
AXIoN. FCC Revamp ( Argentina ): Development for AXION
Energy of detail engineering for the Cracking Catalytic Unit
(FCCU) expansion from 28 KBPD to 31 KBPD of Heavy Gas
Oil (EGO). The refinery is located at Campana City –Province
of Buenos Aires, Argentina.
yPF - IBE (Ingeniería Básica Extendida) - Increase of
Effluents Treatment Capacity (Argentina): Development
of basic engineering for two new effluent treatment plants
to comply with legal requirements and ensure the quality of
water to be reused for cooling.
“Fortín de Piedra” Development Facilities – Basic
Engineering (Argentina): Development of basic engineering
for the necessary facilities at Fortín de Piedra, Vaca Muerta,
Neuquen. Main areas involved: PADs, batteries, CPF, water
intake and storage, production water distribution flow lines,
trunk lines and pipelines.
>
>
>
>
>
>
>
>
>
>
>
>
>
Engineering
41Board of Directors’ Report
“Fortín de Piedra” Development Facilities – Detail
Engineering (Argentina ): Development of detail engineering
for EPC contract, to develop the necessary facilities at Fortín
de Piedra, Vaca Muerta, Neuquen. Main areas involved :
PADs, batteries, CPF, water intake and storage, production
water distribution flow lines, trunk lines and pipelines.
ENAP Magallanes Area Incremental Project (Argentina):
Development of detail engineering for both on-shore and
off-shore facilities to optimize the extraction of gas from
existing wells and platforms in order to increase gas
production in the Magallanes Area to around 4 million of
cubic meters per day, delivering the gas to the Gral. San
Martín pipeline.
yPF – New water Intake works (Argentina): Development
of basic engineering for new water supply facilities and a
transportation pipeline to supply water to La Plata Industrial
Complex (CILP).
yPF - loop gasoducto RDM (Argentina): Development
of detail engineering for a 16”-33 km gas pipeline in Vaca
Muerta, Neuquen, Argentina, including its blocking valves
and scrapper traps .
Ennore lNg B&v (India): Development of detail
engineering, including a 3D Model for LNG Regasification
Terminal for an initial capacity of 20 MMSCMD with future
expansion capabilities to 40 MMSCMD.
Altamira Compressor Station is an EPC project for
Infraestructura Marina del Golfo (a partnership between
IENOVA and TransCanada), located in Altamira, Tamaulipas,
Mexico. Altamira project consists of a compressor station
of 2600 MMSCFD at 2,220 psig and 50 °C. IMG provided
GE turbo-compressors, metering and regulation skids and
all the control and communication systems for the project.
Detail engineering scope includes the design and purchase
of all compressors and metering station facilities.
>
>
>
>
>
>
Shushufindi, Ecuador.
42 TECHINT E&C S.A. Annual Report 2017
Dunkirk lng Terminal, France.
43Board of Directors’ Report
During this fiscal year, we focused on strengthening our
model of operation by executing several projects under the
recently established Shared Services of Purchasing and
Inspection, while maintaining the flexibility of the task-force
scheme for the Expediting and Traffic & Logistics work.
Such projects were PIAM, GNEA, El Bracho, Altamira (in
Mexico), Dunkirk (in France), Al Shahab, South Helwan, West
Damietta and the recent Fortin de Piedra.
Also was performed a deep review of the company
procedures of Expediting, and the required personnel
training. This work will continue in the forecoming fiscal
year in conjunction with an indeep review of the company
procedures of Inspection.
The centralization of the purchasing activity through
Procurement Shared Services of Engineered Materials and
Equipment throughout the projects (including the study of
surplus material use between projects) is already in place for
the mentioned projects.
The objective of establishing new Shared Services in Mexico
was to identify and capture the potential of the North
American Market, mainly in the Houston area.
The Post-Order network helped to increase the integration
and communication between expeditors and inspectors
of the team, and to optimize resources, planning, and
procedures for the operations. We specially focused on the
implementation of Shared Services of Inspection, and on
the utilization of custom software applications to increase
visibility and control of inspections.
We also worked to increase the coverage for projects
where Expediting work is controlled through a SAP custom
application (EXPD).
We also started to analyze the possibility of incorporating
Logistics to the Post-Order network, and started to support
the control of its activities by using standard SAP warehouse
applications.
This, in turn, provided deeper communication and integration
of Logistics with the other areas of Procurement and of the
Company in general, through the use of the same software
platform across these areas.
In relation to Project Support, throughout these years, we
focused on planning and coordinating the materials, suppliers,
commercial agreements, lessons learned and all activities
related to Supply Management, with the challenge of
providing early warnings and proposals for solution in projects
presenting alerts in the KPIs, cost, time and quality.
Our full time activity is centralized and stands out in three
main aspects: planning, best practices, and global networking
(Project Structure, RFQs & Bids, Procedures, IT Solutions).
Procurement
44 TECHINT E&C S.A. Annual Report 2017
The Equipment Division continues seeking the objective of
optimizing the investment in construction equipment and
their allocation to projects, thus reducing the operational
costs, by means of the improvement, among other aspects,
of efficiency and effectiveness of repairs, the creation of a
differentiation and competitive improvement factor, and the
increase of productivity in projects.
This sector has managed to get ready any inventories related
to Pipelines. The last acquisition of the Company of a trencher
machine, improves the productivity in shale gas projects. This
fleet provides a competitive advantage; the availability of such
pipelines to meet contracts, by focusing on cost reduction,
efficiency in repairs in order to increase the productivity of the
projects, translated into the mechanical availability of our fleet.
The investment value in machinery, vehicles and equipment
for the 2017 fiscal year was USD 32.6 million.
During this fiscal year, we focused the investments in equip-
ment in Argentina, representing 61% of the total investment.
Especially for projects related to Vaca Muerta.
Techint E&C Equipment Division
The investment value in machinery, vehicles and equipment for the 2017 fiscal year was USD 32.6 million.
45Board of Directors’ Report
TECHINT E&C has consolidated its management in
prevention (quality, industrial safety, occupational health
and environmental protection - QHSE) as an intrinsic value
of its activity, assigning a high priority to it and focusing
on the effectiveness and productivity of preventive tools,
by reviewing and ensuring the permanent evolution of
the Integrated Management System (IMS), with Quality
and setting in motion different actions on Knowledge
Management (KM) in the Company.
In addition, TECHINT E&C develops its projects taking
into account the requirements of international standards
ISO 9001, ISO 14001 and OHSAS 18001, with preventive
practices that ensure the highest standards of quality, safety,
health and environmental protection.
TECHINT E&C aims at Zero Deviation. This means:
Not having any kind of anomaly.
Having a healthy, safe and well-maintained space.
Being in harmony with the environment and the communities
where we develop our projects.
Managing our knowledge in search for excellence.
TECHINT E&C works on the basis of a more efficient
administration of limited operational resources and with
modern knowledge management. Also, its management
aims at an organization that shares experiences among its
members, as a living social organization in the search for
continuous learning. Part of TECHINT E&C’s culture lies
in adapting to the environment in which it operates. This
is achieved under the leadership of KM, which consists in
providing training to projects and managing the knowledge of
our staff, so that it can be learnt, analyzed, shared, used and
disseminated to the entire Company.
Among KM expected results, we continue with the
improvement in the prevention of deviations, accidents and
incidents, as well as the improvement in quality, compliance
with milestones and deadlines, and customer satisfaction
(external and internal).
During the year, TECHINT E&C’s accident rate showed an
improvement, achieving an IF below the established target at
the end of the period.
Keeping QHSE standards demands sustainable leadership in
the implementation of efficient preventive measures, with
transparency and effective action programs.
Main actions carried out by TECHINT E&C, during this period:
Optimization of specific indicators (PPI).
Integration of the Corporate Assistance System (SAC)
process, focusing on critical processes.
Optimization of company processes focusing on their quality.
Deepening of the Proactive Approach (Base of the
accident pyramid).
Analysis of the deviations detected; identification of lessons
learned for an efficient and effective control of risks.
Deepening of the adherence to work methods: correct,
consistent and safe (Operational Discipline).
Quality, Health, Safety and Environment (QHSE)
>
>
>
>
>
>
>
>
>
>
46 TECHINT E&C S.A. Annual Report 2017
Our Business Conduct Compliance Program sets forth a
Policy on Business Conduct and a series of procedures to
ensure adherence of our employees to our ethical principles
and anti-bribery provisions.
Along with our Code of Conduct and our Transparency
Policy, the Program rules the way we should interact with
Public Officials, Governmental Entities, other organizations
and private persons. It also provides for specific rules to
assess and review third parties’ commitment to our ethical
standards, since we count on their consistent compliance
with applicable laws and specific regulations.
The Program takes a preventive approach by developing an
extensive communication strategy and employee training
activities.
It also emphasizes the importance of implementing activities
related to monitoring and auditing, and the use of the
Company’s Compliance Line to detect and react to potential
policy breaches.
In March 2018 TEBRA received two certifications: ISO 37001:
2016, Anti-bribery Management System and the Declaration
of Conformity ISO 19600: 2014, Compliance Management
System.
The Company acknowledges its responsibilities regarding
environmental protection and sustainable development.
Therefore, it commits before its employees, clients,
contractors and the community as a whole to minimize the
environmental and social impact of its operations and to avoid
any adverse effects on the environment.
During 2017, under our Social Responsibility program, we
developed several initiatives focused on promoting education,
which we consider the driving force for social equity and
creation of opportunities:
Engagement in the Merit Scholarships Program for
secondary schools through the “Fundación Hermanos
Agustín y Enrique Rocca”.
Scholarships granted to undergraduate and post-graduate
students of the courses of studies on Engineering and
Applied Sciences, which are managed through the Roberto
Rocca Education Program.
Donation of IT equipment.
Health, medical care, vaccination and nutrition campaigns
conducted in several communities.
Compliance and Internal Control
Social Responsibility
>
>
>
>
47Board of Directors’ Report
During the period, progress continued to be made in several
IT internal projects related to improvements in technological
infrastructure, upgrade to new software versions, implement
of new solutions and research of different technology
solutions related with digital transformation to cover and
improve our competitiveness in different business processes.
The most outstanding IT projects were the following:
The BIM methodology is being implemented in order to
improve the productivity, control, constructability and commu-
nication along the Engineering phases and Construction.
In order to have state-of-the-art technology in Engineering 3D
tools, several Proofs of Concepts of the latest Engineering
applications version were developed.
A new software is being implemented to improve welding
process traceability and quality control.
Risk control software was implemented for the
construction process.
A new Cost Control / Construction Progress software was
implemented.
New locations continue to be setup in several countries for
Accounting and Electronic Billing.
Mobile solutions to be use at the Site Project, were developed
for Information capture in the Safety processes and HHRR .
Applications were implemented for the Personnel Search and
Selection process.
Works continue in the Document Management and third
party information exchange automation.
A new solution was implemented for collaboration, application
sharing, etc integrated with federated/public service.
A restructuring and fine tuning of the Active Directory and
SCCM Infrastructure was completed.
A new Proxy for Internet access was implemented for
border Security.
A new VPN Global solution was implemented.
Diverse technology solutions are being evaluated in
order to be implemented to increase and improve our
competitiveness, especially for the core EPC process.
The Company acknowledges that its human resources
are the key to success when it develops complex projects
in different countries. For this reason, the Company pays
special attention to the recruiting, training and development
of the personnel making up the Company’s work team. The
Company’s main challenges in terms of human resources
management are ensuring that it has the talent required
to pursue its current projects and seeking to assure the
resources it needs for development in the different areas
where the Company operates.
During the fiscal year, the Company needed to accelerate its
recruitment process to face its increasing activity level and,
in this sense, the Young Professionals Program was the main
gate for those who are likely to hold management positions
in the future. Selection takes place at the main universities
of the countries where the Company is operating and is
supplemented by an intensive training program during the
first two years.
The preparation and follow-up of career development
programs based on aligning its collaborators’ professional
development with the Company’s business strategy
constituted another pillar to support human resources
management during this fiscal year. The Company also
worked on the design of a training program devoted to
introducing deeper technical content focused on new
technologies. In addition, this program reaches all levels
of the Company, from project managers, middle managers
and supervisors to field personnel.
Technology and IT Systems
Human Resources
>
>
>
>
>
>
>
>
>
>
>
>
>
>
48 TECHINT E&C S.A. Annual Report 2017
For the year ended December 2017, the Company obtained
profits for USD 16.6 million including USD 2.9 million
of non-controlling interest, with accumulated earnings for
USD 161.7 million corresponding to the equity holder.
We would like to thank all our clients, suppliers, banking
institutions and, above all, our employees, whose work
on a daily basis have contributed to these results.
The Board of Directors
Board of Directors’ Proposal
49Board of Directors’ Report
PRESIDENT
Lodovico Andrea Palú Rocca
vICE PRESIDENT
Carlos Eduardo Bacher
Eduardo Nicolás Rocca Couture
DIRECToRS
Ricardo Pascale Cavalieri
Luis Pablo Solari Damonte
Alicia Lucía Mondolo
Ricardo Ourique Marques
Alfredo Francesco Luigi Orelli
Directors were appointed at the Regular
Shareholders’ Meeting held on May 30, 2017.
Board of Directors
50 TECHINT E&C S.A. Annual Report 2017
Techint E&C is working on the new coke-oven gas treatment plant for Siderar at San nicolás, Argentina.
51Board of Directors’ Report
52 TECHINT E&C S.A. Annual Report 2017
53Board of Directors’ Report
TECHINT E&C S.A.
Years ended December 31, 2017 and 2016
Consolidated Financial Statements
Consolidated Financial Statements
54 TECHINT E&C S.A. Annual Report 2017
Altamira Compression Station, mexico.
55Consolidated Financial Statements. Years ended December 31, 2017 and 2016.
DENoMINATIoN:
TECHINT E&C Sociedad Anónima.
lEgAl ADDRESS:
La Cumparsita 1373 7th Floor
Montevideo (11200)
(598-2) 901-9091
CoMPANy ACTIvITy:
Investments.
DATE oF REgISTRATIoN:
July 04, 2012.
EXPIRATIoN
oF CoMPANy CHARTER:
July 04, 2112.
REgISTRy NuMBER:
RUT 21-7015450012.
1 See note 13 to the consolidated financial statements
2 UYU: Uruguayan Pesos
3 See note 24
SHARE CAPITAl:
Shares: 16,922,492,830 1.
Face Value: UYU 16,922,492,830 2.
PARENT CoMPANy:
Techint Investments S.A. 3.
lEgAl ADDRESS:
Alquilino de la Guardia 8, piso 5°.
Panama, Panama.
PARENT CoMPANy’S ACTIvITy:
Investments.
PARENT CoMPANy:
Shares: 100%
Votes: 100%
Legal Information
56 TECHINT E&C S.A. Annual Report 2017
57Consolidated Financial Statements. Years ended December 31, 2017 and 2016.
58 TECHINT E&C S.A. Annual Report 2017
59Consolidated Financial Statements. Years ended December 31, 2017 and 2016.
60 TECHINT E&C S.A. Annual Report 2017
All AmoUnTS in USD ThoUSAnDS
ASSETS
non-current assets
Property, plant and equipment (PP&E)
Intangible assets
Investments accounted for using the equity method
Other investments
Non-current tax assets
Trade and other receivables
Deferred income tax assets
Total non-current assets
Current assets
Inventories
Derivative financial instruments
Current tax assets
Trade and other receivables
Construction contracts work in progress
Cash and cash equivalents
Total current assets
Assets of disposal group classified as held for sale
Total Assets
Dec 31, 2017
259,584
4,441
14,827
3,710
13,396
156,317
36,105
488,380
27,546
199
40,914
693,290
158,786
390,063
1,310,798
5,219
1,804,397
272,264
5,032
26,254
10,403
14,047
170,854
30,918
529,772
25,552
589
27,873
602,491
148,304
231,804
1,036,613
16,208
1,582,593
4
5
6
7
8
15
9
26
8
12
11
Dec 31, 2016
Years ended December 31, 2017 and 2016.
Notes
Consolidated Statement of Financial Position
61Consolidated Financial Statements. Years ended December 31, 2017 and 2016.
All AmoUnTS in USD ThoUSAnDS
EQUiTy AnD liABiliTiES
Equity
Capital and reserves attributable to the Company's equity holders
Non-controlling interests
Total Equity
non-current liabilities
Borrowings
Deferred income tax liabilities
Non-current tax liabilities
Derivative financial instruments
Trade and other payables
Other liabilities
Total non-current liabilities
Current liabilities
Borrowings
Trade and other payables
Derivative financial instruments
Construction contracts work in progress
Current tax liabilities
Other liabilities
Total current liabilities
Total liabilities
Total Equity and liabilities
Dec 31, 2017
668,769
4,790
673,559
41,110
13,923
–
2,029
36,375
65,723
159,160
85,093
632,640
5,675
102,474
37,570
108,226
971,678
1,130,838
1,804,397
639,319
5,927
645,246
54,022
28,844
993
–
37,856
51,551
173,266
105,174
507,609
678
64,171
29,684
56,765
764,081
937,347
1,582,593
14
15
26
16
17
14
16
26
17
Dec 31, 2016Notes
The accompanying notes are an integral part of these consolidated financial statements.
Years ended December 31, 2017 and 2016.
Consolidated Statement of Financial Position (cont’d.)
62 TECHINT E&C S.A. Annual Report 2017
All AmoUnTS in USD ThoUSAnDS
Revenues from construction contracts and other services
Cost of revenue
gross profit
General administrative and selling expenses
Result from investments accounted for using the equity method
Other operating results
operating income
Financial income
Financial costs
Income before income tax
Income tax expense
Net Income (1)
(1) Attributable to:
Equity holders of the Company
Non-controlling interests
Net Income
Dec 31, 2017
1,427,133
(1,270,266)
156,867
(141,867)
3,390
(3,738)
14,652
55,514
(53,178)
16,988
(374)
16,614
13,694
2,920
16,614
1,283,816
(1,082,756)
201,060
(138,943)
13,210
(17,248)
58,079
76,255
(48,434)
85,900
(43,509)
42,391
38,481
3,910
42,391
27
27
6
29
28
28
30
Dec 31, 2016Notes
Years ended December 31, 2017 and 2016.
The accompanying notes are an integral part of these consolidated financial statements.
Consolidated Income Statement
63Consolidated Financial Statements. Years ended December 31, 2017 and 2016.
Net Income
other comprehensive income:
items that will not be reclassified to profit or loss
Increase of revaluation of PP&E net of tax effects
Other comprehensive income using the equity method -
Increase of revaluation of PP&E net of tax effects
Remeasurement - Actuarial losses (gains) net of tax effects
Subtotal items that will not be reclassified to profit or loss
items that may be subsequently reclassified to profit or loss
Currency translation differences
Other comprehensive income using the equity method -
Currency translation differences
Cash flow hedge, net of tax effects
Subtotal items that may be subsequently reclassified to profit or loss
other comprehensive income, net of tax
Total comprehensive income (2)
(2) Attributable to:
Equity holders of the Company
Non-controlling interests
16,614
11,198
–
(2,073)
9,125
316
(3,461)
(1,632)
(4,777)
4,348
20,962
19,807
1,155
20,962
42,391
14,482
264
892
15,638
(33,350)
3,004
3,518
(26,828)
(11,190)
31,201
28,261
2,940
31,201
Years ended December 31, 2017 and 2016.
All AmoUnTS in USD ThoUSAnDS Dec 31, 2017 Dec 31, 2016
The accompanying notes are an integral part of these consolidated financial statements.
Consolidated Statement of Comprehensive Income
64 TECHINT E&C S.A. Annual Report 2017
Share Capital
Attributable to the Company´s Equity Holders
Balance at December 31, 2016
Net income for the year
Other comprehensive income
Increase of revaluation of PP&E net of tax effects
Depreciation of reserve for PP&E revaluation surplus net of tax effects
Decrease of reserve for PP&E revaluation surplus due to PP&E
disposal net of tax effects
Remeasurement - Actuarial losses (gains) net of tax effects
Cash flow Hedge net of tax effects
Currency translation differences
Total comprehensive income for the year
Resolution of the Shareholders ordinary meeting held on May 30, 2017
Board of Director´s fee
Legal reserve
Resolution of the Shareholders extraordinary meeting held on August 2, 2017:
Capital Contributions
Incorporation of subsidiary - TEFIN S.A.
Dividends distributed to non-controlling interests
Balance at December 31, 2017
Cumulative translation differences
(493,448)
–
–
–
–
–
–
(1,327)
(1,327)
–
–
–
–
–
(494,775)
legal reserve
7,425
–
–
–
–
–
–
–
–
–
1,924
–
–
–
9,349
Capital Surplus
–
–
–
–
–
–
–
–
–
–
–
–
(261)
–
(261)
867,504
–
–
–
–
–
–
–
–
–
–
10,000
–
–
877,504
All AmoUnTS in USD ThoUSAnDS
4
4
4
13
Notes
The accompanying notes are an integral part of these consolidated financial statements.
Consolidated Statement of Changes in Equity
Years ended December 31, 2017 and 2016.
65Consolidated Financial Statements. Years ended December 31, 2017 and 2016.
Share Capital
Total Equity
reserve for PP&E revaluation surplus
85,240
–
11,198
(17,858)
(5,969)
–
–
–
(12,629)
–
–
–
–
–
72,611
reserve for Cash Flow hedge
(3,546)
–
–
–
–
–
(1,632)
–
(1,632)
–
–
–
–
–
(5,178)
reserve for Pension Plan Benefits
(79)
–
–
–
–
(2,126)
–
–
(2,126)
–
–
–
–
–
(2,205)
reserve for future dividends
50,000
–
–
–
–
–
–
–
–
–
–
–
–
–
50,000
retained Earnings
126,223
13,694
–
17,858
5,969
–
–
–
37,521
(96)
(1,924)
–
–
–
161,724
Total
639,319
13,694
11,198
–
–
(2,126)
(1,632)
(1,327)
19,807
(96)
–
10,000
(261)
–
668,769
Non - Controlling Interests
5,927
2,920
–
–
–
53
–
(1,818)
1,155
–
–
–
225
(2,517)
4,790
645,246
16,614
11,198
–
–
(2,073)
(1,632)
(3,145)
20,962
(96)
–
10,000
(36)
(2,517)
673,559
Attributable to the Company´s Equity HoldersAll AmoUnTS in USD ThoUSAnDS
66 TECHINT E&C S.A. Annual Report 2017
Share Capital
Attributable to the Company´s Equity Holders
Balance at December 31, 2015
Net income for the year
Other comprehensive income
Increase of revaluation of PP&E net of tax effects
Depreciation of reserve for PP&E revaluation surplus net of tax effects
Decrease of reserve for PP&E revaluation surplus due to PP&E disposal net of tax effects
Remeasurement - Actuarial losses (gains) net of tax effects
Cash flow Hedge net of tax effects
Currency translation differences
Total comprehensive income for the year
Resolution of the Shareholder´s meeting held on June 8, 2016
Board of Director´s fee
Legal reserve
Dividends distributed to non-controlling interests
Balance at December 31, 2016
Cumulative translation differences
legal reserve
(464,318)
–
–
–
–
–
–
(29,130)
(29,130)
–
–
–
(493,448)
4,815
–
–
–
–
–
–
–
–
–
2,610
–
7,425
867,504
–
–
–
–
–
–
–
–
–
–
–
867,504
All AmoUnTS in USD ThoUSAnDS
4
4
4
Notes
The accompanying notes are an integral part of these consolidated financial statements.
Consolidated Statement of Changes in Equity
Years ended December 31, 2017 and 2016.
67Consolidated Financial Statements. Years ended December 31, 2017 and 2016.
Share Capital
Non - Controlling Interests
Total Equity
reserve for PP&E revaluation surplus
reserve for Cash Flow hedge
reserve for Pension Plan Benefits
reserve for future dividends
retained Earnings
Total
90,025
–
14,655
(16,489)
(2,951)
–
–
–
(4,785)
–
–
–
85,240
(7,064)
–
–
–
–
–
3,518
–
3,518
–
–
–
(3,546)
(816)
–
–
–
–
737
–
–
737
–
–
–
(79 )
50,000
–
–
–
–
–
–
–
–
–
–
–
50,000
71,008
38,481
–
16,489
2,951
–
–
–
57,921
(96)
(2,610)
–
126,223
611,154
38,481
14,655
–
–
737
3,518
(29,130)
28,261
(96)
–
–
639,319
4,542
3,910
91
–
–
155
–
(1,216)
2,940
–
–
(1,555)
5,927
615,696
42,391
14,746
–
–
892
3,518
(30,346)
31,201
(96)
–
(1,555)
645,246
Attributable to the Company´s Equity HoldersAll AmoUnTS in USD ThoUSAnDS
68 TECHINT E&C S.A. Annual Report 2017
Cash flows from operating activities
Net Income for the year
Adjustments to reconcile net income to cash flow operations
PP&E depreciation
Intangible amortization
Construction contracts in progress
Net provisions
Net allowance for doubtful accounts
Inventories valuation allowance
Income Tax accrued
Gain from the sales of PP&E
Impairment loss
Gain from Indemnity
Interest accrued from trade and other receivables
Interest accrued from borrowings
Result from investments accounted for using the equity method
Other, including currency translation differences
Changes in balances corresponding to:
Trade accounts receivable and tax assets
Inventories
Trade and other payables and tax liabilities
Assets of disposal group classified as held for sale
Income tax payments
Other liabilities
Board of Director´s fees
Changes in non-controlling interests
Net cash generated by / (used in) operating activities
16,614
44,566
2,850
27,821
(15,432)
610
(215)
374
(5,158)
193
(995)
(10,890)
12,645
(3,390)
3,799
(77,374)
(1,737)
133,475
10,989
(21,031)
78,418
(96)
(2,517)
193,519
42,391
42,893
3,273
(114,742)
10,120
34
641
43,509
(4,671)
5,528
(882)
(8,407)
10,210
(13,210)
(4,674)
32,492
16,894
(153,033)
(1,360)
(43,750)
376
(96)
(1,555)
(138,019)
4
5
18
8
9
30
29
4
29
28
28
6
All AmoUnTS in USD ThoUSAnDS Dec 31, 2017 Dec 31, 2016Notes
Years ended December 31, 2017 and 2016.
Consolidated Statement of Cash Flows
69Consolidated Financial Statements. Years ended December 31, 2017 and 2016.
Cash flows from investing activities
Proceeds from disposal of PP&E
Payment for purchases of PP&E
Proceeds from disposal of intangible assets
Purchases of intangible assets
Other investments and investment accounted for using the equity method (net)
Dividend collected from investments accounted for using the equity method
Net cash used in investing activities
Cash flow from financing activities
Shareholders contribution
Payment Interest
Proceeds from borrowings
Repayments of borrowings
Net cash used in financing activities
Net increase / (decrease) in cash and cash equivalents
Cash and cash equivalents at the beginning of the year
Effect of exchange rate changes
Variation in cash due to consolidation of subsidiaries
Cash and cash equivalents at the end of the year
non - Cash transactions
Increase of revaluation of PP&E, net of tax
Remeasurement - Actuarial (gains) losses net of tax
Cash flow hedge, net of tax
15,011
(44,390)
16
(2,360)
6,471
15,200
(10,052)
10,000
(6,283)
51,468
(94,393)
(39,208)
144,259
226,597
8,140
2,290
381,286
11,198
(2,073)
(1,632)
16,077
(34,767)
95
(2,323)
3,716
8,265
(8,937)
–
(9,165)
96,106
(107,745)
(20,804)
(167,760)
403,813
(9,456)
–
226,597
14,746
892
3,518
4
5
5
6
14
14
14
12
12
4
The accompanying notes are an integral part of these consolidated financial statements.
All AmoUnTS in USD ThoUSAnDS Dec 31, 2017 Dec 31, 2016Notes
Years ended December 31, 2017 and 2016.
Consolidated Statement of Cash Flows (cont’d.)
70 TECHINT E&C S.A. Annual Report 2017
magallanes Area incremental Project (PiAm), Argentina.
71
Basis of preparation
Consolidation and equity accounting
Foreign currency translation
Use of estimates
Property, plant and equipment (PP&E)
Intangible assets
Impairment of non-financial assets
Financial assets
Offsetting financial instruments
Derivative financial instruments
Inventories
Construction contracts work
in progress
Other investments
Trade and other receivables
Trade and other payables
Cash and cash equivalents
Equity
Borrowings
Current and deferred income tax
Employee benefits
Provisions
Revenue recognition
Leases
Assets of disposal group classified
as held for sale
General Information
Accounting policies
1.
2.
a.
b.
c.
d.
e.
f.
g.
h.
i.
j.
k.
l.
m.
n.
o.
p.
q.
r.
s.
t.
u.
v.
w.
x.
3.
4.
5.
6.
7.
8.
9.
10.
11.
12.
13.
14.
15.
16.
17.
18.
19.
20.
21.
22.
23.
24.
25.
26.
27.
28.
29.
30.
31.
32.
Financial risk management
Property, plant and equipment (PP&E)
Intangible assets
Investments accounted for using
the equity method
Other investments
Trade and other receivables
Inventories
Financial instruments by category
Assets of disposal group classified
as held for sale
Cash and cash equivalents
Share Capital
Borrowings
Deferred income taxes
Trade and other payables
Other liabilities
Provisions
Employee benefits
Participation in Joint Operations
Contingencies and commitments
Restricted assets
Claims Receivables
Related party transactions
Principal Subsidiaries
Derivate financial instruments
Cost of revenue and expenses by nature
Financial results
Other operating results
Income tax
Main contracts
Subsequent events
Index to the Notes to the Consolidated Financial Statements
72 TECHINT E&C S.A. Annual Report 2017
>
>
>
>
NoTE 1.
gENERAl INFoRMATIoN
lEgAl INFoRMATIoN
Techint E&C Sociedad Anónima (“TEChinT E&C”), a
company controlled by Techint Investments S.A. is a part
of the Techint Group (“TG”). TECHINT E&C’s purpose is
to engage in investments by holding equity interests in
companies or organizations whose corporate purpose
includes engineering, construction and services. References
in these consolidated financial statements to “TECHINT
E&C” or “Company” refer to TECHINT E&C S.A. and its
consolidated subsidiaries.
The Company holds the following direct investments:
TEI&C S.A. (hereinafter, “TEIC”): Uruguayan company (100%)
Techint Ingeniería y Construcciones S.L.U. (hereinafter,
“TIC”): Spanish company, (100%),
Construcciones y Prestaciones Petroleras S.A. CPP
(hereinafter, “CPP”): Ecuatorian company, (99.99%) (0.01%
through subsidiaries)
Construcciones Globales Andinas CGA S.A. (hereinafter, “CGA”):
Ecuatorian company, (98.00%) (2.00% through subsidiaries).
These consolidated financial statements were formulated for
issue by the Company’s Board of Directors on April 26, 2018
and were updated by the Company’s Board of Directors after
this formulation and approved by the Shareholder´s meeting
held on May 10, 2018.
During the current fiscal year TECHINT E&C experienced
some changes in its investment portfolio, which are detailed
as follows:
In March 2017, Techint Inversiones S.A.I.F. (TEINVA), an
argentine subsidiary, acquired shares in Prestaciones
Globales Petroleras S.A. (formerly GEA-GEO Energy
Alternarives S.A.), an argentinian company, wich representing
the 70% of its share capital, for an amount of USD 145,250.
The other 30% was purchased by Flinwok S.A., an uruguayan
subsidiary, for an amount of USD 62,250.
In June 2017, by virtue of a corporate restructuring process
and for the purpose of synergy unification, the subsidiary
TIC acquired the shares held by Techint Investment S.A. in
TEFIN S.A. (“TEFIN”), representing 10% of TEFIN’s share
capital, for an amount of USD 970,000. The other 90%
was purchased by Techint Compañía Técnica Internacional
S.A.C.I. (”TEARG”), an argentine subsidiary, for an amount
of USD 8.73 million.
In July 2017, the dutch subsidiary TE & C Investements
Netherlands BV (TE&C) acquired the 25,000 shares of its
dutch subsidiary Verkotec B.V. In this way, TE&C became
the only shareholder, and in August 2, 2017 initiated the
liquidation process.
The extraordinary Shareholders meetting of the argentine
subsidiary Sidernet S.A. held on September 29, 2017
approved the Sidernet spin-off and as a result of the same,
the constitution of Tecsesi S.A .
In November 2017, the dutch subsidiary TE&C Investments
Netherlands B.V. (“TE&C”) sold to the Company its
participation interest it held in CGA consisting of 980
common shares, representing 98% of CGA’s share capital,
for an amount of USD 14.6 million.
In November 2017, the dutch subsidiary TE&C Investments
Netherlands B.V. (“TE&C”) sold to the Company its
participation interest it held in CGA consisting of 980
common shares, representing 98% of CGA’s share capital,
for an amount of USD 14.6 million. Since November 2017
CGA is in process of merge with CPP.
During the previous fiscal year TECHINT E&C experienced
some changes, which are detailed as follows:
On December 20, 2016, TIC made a distribution in kind
against free-availability reserves (issue premium), for the
sum of USD 1,368,406. Such distribution was made through
the transfer to TECHINT E&C of all the shares held by TIC in
CPP. In particular, TIC transferred 13,099 shares representing
99.99% of the capital stock.
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 73
>
>
>
NoTE 2.
ACCouNTINg PolICIES
The principal accounting policies applied in the preparation
of these consolidated financial statements are set out below.
These policies have been consistently applied to all the years
presented, unless otherwise stated.
a. BASIS oF PREPARATIoN
ACCoUnTing PoliCiES
These consolidated financial statements are prepared in
accordance with International Financial Reporting Standards
(“IFRS”), as issued by the International Accounting Standards
Board (“IASB”), under the historical cost convention, as modified
by the revaluation of machinery, equipment and vehicles
(“Revaluation of PP&E”), used in the construction business
available-for-sale assets, investments accounted for using the
equity method, financial assets and liabilities (including derivative
instruments) at fair value through profit or loss. The consolidated
financial statements are presented in thousands of U.S. dollars
(“USD”), which is the functional currency of TECHINT E&C.
Some comparative amounts have been reclassified to
conform to changes in presentation in the current period.
These changes did not have an impact on the determination
of the results for the year, the equity or any other significant
component of the consolidated financial statements.
The preparation of consolidated financial statements in
conformity with IFRS requires the use of certain critical
accounting estimates. It also requires management to exercise
its best judgment in the process of applying the Company’s
accounting policies. The areas involving a higher degree
of judgment of complexity, or the areas where assumptions
and estimates are significant to the consolidated financial
statements, are disclosed in note 2.d.
ChAngES in ACCoUnTing PoliCy AnD DiSCloSUrES
(a) Standards and amended standards mandatory for the first
time for the Financial Statements beginning january 1, 2017
and adopted by the Company
There are no standards, amendments to standards and
interpretations to existing standards which are effective for
the Company for annual fiscal year ended December 31,
2017 that are relevant to the operations of the Company,
and therefore, no impact resulted from the application of
those standards, amendments and interpretations on these
consolidated financial statements.
(b) Standards, amendments and interpretations to existing
standards that are not yet effective and have not been early
adopted by the Company
IFRS 15, “Revenue from contracts with customers”
In May 2014, the IASB issued IFRS 15, ”Revenue from
contracts with customers”, which sets out the requirements
in accounting for revenue arising from contracts with
customers and which is based on the principle that revenue
is recognized when control of a good or service is transferred
to the customer. IFRS 15 must be applied on annual periods
beginning on or after January 1, 2018.
The Company's management has assessed the effects
of applying the new standard on the Company’s financial
statements and has not identified any material impact in the
application of the new standard.
IFRS 9, “Financial instruments”
In July 2014, the IASB issued IFRS 9, “Financial instruments”,
which replaces the guidance in IAS 39. It includes requirements
on the classification and measurement of financial assets and
liabilities, as well as an expected credit losses model that replaces
the current incurred loss impairment model. IFRS 9 must be
applied on annual periods beginning on or after January 1, 2018.
The Company's management has assessed the effects
of applying the new standard on the Company’s financial
statements and has not identified any material impact in the
application of the new standard.
IFRS 16, “Leases”
In January 2016, the IASB issued IFRS 16, "Leases", which
will result in almost all leases being recognized on the
balance sheet, as the distinction between operating and
finance leases is removed. Under the new standard, an asset
74 TECHINT E&C S.A. Annual Report 2017
(the right to use the leased item) and a financial liability to pay
rentals are recognized. IFRS 16 must be applied on annual
periods beginning on or after January 1, 2019.
The Company is currently in the process of evaluating the
impact on the Consolidated Financial Statement derived from
the application of this new standard.
b. CoNSolIDATIoN AND EquITy ACCouNTINg
SUBSiDiAry ComPAniES
Subsidiaries are all entities over which TECHINT E&C has
control. TECHINT E&C controls an entity when it is exposed
to, or has rights to, variable returns from its involvement with
the entity and has the ability to affect those returns through
its power over the entity. Subsidiaries are fully consolidated
from the date on which control is exercised by the Company
and are no longer consolidated from the date control ceases.
The purchase method of accounting is used to account for
the acquisition of subsidiaries by TECHINT E&C. The cost
of an acquisition is measured as the fair value of the assets
given, equity instruments issued and liabilities incurred
or assumed at the date of acquisition. Acquisition-related
costs are expensed as incurred. Identifiable assets acquired,
liabilities and contingent liabilities assumed in a business
combination are measured initially at their fair values at the
acquisition date. Any non-controlling interest in the acquiree
is measured either at fair value or at the non controlling
interest’s proportionate share of the acquiree’s net assets.
The excess of the aggregate of the consideration transferred
and the amount of any non-controlling interest in the acquiree
over the fair value of the identifiable net assets acquired is
recorded as goodwill. If the cost of acquisition is less than
the fair value of the net assets of the subsidiary acquired, the
difference is directly recognized in the income statement.
If the companies acquired were under common control,
the assets and liabilities of such companies (and
their respective subsidiaries) are accounted for at the
predecessor’s cost, reflecting the carrying amount of such
assets and liabilities contributed to the Company. Accordingly,
the consolidated financial statements include the financial
position of the abovementioned companies at historical
book values and no adjustment has been made to reflect fair
values at the time of the contribution. The difference between
the price paid and the historical book value was charged to
equity as Capital Surplus.
In case of disposal related to companies under common
control, the assets and liabilities of such companies (and
their respective subsidiaries) are accounted for at the
predecessor’s book values, reflecting the carrying amount
of such assets and liabilities disposed of the Company.
Accordingly, the consolidated financial statements exclude
the financial position of the abovementioned companies at
their carrying book values and no adjustment has been made
to reflect fair values at the time of disposal. The difference
between the considerations paid and the carrying book value
of the assets and liabilities of the entities derecognized is
charged to equity.
Material intercompany transactions, balances and unrealized
gains (losses) on transactions between TECHINT E&C
and its subsidiaries have been eliminated in consolidation.
Accounting policies of subsidiaries have been changed where
necessary to ensure consistency with the policies adopted by
TECHINT E&C.
According to the laws of the countries of certain subsidiaries,
a portion of the profit of the year is separated to constitute
statutory reserves until they reach statutory capped amounts.
These legal reserves are not available for dividend distribution
and can only be released to absorb losses.
See note 25 to the consolidated financial statements for the
list of principal consolidated subsidiaries.
TrAnSACTionS AnD non-ConTrolling inTErESTS
The Company treats transactions with non-controlling
interests as transactions with equity owners of TECHINT
E&C. For purchases from non-controlling interests, the
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 75
difference between any consideration paid and the relevant
share acquired of the carrying value of net assets of
the subsidiary is recorded in equity. Gains or losses on
disposals to non-controlling interests are also recorded
in equity. When TECHINT E&C ceases to have control or
significant influence, any retained interest in the entity is
remeasured to its fair value, with the change in carrying
amount recognized in profit or loss.
ASSoCiATED ComPAniES
Associated companies are entities in which TECHINT
E&C has significant influence but not control, generally
accompanying a shareholding of between 20% and 50%
of the voting rights (see note 6). Investments in associated
companies are accounted for using the equity method
of accounting and are initially recognized at cost. The
Company’s investment in associated companies includes
goodwill identified on acquisition, net of any accumulated
impairment loss.
The Company’s share of its associated companies’ post-
acquisition profits or losses is recognized in the income
statement, and its share of post-acquisition movements in
reserves is recognized in reserves. The cumulative post-
acquisition movements are adjusted against the carrying
amount of the investment.
When the Company’s share of losses in an associated
company equals or exceeds its interest in such company,
including any other unsecured receivables, the group does
not recognize further losses, unless it has incurred obligations
or made payments on behalf of the associated companies.
Unrealized gains on transactions between TECHINT E&C
and its associated companies are eliminated to the extent
of TECHINT E&C’s interest in the associated companies.
Unrealized losses are also eliminated unless the transaction
provides evidence of an impairment indicator of the asset
transferred. Financial statements of associated companies
have been adjusted where necessary to ensure consistency
with IFRS.
JoinT ArrAngEmEnTS
This is a joint agreement under which the parties having a
joint control are entitled to the assets and are subject to
the obligations related to liabilities, in connection with the
agreement. In addition, this type of transaction considers the
legal structure, the contractual provisions agreed upon by the
parties, and other relevant factors and circumstances.
The Company records this type of joint transactions
acknowledging all the assets, liabilities, income and expenses
relative to their share in the Joint Agreement, the description
of which is stated in Note 20.
Under IFRS 11, “Joint arrangements“, and IAS 28, “Investments in
associates and joint ventures“, investments in which two or more
parties have joint control must be classified as a “joint operation“,
when the parties have rights to the assets and obligations relating
to the arrangement or, as a "joint venture" when the parties have
rights to the net assets of the arrangement. Taking into account
such classification, joint operations are consolidated line by line
according to TECHINT E&C’s interest, whereas joint ventures are
recorded according to the equity method.
Investments classified as joint ventures are included in
the account “Investments accounted for using the equity
method” in the Consolidated Statement of Financial Position.
Under the equity method of accounting, interests in joint
ventures are initially recognized at cost and adjusted thereafter
to recognize the Company’s share of the post-acquisition profits
or losses and movements in other comprehensive income.
When the Company’s share of losses in a joint venture equals
or exceeds its interests in the joint ventures (which includes
any long-term interests that, in substance, form part of the
Company’s net investment in the joint ventures), the Company
does not recognize further losses, unless it has incurred
obligations or made payments on behalf of the joint ventures.
Unrealized gains on transactions between the Company
and its joint ventures are eliminated to the extent of the
Company’s interest in the joint ventures. Unrealized losses
76 TECHINT E&C S.A. Annual Report 2017
>
>
>
are also eliminated unless the transaction provides evidence
of an impairment of the asset transferred.
Accounting policies of the joint ventures have been changed
where necessary to ensure consistency with the policies
adopted by the Company.
c. FoREIgN CuRRENCy TRANSlATIoN
i. FUnCTionAl AnD PrESEnTATion CUrrEnCy
Items included in the consolidated financial statements of each
entity in which TECHINT E&C holds participating interests are
measured using the currency that best reflects the economic
substance of the underlying events and circumstances relevant
to that entity (“the functional currency”). The consolidated
financial statements are presented in thousands of U.S. dollars
(USD), which is the functional currency of TECHINT E&C. The
consolidated companies’ first record transactions using their
functional currency and their financial statements are then
translated to USD with the only purpose of being consolidated
by TECHINT E&C.
ii. BAlAnCES AnD TrAnSACTionS in CUrrEnCiES
oThEr ThAn ThE FUnCTionAl CUrrEnCy
Transactions in currencies other than the functional currency
are accounted for at the exchange rates prevailing on the date
of the transactions, and the corresponding exchange gains
and losses are recognized in the income statement.
Monetary assets and liabilities in currencies other than
the functional currency are translated at the year end
exchange rate.
iii. TrAnSlATion oF BAlAnCES AnD rESUlTS oF ConSoliDATED
ComPAniES
The results and financial position of all the consolidated
companies that have a functional currency different from
the Company’s presentation currency, which is the currency
of a non-hyperinflationary economy, are translated into the
presentation currency as follows:
assets and liabilities of each balance sheet are translated at
the closing rate on the date of that balance sheet;
income and expenses for each income statement are
translated at an average exchange rate; (unless this average
is not a reasonable approximation of the cumulative effect of
the rates prevailing on the transaction dates, in which case
income and expenses are translated at the rate on the dates
of the transactions);
all resulting exchange differences are recognized as a
separate component of equity.
In the case of sale or other disposition of any such
subsidiary, any accumulated translation adjustment
would be recognized in the income statement as part
of the gain or loss on sales.
The financial statements of subsidiaries companies whose
functional currency is the currency of a hyperinflationary
economy are adjusted for inflation in accordance with the
procedure described in the following paragraph prior to
their translation to USD. Once restated, all the items of
the financial statements are converted to USD using the
closing exchange rate. Amounts shown for prior years for
comparative purposes are not modified.
To determine the existence of hyperinflation, TECHINT E&C
assesses the quantitative characteristics of the economic
environment of the country, such as the trends in inflation
rates over the previous three years. The financial statements
of companies whose functional currency is the currency of a
hyperinflationary economy are adjusted to reflect the changes
in purchasing power of the local currency, such that all
items in the statement of financial position not expressed in
current terms (non-monetary items) are restated by applying
a general price index at the financial statement closing date,
and all income and expense, profit and loss are restated
monthly by applying appropriate adjustment factors. The
difference between initial and adjusted amounts is taken to
profit or loss.
d. uSE oF ESTIMATES
The preparation of consolidated financial statements requires
Management to estimate and evaluate both recorded and
contingent assets and liabilities as of a certain date, as well
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 77
as income and expenses recorded during the reporting
period. The future actual results may differ from estimates
made as of the date of preparation of these consolidated
financial statements.
Estimates and judgments are continually evaluated and are
based on historical experience and other factors, including
expectations of future events that are believed to be
reasonable under the circumstances.
There follows a description of the most relevant estimates
used to prepare these consolidated financial statements:
PErCEnTAgE oF ComPlETion mEThoD
The Company uses the percentage-of-completion method in
accounting for its contract revenues and expenses. Use of
the percentage-of-completion method requires the Company
to estimate the services performed to date as a proportion
of the total services to be performed. Furthermore, in
determining the contract revenue, TECHINT E&C considers
the estimated outcome for each of the construction contracts
which are in progress.
inComE TAxES
The Company is subject to income taxes in numerous
jurisdictions. Significant judgment is required in determining
the worldwide provision for income taxes. There are
transactions and calculations for which the ultimate tax
determination is uncertain. TECHINT E&C recognizes
liabilities for anticipated tax audit issues based on estimates
of whether additional taxes will be due. Where the final tax
outcome of these matters is different from the amounts
that were initially recorded, such differences will impact the
current and deferred income tax assets and liabilities in the
period in which such determination is made.
mEASUrEmEnT oF ClAimS rECEiVABlES
The Company reviews its financial assets and financial
liabilities including its terms, maturities and discount
rates in order to adjust them to its realizable value or its
settlement value considering the time value of money and
other factors.
AllowAnCES For DoUBTFUl ACCoUnTS
Management maintains an allowance for trade and other
receivables to account for estimated losses resulting from
the inability of clients to make required payments. When
evaluating the adequacy of an allowance for trade receivables,
Management bases its estimates on the aging of accounts
receivable balances and historical write-off experience, client
credit worthiness and changes in client payment terms.
FAir VAlUE oF ProPErTy, PlAnT AnD EQUiPmEnT
According to the Group’s accounting policies, on December
31, 2017, and 2016, a technical valuation was carried out
by qualified external experts in relation to construction
equipment, machinery and vehicles, based on the valuations
of assets made do not substantially differ from their fair
value as of the date of the consolidated financial statements
(see note 4).
oThEr ESTimATionS
In addition, the Company’s Management makes estimations
to calculate, at certain moment the recoverable amounts
of assets, the depreciation and amortization, the provision
for cost and contingencies, the pension plans provision
and to assess annually whether an impairment of long-live
assets exists.
e. PRoPERTy, PlANT AND EquIPMENT (PP&E)
EQUiPmEnT, mAChinEry, VEhiClES AnD oThErS
As a general rule, TECHINT E&C has adopted historical
acquisition or construction cost less accumulated
depreciation as the measurement criterion for PP&E.
However, in the case of machinery, equipment and vehicles
used in the construction business, TECHINT E&C has
adopted fair value as the measurement criterion (see note 4).
Some machinery, construction equipment and vehicles
are valued at fair value, based on a technical appraisal
performed by independent professionals, less the
corresponding depreciation in the case of buildings.
Any accumulated depreciation at the date of revaluation
is eliminated against the gross carrying amount of the
78 TECHINT E&C S.A. Annual Report 2017
Buildings and improvements
Production equipment
Vehicles, furniture and fixtures, and other equipment
Lands
20-50 years
3-20 years
3-12 years
Not depreciated
asset, and the net amount is restated to the revalued
amount of the asset.
Increases in the carrying amount arising on revaluation of the
machinery, construction equipment and vehicles are credited
to other comprehensive income and shown as reserve for
PP&E revaluation surplus in shareholders’ equity. Decreases
that offset previous increases of the same asset are charged
to other comprehensive income and attributed to other
reserves in equity; all other decreases are charged to the
income statement. Each fiscal year the difference between
depreciation based on the revalued carrying amount of the
asset charged to the income statement and depreciation
based on the asset’s original cost is transferred from reserve
for PP&E revaluation surplus to retained earnings.
lAnDS AnD BUilDingS
Land and buildings are stated at historical cost. Buildings
are depreciated using the straight-line method, by applying
annual ratios sufficient to terminate the value of each item as
of the end of their estimated useful life.
The straight-line method had been used to calculate
depreciation, by applying annual ratios sufficient to
terminate the value of each item as of the end of their
estimated useful life.
FixED ASSETS oF FErroExPrESo PAmPEAno S.A.C. (“FEPSA”)
These assets represent improvements on the assets
received under concession by FEPSA, as well as those
devoted to service rendering, which will be transferred to
the assignor upon termination of the concession.
Such assets were valued at their acquisition or
construction cost less accumulated depreciation.
The straight-line method had been used to calculate
depreciation, by applying annual ratios sufficient to terminate
the value of each item as of the end of their estimated useful
life or upon termination of concession, whichever occurs first.
USEFUl liVES USED To CAlCUlATE DEPrECiATion ChArgES ArE
AS FollowS:
The residual values and useful lives of significant machinery,
construction equipment and vehicles are reviewed, and
adjusted if appropriate, at each year end date.
Where the carrying amount of an asset is higher than
its estimated recoverable amount, it is written down
immediately to its recoverable amount.
Gains and losses on disposals are determined by comparing
proceeds with carrying amounts. When revalued assets
are sold, the amounts included in the reserve for PP&E
revaluation surplus are transferred to retained earnings.
Repairs and maintenance expenses are charged to the
consolidated income statement during the financial year in
which they are incurred.
f. INTANgIBlE ASSETS
SySTEmS DEVEloPmEnT
Acquired computer software licenses are capitalized on
the basis of the costs incurred to acquire and bring to use
the specific software. These costs are amortized over their
estimated useful lives (three to five years).
Costs associated with developing or maintaining computer
software programs are charged to expenses as incurred.
Costs that are directly associated with the production of
identifiable and unique software products controlled by
TECHINT E&C and that will probably generate economic
benefits exceeding costs beyond one year, are recognized
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 79
as intangible assets. Direct costs include the software
development employee costs and an appropriate portion of
relevant overhead.
Computer software development costs recognized as assets
are amortized over their estimated useful lives (not exceeding
three years).
oThEr
Compañía Inversora Ferroviaria S.A.I.F. (“CoINFER”)
Other intangible assets represent the greater cost derived
from the investment in the subsidiary FEPSA as a result of
the compulsory subscription and payment of the portion
of capital corresponding to Ferrocarriles Argentinos (16%)
and the portion corresponding to staff (4%) pursuant to the
concession contract.
It is valued at original cost, less accumulated amortization; it
was calculated over the term of the concession of the service
provided by FEPSA.
g. IMPAIRMENT oF NoN-FINANCIAl ASSETS
Intangible assets having an indefinite useful life or intangible
assets not in condition to be reused are not subject to
depreciation and, on an annual basis, are reviewed for
impairment losses.
Property and equipment and other non-current assets subject
to depreciation, including intangible assets, are reviewed
for impairment losses whenever events or changes in
circumstances indicate that the carrying amount may not be
recoverable.
An impairment loss is recognized for the amount by
which the carrying amount of the asset exceeds its
recoverable amount, which is the higher of an asset
net selling price and its value in use. For the purposes
of assessing impairment, assets are grouped at the
lowest levels for which there are separately identifiable
cash flows.
Prior impairment losses of non-financial assets (other than
goodwill value) are reviewed for possible reversal on each date
on which the consolidated annual accounts are presented.
h. FINANCIAl ASSETS
The Company classifies its financial assets in the following
categories: at fair value through profit or loss, loans and
receivables, available for sale, and financial assets at amortized
cost. The classification depends on the purpose for which the
financial assets were acquired. Management determines the
classification of its financial assets at initial recognition.
Financial assets at fair value through profit or loss
Financial assets at fair value through profit or loss are
financial assets held for trading. A financial asset is classified
in this category if acquired principally for the purpose of
selling in the short-term.
Derivatives are also categorized as held for trading unless
they are designated as hedges. Assets in this category are
classified as current assets.
loans and receivables
Loans and receivables are non-derivative financial assets with
fixed or determinable payments that are not quoted in an
active market. They are included in current assets, except for
those with maturities greater than 12 months after the date
of the statement of financial position. These are classified as
non-current assets.
Available-for-sale financial assets
Available-for-sale financial assets are non-derivatives that are
either designated in this category or not classified in any of
the other categories. They are included in non-current assets
unless management intends to dispose of the investment
within 12 months of the end of the reporting year.
Financial assets at amortized cost
The company classifies its financial assets as at amortized
cost only if both of the following criteria are met: the asset is
80 TECHINT E&C S.A. Annual Report 2017
held within a business model with the objective of collecting
the contractual cash flows, and the contractual terms give
rise on specified dates to cash flows that are solely payments
of principal and interest on the principal outstanding.
Recognition and measurement
Regular purchases and sales of financial assets are
recognized on the trade - date - the date on which the
Company commits to purchase or sell the asset. Investments
are initially recognized at fair value plus transaction costs
for all financial assets not carried at fair value through profit
or loss. Financial assets carried at fair value through profit
or loss are initially recognized at fair value and transaction
costs are expensed in the income statement.
Financial assets are derecognized when the rights to receive
cash flows from the investments have expired or have
been transferred and the Company has transferred
substantially all risks and rewards of ownership. Available-
for-sale financial assets and financial assets at fair value
through profit or loss are subsequently carried at fair value
except Other investments as described in note 2.m. Loans
and receivables are carried at amortized cost using the
effective interest method.
The Company assesses at each balance sheet date whether
there is objective evidence that a financial asset or a group
of financial assets is impaired. A financial asset or a group
of financial assets is impaired and impairment losses are
incurred only if there is objective evidence of impairment
as a result of one or more events that occurred after the
initial recognition of the asset (a ‘loss event’) and that loss
event (or events) has an impact on the estimated future cash
flows of the financial asset or group of financial assets that
can be reliably estimated. In the case of equity investments
classified as available-for-sale, a significant or prolonged
decline in the fair value of the security below its cost is
considered an indicator that the assets are impaired.
i. oFFSETTINg FINANCIAl INSTRuMENTS
Financial assets and liabilities are offset and the net amount
reported in the statement of financial position when there is
a legally enforceable right to offset the recognized amounts
and there is an intention to settle on a net basis, or realize the
asset and settle the liability simultaneously.
The legally enforceable right must not be contingent on future
events and must be enforceable in the normal course of
business and in the event of default, insolvency or bankruptcy
of the company or counterparty.
j. DERIvATIvE FINANCIAl INSTRuMENTS
Derivatives are initially recognized at fair value on the date a
derivative contract is entered into and are subsequently re-
measured at their fair value.
The method of recognizing the resulting gain or loss depends
on whether the derivative is designated as a hedging
instrument, and if so, the nature of the item being hedged.
The Company adopts hedge accounting and designates
derivatives as either:
Hedges of the fair value of recognized assets or liabilities
or a firm commitment (fair value hedge).
Hedges of a particular risk associated with a recognized
asset or liability or a highly probable forecast transaction
(cash flow hedge).
Hedges of a net investment in a foreign operation (net
investment hedge).
The Company documents at the inception of the transaction
the relationship between hedging instruments and hedged
items, as well as its risk management objectives and
strategy for undertaking various hedging transactions.
TECHINT E&C also documents its assessment, both at
hedge inception and on an ongoing basis, of whether the
derivatives that are used in hedging transactions are highly
effective in offsetting changes in fair values or cash flows
of hedged items.
CASh Flow hEDgE
Trading derivatives are classified as a current asset or liability.
The full fair value of a hedging derivative is classified as
a non-current asset or liability if the remaining maturity
>
>
>
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 81
of the hedged item is more than 12 months and, as a current
asset or liability, if the maturity of the hedged item is less
than 12 months.
The effective portion of changes in the fair value of derivatives
denominated and qualified as cash flow hedging is disclosed
in Other Comprehensive Income. The gain or loss related
to the ineffective portion is immediately disclosed in the
consolidated income statement.
The amounts accumulated in equity are disclosed in the
consolidated income statement in the year in which the
hedged item affects gains and losses.
When a hedging instrument expires or is sold, or when a
hedge no longer meets the criteria for hedge accounting,
any cumulative gain or loss existing in equity at that time
remains in equity and is recognized when the forecast
transaction is ultimately recognized in the consolidated
income statement. When a forecast transaction is no
longer expected to occur, the cumulative gain or loss that
was reported in equity is immediately transferred to the
consolidated income statement.
ForwArD ForEign ExChAngE ConTrACTS
The hedged highly probable forecast transactions
denominated in foreign currency are expected to occur at
various dates during the next 12 months. Gains and losses
recognized in the hedging reserve in equity on forward
foreign exchange contracts as of 31 December 2017 and
2016 are recognized in the income statement in the period
or periods during which the hedged forecast transaction
affects the income statement. In general, this happens within
12 months following the date of the consolidated financial
statements, unless the loss or gain would have been included
in the amount initially recognized for the purchase of fixed
assets, in which case such recognition is made throughout
the useful life of the asset.
k. INvENToRIES
Inventories are stated at the lower of cost or net realizable
value less the corresponding allowance for obsolescence. Net
realizable value is the estimated selling price in the ordinary
course of business, less the costs of completion and direct
selling expenses. In general, cost is determined by using
weighted average price.
The allowance for obsolescence has been calculated based
on Management’s analysis of aging.
l. CoNSTRuCTIoN CoNTRACTS woRK IN PRogRESS
A construction contract is a contract specifically negotiated
for the construction of an asset or a combination of assets
that are closely interrelated or interdependent in terms of
their design, technology and functions or their ultimate
purpose or use.
When the outcome of a construction contract can be
reliably estimated, contract revenue and contract costs are
acknowledged by the percentage of completion method.
The stage of completion is measured by reference to the
relationship contract costs incurred for work performed
to date bear to the estimated total costs for the contract.
When it is probable that total contract costs will exceed
total contract revenue, the expected loss is immediately
recognized as an expense.
When the outcome of a construction contract cannot be
reliably estimated, contract revenue is recognized to the
extent of contract costs incurred where it is probable those
costs will be recoverable. Contract costs are recognized
when incurred.
Costs incurred in the year in connection with future activity
on a contract are excluded from contract costs in determining
the stage of completion. They are presented as inventories,
prepayments or other assets, depending on their nature.
When a construction contract includes reimbursable works
and the Company is responsible for providing design,
engineering and construction services and labor and all
equipment and materials, construction equipment and
supplies, the amount of these works is recognized in
revenues and costs.
82 TECHINT E&C S.A. Annual Report 2017
TECHINT E&C shows as an asset (within Construction
contracts work in progress) the gross amount due from
clients for construction contracts for all contracts in progress
for which costs incurred plus recognized profits (less
recognized losses) exceed progress billings.
TECHINT E&C presents as a liability (within Construction
contracts work in progress) the gross amount due to clients
for construction contract for all contracts in progress for
which progress billings exceed costs incurred plus recognized
profits (less recognized losses).
m. oTHER INvESTMENTS
Other investments consist primarily of deposits in investments
funds and equity instruments where the Company holds a
minor equity interest and does not exert significant influence.
All other investments are classified as financial assets “loans
and receivables” or “available for sale”.
For investments in equity instruments in which TECHINT E&C
has less than 20% of the voting rights, the Company usually
chooses to use the historical cost, because its fair value
cannot be reliably measured.
n. TRADE AND oTHER RECEIvABlES
Trade and other receivables are initially measured at their
fair value, which is generally their nominal value, unless the
effect of discounting is material, subsequently measured at
amortized cost less provision for impairment.
An allowance for doubtful accounts is established when there
is objective evidence that the Company will not be able to
collect all amounts due according to the original terms of
receivables.
SErViCE ConCESSion ArrAngEmEnTS
A service concession arrangement is an arrangement
involving an operator for the construction, improvement
or management of the infrastructure used to provide a
public service for a specified period of time. The operator
is paid for its services over the period of the arrangement.
The arrangement is governed by a contract that sets out
performance standards, mechanisms for adjusting prices and
arrangements for arbitrating disputes. The grantor controls
the infrastructure, and the operator is required to return to
the grantor the infrastructure at the end of the arrangement.
The operator has an unconditional contractual right to receive
payments from the grantor, irrespective of the amount of use
made of the infrastructure.
Techint E&C recognises a financial asset arising from
a service concession arrangement to the extent that it
has an unconditional right to receive cash from or at the
direction of the grantor, for the construction improvement
or management of concession assets. Financial assets
recognised as a result of the service concession
arrangement are measured at fair value upon initial
recognition. Subsequent to initial recognition, the financial
asset is accounted for in accordance with IAS 39 (Financial
Instruments: Recognition and Measurement) and, therefore,
at amortized cost or at fair value through profit or loss.
Financial assets arising from a service concession arrangement
are included within “Trade and other receivables”. The financial
income calculated on the basis of the effective interest rate is
recognised under operating income.
o. TRADE AND oTHER PAyABlES
Trade and other payables are obligations to pay for goods
or services that have been acquired in the ordinary course
of business from suppliers. Accounts payable are classified
as current liabilities if payment is due within one year or less.
If not, they are presented as non-current liabilities.
Trade and other payables are recognized initially at fair value
and subsequently measured at amortized cost.
p. CASH AND CASH EquIvAlENTS
Assets recorded in cash and cash equivalents are carried at
fair market value or at historical cost which approximates fair
market value. For the purposes of the consolidated statement
of cash flows, cash and cash equivalents comprise cash on
hand, demand deposits with banks and other short-term
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 83
highly liquid investments with original maturities of three
months or less and bank overdrafts.
Bank overdrafts are included within borrowings in current
liabilities in the consolidated statement of financial position.
q. EquITy
Ordinary shares are classified as equity. The balances of the
consolidated statement of changes in equity at December 31,
2017 and 2016 include:
The value of share capital, reserve for PP&E revaluation
surplus, reserve for cash flow hedge, legal reserve, reserve
for pension plan benefits, reserve for future dividends and
retained earnings in accordance with IFRS.
The currency translation differences of TECHINT E&C’s subsidiaries.
Capital Surplus
Non-controlling interests in subsidiaries.
Dividends distributions are recorded in the Company’s
financial statements when Company’s shareholders have the
right to receive the payment, or when interim dividends are
approved by the Board of Directors in accordance with the
by-laws of the Company.
r. BoRRowINgS
Borrowings are initially recorded based on the fair value
of the net proceeds. Borrowings are subsequently stated
at amortized cost using the effective yield method; any
difference between proceeds (net of transaction costs) and
the redemption value is recognized in the income statement
over the life of the borrowings.
Borrowings are classified as current liabilities unless TECHINT
E&C has an unconditional right and firm intention to defer
settlement of the liability for at least twelve months after the
balance sheet date.
s. CuRRENT AND DEFERRED INCoME TAX
The current income tax charge is calculated on the basis of
the tax laws in force in the countries in which TECHINT E&C
and each one of its subsidiaries operate.
Deferred income tax is recorded in full, using the liability
method, on temporary differences arising between the tax
basis of assets and liabilities and their carrying amounts in
the consolidated financial statements. Currently enacted tax
rates are used in the determination of deferred income tax.
Deferred tax assets are recognized to the extent that it is
probable that future taxable profit will be available to offset
temporary differences.
Deferred income tax is provided on temporary differences
arising on investments in subsidiaries, associated companies
and joint operations, except where the timing of the reversal
of the temporary difference can be controlled and it is
probable that the temporary difference will not reverse in the
foreseeable future.
The tax expense for the year comprises current and deferred
tax. Tax is recognized in the Consolidated Income Statement,
except to the extent that it relates to items recognized in
the Consolidated Statement of Comprehensive Income.
In this case, the tax is also recognized in the Consolidated
Statement of Comprehensive Income.
t. EMPloyEE BENEFITS
PEnSion PlAnS AnD oThEr PoST-rETirEmEnT BEnEFiTS
Certain TECHINT E&C’s subsidiaries have in force benefit
plans under the modality of “non-funded defined benefits”
and “other long-term benefits” which, subject to certain
conditions established by such companies, are granted during
the term of employment and after retirement, which plans
are recorded following the guidelines of accounting rules and
regulations in force and effect.
The provisioned liabilities for such employee benefits are
recorded at the current value of the future flows of funds,
the amount being charged during the relevant employees’
remaining years of services up to the moment when the
conditions necessary for the granting of each benefit are
satisfied. Such liabilities are calculated by independent
actuaries, at least once a year, using the “Projected credit
unit” method.
>
>
>
>
84 TECHINT E&C S.A. Annual Report 2017
Actuarial gains and losses arising from experience
adjustments and changes in actuarial assumptions are
charged or credited to equity in other comprehensive
income in the period in which they arise. Past-service
costs are recognized immediately in income. Actuarial
gains and losses arising from other post-retirement
benefits are recognized immediately in income.
Certain TECHINT E&C’s subsidiaries officers are covered
by a specific employee retirement plan designed
to provide retirement, termination and other benefits
to those officers.
Retirement costs are assessed using the projected unit
credit method: the cost of providing retirement benefits is
charged to the statement of income over the service lives
of employees based on actuarial calculations. This provision
is measured at the present value of the estimated future
cash outflows, using applicable interest rates.
Certain TECHINT E&C’s subsidiaries are accumulating
assets for the ultimate payment of those benefits in the
form of investments. The investments are not part of a
particular plan, nor are they segregated from TECHINT
E&C’s other assets. Due to these conditions, the plan is
classified as “unfunded” under IFRS.
The laws in the different countries in which TECHINT E&C’s
subsidiaries carry out their operations provide for pension
benefits to be paid to retired employees from government
pension plans and/or private funds managed plans.
Amounts payable to such plans are generally calculated
based on a percentage of employee salaries and are
accounted for on an accrual basis.
TErminATion BEnEFiTS
Termination benefits are payable whenever an employee’s
employment is terminated before the normal retirement
date or whenever an employee accepts voluntary
redundancy in exchange for these benefits.
TECHINT E&C’s subsidiaries recognize termination benefits
when it is demonstrably committed to either terminating
the employment of current employees according to a
detailed formal plan without possibility of withdrawal, or
providing termination benefits as a result of an offer made to
encourage voluntary redundancy. Benefits falling due more
than twelve months after balance sheet date are discounted
to present value.
ProFiT-ShAring AnD BonUS PlAnS
A liability for employee benefits in the form of profit-sharing
and bonus plans is recognized in other provisions when there
is no realistic alternative but to settle the liability and provided
at least one of the following conditions is met:
there is a formal plan and the amounts to be paid are
determined before the time of issuing the financial
statements; or
past practice has created a valid expectation in employees that
they will receive a bonus/profit-sharing and the amount can be
determined before the financial statements are issued.
Liabilities for profit-sharing and bonus plans are expected to
be settled within twelve months and are measured at the
amounts expected to be paid when they are settled.
ConTriBUTion PlAnS
A defined contribution plan is a pension plan under which
the companies pay fixed contributions to a separate entity.
Companies have no further payment obligations once
the contributions have been paid. The contributions are
recognized as employee benefit expense when they are
due. Prepaid contributions are recognized as an asset to
the extent that a cash refund or a reduction in the future
payments is available.
Contributions by the companies include: (a) Basic
contribution – Companies are committed to contribute
amounts equal to the amounts contributed by the
>
>
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 85
employees up to certain limits, (b) Extraordinary
contributions – Companies are non-mandatory contributions
that can be made on a voluntary basis either by the
companies or the employees.
TEBRA has implemented a supplementary pension
benefit plan with two programs: “PGBL - Plano Gerador
de Benefício Livre” and “ VGBL - Programa de Seguro de
Vida com Cobertura por Sobrevivência”. These programs
are generally funded through payments by the subsidiaries
to independent insurance companies. Both programs are
defined contribution plans.
long-TErm inCEnTiVE
TECHINT E&C adopted a long-term retention and incentive
program for some employees of Group. According to such
program, certain senior executives of Group shall receive a
number of units valued at the book value of the Shareholders’
Equity per share of TECHINT E&C (excluding the non-
controlling interest).
Units shall accrue within a 4-year period and the applicable
subsidiaries shall pay them upon the lapsing of a 10-year
period from the date of receipt, with the option for the
employee to request them as from the seventh year,
or when the relationship between the employee and
Group is terminated, at the book value of the controlling
Shareholders’ Equity per share of TECHINT E&C at the
time of payment. The beneficiaries shall also receive
amounts in cash equivalent to the dividend paid per
share, every time TECHINT E&C pays any dividend in cash
to its shareholders.
As of December 31 , 2017 and 2016, TECHINT E&C has
acknowledged non-current liabilities for USD 14,284 and USD
12,974, respectively. The charge to profits as of December
31, 2017 and 2016 for the sum of USD 3,475 and USD
152 respectively, is stated in the line “Wages salaries and
social security costs” in note 27 and in “Foreign exchange
transaction results” in note 28.
PUBliC AnD PriVATE ConTriBUTionS PEnSion PlAn
The laws applicable in the different countries in which the
subsidiaries carry out their businesses establish pension
and retirement benefits to be payable to retired employees
under government retirement plans and/or private retirement
plans. The amounts payable for such plans are calculated, in
general, based on a percentage of employees’ salaries and
are recorded according to the accrual basis of accounting.
u. PRovISIoNS
Provisions are recognized when TECHINT E&C has a present
legal or constructive obligation as a result of past events, it
is probable that an outflow of resources will be required to
settle the obligation, and a reliable estimate of the amount
can be made. When TECHINT E&C expects a provision to be
reimbursed, for example under an insurance contract, the
reimbursement is recognized as a separate asset but only
when the reimbursement is virtually certain.
v. REvENuE RECogNITIoN
rEVEnUES AnD CoST rECogniTion For long-TErm
ConSTrUCTion ConTrACTS
See note 2.l.
SAlES oF SErViCES
The Company sells maintenance services. The revenue is
generally recognized in the period the services are provided,
using a straight-line basis over the term of the contract.
oThEr rEVEnUES
Other revenues earned by TECHINT E&C are recognized on
the following bases:
Interest income: on the effective yield basis.
Dividend income from investments in other companies:
when TECHINT E&C’s right to collect is established.
w. lEASES
Leases in which a significant portion of the risks and rewards
of ownership are transferred from the lessor to TECHINT E&C
>
>
86 TECHINT E&C S.A. Annual Report 2017
are classified as finance leases. At the commencement of
the lease term, TECHINT E&C recognizes finance leases as
assets and liabilities in the statement of financial position at
amounts equal to the value of the leased property or, if lower,
the present value of the minimum lease payments, each
determined at the inception of the lease. The discount rate
used in calculating the present value of the minimum lease
payments is the interest rate implicit in the lease should
this be practicable to determine; otherwise, the lessee’s
incremental borrowing cost is used. Any initial direct costs of
the lessee are added to the amount recognized as an asset.
Each lease payment is allocated between the liability and
finance charges. The corresponding rental obligations, net
of finance charges, are included in borrowings. The interest
element of the finance cost is charged to the income
statement over the lease period so as to produce a constant
periodic rate of interest on the remaining balance of the
liability for each period. The property, plant and equipment
acquired under finance leases is depreciated over their
estimated useful lives.
See amounts of assets and liabilities held under finance
leases in note 22.
Leases in which a significant portion of the risks and rewards
of ownership are retained by the lessor are classified as
operating leases. Payments made under operating leases
(net of any incentives received from the lessor) are charged
to the income statement on a straight-line basis over the
period of the lease.
x. ASSETS oF DISPoSAl gRouP ClASSIFIED AS HElD FoR SAlE
Assets of disposal group are classified as “assets classified
as held for sale” when their carrying amount is to be
recovered principally through a sale transaction and a sale is
considered highly probable.
They are stated at the lower of carrying amount and fair value
less costs to sell if their carrying amount is to be recovered
principally through a sale.
NoTE 3.
FINANCIAl RISK MANAgEMENT
The nature of TECHINT E&C’s operations as well as its
multinational character expose the Company to a variety of
risks, including the effects of changes in foreign currency,
exchange rates, capital risk, concentration of credit risk,
price risk, liquidity risk and interest rates risk. The nature of
its contracts implies that TECHINT E&C has to manage risks
regarding uncertain conditions in the hiring of procurement,
which is usually a large part of the scope of work.
To manage the high volatility related to these financial
matters, management evaluates exposures on a
consolidated basis to take advantage of its global and
multinational activity.
For some of these exposures, the Company or its
subsidiaries enter into derivative transactions in order
to manage potential adverse impacts on the Company’s
financial performance.
a. CAPITAl RISK
The Company seeks to maintain an adequate debt to total
equity ratio considering the risks involved in the industry
and the markets where it operates. The year-end ratio of
debt to total equity (where “debt” comprises all financial
borrowings and “equity” is the sum of financial borrowings
and shareholders equity) is 0.16 as of December 31,
2017 and 0.20 as of December 31, 2016. The Company
does not have to comply with regulatory capital adequacy
requirements.
b. FoREIgN EXCHANgE RISK
TECHINT E&C’s business activities are conducted in
the respective functional currencies of the subsidiaries.
However, the Company transacts in currencies other than
the respective functional currencies of the subsidiaries.
There are significant monetary balances held by
the Company at the twelve-month year-end that are
denominated in USD.
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 87
The following tables show a breakdown of the TECHINT
E&C’s net monetary position in various currencies for the
main functional currency in which the Company operates:
USD
EUR
ARS
UYU
PLN
Others
Functional Currency
173,550
(179)
30
43
(25,747)
(1,381)
146,316
Total
(1,336)
(933)
–
–
–
774
(1,495)
others
8,254
(84)
3
–
–
–
8,173
UyU
–
5,081
27
43
–
(794)
4,357
USD
3,711
(109)
–
–
–
–
3,602
SAr
21,730
–
–
–
–
–
21,730
PEn
43,603
471
–
–
–
292
44,366
mxn
(3,421)
–
–
–
(25,747)
(1,653)
(30,821)
EUr
55,886
–
–
–
–
–
55,886
Chl
(15,167)
(3,774)
–
–
–
–
(18,941)
Brl
60,290
(831)
–
–
–
–
59,459
ArSnet monetary position Asset / (liability)
Dec 31, 2017
88 TECHINT E&C S.A. Annual Report 2017
The Company estimates that the impact under IFRS on the net
exposure at December 31, 2017 of a simultaneous 1% favorable
or unfavorable movement in the main exchange rates would
result in a maximum pre-tax gain or loss of approximately USD
1,463 as compared with a maximum pre-tax gain or loss of
approximately USD 1,676 at December 31, 2016.
The Company’s net exposure to the currency other than the
functional currency is managed on a case-by-case basis,
partly by hedging certain expected cash flows with foreign
exchange derivative contracts.
The Company performed a sensitive analysis of the
Derivative Financials Instruments of a 10% favorable or
unfavorable movement of the Mexican Peso against the
USD at December 31, 2017 and 2016. The impact would
have been, in the case of strengthening USD (8,803) in
equity and USD (1,314) in profit or (loss) (at December 31,
2016: USD (6,197) and USD (4,630) respectively) and
in the case of weakening USD 10,760 in equity and USD
1,606 in profit or (loss) (at December 31, 2016: USD 7,574
and USD 5,659 respectively).
EUR: Euro PLN: Polish Zloty RUB: Ruble SAR: Saudi royal UYU: Uruguayan Peso
Reference: ARS: Argentinian Peso BRL: Brazilian Real MXN: Mexican Peso PEN: Peruvian Nuevo Sol CHL: Chilean Peso
USD
EUR
ARS
UYU
PLN
RUB
Others
187,541
860
(106)
(29)
(18,850)
(560)
(1,268)
167,588
Total
325
4,420
–
(29)
–
–
–
4,716
others
5,740
–
(106)
–
–
–
–
5,634
UyU
3,668
(220)
–
–
–
–
–
3,448
SAr
27,744
–
–
–
–
–
–
27,744
PEn
98,614
822
–
–
–
–
–
99,436
mxn
5,018
–
–
–
(18,850)
(560)
(1,268)
(15,660)
EUr
65,264
–
–
–
–
–
–
65,264
Chl
(9,520)
(4,174)
–
–
–
–
–
(13,694)
Brl
(9,312)
12
–
–
–
–
–
(9,300)
ArSnet monetary position Asset / (liability)
Functional Currency
Dec 31, 2016
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 89
c. PRICE RISK
The Company has no significant risk from the fluctuation in
the market prices.
The group´s investments in equity, classified on the
consolidated balance sheet as available for sale, are not
publicly traded and are valued at cost.
Cash and cash equivalents and other investments classified
as fair value through profit or loss, are carried at fair
market value or at historical cost which approximates fair
market value.
d. CREDIT RISK
Most accounts receivable relate to clients operating in a
range of industries and countries with contract which require
ongoing payments as the development project progresses,
upon the rendering of services or upon completion and
delivering of the project. It is normal practice that the
Company reserves the right to suspend the project if there
is a remarkable breach of the contract term, in particular the
non-payment of amounts owed.
In general the greatest risk for such assets is the risk of not
collecting a trade account receivable. This is because, a) it may be
a significant value in the development of works or in the provision
of services; b) it is beyond the Company’s control. However,
the risk of customers being unable to make a payment in such
contracts is considered to be low, and typically relate to problems
characterized as technical matters, i.e. relating to the risk inherent
in the service rendered, under the Company’s control.
The Company’s receivables (other than those with related
parties) are concentrated on a limited number of clients for
whom works are executed. Management evaluates on a
periodic basis the financial condition of its clients to minimize
the risk of non-collection of its accounts receivable.
The following table sets forth details of the age of trade
receivables:
December 31, 2017
Trade Receivables
Allowance for doubtful accounts (*)
Net value
December 31, 2016
Trade Receivables
Allowance for doubtful accounts (*)
Net value
30,658
(9,043)
21,615
26,903
(9,858)
17,045
451,767
–
451,767
316,178
–
316,178
47,405
(719)
46,686
126,832
–
126,832
529,830
(9,762)
520,068
469,913
(9,858)
460,055
> 180 days (**)1 - 180 days
Past DueNot Due Trade Receivables
8
8
8
8
Notes
> 180 days (**)1 - 180 days
Past DueNot Due Trade Receivables
Notes
(*) It does not include Allowance for doubtful accounts recorded in current other receivables-net (USD 707).
(**) With respect to trade receivables that have due more than 180 days non-provisioned, there is no risk of doubtful accounts.
(*) It does not include Allowance for doubtful accounts recorded in current other receivables-net (USD 337).
(**) With respect to trade receivables that have due more than 180 days non-provisioned, there is no risk of doubtful accounts.
90 TECHINT E&C S.A. Annual Report 2017
The credit quality of financial assets that are neither
past due nor impaired can be assessed by reference to
historical information about counterparty default rates. The
total unimpaired trade receivables are related to existing
customers and related parties with no defaults past due.
At the date of this consolidated financial statements most
credits past due have been collected.
e. lIquIDITy RISK
Management maintains sufficient cash and cash equivalents
to finance normal operations and believes that TECHINT E&C
also has access to capital markets for short-term working
capital requirements.
TECHINT E&C financing strategy is to maintain adequate
financial resources and access to additional liquidity.
During the year ended December 31, 2017 and 2016,
TECHINT E&C has counted on cash flows from
operations as well as additional bank financing to fund
its transactions.
TECHINT E&C has a conservative approach to the
management of its liquidity, which consists of cash
and cash equivalents, comprising cash in banks,
short-term money market funds and highly liquid
short-term securities.
TECHINT E&C holds its cash and cash equivalents primarily
in USD. Liquid financial assets as a whole are 22% of total
assets at December 31, 2017 (15% at December 31, 2016).
Liquidity is managed through the analysis of expected inflows
and outflows monitored by the Treasury department.
See note 14 for the maturity of borrowings, note 16 for the
maturity of trade and other payables and note 17 for the
maturity of other liabilities.
f. INTEREST RATE RISK MANAgEMENT
The Company’s financing strategy is to manage interest
expense using a mixture of fixed-rate and variable-rate debt.
The proportions of variable-rate and fixed-rate debt at the
years ended in 2017 and 2016 are included in note 14.
As the Company has no significant interest-bearing assets, the
Company’s income and operating cash flows are substantially
independent from changes in market interest rates.
The Company estimated that, if interest rates would have
been 100 basis points higher, with all other variables held
constant, total profit for the year ended December 31, 2017
would have been USD 1,025 lower (USD 912 lower for the
year ended December 31, 2016)
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 91
lands and buildings
other Assets (1)
VehiclesEquipment and machinery
NoTE 4.
PRoPERTy, PlANT AND EquIPMENT (PP&E)
The item consists in the following:
The item evolution is as follows:
Land and buildings
Equipment and machinery
Vehicles
Other assets
Total December 31, 2017
(24,680)
(132,136)
(37,514)
(53,900)
(248,230)
101,874
246,131
71,663
88,146
507,814
77,194
113,995
34,149
34,246
259,584
Beginning of the year
Additions
Disposals
Depreciation
Translation differences
Changes in reserve of PP&E
Impairment loss
Others movements
December 31, 2017
33,940
11,952
(87)
(9,828)
(2,894)
1,214
(51)
–
34,246
35,277
9,357
(1,713)
(8,218)
(3,871)
3,404
(40)
(47)
34,149
122,982
23,218
(7,987)
(23,609)
(8,455)
7,901
(102)
47
113,995
80,065
215
(66)
(2,911)
(109)
–
–
–
77,194
272,264
44,742
(9,853)
(44,566)
(15,329)
12,519
(193)
–
259,584
Non-current TotalDec 31, 2017
(1) It includes deferred costs of our subsidiary FEPSA and miscellaneous assets.
Accumulated Depreciation
gross value
Net valueDec 31, 2017
92 TECHINT E&C S.A. Annual Report 2017
Lease rentals amounting to USD 57,061 (at December
31, 2016: USD 50,761) relating to the lease of machinery,
construction equipment and vehicles, are included in the
consolidated income statement.
The item consists in the following:
Land and buildings
Equipment and machinery
Vehicles
Other assets
Total December 31, 2016
The item evolution is as follows:
Beginning of the year
Additions
Disposals
Depreciation
Translation differences
Changes in reserve of PP&E
Impairment loss
Others movements
December 31, 2016
35,249
13,605
(778)
(9,137)
(4,458)
28
–
(569)
33,940
43,933
4,323
(3,248)
(8,936)
(2,634)
3,150
(880)
(431)
35,277
132,228
16,320
(7,216)
(22,026)
(8,422)
17,000
(4,648)
(254)
122,982
75,825
519
(164)
(2,794)
5,936
–
–
743
80,065
287,235
34,767
(11,406)
(42,893)
(9,578)
20,178
(5,528)
(511)
272,264
other Assets (1)
VehiclesEquipment and machinery
lands and buildings
(1) It includes deferred costs of our subsidiary FEPSA and miscellaneous assets.
(23,241)
(126,184)
(37,748)
(56,478)
(243,651)
103,306
249,166
73,025
90,418
515,915
Accumulated Depreciation
gross value
80,065
122,982
35,277
33,940
272,264
Net valueDec 31, 2016
Non-current TotalDec 31, 2016
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 93
TECHNICAl APPRAISAl oF PP&E
On December 31, 2017 and 2016, a technical appraisal was
performed by external professionally qualified valuation
specialists in relation to machinery, construction equipment
and vehicles, based on periodic valuations of the assets
in order not to differ materially from their fair value at
the financial statements date. The Company’s Directors
believe that recording machinery, construction equipment
and vehicles at fair value results in a more appropriate
presentation of these assets in the consolidated financial
statements of the Company.
Revaluations are performed by independent qualified valuers on
a regular basis. In the intervening periods between independent
revaluations, the Company reviews the carrying values of
machinery, construction equipment and vehicles and adjustment
is made where the carrying value exceeds from fair value.
Management believes that the resulting value approximates
fair value. As per International Accounting Standard No. 16
“Property, plant and equipment” (“IAS 16”), when an item
of property, plant and equipment is revalued, the entire class
of property, plant and equipment to which that asset belongs
should be revalued. Machinery, construction equipment and
vehicles corresponding to the subsidiaries that did not make
the abovementioned revaluation are not significant.
The “sales comparison” method was used to obtain the
fair value of these assets for which there is a wide and
transparent secondary market. This approach consists
in obtaining information from recent sales or offers of
assets bearing similar characteristics, age and condition.
Correction factors that take into account the status of the
market offer and demand prevailing as of the date of the
appraisal, the relative age, probable residual useful life, state
of conservation and asset obsolescence are applied to the
sales price. The “cost less depreciation” method was used to
obtain the fair value of assets with a restricted sales market.
Depreciation was computed based on generally used and
accepted engineering criteria which led to establishing the
reasonable value of PP&E. Such criteria take into account
factors such as the age of each asset, probable residual
or expected life, state of conservation and degree of
obsolescence. The market value was obtained by applying the
depreciation ratio to the value of a new asset.
These subsidiaries intend to perform this appraisal with the
frequency required by IAS 16 in order to keep fair values of
appraised assets updated.
The increase in value of machinery, construction equipment
and vehicles resulting from the technical appraisal performed
on December 31, 2017 amounted to USD 12,519 (at
December 31, 2016: USD 20,178) and has been recorded net
of tax effect USD 1,321 (at December 31, 2016: USD 5,432)
in other comprehensive income and accumulated in equity
under the heading of “Reserve for PP&E revaluation surplus”
and “Non-controlling interests”.
The depreciation of the Reserve for PP&E revaluation surplus
net of tax effects for the year ended December 31, 2017
amounts to USD 17,858 (at December 31, 2016: USD 16,489).
Additionally, during the year ended December 31, 2017, the
company recorded a decrease of such reserve amounting to
USD 5,969 net of tax (at December 31, 2016: USD 2,951) due
to disposal of PP&E.
If machinery, equipment and vehicles had been valued at
historical cost, the values would have been the following:
Historical cost
Accumulated depreciation
Residual value
167,084
(97,443)
69,641
164,128
(97,819)
66,309
Dec 31, 2017 Dec 31, 2016
94 TECHINT E&C S.A. Annual Report 2017
The “Reserve for PP&E revaluation surplus” is reversed, net
of tax effects, through (i) the retirement of the equipment
appraised or (ii) depreciation charges. The difference
between depreciation of appraised assets and depreciation
of the historical values of such assets is charged against
accumulated results.
The straight-line method has been used to calculate
depreciation, by applying annual ratios sufficient to
terminate the value of each item as to the end of their
estimated useful life.
The following table analyses the non-financial assets carried
at fair value, by valuation method. The different levels have
been defined as follows:
Quoted prices (unadjusted) in active markets for identical
assets or liabilities (Level 1).
Inputs other than quoted prices included within level 1 that
are observable for the asset or liability, either directly (that is,
as prices) or indirectly (that is, derived from prices) (Level 2).
Inputs for the asset or liability that are not based on observable
market data (that is, unobservable inputs) (Level 3).
>
>
>
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 95
recurring fair value measurements
Equipment and machinery
Vehicles
Other
At December 31, 2017
recurring fair value measurements
Equipment and machinery
Vehicles
Other
At December 31, 2016
–
–
–
–
–
–
–
–
101,809
28,983
18
130,810
99,785
27,069
29
126,883
–
–
–
–
–
–
–
–
Significant Unobservable inputs (level 3)
Significant Unobservable inputs (level 3)
Significant other observable inputs (level 2)
Significant other observable inputs (level 2)
Quoted prices in Active markets for identical assets (level 1)
Quoted prices in Active markets for identical assets (level 1)
vAluATIoN TECHNIquES uSED To DERIvE lEvEl 2
FAIR vAluES
To estimate the fair value of assets for which there is a wide
and transparent secondary market, the valuation specialists
used the “sales comparison” method, which consists in
obtaining information from recent sales or offer of assets
that are comparable in their characteristics, age and state
of conservation. Furthermore, correction factors are
applied over the sale prices determined following the sales
comparison method. These correction factors are based on
the status of the market demand and supply prevailing as
of the date of the appraisal, the relative age, the estimated
residual useful life, the state of conservation and the
obsolescence of assets.
For those assets with a restricted sales market, fair value is
determined based on the “cost less depreciation” method.
Depreciation was computed based on generally used and
accepted engineering criteria, which led to establish the reasonable
value of machinery, construction equipment and vehicles. Such
criteria take into account factors such as the age of each asset,
probable residual life or expected life, state of conservation and
degree of obsolescence. The market value was obtained by
applying the depreciation ratio to the value of a new asset.
Fair value measurements at 31 December 2017 using
Fair value measurements at 31 December 2016 using
96 TECHINT E&C S.A. Annual Report 2017
NoTE 5.
INTANgIBlE ASSETS
The item consists in the following:
The item evolution is as follows:
Beginning of the year
Additions
Disposals
Amortization
Translation differences
December 31, 2017
216
41
–
(103)
8
162
4,816
2,319
(16)
(2,747)
(93)
4,279
5,032
2,360
(16)
(2,850)
(85)
4,441
Dec 31, 2017other Intangible Assets
Systems Development
Systems development
Other intangible assets
Total December 31, 2017
(20,595)
(4,173)
(24,768 )
24,874
4,335
29,209
4,279
162
4,441
Net value at Dec 31, 2017
Accumulated Amortization
gross value
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 97
The item evolution is as follows:
Beginning of the year
Additions
Disposals
Amortization
Translation differences
December 31, 2016
389
–
(82)
(15)
(76)
216
6,117
2,323
(13)
(3,258)
(353)
4,816
6,506
2,323
(95)
(3,273)
(429)
5,032
other Intangible Assets
Systems Development
Dec 31, 2016
Accumulated Amortization
gross value
The item consists in the following:
Systems development
Other Intangible assets
Total December 31, 2016
(18,565)
(3,731)
(22,296)
23,381
3,947
27,328
4,816
216
5,032
Net valueAt Dec 31, 2016
98 TECHINT E&C S.A. Annual Report 2017
Fluor Techint S.R.L. Construcción y Servicios Ltda. (1)
Norpower S.A. de C.V. (2)
AOT Pipelines S.A.P.I. de C.V. (3)
Verkotec B.V. (liquidation process) (4)
Other
Total Investments accounted for using the equity method
Beginning of the year
Result from investments
Investment adquisition and contributions
Dividends earned
Translation differences
Other movements
End of the year
50%
40%
33%
50%
50%
40%
33%
–
990
17,935
4,055
1,839
1,435
26,254
1,005
7,341
5,206
–
1,275
14,827
Chile
Mexico
Mexico
Netherlands
23,137
13,210
–
(8,265)
(381)
(1,447)
26,254
26,254
3,390
602
(15,200)
1,890
(2,109)
14,827
Joint Ventures
NoTE 6.
INvESTMENTS ACCouNTED FoR uSINg
THE EquITy METHoD
Dec 31, 2017
Dec 31, 2017
Non-Current Dec 31, 2016
Dec 31, 2016
(1) Fluor Techint S.R.L. Construcción y Servicios Ltda provides to Compañia Minera Nevada Ltda: basic engineering services, detail engineering, supply management, construction management and construction.
(2) Pipeline maintenance services.
(3) AOT Pipelines S.A.P.I. de C.V. consist on the construction of a pipeline.
(4) See note 1.
% of ownership
% of ownership
Book value
Book value
Country of incorporation
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 99
The result from investments accounted for using the equity
method has arisen from the Company’s participation in the
results of the following companies:
Fluor Techint S.R.L. Construcción y Servicios Ltda.
Norpower S.A. de C.V.
AOT Pipelines S.A.P.I. de C.V.
Verkotec B.V.
Others
Total result from investments accounted for using the equity method
(3)
10,937
1,912
76
288
13,210
(71)
3,043
960
278
(820)
3,390
The following amounts represent the assets, liabilities,
revenues and results of the investment accounted for
using the equity method:
December 31, 2017
Norpower S.A. de C.V.
AOT Pipelines S.A.P.I. de C.V.
Fluor Techint S.R.L. Construcción y Servicios Ltda.
December 31, 2016
Norpower S.A. de C.V.
AOT Pipelines S.A.P.I. de C.V.
Verkotec B.V.
Fluor Techint S.R.L. Construcción y Servicios Ltda.
Dec 31, 2017 Dec 31, 2016
7,614
2,880
(141)
Results
27,342
5,738
(151)
(11)
Results
28,199
5,222
–
Revenues
42,576
106,338
5,117
–
Revenues
2,706
4,887
–
Total liabilities
9,029
11,102
4,719
47
Total liabilities
2,633
4,887
–
Current liabilities
8,956
10,425
4,719
47
Current liabilities
21,074
20,507
2,010
Total Assets
53,865
23,267
8,395
1,981
Total Assets
19,585
20,485
2,010
Current Assets
51,276
20,249
8,395
1,981
Current Assets
100 TECHINT E&C S.A. Annual Report 2017
non-current
Other investment in related parties
Total other investments
Current
Temporary placements
Total other investments
non-current
Beginning of the year
Translation differences
Other movements
Increase of other investments (*)
End of the year
Current
Beginning of the year
Translation differences
Increase / Decrease of other investments
End of the year
10,403
10,403
–
–
10,360
–
–
43
10,403
4,581
(822)
(3,759)
–
3,710
3,710
–
–
10,403
380
(8,408)
1,335
3,710
–
–
–
–
Dec 31, 2017
Dec 31, 2017
Dec 31, 2016
Dec 31, 2016
NoTE 7.
oTHER INvESTMENTS
(*) This corresponds to creation/reversal of fixed-term, other deposits and investment in liquidity (obligation and bond).
24
Notes
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 101
non-current
Trade receivables from related parties
Other receivables from related parties
Claims receivables
Other
Total trade and other receivables
Current
Trade receivables – net
Trade receivables from related parties
Other receivables from related parties
Other receivables (*)
Advances to suppliers and subcontractors
Prepayments
Total trade and other receivables
639
8,028
129,226
32,961
170,854
460,055
62,155
10,778
49,682
15,052
4,769
602,491
–
11,109
140,478
4,730
156,317
520,068
40,592
271
83,782
39,338
9,239
693,290
NoTE 8.
TRADE AND oTHER RECEIvABlES
Dec 31, 2017 Dec 31, 2016
24
24
23
24
24
Notes
(*) At December 31, 2016 include USD 4,285 with OSX Group Companies originated from the transfer of the rights under the “Settlement Agreement” signed between Wisdery S.A and OSX Group Companies.
102 TECHINT E&C S.A. Annual Report 2017
non-current
Beginning of the year
Translation differences
Additions
Used
End of the year
Current
Beginning of the year
Translation differences
Reversal
Additions
Used
End of the year
704
(339)
1,427
(476)
1,316
12,984
(1,247)
(1,393)
–
(1,095)
9,249
1,316
(240)
90
(139)
1,027
9,249
(515)
(659)
1,179
(182)
9,072
At December 31, 2017 and 2016 the evolution of the
allowance for doubtful accounts that was deducted from
Trade and Other receivables is:
Dec 31, 2017 Dec 31, 2016
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 103
Materials and spare parts
Valuation allowance
Total Inventories
28,766
(3,214)
25,552
31,017
(3,471)
27,546
NoTE 9.
INvENToRIES
The item consists in the following:
At December 31, 2017 and 2016 the evolution of the valuation
allowance that was deducted from Inventories is:
Dec 31, 2017 Dec 31, 2016
Beginning of the year
Translation differences
Reversal
Additions
End of the year
1,830
743
(3,081)
3,722
3,214
3,214
42
(349)
564
3,471
Dec 31, 2017 Dec 31, 2016
104 TECHINT E&C S.A. Annual Report 2017
Assets as per balance sheet
Derivative financial instruments
Trade and other receivables (1)
Other investments
Cash and cash equivalents
Total
liabilities as per balance sheet
Borrowings
Trade and other payables (1)
Derivative financial instruments
Other liabilities (2)
Total
199
–
–
–
199
–
–
7,704
–
7,704
126,203
566,969
–
88,678
781,850
–
–
3,710
–
3,710
–
801,030
–
–
801,030
–
–
–
27,201
27,201
–
–
–
362,862
362,862
199
801,030
3,710
390,063
1,195,002
126,203
566,969
7,704
88,678
789,554
Derivative financial instruments
Derivative financial instruments
other financial liabilities at amortized cost
Total
Total
Available- for-sale
loans and receivables
Assets at fair value through the profit and loss
Financial assets at amortized cost
Dec 31, 2017
(1) Excluding prepayments and advanced to suppliers and subcontractors.
(1) Excluding social security contributions.
(2) Excluding advances received on construction contracts .
NoTE 10.
FINANCIAl INSTRuMENTS By CATEgoRy
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 105
Assets as per balance sheet
Derivative financial instruments
Trade and other receivables (1)
Other investments
Cash and cash equivalents
Total
liabilities as per balance sheet
Borrowings
Trade and other payables (1)
Derivative financial instruments
Other liabilities (2)
Total
589
–
–
–
589
–
–
678
–
678
159,196
465,972
–
77,336
702,504
–
–
2,128
–
2,128
–
753,524
8,275
–
761,799
–
–
–
21,134
21,134
–
–
–
210,670
210,670
589
753,524
10,403
231,804
996,320
159,196
465,972
678
77,336
703,182
Derivative financial instruments
TotalAvailable- for-sale
loans and receivables
Assets at fair value through the profit and loss
Financial assets at amortized cost
Dec 31, 2016
(1) Excluding prepayments and advanced to suppliers and subcontractors.
(1) Excluding social security contributions.
(2) Excluding advances received on construction contracts.
Derivative financial instruments
other financial liabilities at amortized cost
Total
106 TECHINT E&C S.A. Annual Report 2017
DETERMININg FAIR vAluES
The table below analyzes financial instruments carried at fair
value, by valuation method.
The different methods have been defined as follows:
Level 1- Quoted prices (unadjusted) in active markets for
identical assets or liabilities.
There was no transfer between level 1, 2 and 3 during the year.
Level 2- Inputs other than quoted prices included within level
1 that are observable for the asset or liability, either directly
(that is, as prices) or indirectly (that is, derived from prices).
Level 3- Inputs for the asset or liability that are not based on
observable market data (that is, unobservable inputs).
The following table presents the financial instruments that
are measured at fair value:
Assets at December 31, 2017
Cash and cash equivalents
Derivative financial instruments
Total
liabilities at December 31, 2017
Derivative financial instruments
Total
Assets at December 31, 2016
Cash and cash equivalents
Derivative financial instruments
Total
liabilities at December 31, 2016
Derivative financial instruments
Total
–
–
–
–
–
–
–
–
–
–
–
199
199
7,704
7,704
–
589
589
678
678
27,201
–
27,201
–
–
21,134
–
21,134
–
–
27,201
199
27,400
7,704
7,704
21,134
589
21,723
678
678
level 3
level 3
level 2
level 2
level 1
level 1
Total
Total
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 107
FINANCIAl INSTRuMENTS vAluED AT FAIR vAluE
FAir VAlUE ESTimATion
Financial assets or liabilities classified as assets at fair value
through profit or loss are measured under the framework
established by the IASB accounting guidance for fair value
measurements and disclosures.
The fair values of quoted investments are generally based
on current bid prices. If the market for a financial asset is not
active or no market is available, fair values are established
using standard valuation techniques.
For the purpose of estimating the fair value of Cash and
cash equivalents and Other Investments expiring in less
than ninety days from the measurement date, the Company
usually chooses to use the historical cost because the
carrying amount of financial assets and liabilities with
maturities of less than ninety days approximates to their fair
value.
The fair value of all outstanding derivatives is determined
using specific pricing models that include inputs that
are observable in the market or can be derived from or
corroborated by observable data. The fair value of forward
foreign exchange contracts is calculated as the net present
value of the estimated future cash flows in each currency,
based on observable yield curves, converted into U.S. dollars
at the spot rate of the valuation date.
FINANCIAl INSTRuMENTS vAluED
AT AMoRTIZED CoSTS
Borrowings are comprised primarily of fixed rate debt and
variable rate debt with a short term portion where interest
has already been fixed. They are classified under other
financial liabilities and measured at their carrying amount. Fair
values were calculated using standard valuation techniques
for floating rate instruments and comparable market rates for
discounting flows (See note 14).
The carrying amount of financial assets and liabilities with
maturities of less than one year as at December 31,2017
and 2016 approximates to their fair value. The fair value are
based on cash flow discounted and are within level 2 of the
fair value hierarchy. The amortized cost of assets and liabilities
with maturities more than one year, are not material, so the
fair values are not reported.
108 TECHINT E&C S.A. Annual Report 2017
NoTE 11.
ASSETS oF DISPoSAl gRouP ClASSIFIED
AS HElD FoR SAlE
The item consists in the following:
Assets of disposal group classified as held for sale
Property, plant and equipment (PP&E)
Investments in SA.T SPA
Other investments
Other
Total held – for – sale assets
1,620
9,524
5,064
–
16,208
1,620
2,045
1,534
20
5,219
Dec 31, 2017 Dec 31, 2016
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 109
NoTE 12.
CASH AND CASH EquIvAlENTS
Cash at bank and on hand
Short-term bank deposits
Liquidity funds
Short-term deposits in related parties
Total cash and cash equivalents
Cash and cash equivalents
Bank overdrafts
Total cash and cash equivalents
86,974
48,851
21,134
74,845
231,804
231,804
(5,207)
226,597
111,610
67,353
27,201
183,899
390,063
390,063
(8,777)
381,286
Cash, cash equivalents and bank overdrafts include the
following for the purposes of the consolidated statement
of cash flows:
Dec 31, 2017
Dec 31, 2017
Dec 31, 2016
Dec 31, 2016
24
14
Notes
Notes
110 TECHINT E&C S.A. Annual Report 2017
NoTE 13.
SHARE CAPITAl
The composition of the Company’s capital is as follows:
At December 31, 2017
At December 31, 2016
16,922,493
16,639,453
16,922,493
16,639,453
in ThoUSAnDS oF ShArES
The ordinary shares have a value of UYU 1 per share and
one vote per share. All issued shares are fully paid.
On August 2, 2017, Techint Investments S.A. made a
contribution to the Company for USD 10 million (equivalent
to Uruguayan Pesos 283 million).
At December 31, 2017 and 2016 the authorized Share Capital
amounted to UYU 17,500,000,000.
ordinary shares
number of shares
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 111
NoTE 14.
BoRRowINgS
non-current
Bank borrowings
Financial leases
Other borrowings
Total Non-Current borrowings
Current
Bank overdrafts
Bank borrowings
Borrowings from related parties
Financial leases
Other borrowings
Total Current borrowings
Total Borrowings
50,353
3,669
–
54,022
5,207
67,068
13,157
1,093
18,649
105,174
5.17% 5.20%
Dec 31, 2017
Dec 31, 2016
Dec 31, 2016
The weighted average interest rates before tax
shown bellow were calculated using the rates set
for each instrument in its corresponding currency
as of December 31, 2017 and 2016.
Notes
24
32,584
2,584
5,942
41,110
8,777
45,586
1,680
1,215
27,835
85,093
Dec 31, 2017
112 TECHINT E&C S.A. Annual Report 2017
Breakdown of borrowings by currency and rate is as follows:
non-CUrrEnT
ARS
PEN
BRL
BRL
EUR
MXN
USD
USD
CUrrEnT
ARS
ARS
BRL
BRL
PEN
MXN
USD
USD
EUR
Fixed
Fixed
Variable
Fixed
Variable
Fixed
Fixed
Variable
Fixed
Variable
Variable
Fixed
Fixed
Fixed
Fixed
Variable
Variable
Currency
1,779
2,584
24,580
5,942
2,398
–
1,639
2,188
41,110
401
4,115
12,313
3,962
1,215
307
5,897
1,430
55,453
85,093
–
3,669
36,926
–
8,169
294
1,408
3,556
54,022
4,342
–
17,970
–
1,093
294
16,924
10,451
54,100
105,174
Reference: ARS: Argentine Peso BRL: Brazilian Real MXN: Mexican Peso EUR: Euro PEN: Soles peruanos
Dec 31, 2017Interest Rate Dec 31, 2016
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 113
The evolution of the borrowings during the year is as follows:
(**) From non - current to current.
Beginning of the year
Cash flows
Interests accrued
Reclassifications (**)
Acquisitions - finance leases
Other movements
Foreign exchange adjustments
Overdrafts variation
End of the year
50,353
(2,195)
–
(10,803)
–
1,368
(197)
–
38,526
104,081
(55,277)
11,878
10,803
–
906
7,917
3,570
83,878
4,762
(1,896)
767
–
–
–
166
–
3,799
159,196
(59,368)
12,645
–
–
2,274
7,886
3,570
126,203
long-term borrowings
Short-term borrowings
Finance lease liabilities
Total
Fixed rate
Variable rate
The following table summarizes the proportions of variable
rate and fixed rate debt as of the year ended at December 31,
2017 and 2016.
19%
81%
28,024
131,172
18%
82%
23,726
102,477
Borrowings Percentage Borrowings Percentage
Dec 31, 2016 Dec 31, 2017
28
Notes
114 TECHINT E&C S.A. Annual Report 2017
Financial leases
Other borrowings
Total Borrowings
Interest to be accrued
Financial leases
Other borrowings
Total Borrowings
Interest to be accrued
-
6,704
6,704
588
1,237
7,480
8,717
53
-
4,468
4,468
122
–
6,732
6,732
9
–
–
–
–
–
4,486
4,486
18
1,305
16,931
18,236
1,762
1,173
21,375
22,548
891
1,215
83,878
85,093
3,440
1,093
104,081
105,174
698
1,279
10,423
11,702
1,123
1,259
10,280
11,539
253
1 year or less
1 year or less
1 - 2 years
1 - 2 years
2 - 3 years
2 - 3 years
3 - 4 years
3 - 4 years
4 - 5 years
4 - 5 years
over 5 years
over 5 years
The maturity of borrowings is as follows:
The fair value of borrowings equals their carrying amount,
as the impact of discounting is not significant.
The fair values are within level 2 of the fair value hierarchy.
Dec 31, 2016
Dec 31, 2017
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 115
NoTE 15.
DEFERRED INCoME TAXES
As further explained in note 2.s., TECHINT E&C and most
of the Company’s subsidiaries are subject to income taxes.
At December 31, 2017 and 2016 the Company discloses
under the caption “deferred income tax assets” the net
balance recognized by those subsidiaries that recorded
a net deferred income tax asset, while the net balance
recognized by those subsidiaries that recorded a net
deferred income tax liability has been disclosed under
“deferred income tax liabilities” in the consolidated
statement of financial position.
Deferred income tax assets and liabilities are offset when
(1) there is a legally enforceable right to offset current tax
assets against current tax liabilities and (2) the deferred
income taxes relate to the same fiscal authority.
The main subsidiaries generating deferred income tax
balances are detailed below:
Deferred income Tax Assets
TEBRA
Techint Chile S.A.
Techint S.A.C.
Techint Compañia Técnica Internacional S.A.C.I. (Uruguay)
Techint Cimimontubi Nigeria LTD
Carbonser, S.A. de C.V.
Carbontec, S.A. de C.V.
Techint Servicios, S.A. de C.V.
Constructora Mexicana Electromecánica y de Instrumentación, S.A. de C.V.
Mexcarbon
TESUR
TEMIL
Sidernet Argentina
20,426
–
–
955
–
604
221
523
2,146
–
–
5,947
96
30,918
Dec 31, 2016
23,345
598
94
–
93
693
248
510
1,886
28
773
6,927
910
36,105
Dec 31, 2017
116 TECHINT E&C S.A. Annual Report 2017
Deferred income Tax liabilities
Techint Compañia Técnica Internacional S.A.C.I. (Uruguay)
TEMEX
Techint Chile S.A.
Techint S.A.C.
TEARG
FEPSA
Sidernet Argentina
Sidernet Mexicana S.A. de C.V.
Techint India Private Limited
Tecsesi S.A.
TIC
–
9,404
2,318
2,864
3,428
4,444
4,498
1,347
455
–
86
28,844
Dec 31, 2016
53
1,299
–
–
4,379
4,006
–
1,189
335
2,546
116
13,923
Dec 31, 2017
Deferred tax assets and liabilities are offset when: (1) there is
a legally enforceable right to offset current tax assets against
current tax liabilities and (2) when taxes on deferred benefits
are associated with the same tax authority.
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 117
At December 31, 2017 and 2016 the deferred tax balance
is originated by the following items:
Deferred income Tax Assets
Tax-loss carry-forwards
Provisions for bad debts
Deferred costs/Construction contracts
Advances from clients
Others
Subtotal
Deferred income Tax liabilities
Committed investment FEPSA
Deferred income/Construction contracts
PP&E revaluation
Inventories
PP&E
Others
Subtotal
Net deferred income tax assets
16,884
21,102
930
952
17,946
57,814
7,843
11,917
28,668
1,585
4,434
1,293
55,740
2,074
Dec 31, 2016
20,074
57,869
485
12,004
20,810
111,242
8,489
49,834
21,625
1,681
5,682
1,749
89,060
22,182
Dec 31, 2017
118 TECHINT E&C S.A. Annual Report 2017
The evolution of net deferred income tax asset during
the year is as follows:
The amounts shown in the consolidated statement of financial
position include the following:
Deferred tax assets to be recovered within 12 months
Deferred tax assets to be recovered after more than 12 months
Deferred tax liabilities to be recovered within 12 months
Deferred tax liabilities to be recovered after more than 12 months
Net deferred income tax assets
Beginning of the year
Translation differences
PP&E revaluation
Cash flow Hedge
Other movements
Income statement charge
End of the year
10,305
47,509
(17,459)
(38,281)
2,074
21,309
(2,948)
(5,432)
–
(2,156)
(8,699)
2,074
Dec 31, 2016
Dec 31, 2016
30
Notes
48,822
62,420
(54,048)
(35,012)
22,182
2,074
677
(1,321)
2,207
1,783
16,762
22,182
Dec 31, 2017
Dec 31, 2017
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 119
The evolution of deferred income tax assets and liabilities
during the year ended December 31, 2017 is as follows:
Beginning of the year
Translation differences
Cash flow Hedge
Other movements
Income statement (charge) / credit
End of the year
Beginning of the year
Translation differences
PP&E revaluation
Other movements
Income statement charge / (credit)
End of the year
16,884
(73)
–
3
3,260
20,074
Tax-loss carry- forwards
7,843
(1,444)
–
2,029
61
8,489
Commited investment FEPSA
Deferred tax assets
Deferred tax liabilities
21,102
(1,459)
–
2,652
35,574
57,869
Provisions for bad debts
11,917
(113)
–
–
38,030
49,834
Deferred Income/Construction contracts
930
46
–
–
(491)
485
Deferred costs/Construction contracts
28,668
(836)
1,321
–
(7,528)
21,625
PP&E revaluation
952
(45)
–
–
11,097
12,004
Advances from clients
1,585
(76)
–
150
22
1,681
Inventories
4,434
(161)
–
(160)
1,569
5,682
PP&E
17,946
(280)
2,207
1,147
(210)
20,810
others
1,293
142
–
–
314
1,749
others
57,814
(1,811)
2,207
3,802
49,230
111,242
Total
55,740
(2,488)
1,321
2,019
32,468
89,060
Total
120 TECHINT E&C S.A. Annual Report 2017
Beginning of the year
Translation differences
Other movements
Income statement (charge) / credit
End of the year
Beginning of the year
Translation differences
PP&E revaluation
Other movements
Income statement charge / (credit)
End of the year
25,067
1,082
(574)
(8,691)
16,884
Tax-loss carry- forwards
7,444
(1,335)
–
–
1,734
7,843
Commited investment FEPSA
Deferred tax assets
Deferred tax liabilities
29,212
559
387
(9,056)
21,102
Provisions for bad debts
16,594
3,025
–
–
(7,702)
11,917
Deferred Income/Construction contracts
4,127
166
–
(3,363)
930
Deferred costs/Construction contracts
25,080
5,730
5,432
(560)
(7,014)
28,668
PP&E revaluation
5,475
465
–
(4,988)
952
Advances from clients
1,773
453
–
–
(641)
1,585
Inventories
4,579
(611)
–
–
466
4,434
PP&E
17,465
2,028
(1,979)
432
17,946
others
4,567
(14)
–
550
(3,810)
1,293
others
81,346
4,300
(2,166)
(25,666)
57,814
Total
60,037
7,248
5,432
(10)
(16,967)
55,740
Total
The evolution of deferred income tax assets and liabilities
during the year ended December 31, 2016 is as follows:
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 121
The tax loss carry-forwards mature as detailed below:
Year 2017
Year 2018
Year 2019
Year 2020
Year 2021
Year 2022
Without maturity
–
21,279
7,458
76
3,086
11,588
306,487
349,974
7,158
20,340
10,155
112
11,959
–
244,395
294,119
The recoverable value of deferred tax assets depends on the
existence of future income subject to income tax, sufficient
to be used before their legal prescription. In this regard,
Management estimates that TECHINT E&C’s subsidiaries will
generate sufficient taxable income in future periods so as to
offset the net balance of deferred income tax assets recorded
at December 31, 2017.
As at December 31, 2017 the Company and subsidiaries
had in its tax books an amount of USD 77,269 of taxes
to be offset against future taxable income which are not
recognized in the balance sheet, because it is not probable
that they will be realized.
yEAR Dec 31, 2017 Dec 31, 2016
122 TECHINT E&C S.A. Annual Report 2017
NoTE 16.
TRADE AND oTHER PAyABlES
non-current
Trade payables
Social security contributions (*)
Other payables
Total trade and other payables
Current
Trade payables
Social security contributions
Amounts due to related parties
Other payables
Total trade and other payables
–
36,147
228
36,375
552,353
65,899
12,529
1,859
632,640
3,360
34,312
184
37,856
422,711
45,181
28,902
10,815
507,609
The maturity of trade and other payables is as follows:
over 5 years
December 31, 2017
Trade and other payables
Total Trade and other payables
December 31, 2016
Trade and other payables
Total Trade and other payables
3 - 4 years
350
350
7,955
7,955
4 - 5 years
6,932
6,932
4,316
4,316
2 - 3 years
325
325
1,903
1,903
1 - 2 years
4,294
4,294
5,751
5,751
1 year or less
632,640
632,640
507,609
507,609
15,133
15,133
–
–
9,341
9,341
17,931
17,931
without due date
24
Dec 31, 2017 Dec 31, 2016Notes
(*) Include employee benefits
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 123
NoTE 17.
oTHER lIABIlITIES
non-current
Provisions
Advances received on construction contracts
Amounts due to related parties
Other liabilities
Total other liabilities
Current
Provisions
Advances received on construction contracts
Amounts due to related parties
Other liabilities and provisions
Total other liabilities
46,130
9,700
2,881
7,012
65,723
9,349
75,571
609
22,697
108,226
41,395
340
–
9,816
51,551
8,912
30,640
609
16,604
56,765
Dec 31, 2017 Dec 31, 2016
18
24
18
24
Notes
The maturity of trade and other payables is as follows:
over 4 years
December 31, 2017
Other liabilities
Total other liabilities
December 31, 2016
Other liabilities
Total other liabilities
33,728
33,728
28,965
28,965
3 - 4 years
15
15
2,098
2,098
2 - 3 years
15
15
280
280
1 - 2 years
2,408
2,408
10,699
10,699
1 year or less
108,226
108,226
56,765
56,765
29,557
29,557
9,509
9,509
without due date
124 TECHINT E&C S.A. Annual Report 2017
NoTE 18.
PRovISIoNS
The evolution of provisions during the year is as follows:
non-current
Beginning of the year
Translation differences
Reversal
Additions
Used
End of the year
Current
Beginning of the year
Translation differences
Reversal
Additions
Used
End of the year
4,595
(571)
54
3,759
(1,249)
6,588
5,240
275
(1,620)
1,667
–
5,562
2,019
105
(294)
206
–
2,036
754
66
(3)
–
–
817
1,110
(119)
(372)
510
(135)
994
660
28
(160)
13
-
541
25,779
(6,175)
–
9,307
(30)
28,881
449
62
-
9
-
520
7,892
(160)
(52)
2,419
(2,468)
7,631
1,809
131
(65)
54
(20)
1,909
41,395
(6,920)
(664)
16,201
(3,882)
46,130
8,912
562
(1,848)
1,743
(20)
9,349
CivilsTaxeslabor
legal Fees (1) other (2) Total
Dec 31, 2017
CivilsTaxeslabor legal Fees other Total
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 125
non-current
Beginning of the year
Translation differences
Reversal
Additions
Used
End of the year
Current
Beginning of the year
Translation differences
Additions
Used
Other movements
End of the year
4,225
(150)
(324)
972
(128)
4,595
989
(212)
4,463
–
–
5,240
3,037
(1,099)
(272)
353
–
2,019
708
43
3
–
–
754
1,118
(100)
110
367
(385)
1,110
753
7
–
(100)
–
660
19,794
3,992
–
1,993
–
25,779
208
(18)
259
–
–
449
7,867
(290)
(260)
2,217
(1,642)
7,892
2,767
(270)
239
(1,273)
346
1,809
36,041
2,353
(746)
5,902
(2,155)
41,395
5,425
(450)
4,964
(1,373)
346
8,912
(1) See note 23. (2) It includes contractual obligations undertaken by the subsidiary Carbonser SA de CV in relation to the contract for the supply of coal handling services, calculated based on a technical study which indicates the degree of wear and tear of the main components of the Petacalco Plant, as well as the amount of expenditures estimated to be made in the future due to the wear and tear generated by the use of such Plant. Based on the mentioned study, by the end of December 2017 and 2016 Carbonser SA de CV recognized a maintenance provision of USD 6,107 and USD 5,872 respectively.
Dec 31, 2016
CivilsTaxeslabor legal Fees (1) other (2) total
CivilsTaxeslabor legal Fees other total
126 TECHINT E&C S.A. Annual Report 2017
NoTE 19.
EMPloyEE BENEFITS
The company has the following employee benefits:
NoN-FuNDED DEFINED BENEFITS AND oTHER
loNg-TERM BENEFITS
At December 31, 2017 and 2016, the amounts recognized as
liabilities in the consolidated statement of financial position is
determined as follows:
There are no due and payable debts as of December 31, 2017
and 2016.
At December 31, 2017 and 2016, the amounts recognized
in the consolidated income statement are as follows:
Liabilities for retirement benefit and other plans
liability in the consolidated statement of financial position
Current service cost
Interest cost
Transfers and new participants of the plan
Other
Total included in wages salaries and social costs
26,270
26,270
1,866
2,847
(117)
–
4,596
21,867
21,867
1,965
2,632
195
228
5,020
Dec 31, 2017 Dec 31, 2016
Dec 31, 2017 Dec 31, 2016
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 127
Beginning of the year
Translation differences
Transfers and new participants of the plan
Total expense
Remeasurement - Actuarial losses (gains) and Others
Contributions paid
End of the year
21,867
(327)
136
4,596
3,040
(3,042)
26,270
23,098
(2,130)
18
5,020
(1,446)
(2,693)
21,867
The amounts and movements in the liabilities recognized in
the consolidated statement financial position are determined
as follows:
At December 31, 2017 and 2016, the main actuarial
premises in the argentinian subsidiaries used for calculation
of such plans contemplate a discount rate average of 7%
and 5,7% real and a salary increase rate of 2 and 3%.
The actuarial premises used in the mexican subsidiaries
for calculation of such plans contemplate a discount rate
of 7.6%, and a salary increase rate of 3.75% at December
31, 2017 and 4.79%, at December 31, 2016. Additionally,
the actuarial premises used in the subsidiary TEMIL for
calculation of such plans contemplate a discount rate
of 1.35% at December 31, 2017 and 2016, and a salary
increase rate of 2.5%.
Contribution plans
During the year ended December 31, 2017 and 2016
TECHINT E&C and subsidiaries contributed USD 66
and USD 103 to the defined contribution plans, respectively.
(See note 27).
Dec 31, 2017 Dec 31, 2016
128 TECHINT E&C S.A. Annual Report 2017
NoTE 20.
PARTICIPATIoN IN joINT oPERATIoNS
The Company’s subsidiaries were part of different Joint
Operations which also performs engineering, procurement
and construction activities. The Company’s participation in
these Joint Operations was recorded through proportional
consolidation of assets, liabilities and results. The following
balances represent the Joint Operations assets and liabilities
at December 31, 2017 and 2016.
Techint Cia Técnica Internacional S.A.C.e I. –
Dycasa S.A. - Unión Transitoria de Empresas -
Proyecto: Ampliación Subte H (1)
Techint Cia Técnica Internacional S.A.C.I. -
Panedile Argentina S.A. - Unión Transitoria
de Empresas - Complejos "Los Caracoles"
and "Punta Negra" (1)
Techint Cia Técnica Internacional S.A.C.I. -
Impregilo S.p.A (Sucursal Argentina) -
Iglys S.A. - Unión Transitoria de Empresas -
Complejo Penitenciario Ezeiza (1)
Techint Cia Técnica Internacional S.A.C.e I. -
FLUOR Inc. - Unión Transitoria de Empresas -
Proyecto: Pascua Lama (1)
Techint Cia Técnica Internacional S.A.C.e I. -
Panedile Argentina S.A.I.C.F e I - GNEA (1)
PANEDILE S.A.I.C.F. e I. - Tecnologia en Servicios
Urbanos S.A. - Unión Transitoria de Empresas (LPI 01) (6)
PANEDILE S.A.I.C.F. e I. - Tecnologia en Servicios
Urbanos S.A. - Unión Transitoria de Empresas (LP 49) (6)
SIEMENS S.A. - Tecnologia en Servicios Urbanos
S.A. - Unión Transitoria de Empresas (UEC) (6)
Tecnologia en Servicios Urbanos S.A. - PANEDILE
S.A.I.C.F. e I. Unión Transitoria de Empresas (MDQ) (6)
40,954
16,302
39,988
8,132
47,500
–
–
–
–
60.00%
75.00%
65.00%
50.00%
80.00%
50.00%
50.00%
40.20%
30.00%
36,782
11,982
1,315
12,289
827
6,324
1,503
3,504
393
42,506
13,205
42,778
7,753
40,990
6,656
1,633
3,909
90
Argentina
Argentina
Argentina
Argentina
Argentina
Argentina
Argentina
Argentina
Argentina
34,761
13,809
1,532
13,280
3,162
–
–
–
–
60.00%
75.00%
65.00%
50.00%
80.00%
–
–
–
–
Total J.o.’S liabilities
Total J.o.’S Assets
Country of operation
% of ownership
Total J.o.'s liabilities
% of ownership
Total J.o.'s Assets
main Joint operations (J.o.)
Dec 31, 2017 Dec 31, 2016
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 129
(1) Controlling interest through TEARG.
(2) Controlling interest through TEMEX.
(3) Controlling interest through TEMIL.
(4) Controlling interest through TEBRA.
(5) Controlling interest through TENCO.
(6) Controlling interest through TEFIN.
Techint / Black & Veatch - LNG Costa Azul Project (2)
TS LNG SAS (3)
TS LNG BELGIUM BVBA (3)
Polskie LNG Consortium (3)
Consórcio Techint Confab UMSA - Lot I Tanks
Refinería do Nordeste, Abreu e Lima (RNEST) (4)
Consorcio Andrade Gutierrez - Techint (AG-TECH)
Diesel Unit of Landulpho Alves - Mataripe Refinery
(RLAM) (4)
Consorcio Andrade Gutierrez - Techint (TE - AG) (4)
Consorcio Technip – Techint (TTP – 76) (4)
Consorcio Angramon (4)
Empresa Constructora Belfi S.A. Sucursal Uruguay
- Techint Compañía Técnica Internacional S.A.C.I. -
Uruguay (5)
Consorcio Construcciones y Montajes (5)
Consorcio para la Atención y Mantenimiento
de Ductos del Perú – “Consorcio AMDP”(5)
Consorcio AMDP Norte (5)
Ingeniería y Construcción Bechtel Techint EWS Ltda. (5)
Bechtel Techint Servicios Complementarios Ltda. (5)
Mexico
France
Belgium
Poland
Brazil
Brazil
Brazil
Brazil
Brazil
Uruguay
Peru
Peru
Peru
Chile
Chile
227
50,610
21,338
34,752
1
101
6,972
83,357
3,603
737
2,043
35,101
–
19,957
24,987
50.00%
50.00%
50.00%
33.33%
41.00%
50.00%
50.00%
100.00%
14.29%
40.00%
75.00%
50.00%
50.00%
40.00%
40.00%
232
145,143
46,196
74,515
95
319
965
778,013
6,386
80
31
15,099
96
4,295
31
236
63,987
7,410
21,534
31,928
136,852
186,760
810,669
16,763
554
1,134
35,773
168
15,638
20,258
228
133,800
55,266
72,401
47
159
513
14,810
3,308
46
755
24,413
–
4,621
6,954
50.00%
50.00%
50.00%
33.33%
41.00%
50.00%
50.00%
50.00%
14.29%
40.00%
75.00%
50.00%
–
40.00%
40.00%
Total J.o.’S liabilities
Total J.o.’S Assets
Country of operation
% of ownership
Total J.o.'s liabilities
% of ownership
Total J.o.'s Assets
main Joint operations (J.o.) (cont’d.)
Dec 31, 2017 Dec 31, 2016
130 TECHINT E&C S.A. Annual Report 2017
The following balances represent the J.O.s results
at December 31, 2017 and 2016:
Techint Cia Técnica Internacional S.A.C.e I. –
Dycasa S.A. - Unión Transitoria de Empresas -
Proyecto: Ampliación Subte H (1) (11)
Techint Cia Técnica Internacional S.A.C.I. -
Panedile Argentina S.A. - Unión Transitoria
de Empresas - Complejos “Los Caracoles“ and
“Punta Negra“ (1) (12)
Techint Cia Técnica Internacional S.A.C.I. -
Impregilo S.p.A (Sucursal Argentina) -
Iglys S.A. - Unión Transitoria de Empresas -
Complejo Penitenciario Ezeiza (1) (13)
Techint Cia Técnica Internacional S.A.C.e I. -
FLUOR Inc. - Unión Transitoria de Empresas -
Proyecto: Pascua Lama (1)
Techint Cia Técnica Internacional S.A.C.e I. -
Panedile Argentina S.A.I.C.F e I - GNEA (1) (14)
PANEDILE S.A.I.C.F. e I. - Tecnologia en Servicios
Urbanos S.A. - Unión Transitoria de Empresas
(LPI 01) (6) (20)
PANEDILE S.A.I.C.F. e I. - Tecnologia en Servicios
Urbanos S.A. - Unión Transitoria de Empresas
(LP 49) (6) (21)
SIEMENS S.A. - Tecnologia en Servicios Urbanos
S.A. - Unión Transitoria de Empresas (UEC) (6) (22)
Tecnologia en Servicios Urbanos S.A. - PANEDILE
S.A.I.C.F. e I. Unión Transitoria de Empresas (MDQ) (6) (23)
Techint / Black & Veatch - LNG Costa Azul Project (2)
TS LNG SAS (3) (15)
TS LNG BELGIUM BVBA (3) (16)
Polskie LNG Consortium (3)
Consórcio Techint Confab UMSA - Lot I Tanks
Refinería do Nordeste, Abreu e Lima (RNEST) (4)
(512)
9,338
9,694
(168)
2,355
332
130
405
(303)
6
2,174
13,233
(5,220)
(32)
Argentina
Argentina
Argentina
Argentina
Argentina
Argentina
Argentina
Argentina
Argentina
Mexico
France
Belgium
Poland
Brazil
J.o.’S results
Country of operation
60.00%
75.00%
65.00%
50.00%
80.00%
50%
50%
40%
30%
50.00%
50.00%
50.00%
33.33%
41.00%
% of ownership
(1,527)
6,919
12,583
1,229
23,629
–
–
–
–
(35)
(4,065)
(406)
(4,568)
2
J.o.’S results
60.00%
75.00%
65.00%
50.00%
80.00%
–
–
–
–
50.00%
50.00%
50.00%
33.33%
41.00%
% of ownership
main Joint operations
Dec 31, 2017 Dec 31, 2016
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 131
(1) Controlling interest through TEARG.
(2) Controlling interest through TEMEX.
(3) Controlling interest through TEMIL.
(4) Controlling interest through TEBRA.
(5) Controlling interest through TENCO.
(6) Controlling interest through TEFIN.
(7) It was created for the preliminary works for the terminal at Conchillas Port, Department of Colonia, Uruguay and the construction of such terminal. (8) It was created for the sole purpose of signing for and executing the works of engineering, partial procurement and construction of a natural gas compression plant. (9) It was created for the execution of construction works related to aqueducts, pumping stations, power substations, high voltage lines, reservoir and other works requested for such project. (10) It was created for the provision of engineering, procurement and other related services, including the sale and lease of machinery, tools and equipment for the project.
(11) It was created for the construction of subway stations line H for the client Subterráneos de Buenos Aires Sociedad del Estado (SBASE). (12) Created in order to increase the regulation of water resources on the river San Juan (Argentina). (13) Created for the construction of a prison in Ezeiza - Buenos Aires Province (Argentina). (14) Created with the purpose of carrying out the engineering, procurement of equipment and construction of Gasoducto Noreste Argentino (GNEA). (15) Created to perform engineering, procurement of materials and construction of a terminal for liquefied natural gas (LNG) located in Dunkerque (France). (16) Created for the expansion of LNG regasification terminal in Zeebrugge Belgium. (17) Created for the purpose of negotiation, underwriting and execution of the contract with the Compañía Operadora de Gas del Amazonas S.A. (COGA) to provide the service and maintenance of the transportation system for natural gas and natural gas liquids.
(18) It was created for performing some works on the pipeline Norperuano including maintenance and repair of equipment and hot tap maintenance and replacement of pipes 16 and 36 inches. (19) As of June 2017 TEBRA increases its participation to 100%. (20) Created for the Recovery and Improvement of Ferrocarril General Belgrano – Total renewal of the infrastructure of tracks in tranche 5, Sector “A” (km. 211,340 to km 275,479) in the Province of Santa Fe, Argentina. (21) Created for the Recovery and Improvement of Ferrocarril General Belgrano – Total renewal of the infrastructure of tracks in Sector B (km 37,900 to km 83,900) in the Province of Santa Fe, Argentina. (22) Created for the construction of a substation, switching stations, self-transformation and tele-command for Ferrocarril General Roca, Constitución - La Plata, Argentina. (23) Created for the replacement of rails and sleepers of Ferrocarril General Roca, Vivoratá-Mar del Plata, and the construction of a new tracks between Camet and Mar del Plata.
J.o.’S results
Country of operation
% of ownership
J.o.’S results
% of ownership
50.00%
50.00%
100.00%
14.29%
40.00%
75.00%
50.00%
50.00%
40.00%
40.00%
(34)
8,295
3,118
414
(508)
4,112
10,632
–
9,318
36,079
50.00%
50.00%
50.00%
14.29%
40.00%
75.00%
50.00%
–
40.00%
40.00%
(59)
(1,072)
(21,471)
(3,049)
(94)
(227)
9,556
316
(5,359)
589
Brazil
Brazil
Brazil
Brazil
Uruguay
Peru
Peru
Peru
Chile
Chile
Consorcio Andrade Gutierrez - Techint (AG-TECH)
Diesel Unit of Landulpho Alves - Mataripe Refinery
(RLAM) (4)
Consorcio Andrade Gutierrez - Techint (TE - AG) (4)
Consorcio Technip - Techint (TTP - 76) (4) (19)
Consorcio Angramon (4)
Empresa Constructora Belfi S.A. Sucursal
Uruguay - Techint Compañía Técnica Internacional
S.A.C.I. - Uruguay (5) (7)
Consorcio Construcciones y Montajes (5) (8)
Consorcio para la Atención y Mantenimiento
de Ductos del Perú – “Consorcio AMDP”(5) (17)
Consorcio AMDP Norte (5) (18)
Ingeniería y Construcción Bechtel Techint EWS
Ltda. (5) (9)
Bechtel Techint Servicios Complementarios Ltda. (5) (10)
main Joint operations (cont’d.)
Dec 31, 2017 Dec 31, 2016
132 TECHINT E&C S.A. Annual Report 2017
NoTE 21.
CoNTINgENCIES AND CoMMITMENTS
a. guARANTEES AND BoNDS gRANTED
TECHINT E&C and its subsidiaries have entered into a series
of guarantee contracts with third parties through which
they undertake the unconditional and irrevocable obligation
to guarantee the prompt and complete payment and
performance of certain liabilities incurred by related parties.
As of December 31, 2017 TECHINT E&C has issued
guarantees to related parties totaling USD 1,318 million (at
December 31, 2016: USD 744 million) and to third parties
USD 682.7 million (at December 31, 2016: USD 494.4 million).
b. woRKS EXECuTED uNDER A TRuST, CoNSTRuCTIoN
AND lEASINg AgREEMENT
TEARG, as a member of the J.O. Techint Compañía Técnica
Internacional S.A.C.I. – Impregilo S.p.A. (Sucursal Argentina) –
Iglys S.A., has signed a contract with the Argentine Government
for the construction of a penitentiary institution, under the
turnkey system, located in Ezeiza, province of Buenos Aires,
payable in 60 quarterly installments as canon, nominated in USD
4,650 each one (plus the corresponding value for VAT).
The J.O. accepted the pesification of canons at an ARS 1-USD
1 rate and the application of the Reference Stabilization Index
(RSI) until the effective date of payment, according to the
Agreements executed by the J.O. with the Ministry of Justice
and Human Rights, dated November 19, 2003 and September
9, 2004. The canons collected plus RSI after the Agreement
dated September 9, 2004, were Nos. 17, 18, 19, 20, 21 and
22. On the other hand, before execution of such Agreement,
canon No. 8 was also collected plus RSI in January 2003.
That notwithstanding, the J.O. received from such Ministry
payments for several canons not applying the RSI, which
have been taken by the J.O. as partial payments of the total
amount due and payable arising from the Agreement dated
September 9, 2004.
Thus, from January 2006 to the date of issue of these
consolidated financial statements, the J.O. received as partial
payment a total amount of USD 13,577 corresponding to
canons 10 to 16 and 23 to 60 at an ARS 1-USD 1 rate, not
applying the RSI.
Taking into account the Ministry of Justice’s delay as to a
resolution and payment of the overdue debt, Santander
Río Trust S.A., in its capacity as Trustee and Grantor of
the Leasing, on July 4, 2008, following the J.O.’s express
instructions, submitted a note demanding payment of
amounts due. Upon failure to answer by the Ministry of
Justice, on November 28, 2008, an Arbitration Claim was
filed before the International Court of Arbitration of the
International Chamber of Commerce, for the purpose
of appointing an arbitration tribunal consisting of three
arbitrators and to hold the respondent, the Argentine
Government, liable for payment of the amounts claimed plus
any interest that may be accrued and the new terms of the
debt to expire during the arbitration process. The arbitration
claim was notified to the Argentine Government in May
2009, the Arbitral Tribunal was constituted and the Mission
Statement was issued on December 7, 2010.
In May 2009, the J.O. was informed of the passing of
Executive Order No. 541/09, which empowers UNIREN to
renegotiate the Construction, Trust and Leasing Agreement
executed in 1998 in relation to Penitentiary Complex I
(Ezeiza). The J.O. has not consented to the provisions of
such executive order by virtue of the defects thereof. On
June 18, 2009, a letter was submitted through Santander
Río Trust S.A., in its capacity as Trustee and Grantor of
the Leasing, following the J.O.’s express instructions, to
the above-stated respect claiming the unlawful nature of
such executive order. That notwithstanding, and making it
clear that this entails no waiver whatsoever of its rights,
including the right to enforce its rights and defenses in
the ongoing arbitration proceeding, the J.O. executed a
Memorandum of Understanding (MOU) and an Agreement
(“Entendimiento Contractual”) on September 8, 2010
and on Novenber 18, 2011 respectively, whereby (i) the
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 133
acknowledgement made in the Agreement executed with
the Ministry of Justice on September 9, 2004 is ratified,
(ii) UNIREN acknowledges the debt upon failure to apply
the RSI, (iii) the Legal Board of Juridical Affairs (Dirección
Legal de Asuntos Jurídicos) of the Ministry of Economy
and Public Finance concludes that the application of RSI
complies with the provisions under the applicable legal
framework upon the passing of Law No. 25561 and
Executive Order No. 214/2002, (iv) the J.O. undertakes
to suspend the arbitration proceeding for 180 days and to
obtain the ratification of such agreement by the Trustee, (v)
the UNIREN undertakes, upon compliance by the J.O. with
the obligation stated in (iv), to ratify the agreement within
180 days jointly with the Ministry of Justice and Human
Rights (MINJU) and with the Argentine Executive Branch
(PEN) and (vi) upon ratification by the PEN, the MINJU
shall have a 90-day term to cancel the debt, and the J.O.
shall abandon the arbitration proceeding before or after the
administrative act stating the cancellation of the debt is
passed by the MINJU, but before the actual cancellation.
The J.O. obtained the ratification by the Trustee and
complied with the arbitration suspension for 180 days. This
suspension was extended several times so that the Argentine
Government would satisfy the commitment to ratify the
agreement undertaken by the Argentine Executive Branch
(PEN). The last extension granted expired on July 2014, and
the Arbitration Court, according to the notice from the Paris
International Chamber of Commerce (ICC), had until April 30,
2018, to issue the award.
The J.O. learnt that the Memorandum of Understanding
executed on November 18, 2011, as of this date is still
awaiting ratification by PEN. In such respect, we must
point out that the Argentine Attorney General’s Office
(Procuración del Tesoro de la Nación), on a letter dated July
29, 2013, sent to the Court Clerk’s Office of the International
Court of Arbitration of the International Chamber of
Commerce, stated that the relevant administrative
proceedings were being conducted to effectively promote
such ratification, and for such purpose the Ministry of
Justice, Security and Human Rights (MINJU) was seeing to
getting the budget credit to afford any expenditures to be
incurred to comply with the above-mentioned Memorandum
of Understanding.
In addition, on February 6, 2014, the Argentine Attorney
General’s Office issued a note to the Assistant Counsel of the
Court Clerk’s Office of the International Court of Arbitration
of the International Chamber of Commerce stating the
Argentine Government’s willingness to settle the dispute
as agreed under the Agreement executed between the
Claimants and the Public Services Contract Analysis and
Renegotiation Unit (UNIREN).
In February 2016, this J.O. was notified of the issuance
of Decree No. 367/2016 repealing Decree No. 311 which
assigned jurisdiction to the Claimants and the Public Services
Contract Analysis and Renegotiation Unit (UNIREN) to
renegotiate the Construction, Trust and Leasing Agreement
signed in 1998 in relation to Penitentiary Complex I (Ezeiza)
and assigns functions related to the renegotiation of
contracts for public works and services to the respective
ministries related to their subjects, according to the
responsibilities arising from the Law on Ministries (Text
Sorted by Decree No. 438 dated March 12, 1992), jointly with
the Ministry of Economy and Public Finance.
Consequently, the claimants and the respondent continue
holding conversations aimed at expediting compliance with
the provisions in the Memorandum of Understanding to
pay the overdue amount of Reference Stabilization Index
(CER). As of the date of issue of these consolidated financial
statements, on February 5, 2018, an addendum was executed
to the Memorandum of Understanding entered into on
November 18, 2011, stating the following (i) the parties state
that all provisions of the Memorandum of Understanding not
modified by the addendum are deemed to be reproduced,
(ii) payment of the overdue amount shall be made by means
of delivery of government securities with a market value at
the time of actual delivery representing an amount equal to
90% of the amount calculated pursuant to the provisions of
134 TECHINT E&C S.A. Annual Report 2017
the above-mentioned Memorandum of Understanding, (iii)
the addendum is executed at referendum of the Argentine
Executive (PEN) since the ratification of the addendum shall
entail the ratification of the Memorandum of Understanding,
(iv) upon ratification by PEN, the Ministry of Finance shall
proceed to the delivery of the securities but prior to such
delivery, the Trustee, the JV and each member of the JV shall
abandon their right to file an action before the International
Chamber of Commerce, and they shall waive this and all and
any other claim and/or any right to bring an action in the future
against the Argentine Government based on the Construction,
Trust and Leasing Agreement of Penitentiary Complex I Ezeiza
before an arbitration, judicial and/or administrative court,
either national or international, and (v) in case of absence of
ratification by PEN, both the Memorandum of Understanding
and the addendum shall not be valid.
On March 27, 2018, Executive Order No. 249/2018 was
published in the Official Gazette (B.O.). Such Executive Order
ratifies the addendum to the Memorandum of Understanding
entered into on November 18, 2011 by and between UNIREN
(Public Services Contract Analysis and Renegotiation Unit)
and the JV, with addendum was executed by the MINJU
(Ministry of Justice), the Ministry of Economy and the JV,
each one of the companies member of the JV and the Trustee
and grantor of the Leasing, Santander Río Trust S.A., pursuant
to the terms of the document signed on February 5, 2018.
In addition, such Executive Order provides for the Entity
Responsible for Systems Coordination, within the sphere of
the Financial Administration of the National Public Sector, to
establish the issue of public debt securities necessary for
cancellation of the unpaid balance of the Construction, Trust
and Leasing Agreement of Penitentiary Complex I Ezeiza.
The Executive Order also stated that the MINJU had to
terminate the Construction, Trust and Leasing Agreement of
Penitentiary Complex I Ezeiza entered into on May 28, 1998.
On April 16, 2018, the beneficiaries of the government
securities consented on the number of bonds to be delivered
and the total discharge of obligations to be canceled
thereby, in the terms to be provided for by the MINJU, shall
be a necessary condition precedent to be reported to the
Secretary of Finance of the Ministry of Finance for settlement
of such government securities.
In addition, on April 17 the Trustee, the JV and each
member company of the JV withdrew from the arbitration
proceeding before the ICC with the scope agreed upon in the
aforementioned addendum.
By virtue of the above, the J.O. started to accrue the RSI
again, from January 1, 2009 to November 30, 2017 but
considering a 10% reduction.
In such respect, the J.O.’s Management and Legal Advisors
believe that, by virtue of application of the legal rules
and regulations regarding pesification (application of the
Reference Stabilization Index (RSI) to overdue canons) which
should be applied to this contractual structure, the J.O. has
a sound legal position to collect its claims in the context of
application of the above-mentioned rules and regulations.
The proportional participation of TEARG in the total balance
receivable of the J.O. with the Argentine Government as of
November 30, 2017 amounts to USD 34,374 (RSI USD 34,374).
The amount of such receivable recorded in these
consolidated financial statements, resulting from the
application of a 10% reduction on the above-stated values,
is USD 31,224.
All these financial credits correspond to the canons receivable
from the Argentine Government, due and to become due,
which were recorded as per the Agreement executed on
September 9, 2004 with the Undersecretariat of Coordination
and Innovation under the National Ministry of Justice and
Human Rights, in Pesos at a rate of ARS 1-USD 1 and adjusted
with RSI up to November 30, 2017.
On 23 April, 2018 the bonds were collected.
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 135
c. oTHER CoNTINgENCIES AND uNCERTAINTIES
Techint E&C´subsidiaries have tax and civil lawsuits for which
the legal advisors do not expect a probable unfavorable
outcome and, therefore, no provision was set up. The
amounts of these contingencies amount as of December 31,
2017 to USD 670 for tax contingencies, USD 1,081 for civil
contingencies. (At December 31, 2016: USD 1,549 for tax
contingencies, USD 2,942 for civil contingencies).
d. INvESTMENT IN FERRoEXPRESo PAMPEANo S.A.C
As of December 31, 2017, the subsidiary TEARG participates
in the activity of rail transport of cargo through its investment
in the company Ferroexpreso Pampeano S.A.C. materialized
through its stake in the holding company Compañía Inversora
Ferroviaria S.A.I.F. The activity of Ferroexpreso Pampeano
S.A.C. is the provision of freight transportation on the rail
line Rosario - Bahia Blanca, operating its activity in more than
5,000 kilometers of railroads.
The net assets of Ferroexpreso Pampeano S.A.C. included
in the consolidated financial statements amounted to USD
14,455 net of non-controlling interests.
On May 21, 2015 was published in the Official Gazette
the Law 27132 which declares the national public interest the
reactivation of railway service of passengers and cargo and
the creation of Ferrocarriles Argentinos S.E. The Argentine
Government should regulate this law within one hundred
eighty days published, at the date of issuance of these
financial statements, this has not been made. According
the content of that law and since it is pending the definition
of the relevant regulatory framework, there is uncertainty
about the potential effects that such changes may cause.
Notwithstanding the above, do not exist in our view, elements
to contemplate on the financial statements of the Company.
e. TAX PRoCEEDINgS - FluoR TECHINT SRl CoNSTRuCCIóN
y SERvICIoS lTDA.
The company Fluor Techint SRL Construcción y Servicios
Limitada (company in which Techint E&C has common
control) is currently subject to tax proceedings brought by the
Internal Revenue Service of Chile (“SII“, as per its name in
Spanish) with respect to requests for refunds of export VAT
made by the company in relation to the contract “Proyecto
Pascua Lama BEASA- Contrato SRL”. These requests
submitted for the tax periods from April 2008 to July 2010
were initially accepted by the tax authority but, later on,
they were rejected based on change of criteria by the tax
authority, who decided that, due to the nature of services
rendered they were not subject to VAT and applied that new
criteria retroactively. Several stages of the proceedings have
already taken place, and the company has filed motions and
appeals at each stage, which, so far, have been rejected, by
the courts of appeal.
On September 5, 2017, the case was sent up to the Supreme
Court and, on April 17, 2018, the decision made by such Court
was to dismiss the appeal filed by the company.
Based on the arguments provided for in such decision, on
April 20, 2018, the company filed a new appeal for reversal
(Recurso de Reconsideración in Spanish). On May 4, 2018,
the appeal was denied.
The company’s position is that with this unfavorable decision,
the Client of the project should be responsible for the
payment of this tax assessment. The base value of VAT
refunds under discussion is USD 15.4 million, and Techint is
accountable for 50% of such amount.
NoTE 22.
RESTRICTED ASSETS
TENCo AND SuBSIDIARIES
At December 31, 2017 and 2016, the net carrying amounts
of the PP&E held under finance lease amount to USD 6,328
and USD 6,206 respectively. At December 31, 2017 and 2016,
liabilities for finance leases amount to USD 3,799 and USD
4,762, respectively.
136 TECHINT E&C S.A. Annual Report 2017
TEBRA
At December 31, 2017, there is no liabilities for finance leases
(at December 31, 2016, liabilities for finance leases amount to
USD 2,786).
Additionally, the information about a request of preventive
blocking of assets made by Tribunal de Contas da União to
TEBRA, has been included in Note 31. Up to the issue of
these Financial Statements, there's no judicial decision
providing an specifically restriction to any asset of TEBRA.
CoINCAR S.A.
Under the Credit Facility Agreement entered into by
Coincar S.A. with Banco Santander Río S.A. and Banco
de Galicia y Buenos Aires S.A., Coincar S.A. agreed not to
sell nor cause to be sold, assign in ownership and/or use
and/or usufruct, mortgage, pledge, loan and/or loan for
use, levy in any manner whatsoever, lease and/or enter
into a leasing, grant a security and/or personal interest with
respect to, not to transfer and/or in any manner dispose
of, either in a transaction or a series of transactions, all
or a substantial portion of any of its assets, goods and/
or rights and/or of its assets, goods and/or rights to be
acquired in the future, nor to distribute dividends, pay fees
to the company’s directors or consultants, without the prior
consent of the majority of the banks that granted the Credit
Facility Agreement.
CoINFER
licensed assets:
In conformity with the regulations established in the
bid specifications and the License Agreement, the
subsidiary FEPSA received from Ferrocarriles Argentinos
assets of its own to be used in the operation (included
in “Property, plant and equipment” non-current). They
primarily comprised infrastructure (main and secondary
railway network), real property (warehouses and
buildings), transportation material (locomotives and
coaches), fixed facilities and other. Upon expiration
of the license, the assets would be returned to
Ferrocarriles Argentinos, at no additional cost, in their
normal condition of maintenance, except for the wear
and tear over time and the normal use.
NoTE 23.
ClAIMS RECEIvABlES
In the year ended December 31, 2011, the Company
recognized the gain arising from indemnification for
consequential damages, as a result of a final and unappealable
decision on April 4, 2011, relating to a Construction Contract
entered into on October 1, 1991 with the Ministry of Education
and Sport that had as its object the construction of 200 units
of the Integrated Center for Child Support (CIAC). This
indemnity was postulated by the Company as a result of the
unilateral termination of the Contract by the Public Power,
executed on September 30, 1996 when 41 CIAC units had
already been completed and others were under construction.
On September 15, 2010, the Superior Court of Justice
recognized the Company's right to be indemnified for the
damages arising from the expert's report, up to December
31, 1998 of R $ 93 millions, duly updated in accordance with
the criteria defined in the decision which became the subject
of judgment on 4 April 2011.
The technical expert report, completed on July 27, 1999,
established the following amounts, as a consequence of
the damages caused, considering the monetary adjustment
factors, valid for the Federal Justice, based on the evolution
of ORTN / OTN / BTN / TR / UFIR, with update until December
31, 1998. On July 18, 2011, the Company proposed the
execution of the decision, accompanied by an accounting
expert's report that updated the amount of the damages
arising in accordance with the criteria defined in the final
judgment, totaling the restated amount R $ 339 millions
as of June 30, 2011.
The amount of the indemnity recorded in 2011 was calculated
based on the value established in the expert's report, net of
legal expenses linked to the realization of the credit and tax
effects, plus monetary restatement by the official indices
(INPC / BACEN) and interest of 1% per month, and the
resulting amount is discounted to present value based on
the DI x TR indices disclosed by BM & FBOVESPA, taking
into account the receipt in court and liquidation thereof in ten
annual installments of equal value as of 2013.
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 137
On October 25, 2011, having been duly summoned to
Execution, the Union opposed Embargoes to Execution, in
which it postulated criteria for updating the debt, divergent
from those defined in the final decision, whose trial occurred
on October 19, 2012. Although the Company considers that
the decision of the lower court judge to reduce the indemnity
amount by six months, the Company conservatively
recognized a reduction in the amount of R $ 14.9 millions,
maintaining the remaining amounts and criteria to update the
credit in accordance with the final decision. The competent
Appeal was filed and awaits judgment by the Federal
Regional Court of the 1st Region.
On September 6, 2012, the Federal Court filed a rescissory
action requesting that the final decision be revoked, which
was challenged by the Company on November 9, 2012, in
order to dismiss the allegations of action . Under current
legislation, a rescission action is only applicable in specific and
fairly restricted circumstances. In the opinion of management,
based on its legal advisors, the likelihood of the rescission
action being favorable to the Federal Government is remote.
The instruction of the rescission action is made, including with
the rejection of the request for production of evidence made
by the Union, and awaits judgment by the STJ.
In 2017, the credit update was made based on the
assumptions that the estimated date of issuance of the
precatory by the Judiciary will be until June 30, 2019 and that
the amounts will be paid by the Federal Government in up
to ten annual installments of equal value to from December
31, 2020 (the maximum payment date according to prevailing
legislation issued by June 30, 2019).
Details:
Claim restated up to the date of recognition by the final and irrevocable court decision
Restatement for the period between the final and irrevocable court decision and December 31,
2011 (INPC)
Interest for the period between the final and irrevocable court decision and December 31, 2011 (1% p.m.)
Total amount at December 31, 2011
Adjustment to present value
Total adjusted to present value at December 31, 2011
Provision for legal fees - 20%
Amount recognized as "Gain from claims, net"
339,263
3,359
13,412
356,034
(57,855)
298,179
(59,636)
238,543
187,711
(37,542)
150,169
Amounts in R$ thousand
Amounts in uSD thousand (*)
2.d
Notes
(*) The amount of the net gain has been translated at the average exchange rate of April 2011 the month on which the final unappealable decision was issued. The receivable as of December 31, 2017 translated at the year-end exchange rate amounts to USD 140,478 (see note 8) and the related provision for legal fees amounts to USD 28,030 (see note 18).
The net amount recorded in income for the year ended
December 31, 2011 is as follows:
138 TECHINT E&C S.A. Annual Report 2017
The changes in the amounts recorded in the claims
receivable and in the related provision for legal fees
are presented below:
Beginning of the year
Translation effect
Increase in the receivable due to application of inflation index (INPC) and interest (1% p.m.)
established in the final court decision (*)
Unwinding of present value adjustment (*)
End of the year
(*) Amount recognized as "Financial results".
129,226
(1,970)
11,338
1,884
140,478
13,222
(25,779)
393
(2,267)
(377)
(28,030)
(2,644)
Claim Provision for legal fees
28
Notes
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 139
NoTE 24.
RElATED PARTy TRANSACTIoNS
TECHINT E&C is controlled by Techint Investments S.A. ,
which owns 100% of the company’s shares. San Faustin SA,
a Luxembourg Société Anonyme (“San Faustin”) owned the
Company through its subsidiaries.
yEAR END BAlANCES wITH RElATED PARTIES oTHERS
THAN THE PARENT CoMPANy.
Rocca & Partners Stichting Administratiekantoor Aandelen
San Faustin, a Dutch private foundation (Stichting) (“RP
STAK”) held voting shares in San Faustin sufficient to control
San Faustin.
No person or group of persons controlled RP STAK.
Notes
non-current assets
Other investments in other related parties
Other investments in associated related parties
Trade receivables from other related parties
Other receivables from associated related parties
Other receivables from other related parties
Current assets
Trade receivables
Trade receivables from associated related parties
Trade receivables from other related parties
Other receivables
Other receivables from associated related parties
Other receivables from other related parties
Cash and cash equivalents
Short-term deposits in other related parties
–
3,710
–
10,382
727
2,944
37,648
–
271
183,899
8,275
2,128
639
8,028
–
21,521
40,634
9,373
1,405
74,845
7
7
8
8
8
8
8
8
8
12
Dec 31, 2017 Dec 31, 2016
140 TECHINT E&C S.A. Annual Report 2017
non-current liabilities
Other liabilities
Other liabilities due to other related parties
Current liabilities
Borrowings
Borrowings from other related parties
Trade and other payables due to associated related parties
Trade and other payables due to other related parties
Other liabilities due to other related parties
Transactions with associated related companies
Sales of goods and services (*)
Purchases of goods and services
Transactions with other related companies
Sales of goods and services
Purchases of goods and services
Financial results net
2,881
1,680
7,114
5,415
609
(4,665)
30
269,386
23,578
1,016
–
13,157
16,648
12,254
609
5,016
266
297,352
26,693
1,629
Dec 31, 2017
Dec 31, 2017
Dec 31, 2016
Dec 31, 2016
17
14
16
16
17
Notes
TRANSACTIoNS wITH RElATED PARTIES
The aggregate compensation of the directors and executive
officers earned during the year ended at December 31, 2017
and the year ended December 31, 2016 amounts to USD
17,061 and USD 15,809, respectively.
(*) In 2017 corresponds to credit notes of AOT Pipelines S.A.P.I de C.V.
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 141
Company
NoTE 25.
PRINCIPAl SuBSIDIARIES
The following is a list of TECHINT E&C’s principal subsidiaries
and its direct and indirect percentage of ownership of each
controlled company at December 31, 2017 and 2016:
Carbonser, S.A. de C.V.
Carbontec, S.A. de C.V.
Compañía Inversora Ferroviaria S.A.I.F.
Constructora Mexicana Electromecánica
y de Instrumentación, S.A. de C.V.
Construcciones Globales Andinas CGA S.A.
Construcciones y Prestaciones Petroleras S.A. (CPP)
Ferroexpreso Pampeano S.A.C.
Flinwok S.A.
Saudi Techint Ltd.
Sidernet Mexicana S.A. de C.V.
Sidernet S.A.
Socominter Sociedade Comercial Internacional Ltda.
Techint Chile S.A.
Techint Compagnia Tecnica Internazionale S.p.A.
Techint Compañía Técnica Internacional S.A.C.I.
Techint Compañía Técnica Internacional S.A.C.I.
Techint Engenharia e Construção S/A. (TEBRA)
TEI&C S.A.
50.00%
50.00%
77.14%
100.00%
100.00%
100.00%
61.71%
100.00%
60.00%
100.00%
100.00%
100.00%
100.00%
100.00%
100.00%
100.00%
100.00%
100.00%
Loading and transportation of coal
Personal Services
Holding Company
Personal Services
Engineering and construction
Engineering and construction
Cargo Railway Transportation Concession
Holding Company
Engineering and construction
Heavy cleaning services
Heavy cleaning services
Sale of machinery and equipment
Engineering and construction
Engineering and construction
Engineering and construction
Engineering and construction
Engineering and construction
Holding Company
Mexico
Mexico
Argentina
Mexico
Ecuador
Ecuador
Argentina
Uruguay
Saudi Arabia
Mexico
Argentina
Brazil
Chile
Italy
Argentina
Uruguay
Brazil
Uruguay
50.00%
50.00%
77.14%
100.00%
100.00%
100.00%
61.71%
100.00%
60.00%
100.00%
100.00%
100.00%
100.00%
100.00%
100.00%
100.00%
100.00%
100.00%
Dec 31, 2017% of ownership
Dec 31, 2016% of ownership
Main ActivityCountry
(1)
(1)
(2)
(1)
(1)
(2)
(1) TEMEX has the power to govern the financial and operating policies of the entity.
(2) Controlling interest through COINFER
(3) On June 27, 2017 TEARG and TIC decided to buy a new subsidiary, with the name of Tefin S.A.
(4) The extraordinary Shareholders meetting of the argentine subsidiary Sidernet held on September 29, 2017 approved the Sidernet spin-off and as a result of the same, the constitution of Tecsesi S.A .
142 TECHINT E&C S.A. Annual Report 2017
Company
Techint Iberia S.L.
Techint International Construction Corp. (TENCO)
Techint Ingeniería y Construcciones S.L.
Techint Inversiones S.A.I.F.
Techint S.A.C.
Techint, S.A. de C.V.
Techint Servicios, S.A. de C.V.
Tecnología en Servicios Urbanos TESUR S.A.
Tecsesi S.A.
Tefin S.A.
TE&C Investments Netherlands BV
TS LNG S.A.S.
Wisdery S.A.
100.00%
100.00%
100.00%
100.00%
100.00%
100.00%
100.00%
–
–
–
100.00%
50.00%
100.00%
Engineering and construction
Holding Company
Holding Company
Holding Company
Engineering and construction
Engineering and construction
Personal Services
Engineering and construction
Heavy cleaning services
Engineering and construction
Holding Company
Engineering and construction
Trading Company
Spain
Bahamas
Spain
Argentina
Peru
Mexico
Mexico
Argentina
Argentina
Argentina
Netherlands
France
Uruguay
100.00%
100.00%
100.00%
100.00%
100.00%
100.00%
100.00%
97.50%
100.00%
100.00%
100.00%
50.00%
100.00%
Dec 31, 2017% of ownership
Dec 31, 2016% of ownership
Main ActivityCountry
(4)
(3)
(1) TEMEX has the power to govern the financial and operating policies of the entity.
(2) Controlling interest through COINFER
(3) On June 27, 2017 TEARG and TIC decided to buy a new subsidiary, with the name of Tefin S.A.
(4) The extraordinary Shareholders meetting of the argentine subsidiary Sidernet held on September 29, 2017 approved the Sidernet spin-off and as a result of the same, the constitution of Tecsesi S.A .
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 143
Current
Cash-flow hedge
Total derivative financial instruments - current
non-current
Cash-flow hedge
Total derivative financial instruments – non current
199
199
–
–
5,675
5,675
2,029
2,029
Dec 31, 2017
NoTE 26.
DERIvATIvE FINANCIAl INSTRuMENTS
liabilitiesAssets
Current
Cash-flow hedge
Derivative financial instruments
Total derivative financial instruments - current
589
–
589
525
153
678
Dec 31, 2016
liabilitiesAssets
Contract Types
Forwards to sell US dollars vs pesos mexicanos
Forwards to sell US dollars vs euros
Forwards to buy US dollars vs euros
Forwards to buy indian rupees vs euros
103,263
21,093
19,941
–
–
16,188
12,012
6,730
Dec 31, 2016Dec 31, 2017Total notional amount in currency of the contract
FoRwARD FoREIgN EXCHANgE CoNTRACTS
The notional principal amounts of the outstanding forward foreign
exchange contracts at 31 December 2017 and 2016 were:
144 TECHINT E&C S.A. Annual Report 2017
(1) Includes employee benefits for USD 4,596 (USD 5,020 at December 31, 2016), contribution plans for USD 66 (USD 103 at December 31, 2016) and long-term incentives for USD 2,661 ( USD 180 at December 31, 2016) .
NoTE 27.
CoST oF REvENuE AND EXPENSES By NATuRE
Wages salaries and social security costs (1)
Taxes, rates and contributions
Fees and technical advice
Sub-contract for services
Purchases of material and supplies
PP&E depreciation
Intangible assets amortization
Work structure expenses
Office structure expenses
Unallocated costs
Total December 31, 2017
Total December 31, 2016
76,279
2,687
22,416
2,372
452
8,787
2,623
1,460
4,572
20,219
141,867
138,943
general administrative and selling expenses
479,724
33,081
104,977
114,964
441,298
35,779
227
9,761
23,955
26,500
1,270,266
1,082,756
Cost of revenue
4
5
Notes
556,003
35,768
127,393
117,336
441,750
44,566
2,850
11,221
28,527
46,719
1,412,133
Dec 31, 2017
536,719
30,189
71,521
165,499
253,571
42,893
3,273
43,695
21,204
53,135
1,221,699
Dec 31, 2016
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 145
NoTE 28.
FINANCIAl RESulTS
income
Interests and indexation
Foreign exchange transaction results
Results from Techint Cía Técnica Internacional S.A.C.I. Impregilo S.p.A. (suc. Arg.) Iglys S.A. -
Unión Transitoria de Empresas – Complejo Penitenciario Ezeiza
Restatement and interest on claims
Other
Costs
Interests and indexation
Foreign exchange transaction results
Comissions
Other
10,890
23,504
6,562
10,578
3,980
55,514
(12,645)
(32,409)
(2,025)
(6,099)
(53,178)
8,407
46,842
8,478
7,971
4,557
76,255
(10,210)
(34,113)
(1,187)
(2,924)
(48,434)
Dec 31, 2017 Dec 31, 2016
21.b
23
Notes
146 TECHINT E&C S.A. Annual Report 2017
NoTE 29.
oTHER oPERATINg RESulTS
Gain from the sale of PP&E
Impairment loss of PP&E
Gain from indemnity
Claims
Restructuring gain /(cost)
Dividens earned
Taxes
Impairment loss other assets
Other
5,158
(193)
995
(2,935)
1,620
104
(1,365)
(4,285)
(2,837)
(3,738)
4,671
(5,528)
882
–
(25,819)
–
(1,199)
–
9,745
(17,248 )
NoTE 30.
INCoME TAX
Current income tax
Deferred income tax
(17,136)
16,762
(374)
(34,810)
(8,699)
(43,509)
Dec 31, 2017
Dec 31, 2017
Dec 31, 2016
Dec 31, 2016Notes
15
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 147
(*) The income tax rates for argentine subsidiaries would be gradually reduced from 35% to 30% for fiscal periods starting from January 1, 2018 until December 31, 2019, and at 25% for fiscal periods beginning on or after January 1, 2020, inclusive.
85,900
(29,546)
1,649
5,263
16
(10,725)
541
(4,589)
(4,381)
–
(1,737)
(43,509)
The net difference between the tax calculated at the rate
in effect in each country and the total charge for the year
is generated by the following:
Income before income tax
Tax calculated at the applicable rate on the result for the year
Effect of restatement in constant currency
Result due to participating interests in subsidiaries and related companies
Provision for loss with inventories and advances to suppliers
Tax loss carry - forwards
PP&E
Non-deductible expenses
Impairment of losses
Effect of change in rate (*)
Other, net
Income Tax
16,988
(10,363)
2,620
479
(11)
(705)
426
(391)
–
(672)
8,243
(374)
Dic 31, 2017 Dic 31, 2016
148 TECHINT E&C S.A. Annual Report 2017
NoTE 31.
MAIN CoNTRACTS
Peru
Coga 5 Proyect - Compañía Operadora de Gas del
Amazonas S.A. (COGA)
Chile
Escondida Water Supply (EWS) Project – Betchtel Chile Limitada
Los Bronces Duct Replacement (High area) - Anglo American Sur S.A.
Los Bronces Duct Replacement (Middle area) - Anglo American Sur S.A.
Uruguay
Maldonado Sewage System - Obras Sanitarias del Estado (OSE)
Route 9 – Corporación Vial del Uruguay S.A.
Brazil
Modules for P-76 Platform – Petrobras Netherlands BV
Projet Ferro Carajás S-11D - Vale S.A.
Argentina
Punta Negra Hydroelectric Power Station
Hydroelectric Power Station - Tambolar
Subway Line H Expansion
Gasoducto Noreste Argentino (GNEA)
ENAP - Piam Magallanes
CAREM 25
Fortín de Piedra
Genelba Plus
260
786
13
28
70
44
889
124
499
98
491
199
123
60
392
191
52%
100%
100%
10%
97%
76%
82%
100%
100%
83%
81%
100%
100%
2%
25%
1%
29%
100%
1%
–
90%
63%
88%
77%
99%
51%
70%
98%
21%
–
–
–
243
781
12
–
69
25
756
122
499
96
387
193
171
–
–
–
Physical progress
Physical progress
Total contract amount (USD million)
Total contract amount (USD million)
Country / work
At December 31, 2017 and 2016 , the main contracts
are the following:
(3)
(2)
(4)
(4)
(1)
(6)
Dic 31, 2017 Dic 31, 2016
Reference:
(1) The Company's participation is 60%
(2) The Company's participation is 40%
(3) The Company's participation is 50%
(4) The Company's participation is 75%
(5) The Company's participation is 33%
(6) The Company's participation is 80%
Notes to the Consolidated Financial Statements. All amounts are shown in USD thousands, unless otherwise stated. 149
mexico and United States of America
Combined Cycle Power Plant Norte III
Internal Coal Handling System Revamp (RSIMC)
Altamira Facilities Compressor Station
Tenaris Bay City
Europe
Dunkerque LNG Fast Reloading
Africa
West Damietta CP-118
Al Shabab CP-118
South Helwan
574
39
87
46
35
30
41
77
5%
0%
42%
100%
56%
95%
99%
81%
–
–
2%
93%
17%
28%
42%
31%
–
–
77
41
33
26
34
71
(3)
Physical progress
Physical progress
Total contract amount (USD million)
Total contract amount (USD million)
Country / work
Dec 31, 2017 DIC 31, 2016
Reference:
(1) The Company's participation is 60%
(2) The Company's participation is 40%
(3) The Company's participation is 50%
(4) The Company's participation is 75%
(5) The Company's participation is 33%
(6) The Company's participation is 80%
150 TECHINT E&C S.A. Annual Report 2017
The Company informs that its Brazilian subsidiary, Techint
Engenharia e Construção S.A. (TEBRA), has contracts with
Petróleo Brasileiro S/A – Petrobras (“Petrobras”) related to
construction services and industrial assembly of oil refining
units (onshore) and oil rigs (offshore) which were signed
following bidding processes conducted in accordance with
Decree No.2.745/98.
On December 29, 2014, TEBRA received a notification from
Petrobras, stating that it was temporarily prevented from
participating in new bidding processes and/or signing new
contracts with Petrobras. TEBRA took all the administrative
(presented its defense) and judicial (filed injunction) measures
in order to reverse such decision. Documentation related
to the administrative process was submitted to the former
Controladoria Geral da União (CGU), now Ministério da
Transparência, which continued with the administrative
procedure of defining responsibility. On April 10, 2015,
TEBRA received a notification from CGU informing that such
administrative procedure was initiated. Until now, TEBRA
has not received any notice of irregularity. Both procedures,
administrative and judicial, are awaiting a final decision.
In addition, TEBRA received notification of two further
administrative procedures opened by Conselho
Administrativo de Defesa Econômica (CADE) in order to
investigate possible infractions in relation to the contract
held with Eletronuclear (procedure opened on November 5,
2015) and Petrobras (procedure opened on December 22,
2015). Another two processes were opened by Tribunal de
Contas da União (TCU) on the same subjects thereafter. In
relation with the TCU administrative procedure regarding the
contract held by the consortium (of which TEBRA was part)
and Eletronuclear, TEBRA was officially notified on March
30th 2017 of a resolution from such agency ruling a 5-year
temporary exclusion for TEBRA to participate in further
tenders to be issued by Federal governmental entities.
TEBRA has already challenged the resolution and this appeal
has suspensive effects. TEBRA will resort all administrative
and judicial instances available. In the other process, TEBRA
had been notified of a request of TCU for a preventive
blocking on its assets in relation to the COMPERJ Project,
which was executed in consortium with Andrade Gutierrez.
TEBRA submitted a proposal by granting a guarantee on a
property owned by the Company, but reserving its rights to
appeal the resolution which considers unfounded. In addition,
and for the same project, the consortium Techint / Andrade
Gutierrez was notified by Petrobras of an internal decision by
which declared the nullity of the contract and requested an
economic repair to the consortium companies. This decision
is not yet firm and will be disputed by the consortium.
Regarding ongoing investigations on the operation known
as Lava Jato (“Car Wash”), the management of the
company reiterates that, to the best of their knowledge
and in accordance with those internal investigations
deemed necessary and sufficient for the management
of the company to be properly informed, no evidence of
wrongdoings has been found with respect to the operations
of our Brazilian subsidiary.
TEBRA will continue to resort to those administrative
and judicial instances available with respect to the
abovementioned reported processes.
NoTE 32.
SuBSEquENT EvENTS
After December 31, 2017, no other events, situations or
circumstances have occurred which might significantly
affect the Company´s equity or financial position, which
have not been adequately contemplated or mentioned in
these consolidated financial statements.
151Board of Directors’ Report
TECHINT E&C S.A.
Board of Directors’ Report
and Consolidated Financial Statements
Annual Report
For the year ended December 31, 2017
and December 31, 2016