______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
NOT Transferable
Security Classification: Non Security
Tender Document For: - “Outsourcing of repairing & maintenance of various
electrical activities”
Tender Number: - 6000007879/BNP/P/Electrical/Outsourcing/2015/OT/RT, Dated: 18-06-2016
This Tender Document Contains _____ Pages. Tender Document is sold to: The Bidder, (104573) INDIA Details of Contact person in SPMCIL regarding this tender: Name : PARIKSHIT JOSHI Designation : DEPUTY MANAGER (MATERIALS) Address : BNPD (Bank Note Press, Dewas) India
BANK NOTE PRESS DEWAS - 455001 (M.P.) A Unit of Security Printing and Minting Corporation of India Limited Miniratna Category - I CPSE Wholly owned by Government of India Web: http://bnpdewas.spmcil.com Tel:07272-255222 E-Mail:[email protected] Fax:07272-255111 Telegram: BANOPRIN
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
_________________________________________________________________________________________
Section 1: Notice Inviting Tender (NIT) 6000007879/BNP/P/Electrical/Outsourcing/2015/OT/RT, Dated: 18-06-2016
(SPMCIL's Tender SI No.) (Date)
1. Sealed tenders are invited from eligible and qualified tenderers for supply of following & services:
Schd. No.
Brief Description of Goods/services
Tentative
Requirement
(In Nos.)
Earnest Money (In Rs.)
1.
Outsourcing of repairing and maintenance of electrical activities for 1 Year.
1 Job
Rs. 53,000/- (Rupees Fifty Three thousand only) in favour of “The General Manager, Bank Note Press, Dewas payable at Dewas”
Type of Tender (Two Bid/ PQB/ EOI/ RC/
Development/Indigenization/ Disposal of Scrap/
Security Item etc.)
TWO-BID Open Tender
(National Competitive Bid)
Dates of sale of tender documents: From 20.06.2016 to 28.07.2016 during office hours.
Place of sale of tender documents Bank Note Press, Dewas
Closing date and time for receipt of tenders 29/07/2016 at 14:30 Hrs.
Place of receipt of tenders BANK NOTE PRESS, DEWAS
Time and date of opening of tenders 29/07/2016 at 15:00 Hrs.
Place of opening of tenders BANK NOTE PRESS, DEWAS
Nominated Person/ Designation to Receive Bulky
Tenders (Clause 21.21.1 of GIT)
PARIKSHIT JOSHI
CHIEF PURCHASE & STORE OFFICER (I/c.)
2. Interested tenderers may obtain further information about this requirement from the above office selling the
documents. They may also visit our website mentioned above for further details.
3. Tender documents may be purchased on payment of non-refundable fee of Rs. 500/- per set in the form of
account payee Demand Draft/Cashier‟s Cheque/Bankers Cheque, drawn on a scheduled commercial bank in
India, in favour of The General Manager, Bank Note Press, Dewas payable at Dewas.
4. Tenderer may also download the tender documents from the web site http://bnpdewas.spmcil.com &
www.eprocure.gov.in and submit its tender by utilizing the downloaded document, along with the required non-
refundable fee as mentioned in Para 3 above.
5. Tenderers shall ensure that their tenders, duly sealed and signed, complete in all respects as per instructions
contained in the Tender Documents, are dropped in the tender box located at the address given below on or
before the closing date and time indicated in the Para 1 above, failing which the tenders will be treated as late
and rejected.
Address:
The General Manager
Administration Block Gate,
Bank Note Press, Dewas (M.P.) 455 001
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
________________________________________________________________________________________
Section II: General Instructions to Tenderers (GIT)
Part I: General Instructions Applicable to all Types of Tenders
Please refer to our website for:
http://bnpdewas.spmcil.com/spmcil/upload document/GIT.pdf
GIT (Total pages : 32)
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
________________________________________________________________________________________
Section III: Special Instructions to Tenderers (SIT) The following Special Instructions to Tenderers will apply for this purchase. These special instructions
will modify/ substitute/ supplement the corresponding General Instructions to Tenderers (GIT)
incorporated in Section II. The corresponding GIT clause numbers have also been indicated in the text
below:
In case of any conflict between the provision in the GIT and that in the SIT, the provision contained in
the SIT shall prevail.
S.No. GIT Clause No. Topic SIT Provision
1 4 Eligible Services (Origin of Services) SIT -1 (Mentioned below)
2 8 Pre bid Conference N.A.
3 9 Time Limit for receiving request for clarification
of Tender Documents SIT -2 (Mentioned below)
4 11.2 Tender Currency SIT -3 (Mentioned below)
Indian rupees (Supplier is
requested to quote price within 2
decimal place. Quotation with
price quote beyond 2 decimal
place is ignored)
5 12.10 Applicability of Octroi and Local taxes SIT -4 (Mentioned below)
6 14 PVC Clause SIT -5 (Mentioned below)
7 19 Tender Validity SIT -6 (Mentioned below)
8 20.4 Number of Copies of Tenders to be submitted SIT -7 (Mentioned below)
9 21 Submission of Tender SIT-8(Mentioned below)
10 33 Evaluation Criteria SIT-9 (Mentioned below)
11 35.2 Additional Factors for Evaluation of Offers SIT-10 (Mentioned below) 12 43 Parallel Contracts Not Applicable
13 50.1, 50.3 Tender For rate Contracts Not Applicable
14 51.1, 51.2 Eligibility Criteria SIT-11 (Mentioned below)
15 52.1, 52.3, 52.5 Tenders involving Pre-Production Samples Not Applicable
16 53.4, 53.5, 53.7 EOI Tenders Not Applicable
17 54.3.1, 54.5.2 Tenders for Disposal of Scrap Not Applicable
18 55.2, 55.3, 55.7,
55.8
Development/ Indigenization Tenders Not Applicable
19 21.1,24.1 Correction in GIT Clause SIT -12 (Mentioned below)
SIT 1 : Eligible Services
All the related services to be provided under the contract shall have their origin in India, subject to any
restriction imposed in this regard in Section III (SIT). The term “origin” used in this clause means the
place where the related services are arranged and supplied.
SIT 2 : Clarification of Tender Documents
A Tenderer requiring any clarification or elucidation on any issue of the tender documents may take up
the same with BNP DEWAS in writing or by fax / e-mail/ post. BNP DEWAS will respond in writing
to such request provided the same is received by BNP DEWAS not later than 21 Days prior to the
prescribed date of submission of tender. In case the clarifications are not given by BNP Dewas in
stipulated time frame then the bidder must strictly follow the tender terms & conditions. Copies of the
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
query and clarification, if any, shall be sent to all prospective bidders who have received the bidding
documents.
_______________________________________________________________________________________________
SIT3 Tender currencies
1.1 The tenderer shall quote only in Indian rupees.
1.2 The tenders quoted in foreign currencies should not be accepted.
SIT 4 : Wherever Service Tax/Other tax is applicable, the following may be noted :
The tenderer should quote the exact percentage of Service Tax/other tax that they will be charging extra.
SIT 5 : Price Variation Clause: As per the revision in the minimum wages time to time by the
concerned authorities of Central/State Government, the minimum wages applicable in that period will be
given.
SIT 6 : Tender Validity
The tenders shall remain valid for acceptance for a period of 120 days after the date of tender
opening prescribed in the tender document. Any tender valid for a shorter period shall be treated
as unresponsive and rejected.
In exceptional cases, the tenderers may be requested by BNP DEWAS to extend the validity of
their tenders up to a specified period. Such request(s) and responses thereto shall be conveyed by
surface mail or by fax/e-mail followed by surface mail. The tenderers, who agree to extend the
tender validity, are to extend the same without any change or modification of their original tender
and they are also to extend the validity period of the EMD accordingly. A tenderer, however, may
not agree to extend its tender validity without forfeiting its EMD.
In case the day up to which the tenders are to remain valid falls on/ subsequently declared a
holiday or closed day for BNP DEWAS, the tender validity shall automatically be extended up to
the next working day.
Compliance with the Clauses of this Tender Document: Tenderer must comply with all the
clauses of this Tender Document. In case there are any deviations, these should be listed in a chart
form without any ambiguity along with justification.
SIT 7 : Number of Copies of Tenders to be submitted :
Tenderer shall submit their tender in “Original” only.
SIT 8 : Submission of Tender :
Techno-commercial bid and Price Bid are to be submitted in two separate double sealed Envelopes on
or before the due date of the submission of the tender as stated below otherwise tender / bid /quotation
shall be liable for rejection.
Part-I : Techno-commercial bid [First Envelope]
Mandatory Check List
The tenderer has to submit sealed & signed tender document by authorized signatory of the
tenderer as a token of acceptance of all section/terms & conditions of this tender document.
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
_______________________________________________________________________________________________
Tender Fee : Rs. 500/- in form of DD/Bankers Cheque, if the tender document is downloaded
directly from SPMCIL website or Cash receipt in case the tender is purchased from Bank Note
Press Dewas. The firm who are registered under NSIC, DGS&D, and Micro & Small Enterprises
(MSE) for Similar Work may be exempted from submitting the EMD on producing valid
certificate. The certificate should clearly indicate the Service Details similar to Bank Note Press
requirement and the validity of the certificate (Valid upto _________________) otherwise,
certificate will not be considered for exemption of Tender Fee.
Earnest Money Deposit: EMD of Rs. 53,000/- (Rs. Fifty Three Thousand Only)
EMD must be submitted along with the tender in form of DD/FDR/Bankers Cheque only in favour
of “The General Manager, Bank Note Press, Dewas” Payable at Dewas, Failing which the offer
will be ignored. The firm who are registered under NSIC, DGS&D, and Micro & Small
Enterprises (MSE) for Similar Work may be exempted from submitting the EMD on producing
valid certificate. The certificate should clearly indicate the Service Details similar to Bank Note
Press requirement and the validity of the certificate (Valid upto _________________) otherwise,
certificate will not be considered for exemption of EMD.
Power of attorney indicating that authorized signatory is competent & legally authorized to submit
the tender and /or to enter into legally binding contract.
The eligibility criteria for the tender are given in Section IX. The bidder have to submit all the
documents & relevant proof in support of relevant clauses mentioned in section – IX along with
all desired document as per Section - VI: List of Requirement and Section –VII: Scope of Work.
A Copy of the price bid proforma shall be submitted along with Techno-commercial Bid leaving
blank the price portion (i.e. showing the unit, currency & total price of the service offered as
xxxx) so as to indicate the services being offered. It may be noted that the price is NOT to be
quoted with the techno-commercial Bid otherwise the tender shall be liable for rejection.
Part-II : - Price Bid [Second Envelope]
The tenderer shall quote their prices strictly as per the proforma given in Section-XI of the tender
document. No additional / extra item with price shall be included other than that of Section-XI.
NOTE:-
i. The envelopes containing bids shall be super scribed as Techno-commercial Bid and Price Bid
separately for “Outsourcing of Manpower for BNP W/Shop (Electrical) for the period of one
Year”. The sealed envelopes shall be again put in another envelope and should be sealed & super
scribed as tender for “Outsourcing of Manpower for BNP W/Shop (Electrical) for the period
of One Year”. Due on: 29/07/2016 at 15.00 hrs.
ii. If the tender is not submitted as per above format, offer / bid / tender will be liable for rejection.
iii. Late tender shall not be accepted. Tenderer shall submit their offer only on prescribed form.
Tenders by fax/email shall not be accepted. Tender by post / hand/ courier received on or before
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
the due date & time shall be accepted. Postal delay / delay by courier services etc. shall not be
condoned, what so ever reason may be.
_______________________________________________________________________________________________
SIT 9:- Evaluation Criteria:
In the first instance, the eligibility criteria and the techno-commercial part of the tender
document will be considered for the evaluation. These offers/bids will be scrutinized & evaluated
by the committee/authority with reference to the parameters prescribed in the Section - VI: List
of Requirement, Section –VII: Scope of Work & Section IX: Eligibility Criteria and the
technical acceptance of the bids is on the basis of Section - VI: List of Requirement, Section –
VII: Scope of Work & Section IX: Eligibility Criteria of the tender document .If the
clarifications required by the purchaser the bidder have to submit their reply within stipulated
time period by fax /email/courier/speed post accordingly the offers submitted by the firms would
be scrutinized & evaluated .
In the Second stage, the Price bid of only eligible/the technical acceptable offers (as mentioned in
first stage) will be opened for further scrutiny & evaluation . The evaluation criteria for awarding
the contract shall be given to L1 Bidder as per Section-XI of the price bid.
SIT 10 : Additional Factors for Evaluation:
35.2: MSE registered firms are exempted from paying the cost of tender document.
35.3: Price preference to MSE is applicable vide Ministry of Micro Small and Medium
Enterprises letter no. D.O. 21(1)/2011-MA dt. 25/04/2012 and NSIC letter no.
BSIC/HO/BD/66/PPP/14-15 dt. 23/01/2015. In tenders participating MSEs quoting price within
price band of L1+15 percent shall also be allowed to supply a portion up to 20% of requirement
by bringing down their price to L1 price where L1 in non MSEs
SIT11: Eligibility Criteria The eligibility criteria for the tender has given in Section IX .The bidder have to submit all the
documents & relevant proof in support of relevant clauses mentioned in section – IX in technical bid
only.
SIT 12: Corrections in GIT Clauses:
GIT CLAUSE WRITTEN AS IN GIT CORRECTED AS IN SIT
21.1 In 3rd
line of procurement manual the words
“Para 11 of NIT”
“Para 1 of NIT”
21.1 In 6th
line of procurement manual the words
“Clause 11 of NIT”
“Clause 1 of NIT”
24.1 In 2nd
line of procurement manual the words
“Clause 11 of NIT”
“Clause 1 of NIT”
18.4 In third line of last para of procurement
manual the words “Clause 33 of NIT”
“Clause 3 of NIT”
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
10.1 10.1(a) second line “clause no.19.19” “Clause 19.4 of GIT”
________________________________________________________________________________________
Section IV: General Conditions of Contract (GCC)
Part I: General Conditions of Contract applicable to all types of Tenders
Please refer to our website for:
http://bnpdewas.spmcil.com/spmcil/upload document/GCC.pdf
GIT (Total pages: 28)
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
________________________________________________________________________________________
Section V: Special Conditions of Contract (SCC)
The following Special Conditions of Contract (SCC) will apply for this purchase. The corresponding
clauses of General Conditions of Contract (GCC) relating to the SCC stipulations have also been
incorporated below. These Special Conditions will modify/ substitute/ supplement the corresponding
(GCC) clauses.
Whenever there is any conflict between the provision in the GCC and that in the SCC, the provision
contained in the SCC shall prevail.
S. No GCC Clause No. Topic SCC Provision
1 8.2 Packing and Marking Not Applicable
2 11.2 Transportation of Domestic Goods Not Applicable
3 12.2 Insurance Not Applicable
4 14.1 Incidental Services Not Applicable
5 15 Distribution of Dispatch Documents
for clearance/ Receipt of Goods
Not Applicable
6 16.2,16.4 Warrantee Clause Not Applicable
7 19.3 Option Clause Not Applicable
8 20.1 Price Adjustment Clause Not Applicable
9 21.2 Taxes and Duties SCC-1 (Mentioned below )
10 22,22.1,22.2,
22.4, 22.3,22.6
Terms and Mode of payments SCC-2 (Mentioned below )
11 24.1 Quantum of LD & Penalty SCC-3 (Mentioned below )
12 25.1 Bank Guarantee and Insurance
for Material Loaned to Contractor
Not Applicable
13 33.1 Resolution of Disputes SCC-4 (Mentioned below )
14 36.3.2,36.3.9 Disposal/ Sale of Scrap by Tender Not Applicable
16 Failure & Termination SCC-5 (Mentioned below )
17 Force Majeure SCC-6 (Mentioned below )
SCC-1 : Taxes and Duties Supplier shall be entirely responsible for all taxes, duties, fees, levies etc.
incurred until the completion of contract at BNP DEWAS.
SCC-2 : Terms and Mode of Payment :
The payment (s) shall be made to the contractor are subject to deduction of tax (s), cess levied by any
Government as per rules from time to time and will be made through RTGS / NEFT after the completion
of every month on completion of the assigned work on 7th
day of each month and after certification by
user department. The bill must be submitted in triplicate. Further, the agency shall furnish a copy of
deposition of monthly EPF/ESIC challans / returns etc. with next bill, failing which amount as deemed fit
by Bank Note Press, Dewas shall with hold in the next subsequent bill. The payment must be made
before Officer (HR)/Officer (Estate) or GM, BNP representative, which should be duly authenticated by
him. The required strength of manpower under various categories shall be as per actual requirement and
any increase/decrease thereby in the actual deployed manpower shall increase/reduce the payment to be
made proportionately as per contracted rates
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
_______________________________________________________________________________________________
SCC-3 : Quantum of Liquidated damages & Penalty : 3.1 The Contractor shall disburse monthly payment to its deployed manpower latest by 5th of every
month, failing which penalty of Rs. 1000/- per day will be imposed up to 15th of the month and
thereafter the contract shall liable to be terminated. Security Deposit /Performance Bank
Guarantee shall be forfeited and Bank guarantee will be en-cashed. The BNP will have the power
to appoint any other agency for the manpower services at the risk and cost of the Contractor.
3.2 Whenever and wherever it is found that the assigned work is not performed up to the entire
satisfaction of the BNP, it will be brought to the notice of Contractor by the BNP and if no action
is taken immediately, penalty of Rs.1000/- per day per complaint will be imposed by invoking
penalty clause.
3.3 The Contractor has to maintain adequate number of manpower as per this contract and also
arrange a pool of standby manpower of requisite qualifications. If the required number of persons
is less than the specified number as mentioned in the contract, a penalty of Rs.500/- per absentee
per day shall be deducted from the bill(s)
3.4 In case the Contractor fails to fulfill the minimum statutory requirements (ESIC/ EPF) as per the
conditions of the tender document and fails to produce the concerned documents, it shall be
treated as breach of the Contract and the Contractor is liable to be blacklisted by the BNP, in
addition to forfeiting of the monthly bills and Performance Security Deposit.
3.5 In case of breach of any conditions of the contract and for all types of losses caused including
excess cost due to hiring services in the event of Contractor failing to provide requisitioned
number of manpower, the BNP shall make deductions at double the rate of hiring rate on pro rata
basis from the bills preferred by the Contractor or that may become due to the Contractor under
this or any other contract or from the security deposit or may be demanded from him to be paid
within seven days to the credit of the BNP.
SCC-4: Resolution of disputes
If dispute or difference of any kind shall arise between BNP Dewas and the supplier in connection with or
relating to the contract, the parties shall make every effort to resolve the same amicably by mutual
consultations. If the parties fail to resolve their dispute or difference by such mutual consultation within
twenty one days of its occurrence, then, unless otherwise provided in the SCC, either BNP Dewas
or the supplier may seek recourse to settlement of disputes through arbitration as per the Arbitration
and conciliation Act 1996 as per following clause.
Arbitration Clause: - If both parties fail to reach such amicable settlement, then either party (the
Purchaser or Seller) may within 21 days of such failure give a written notice to the other party requiring
that all matters in dispute or difference be arbitrated upon. Such written notice shall specify the matters
which are in difference or of difference of which such written notice has been given and no
other matter shall be referred to the arbitration in accordance with the conciliation and
arbitration rules of International Chamber of Commerce (ICC)/United National Commission on
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
International Trade Law (UNCITRL) by three arbitrators appointed in accordance with the
procedure set out in clause below. The arbitration proceeding shall be held in New Delhi
_______________________________________________________________________________________________
and shall be conducted in English language. All documentation to be reviewed by the arbitrators and/
or submitted by the parties shall be written or translated into English. Venue of
arbitration shall be New Delhi. The arbitrator or arbitrators appointed under this article shall have the
power to extend time to make the award with the consent of the parties. Pending reference to arbitration,
the parties shall make all endeavours to complete the contract/work in all respects and all disputes,
if any, will finally be settled in the arbitration.
SCC-5: Failure & Termination A) Cancellation of contract for Default: Without prejudice to any other remedy for breach of contract, like
removal from the list of registered Contractor, by written notice of default sent to the Contractor, the
contract may be terminated in whole or in part:
(i) If the Contractor fails to provide any or all the services within the time period (s) specified in the
contract, or any extension thereof granted
(ii) If the Contractor fails to perform any other obligation under the contract within the period (s)
specified in the contract or any extension thereof granted.
B) Termination of Contract for convenience: Bank Note Press, Dewas (M.P.) may at any time terminate
the Contract by giving you one month‟s prior notice in writing to that effect and shall have the liberty to
appoint any other agency to carry out your obligations under this Contract.
SCC-6: Force Majeure:
7.1 In the event of any unforeseen event directly interfering with the supply of stores arising during the
currency of the contract, such as war, hostilities, acts of the public enemy, civil commotion,
sabotage, fires, floods, explosions, epidemics, quarantine restrictions, strikes, lockouts, or acts of
God, the Contractor shall, within a week from the commencement thereof, notify the same in
writing to the Purchaser with reasonable evidence thereof. Unless otherwise directed by in writing, the
supplier shall continue to perform its obligations under the contract as far as reasonably practical, and
shall seek all reasonable alternative means for performance not prevented by the Force Majeure event.
If the force majeure condition(s) mentioned above be in force for a period of 90 days or more at any
time, either party shall have the option to terminate the contract on expiry of 90 days of
commencement of such force majeure by giving 14 days‟ notice to the other party in writing. In case of
such termination, no damages shall be claimed by either party against the other, save and except those which
had occurred under any other clause of this contract prior to such termination.
7.2 Notwithstanding the provisions contained in GCC clauses 23, 24 and 26, the supplier shall
not be liable for imposition of any such sanction so long the delay and/ or failure of the supplier in
fulfilling its obligations under the contract is the result of an event of Force Majeure.
7.3 In case due to a Force Majeure event is unable to fulfill its contractual commitment and
responsibility, BNP Dewas will notify the supplier accordingly and subsequent actions taken on
similar lines described in above sub-paragraphs.
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
_______________________________________________________________________________________________
Section VI: List of Requirements Schd. No.
Brief Description of Goods/services
Tentative
Requirement
(In Nos.)
Earnest Money (In Rs.)
1. Outsourcing of Manpower for BNP
W/Shop (Electrical) for the period of
1 YEAR.
One Job Rs. 53,000/- (Rupees Fifty Three
thousand Only)
1. Duration of Contract: The contract will remain enforce for a period of one year from the date of award
of contract.
2. Security Deposit: The firm on whom contract will be placed will have to submit 10% of the total
cost of the contract against security deposit in form of DD/FDR/Bank Guarantee drawn on any
scheduled commercial bank in India only in the favour of "The General Manager, BNP Dewas"
payable at Dewas within 21 Days from the date of contract. The Security Deposit should remain valid
for a period of 60 days beyond the date of completion of all contractual obligations.
3. Statutory requirement (Certified copy to be enclosed):
Labour License from competent authority.
PF Registration
ESI Registration
PAN/TAN Number
Service Tax Number (PAN Based)/ VAT/TIN Number
4. Other requirements for the Bidders :
a. The bidder shall provide names of organization(s)/firm(s) with addresses & telephone numbers,
fax numbers, email addresses to which they have provided similar type of services annually
during the last five years.
b. The application should be submitted in Hindi/English Language. The authenticated copies of the
documents in support of the applicant‟s claims may be submitted in Hindi/English Language.
c. The bidder shall indicate that authorized signatory is competent & legally authorized to submit
the tender and / or to enter into legally binding contract.
Note: Tenderer‟s attention is drawn to GIT clause 17 and GIT sub-clause 10.1
The tenderer is to provide the required details, information, confirmations, etc accordingly, failing which
it‟s tender is liable to be ignored. Following details may also be provided.
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
_______________________________________________________________________________________________
Detail of Agency or firm:-
Name and Complete address of the firm :- ______________________________________________________
_____________________________________________________
____________________________________________________________
____________________________________________________
Contact of firm: Phone No : ---------------------------------------
Mobile No: --------------------------------------
FAX No : ----------------------------------------
E-mail No:----------------------------------------
Local / Central Sales Tax / Service Tax / Excise Registration No.
(Copy of certificate enclosed. If applicable):-
____________________________________________________________
Income Tax P.A.N. No.(Copy enclosed):- _______________________
For transaction through RTGS/NEFT:-
1. Name of Bank: _______________________________________
2. Account No : _______________________________________
3. MICR No : _______________________________________
4. IFSC Code : _______________________________________
Details of ITCC / NSIC / DGS&D Registration. Please enclose Photostat
copies.
Date: Name & Signature
Seal of the Firm
Address:_________________
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
________________________________________________________________________________________
Section VII: Scope of Work & Terms & Conditions _______________________________________________________________________________________
Subject: Outsourcing for operation and maintenance of Electrical Activities in Utility Area.
ANNEXURE – A
Description of Work
1 Repairing & maintenance work for the Workshop-Electrical: BNP‟s workshop- electrical section is dealing with maintenance & the repair work for the various key areas in the
factory premises for the various departments which require the electrical related preventive, breakdown and
corrective maintenance & repairing work on as and when required basis as per Annexure-B & Annexure-C. The
work and requirement is mentioned below -
S. No. Description/Activity Manpower
required as
per nature
of work (Nos.)
Nature of Manpower Qualification
1 Electrical Work
The electrical section is having
the various types of electrical
works such as operation of HT/LT
substations, maintenance of
DG set, Ink Factory and varnish
plant machines, maintenance of
electrical appliances and various
types of electrical repairs, Street
and Perimeter Lighting Work,
Electrical maintenance
Work in A.C. Plant, Air Washer,
A.H.Us, maintenance & servicing
of machine and equipment are day
to day performed in the electrical
section. Detail description is as per
Annexure B & Annexure-C.
Daily Regular work like cleaning
of Substation yard, substation I,II,
and III, DG rooms and other
utility area and also do the work
04
(Electrician/Sr.
Electrician)
skilled
10 (Electrician)
skilled
6 Attendant
/Helper
Unskilled
Skilled and experienced
in HT/LT Substation
Operation and MOCB,
ACB, VCB, switch gear
operation and Electrical
Maintenance work and
11KV & 440 V Diesel
generator operation and
maintenance work
Skilled and experienced
in electrical maintenance
work and diesel generator
operation
Having work experience
of doing such type of
work in any
Diploma Holder
with more than 5
year experience
in relevant field
(approved by
CEIG of MPELB)
Diploma/ITI Holder
with 3 year
experience or
5 year experience in
relevant field
(approved by
CEIG of MPELB)
At least 10 standards
passed and having
basis knowledge of
electrical
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
like digging for cable routing etc. organization. fundamentals.
ANNEXURE – B
SCOPE OF WORK
1. GENERAL
The work of Electrical activities are to be carried out in BNP through annual contract which shall cover the
following scope of work :-
S
No
Description Qty.
I
The contractor shall deploy four Diploma Engineers and eight licensed diploma/ITI
technicians (approved by CEIG of MPELB) and four attendants to BNP and their
posting will be done as per requirements of BNP in each shift for operation and
maintenance of electrical installations. There shall be 3 shifts per day throughout the
year and each shift is of 8 hours duration. Contractor shall provide minimum one-day
duty off once in a week for the employee working on shifts and shall provide
alternative arrangements for the employee on off duty / sick leave
II
Electrical Operation /Maintenance :
1. Routine maintenance of all electrical installations such as substation equipment's
including 33 kV Switchyard, Transformers (33/11kV, 11/0.4 kV) HT/LT panels
including CT/PT, switchgears, OCBs, ACBs, A/C plant panels, Air-washer
panels, DG set panels, pump motors, starters, Ink Factory and varnish plant
machines bore well motors, UPS, sewage pumps, general lighting, street lightings,
canteen equipment and installation etc. in the BNP non-security areas.
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
2. Attending day-to-day faults of any kind of light/fan fittings, water coolers,
heaters, water pumps, motor starters, HT/LT cables, LT panels, HT panels, AC
plant panels and transformers, street lights, perimeter wall lights, main-canteen
and electrical installation of non-security areas.
3. Attending of faults in main switches, distribution boards, HT/LT, ACBs, OCBs,
MCBs, MCCBs panel board and AMF panel etc. In case of major breakdown, the
contractor should assist the in-charge/department staff till the rectification of the
defects.
4. Attending cable faults, termination of cable, re-termination, if required. The
contractor shall arrange to give temporary connection if the cable fault could not
be rectified within a day.
5. Operation and maintenance of all the electrical installations in accordance with
manufacture‟s specification, instruction manuals, IE rules and other rules as
specified by CEIG and MPPKVVCL.
6. Maintenance of DG sets whenever required including its electrical installations /
equipment such as alternators, pumps, motors, solenoid etc.
7. Operation of DG set, panels/battery maintenance, including periodical lubrication,
greasing, oiling and cleaning. A separate register shall be maintained with all the
details for the operation and maintenance carried out including consumption of
diesel oil, daily logbook will be maintained by logging all readings of DG sets as
per OEM‟s instructions and shall be produced to Engineer in charge BNP timely.
8. To check the power factor (PF) and operate the capacitor bank for PF correction,
if required.
9. Checking of all earth electrodes, continuity of earth, measurement of earth
resistance and maintain record for each electrode at least once in a six months.
10. Maintenance of all lighting circuits in all workplaces including perimeter and
street lighting, Replacement of tubes, lamps and other accessories with the spare
parts provided by the BNP.
11. Consistently coordinate with the related equipment maintenance contractors for
DG set, ACBs, OCBs etc. and get the servicing done by them.
12. During breakdowns, the electrical staff should immediately rectify the problem or
contact the Engineer in-charge of BNP in case of any difficulties arises for
attending the breakdown.
13. Any other item/work not included above but required for ensuring uninterrupted
electrical and smooth maintenance at the campus.
III Preventive Maintenance : 1. Preventive maintenance of all electrical installations to be carried out in a well-
planned manner with periodicity as detailed in general or as directed by Engineer
In charge of BNP.
2. Servicing of all panels, DBs on weekly, monthly and yearly basis.
3. Routine preventive maintenance work such as battery maintenance, checking and
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
tightening of electrical wiring connections/joints and replacing accessories as
when required.
IV Cleaning : 1. Cleaning & checking of all electrical appliances such as light fitting, ceiling /
exhaust fans, switchboard, cable boxes, panel board etc., once in a quarter.
2. Cleaning of the meters / MCCBs / Feeder Pillars / distribution boards located at
various locations on monthly basis.
3. Cleaning of LT/HT panel room, DG room, transformer room, all MCBs, starters,
distribution panels etc. These areas should be kept neat and clean.
4. Cleaning of floor and all electrical equipment's and machinery and grass cutting
of Substation I yard
5. Dusting and cleaning of utility area as required to clean and all instruction will be
Followed by the workers provided by the concern officer of Substation.
V General : 1. All the removed materials for routine maintenance works should be brought to the
office for accountability and a separate register needs to be maintained showing
all received/used electrical consumables supplied by the BNP. No materials
should be left anywhere in the campus.
2. All tools and machinery required for routine works, preventive maintenance etc.
such as pliers, cutter, screw drivers, spanner set, blower, drill machine, crimping
tool, megger, earth tester, pipe wrench, tripod, safety equipment‟s etc. shall be
provided by the contractor.
3. All breakdown calls / complaints received during normal working hours should be
attended to as early as possible. No complaints should be left unattended and not
be postponed to next day.
4. Any damage is caused to any equipment / or items available at the office
premises due to negligence of the contractor‟s work force shall be entirely on
contractor, the amount so involved on this account shall be deducted from the
payment due to contractor.
5. All employees would be in neat, clean and well groomed appearance and should
have proper name badges. The police verification all employees of contractor
posted in day/night shift shall be submitted to this office for preparing gate passes.
6. While on duty, all employees will wear uniform provided by the contractor.
Uniform would be clean, in good state and having different color than BNP
employees.
7. The staff will be carrying the identity card while on duty.
8. Safety shoes will be worn by all staff.
9. The staff will ensure wearing respective work masks, safety gloves and belts as
and when required.
10. The staff would be trained to face emergency situations, such programs could be
industry specific and would be conducted in co-ordination with the clients training
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
department.
11. Any special tools are not considered will be provided by contractor.
12. Conveyance to site to & fro and food charges / canteen charges will be borne by
contractor.
13. Submission of bills: Bills should be submitted in triplicate duly pre-receipted
after affixing appropriate revenue stamp on the original. Proper reference of this
work order with date should be made in the bill to avoid delay. In maintenance
service vouchers necessary details / ref. may be given to verify the bills.
ANNEXURE – C 1. Maintenance work at Sub-station
S. No. Description Work
1 33 kV Sub-station N0.1. switch yard maintenance
Pre-Monsoon and after monsoon maintenance of Isolator, MOCB
and overhead lines/bus bars
One time pre-monsoon &
after monsoon in a year
2 Sub-station No. 1, 2, 3 & Ink factory sub-station, maintenance of
knife switches (9 Nos.), OCB‟s (28 Nos.), CT/PT and transformers
yearly maintenance
3 (i) Maintenance of 33/11 kV transformer 6000 kVA - 02 Nos.
(ii) Maintenance of 11/0.433 kV transformer 50 kVA - 01 No.
(iii) Maintenance of 11/3.3 kV transformer 4500 kVA - 01 No.
(iv) Maintenance of 11/3.3 kV transformer 3000 kVA- 01No.
(v) Maintenance of 11/0.433 kV transformer 1000 kVA - 04 Nos.
(vi) Maintenance of 11/0.433 kV transformer 3150 kVA - 02 Nos.
(vii) Maintenance of 11/0.433 kV transformer 500 kVA - 03 Nos.
Monthly / yearly
maintenance
4 Testing of earth resistance, HT/LT cable, IR value yearly maintenance
5 Maintenance of Switch board panels of sub-station No. 1, 2, 3 & Ink
factory sub-station
yearly maintenance
6 Maintenance of Alternator, self-starter and panels of 9 Nos. DG sets yearly maintenance
7 Maintenance & lighting arrangement, of Electrical equipment of
Canteen, Pump house, Solar system, Fire station
As and when required
8 Maintenance & lighting arrangement of Tube well motor & starters,
old & new D- Plant.
As and when required
9 Maintenance & lighting arrangement of Sewage plant. As and when required
10 Lighting maintenance work of Press street light & perimeter wall.
Lighting maintenance of AC Plant building, S/S, DG sets building
etc.
As and when required
11 Break down to attended on the panels of Sub-station & Air
conditioning plant
As and when required
2. Maintenance of Diesel Generating Sets
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
S.No. Description Work
1 General Maintenance of 9 Nos. of DG sets (Cleaning, Water level,
Diesel level checking)
Daily
2. Weekly checking of DG sets Weekly
3. Cleaning & replacement of air filter, oil filter Periodically / quarterly
4. Checking & adjusting of DG set head bolts, tappet, and clearance. After every 5000 hrs.
5. Sound level & pollution testing Quarterly
6. Periodically maintenance of 9 DG sets & 1 No. Portable DG set. Periodically & yearly
3. Maintenance work in Air Conditioning Plant
S.No. Description Work
1 Centrifugal Compressor Motor and starter 580 H.P. 3.3KV – 04 nos
120 HP Reciprocating Compressor Motor- 01 No
100 HP Motor- 04 Nos
40 HP to 60HP Motor- 35 Nos
15 HP to 30 HP Motor- 50 Nos
Less than 15 HP Motor- 60 Nos
Yearly Maintenance
2 Maintenance of Console Panels of A.C. Plant Half Yearly Maintenance
ANNEXURE – D
1. General Instruction
1.1 The Annual contract shall be initially for a period of one year and shall be extendable up to two more years on
observation of satisfactory performance.
1.2 The contractor shall provide the maintenance services to the satisfaction of Engineer In-charge of BNP.
1.3 The performance of the contractor shall be reviewed on monthly basis and in case the services are not found
to be satisfactory the contract shall be terminated even before the expiry of contract period by giving one month’s notice. However, the contract is liable for immediate termination on violation of any of the provisions by the contractor. BNP shall not pay any compensation for early termination.
1.4 If the contractor fails to execute the maintenance works as detailed in ‘Scope of Work’ within stipulated time,
the BNP will be at liberty to execute the work through an alternate source and the charges so incurred shall be recovered from the contractor.
1.5 The contractor, whose tender is accepted, shall deposit an amount equal to 10% of the contract value towards
Security Deposit for the due performance of the contract, which shall be refundable after expiry / termination of the contract. The security deposit shall be in the form of Demand Draft in favor of ‘General Manager BNP, Dewas’ payable at Dewas. The deposit shall not bear any interest.
1.6 Care must be taken to ensure while carrying out the work so that no machines, fittings, fixtures, installation &
furnishings are damaged. Any damages done to the same or any other property will have to be repaired / replaced by the contractor, failing which the same will be got done at his risk and cost.
1.7 The BNP shall be entitled to adjust or appropriate the security deposit towards loss or damage caused by the
contractor or his staff or the amount of value of breakage or damage to BNP property or against any other liability of the contractor.
1.8 The contractor shall obtain at his own cost, any license. Police Verification or permission of any sort
whatsoever that may be required under various Acts from the Central / State Government authorities for carrying out the said activities in the premises of the BNP and such registrations and license for engagement of maintenance workers for such purpose.
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
1.9 The contractor shall comply and implement all the statutory provisions of the State & Central Acts relating to
the employment of labor i.e. various acts relating to payment of minimum wages, ESI, PF, Insurance etc. and all other statutory rules as amended from time to time. Further, the contractor shall indemnify the BNP against any claims whatsoever that may arise on account of such non-compliance of any of the rules, regulations etc. laid down by the central/state government and other statutory authorities from time-to-time.
1.10 The contractor shall maintain such records as are necessary under the various statutory acts notified by the
Govt. and product them for inspection as and when required.
1.11 The contractor shall satisfy the BNP showing adequate recorded proof that the minimum wages, ESI, contribution to provident fund as applicable are being paid to his staff as required under various statutory acts notified by the Government from time-to-time.
1.12 The contractor shall be responsible for any claim arising out of the terms and conditions of the employment
under the payment of wages act and contract labor (abolition and registration) act or any other law
1.13 TERMINATION OF THE CONTRACT BY BNP:
If the Contractor stops the works for more than 3 days continuously, then the BNP has the power to
terminate the Contract without giving any notice whatever may be the reason. In this case the
contractor has no power to claim compensation and their Security Deposit will be forfeited. The BNP
has the authority to complete the remaining works through other agencies. Decision of the BNP in this
regard is final. The BNP has the authority to terminate the contract without specifying any reasons
thereof, without any compensation at any time during the current contract. However, one-month notice
will be given prior to cancellation. The contractor has no right to withdraw or leave the contract in mid
before expiry of the term of the specified valid tenure of the contract.
1.14 CONTRACTOR’S RESPONSIBILITY:
The contractor shall provide everything necessary for the proper execution of the works according to
the intent and meaning of the schedule of quantities and specifications taken together whether the same
may or may not be particularly shown or described therein provided that the same can reasonably be
inferred there from. If that contractor finds any discrepancy in the schedule of quantities and
specifications, he shall immediately and in writing refer the same to the BNP Authorities who shall
decide which is to be followed.
1.15 The contractor shall work and keep records following ISO 9001/ISO14001 1.16 The Contractor shall deploy all manpower at BNP in the manner and as per the instructions of Bank Note
Press, Dewas 1.17 The Contractor shall ensure that all personnel are fully conversant with the premises and with the BNP’s
business activities and its related work requirements. 1.18 Bank Note Press, Dewas shall have the right to have any person removed who is considered to be undesirable
or otherwise and similarly the Contractor reserves the right to remove the personnel with prior permission of BNP, emergencies exempted.
1.19 The Contractor shall cover its personnel for personal accident and/ or death whilst performing the duty. 1.20 The Contractor shall exercise adequate supervision to ensure proper performance of services in accordance with
the requirements. 1.21 The Contractor shall issue identity cards / identification documents to all its employees who will be instructed
by the Contractor to display the same at all times. The personnel of the Contractor shall be subject to detailed direction and control of the Contractor and in relation to manner and model of performance of duties, as agreed vide this agreement.
1.22 The personnel of the Contractor shall not be the employees of the BNP and they shall not claim any salary or allowances, compensation, damages or anything arising out of their employment/duty under this Contract. The Contractor shall make them known about this position in writing before deployment under this agreement.
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
1.23 The Contractor must have any experience of relevant field of at least one year and successfully completed of one project (at least) in any organization in every year.
2. TERMS AND CONDITIONS 2.1 The Contractor firm must fulfill all the conditions required under Contract LABOUR LAW 1970 (R&A) Act. 2.2 Hours of work the normal working hours shall be 07.30 AM to 04.30 PM with one hour lunch break from 12:.00 PM
to 1.00 PM. However the timing may be changed for the day and night shift at the discretion of the Bank Note Press, Dewas from time to time. In case of urgency/ emergency, the labour can be deployed beyond normal duty hours which shall be compensated on hourly basis.
2.3 The deployed manpower will wear proper uniform without pocket as approved by the Bank Note Press, Dewas with name plate to be provided by the Contractor firm, failing which wages of that day is liable to be deducted.
2.4 Agency should provide Police Verification & Character Certificate of the manpower. The clearance of the local police with regards the antecedents of the persons deployed by it will be obtained by the agency before deployment of the personnel.
2.5 The Contractor firm shall have to furnish a Performance Bank Guarantee/Security Deposit valid for 18 months before awarding of contract which is returnable after successful execution/completion of the contract.
2.6 The Security Deposit shall be returned to the contractor on the expiry of the contract period on (contractor / agency) furnishing the usual clearance / No Demand Certificate.
2.7 The Contractor firm shall in no case pay its employees less than the minimum mandatory rates per day/per month in accordance with the Minimum Wages fixed by Government of M.P. and a record of that should be kept in a register, which may be made available for examination to the as and when demanded and all compliances related to Labor Laws must be fulfilled by the supplier.
2.8 The General Manager, Bank Note Press, Dewas in his sole discretion unconditional and without having to assign any reason, reserves the right:
(a) To apportion the total services amongst different tenderers.
(d) To enforce Fore-closure clause after placement of job orders by giving due notice of 15 days i.e. “if
at any time during contract, the contractor can be terminated by the General Manager, Bank Note
Press, Dewas.” for any security reasons or unsatisfactory performance by the contractor, without
giving any right to the contractor for any claim or damages or loss to be lodged against Bank Note
Press, Dewas.
2.9 The names of the workers to be deployed by the agency shall be made known to the
Authorities with their identity card / employment number, before commencing services.
The frequent changes in the manpower will not be allowed.
2.10 The rates quoted shall be for the entire period of the contract. Any amendment there to shall be at the sole option
of Bank Note Press, Dewas. The said rate shall be quoted keeping in the mind that the statutory compliance of all
labor laws / regulations must be compliance by the contractor/agency.
2.11 In case of increase in minimum wages of M.P. Govt., subsequent to opening of the tender, then the increase
amount of the wages including the corresponding PF / ESI share shall be revised in the contract by Bank Note
Press, Dewas. Any change /Increment in the minimum wages issued by M.P. Govt. will be paid to the contractor
and the contractor should pay the same to their staff.
2.12 Payment, The payment (s) shall be made to the contractor are subject to deduction of tax (s), Cess leviable by
any Government as per rules from time to time and will be made after the completion of every month on
completion of the assigned work on 7th day of each month and after certification by user department. The bill
must be submitted in triplicate. Further, the agency shall furnish a copy deposition of monthly EPF/ESIC
challans / returns etc. with next bill, failing which amount as deemed fit by Bank Note Press, Dewas shall with
hold in the next subsequent bill. The payment/wages to the manpower deployed should be made in presence of
AM (HR)/Officer (HR), which should be duly authenticated by them. The required strength of manpower under
various categories shall be as per actual requirement and any increase/decrease thereby in the actual deployed
manpower shall increase/reduce the payment to be made proportionately as per contracted rates.
2.13 The agency shall claim their commission in the form of Administration and service charges for providing
services at a rate quoted by it in the price tender document and contract.
2.14 The Contractor firm should make suitable arrangement for supervision of the manpower deployed and other
related works.
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
2.15 The agency shall ensure that their staff deployed for service in Bank Note Press, Dewas premises shall be
available during their duty hours as per the roster and they shall not leave their place of duty without
authorization.
2.16 That the agency shall deploy suitable personnel at all relevant time for rendering services and shall further
maintain a list of the reserves police verification duly complied to provide the replacement and supplement the
strength at short notice. The agency shall furnish such list to the officer authorized by Bank Note Press, Dewas
every month.
2.17 The Contractor firm shall maintain a daily attendance register including the number and names of the workers
engaged in the BNP Dewas for works as per scope of the contract. Also shall maintain all necessary registers as
per mandatory requirement under the law of land.
2.18 The agency staff shall be responsible to provide immediate replacement for personnel who are not available on
duty at the place of posting for any emergency and pressing reasons.
2.19 That the Bank Note Press Dewas authorities shall have the right to seek replacement of any staff of the agency
by any other suitable person in case the staff is not discharging its services properly. The decision by Bank Note
Press, Dewas shall be final and the agency shall comply with the same at the earliest.
2.20 That the agency staff shall carry out such other legitimate duties as are entrusted to them from time to time.
2.21 That the agency shall not engage any sub-contractor or transfer the contract to any other person.
2.23 Bank Note Press, is not responsible for any dispute of manpower deployed, and the manpower so provided shall
not be in any way is the employees of Bank Note Press, Dewas
2.24 Contractor firm will be responsible for making the payment directly to the deployed manpower by 5th of each
month EPF and ESI need to be paid by 7th of each month and subsequently raise the bill for reimbursement
which will be verified on the basis of actual amount disbursed and attendance etc. and will paid within 7 days
after payment of wages & statutory payment. Contractor liable for penalty as decided by the BNP Dewas for not
making timely payment to its manpower as per above schedule.
2.25 The contract will be for one year in the first instance. However, the contract can be extended on the same terms
and conditions subject to satisfactory work of the contractor till the execution of new contract whichever is
earlier.
2.26 The Contractor firm shall be responsible for all injuries and accidents to persons employed by him. The
workmen shall be insured against personal accidents arising out of and during the course of their duties. In the
event of injury, illness or mis-happening to any worker, the company will not be liable to pay any compensation.
The insurance cover shall include the liability under the workmen‟s Compensation Act by the supplier firm.
2.26 The Contractor firm shall have to engage the required number of manpower and in case required number is not
available on any day without proper and acceptable reason BNP can impose penalty on Contractor firm as it
thinks fit.
2.27 The Contractor firm shall not appoint any sub company/agency to carry out any obligation under the contract.
2.28 The Contractor firm shall be governed by the laws of India/ M.P. Govt. And interpretations in accordance with
such laws. It shall be the responsibility of the contractor/agency to comply with all labor laws/ regulations
applicable with respect to its staff working under the arrangement as is envisaged under the tender. The
contractor/agency shall further undertake to indemnify Bank Note Press, Dewas of any liability incurred by it on
account of non-adherence to labour laws/regulations by it.
2.29 If the contractor repeatedly violates the terms and conditions of the contract or fails to supply required number of
skilled/semi-skilled/unskilled manpower despite Bank Note Press, having served him proper notices, the contract
shall be liable to be terminated and security so deposited shall be forfeited.
2.30 The skilled/semi-skilled/unskilled manpower presently working in the Institute on contract basis may be engaged
by the Contractor firm as per his own terms and conditions and with the existing individual EPF account
number.
2.31 In case of disputes for nonpayment of wages to the deployed manpower or any other, the payment due to the
Contractor firm can be withheld till settlement of the disputes by the board or on the orders of the court of law.
2.32 The contractor shall abide by all the law of land including Labour Laws (PF, Income Tax, Service Tax or any
other extra taxes levied by the Government)
2.33 Companies Act, Tax deduction liabilities, welfare measures of its employees and all other obligations that enjoin
in such cases and are not essentially enumerated and defined herein, though any such onus shall be the exclusive
responsibility of the contractor and it shall not involve Bank Note Press, Dewas in any way whatsoever.
Compliance of these provisions shall be ensured at the time of making monthly payments.
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
2.34 The contract can be terminated by the Bank Note Press, Dewas by giving a month's notice. The
contractor/agency can terminate the contract by giving three months' notice.
2.35 In case the contractor/ Agency leaves the job before completion of the period of contract Bank Note Press,
Dewas shall be entitled to forfeit the security money deposited by the contractor/agency for the execution of this
contract. The same shall be over and above the liquidated damages suffered on such account by Bank Note
Press, Dewas. If any.
2.36 In case of any loss or theft, it shall be made good by the agency and failure on the part of the contractor/agency
part to do so within a period of 30days, the loss shall be made by good by the encashment of bank guarantees,
and if the amount of loss or damage exceed the amount of bank guarantee then remaining amount shall be
recovered form amount standing due and payable to the contractor /agency.
2.37 Any controversy of dispute arising out of this contract shall be referred to the sole arbitrator for adjudication of
dispute to be appointed by Bank Note Press, Dewas and/or any other officer authorized by Bank Note Press,
Dewas it on an application made to it within 30days of the arising of the dispute. To entertain ability of an
application made after the period of thirty days shall be at the discretion of Bank Note Press, Dewas and / or any
other officer authorized by Bank Note Press, Dewas. The arbitration and conciliation act, 1996 shall apply and
the venue of the arbitration shall be Dewas. The cost of arbitration shall be shared equally by both the parties.
2.38 Any individual/firm/company/registered society/registered co-operative society presently engaged by this
institution and whose performance has not been found satisfactory shall not be eligible for offering tender even if
the individual firm/company/ registered society/ registered co-operative society subsequently changes the
character /style /nomenclature /compositions of the tenderer and such tender shall be rejected out rightly.
2.39 The contractor shall disclose in writing all relevant facts as to ownership of the agency and constitution of the
business. If it is propriety concern, the name of the proprietor, if it is a firm, the names of all the partners and
attested copy of the partnership deed: and if it is a company, the names of all the directors, shall be disclosed.
Further, if the said proprietor/ any of the partners/ any of the directors has/have substantial interest in any other
agency, the said fact and the nature of the said interest shall also be disclosed. If the concerned agency has any
associated concern/subsidiary/principal/holding company/holding firm, the same shall be disclosed with full
particulars.
2.40 Contractor shall be responsible to ensure high integrity of the manpower deployed by it. Any personnel deployed
by the agency, caught making theft shall be handed over to the local police as per law in addition to actions liable
as contained in the terms and condition of the tender/contract. Contractor should ensure that all administrative &
security rules of the Bank Note Press must adhere by the personal deployed by the agency.
2.41 The terms and conditions contained herein shall form part of and shall take as if they were included in the
contract agreement to be entered in to between Bank Note Press, Dewas with contractors.
Note: If any of the terms & conditions (2.1) to (2.43) above is not found fulfilled during the work contract, Bank Note
Press, Dewas reserves the right to discontinue the contract without assigning any reasons thereof by providing a
hearing to the contractor, if he wants so.
3. Special Instruction and compliances-
3.1 Labor Law Act 1970 (R&A) Act compliances
3. 1.1 The engagement and employment of laborers and payment of wages to them should be as per existing
provisions of various labor laws and regulations is the sole responsibility of the Contractor and any breach of such
laws or regulations shall be deemed to be breach of this contract. BNP may ask the contractor to produce documents
to verify that these provisions/laws are complied with by the contractor.
(a) All wages allied benefits such as leave, ESI, PF, Gratuity , Bonus etc, shall be paid by the contractor and BNP shall
not incur any liability or additional expenditure whatsoever for personnel deployed.
(b) It is mandatory that the contractor‟s employees must be paid through bank/ cheques only in the presence of BNP‟s
officer (Nominated)
3.1.2. The Contractor shall abide by all labor laws, laws related to EPF Organizations, ESI Corporation, Workmen
Compensation Act. The details of EPF, ESIC in respect of their deployed staff shall be submitted by the Contractor to
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
BNP every month along with the bills. The Contractor shall abide including but not limited to, matters relating to
timely payment of wages and allowances, payment of minimum wages, payment of overtime, grant of leave, payment
of workmen's compensation, working hours, safety, maternity benefits, holidays, framing of standing orders,
disciplinary action against their employees, payment of provident fund contributions, payment of gratuities and
payment of bonuses as per statutory rules.
3.1.3. The contractor shall be liable for any legal dispute / case / claims that arises or may arise during currency of the
contract due to non-compliances of labor or other related laws.
3.1.4. The contractor shall be responsible for compliance of all the laws LABOUR LAW 1970 (R&A) Act
rules/regulations and State Govt. instructions that are/will be applicable to and aimed to protect the interest of the
employees/worker engaged by it and shall ensure payment of all the statutory dues/liabilities as may have arisen
during the past „or‟ may arise during the course of performance of contract.
3.1.5. The Contractor shall submit periodical returns as may be specified from time to time.
4) OFFICIAL RECORDS:
4.1 The Contractor shall maintain complete official records of disbursement of wages/ salary, showing specifically
details of all deductions such as ESI, PF etc. in respect of all the staff deployed in BNP Premises.
4.2 The Contractor shall maintain a personal file in respect of all their staff that is deployed in BNP office. The
personal file shall invariably consist of personal details such as name, address, date of birth, sex, residential address
(Temporary / Permanent) and all grievances recorded by the staff vis-à-vis action taken etc.
4.3 The Contractor shall furnish an undertaking that within seven days of the close of every month they will submit to
BNP a statement showing the recoveries of contributions in respect of employees with Certificate that the same have
been deposited with ESIC/EPFO Commissioners.
4.4 Each monthly bill must accompany the:
(a) List of employees with their date of engagement
(b) The amount of wages (The Contractor shall ensure that minimum wages are paid to all the
Employees with all the benefits (such as ESIC/EPF/Bonus etc.)
(c) Copies of authenticated documents of payments of such contributions to EPFO/ESIC
(d) Declaration of the Contractor regarding compliance of Amount of EPF /ESIC
4.5 The Contractor shall also prepare a register indicating all payments / dues in respect of all
the employees.
5. OBLIGATION OF CONTRACTOR
5.1 Contractor must provide to its employees their photo identity cards properly displayed during duty time. No extra
payments shall be claimed by the Contractor or its deployed staff from the BNP for such item.
5.2 The Contractor must provide salary slips, EPF numbers and ESI Cards, duly activated, to all the deployed manpower
at BNP‟s office. The Contractor should also ensure that EPF statements to the deployed manpower are provided
immediately after the financial year closing. Any delay in submission of these records will force BNP to deduct a
proportionate amount from the bills, as decided by the competent authority of BNP.
5.3 Contractor must employ adult and skilled personnel only. Employment of child labour shall lead to the termination
of the contract at the risk and cost of the Contractor. Contractor shall deploy/engage reliable persons at BNP after proper
character and police verification and impose any conditions as per prevailing contractual labour laws for such
engagements, take disciplinary action or reward any person at work etc., at its sole costs, risks and responsibilities.
Contractor shall intimate the details like name, age, parentage, address (residential as well as permanent) of all staff to
the BNP and shall also intimate changes in addresses of the staff as and when they take place.
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
5.4 In the event of the personnel having been provided by the Contractor not performing duties as per expected standards
in whatsoever manner or in case the personnel behave in an unacceptable manner, the Contractor shall, on request of the
BNP, remove the said personnel the same day and provide a suitable substitute in his/ her place of equivalent
qualifications and experience within seven days failing which the BNP may get the services performed by other means
for which the Contractor shall be liable to bear any extra cost that may be incurred by the BNP.
5.5 A Service Log Book shall be maintained at the BNP‟s premises and daily record of the actual services provided shall
be kept.
5.6 Contractor shall deal with and settle the matters related with unions and shall make sure that no labour disputes
/problems are referred to BNP. It shall totally indemnify BNP in this regard.
5.7 Contractor should at all times indemnify BNP against their all claims, damages or compensation under the
provisions of Payment of Wages Act, 1936; Minimum Wages Act, 1948; Employer‟s Liability Act, 1938; The Workmen
Compensation Act, 1923; Industrial Disputes Act, 1947; Maternity Benefit Act, 1961; Payment of bonus Act 1965;
Factory Act 1948 or any modification thereof or any other law relating thereto and rules made hereunder from time to
time. BNP will not own any responsibility in this regard.
5.8 Contractor‟s staff shall always be disciplined, properly dressed and be presentable all the time during duty. The
persons deployed by Contractor shall be properly trained, have requisite experience and skills for carrying out the multi
tasks assigned at BNP‟s office. The Contractor shall be solely responsible to tackle the matters in case any of its staff
deployed under this contract falls sick or is injured or goes on strike/ unfair activities etc. during performance of his/her
duty. It shall indemnify BNP in all respects under this contract.
5.9 Be it private or public areas, the Contractor‟s employees shall be liable to be frisked/ checked by the security
personnel at BNP premises or on duty at any time during performance of their duties.
5.10 Contractor‟s employees shall perform their duties at the premises with due diligence and take all precautions to
avoid any loss or damage to the government property/person.
5.11 Contractor shall be solely responsible for any indiscipline, theft, loss or damage to any or persons/ property at
the premises on account of acts of omission and commission by the staff deployed by him.
5.12 The payments to its employees shall be disbursed by the Contractor in the presence of the representative of BNP
who shall sign the payment register in token of having disbursed the salary in his presence by Contractor.
6. PENALTIES
6.1 The Contractor shall disburse monthly payment to its deployed manpower latest by 5th of every month, failing
which penalty of Rs.1000/- per day may be imposed up to 15th of the month and thereafter the contract shall liable to
be terminated. Security Deposit /Performance Bank Guarantee shall be forfeited and Bank guarantee will be encased.
The BNP will have the power to appoint any other agency for the manpower services at the risk and cost of the
Contractor.
6.2 Whenever and wherever it is found that the assigned work is not performed up to the entire satisfaction of the
BNP, it will be brought to the notice of Contractor by the BNP and if no action is taken immediately, penalty of
Rs.1000/- per day per complaint will be imposed by invoking penalty clause.
6.3 The Contractor has to maintain adequate number of manpower as per this contract and also arrange a pool of
standby manpower of requisite qualifications. If the required number of persons is less than the specified number as
mentioned in the contract, a penalty of Rs.500/- per absentee per day shall be deducted from the bill(s).
6.4 In case the Contractor fails to fulfill the minimum statutory requirements (ESIC/ EPF) as per the conditions of the
tender document and fails to produce the concerned documents, it shall be treated as breach of the Contract and the
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
Contractor is liable to be blacklisted by the BNP, in addition to forfeiting of the monthly bills and Performance
Security Deposit.
6.5 In case of breach of any conditions of the contract and for all types of losses caused including excess cost due to
hiring services in the event of Contractor failing to provide requisitioned number of manpower, the BNP shall make
deductions at double the rate of hiring rate on pro rata basis from the bills preferred by the Contractor or that may
become due to the Contractor under this or any other contract or from the security deposit or may be demanded from
him to be paid within seven days to the credit of the BNP.
________________________________________________________________________________________
SECTION IX: ELIGIBILITY CRITERIA
1. The bidder firm must meet/provide following eligibility criteria/information to qualify:
(a) Experience and past performance: Firm should have minimum one similar work experience of
deployment of electrical staff (at least 04 persons) in any one year during last five years i.e. 1st
January 2011 to December 2011, 1st January 2012 to December 2012, 1st January 2013 to
December 2013, 1st January 2014 to December 2014 and 1st January 2015 to December 2015 to
any unit of Central/State Govt./PSU/Autonomous bodies. Copy of work order and completion
certificates must be enclosed as documentary evidence.
(b) Financial Standing:
i) Average Annual turnover of the Bidder firm during last three financial years ending on 31.03.2015
should be more than Rs. 7,92,000/-
ii) Bidder Firm should not have suffered any financial loss for more than one year during the last
three financial years ending on 31.03.2015.
iii)The net worth of the firm should not have eroded by more than 30% in the last three financial
years ending on 31.03.2015
Note:
(i) All experience, past performances related data e.g. work order/contract copy, invoice copy, and
experience certificate etc. should be enclosed in support of fulfillment of experience & past performance
criteria and it must be duly certified by the authorized signatory of the Bidder firm.
(ii) The credentials regarding experience and past performances to the extent required as per the above
eligibility criteria as submitted by the Bidder may be verified from the parties for whom work has been
done.
(iii) For financial standing criteria, the firm should enclose Balance Sheets and Profit & Loss Accounts
OR Certificate of Turnover, Profit & Loss, Net Worth of above mentioned financial years duly
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
certified by certified accountants e.g. Chartered Accountants (CA) in India & certified Public
Accountant/Chartered Accountant in other countries
(iv) Bidders have to furnish stipulated documents in support of fulfillment of statutory requirements. Non-
submission or incomplete submission of above required documentary evidence may lead to rejection of
offer.
________________________________________________________________________________________
Section X: Tender Form Date……….
To
The General Manager,
Bank Note Press,
(A unit of Security Printing and Minting Corporation of India Limited)
Dewas (M.P.) - INDIA
Ref: Your Tender document No. …………………………dated …………
We, the undersigned have examined the above mentioned tender enquiry document, including
amendment No. --------, dated --------- (if any), the receipt of which is hereby confirmed. We now offer to
supply and deliver………. (Description of goods and services) in conformity with your above referred
document for the sum of _____________ (total tender amount in figures and words), as shown in the
price schedule(s), attached herewith and made part of this tender.
If our tender is accepted, we undertake to supply the goods and perform the services as mentioned above,
in accordance with the delivery schedule specified in the List of Requirements.
We further confirm that, if our tender is accepted, we shall provide you with a performance security of
required amount in an acceptable form in terms of GCC clause 6, read with modification, if any, in
Section V – “Special Conditions of Contract”, for due performance of the contract.
We agree to keep our tender valid for acceptance for a period up to -------, as required in the GIT clause
19, read with modification, if any in Section-III – “Special Instructions to Tenderers” or for subsequently
extended period, if any, agreed to by us. We also accordingly confirm to abide by this tender upto the
aforesaid period and this tender may be accepted any time before the expiry of the aforesaid period. We
further confirm that, until a formal contract is executed, this tender read with your written acceptance
thereof within the aforesaid period shall constitute a binding contract between us.
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
We further understand that you are not bound to accept the lowest or any tender you may receive against
your above-referred tender enquiry.
……………………..
(Signature with date)
………………………..
(Name and designation)
Duly authorized to sign tender for and on behalf of
……………………………………….
……………………………………….
________________________________________________________________________________________
SECTION XI: PRICE SCHEDULE
[To be submitted along with the tender]
From:
To,
The General Manager,
Bank Note Press, Dewas (M.P.) – INDIA
(A unit of Security Printing and Minting Corporation of India Limited)
Sub: Outsourcing of Manpower for BNP for Electrical Sub Station & DG Set Operation & Maintenance for the
period of 01 Year.”
Ref: Tender no.:- 6000007879/BNP/P/Electrical/Outsourcing/2015/OT/RT, Dated: 18-06-2016
Dear Sir,
We have received your tender enquiry cited and we are pleased to enclose the following Commercial bid
for your kind consideration. Sl.
No.
Type of
Manpower
No. of
Persons
Daily
Wages
Per
Person
(A)
EPF
Per
Person
(B)
Other
Statutory
Charges
like ESI,
Bonus etc.
Per Person
(C)
Total
Per
Person
(D)
A+B+C
Administ
ration
Charges
Per
Person
(E)
Charges for
Uniform, ID
card &
Physical
protection
equipment etc.
Per Person (F)
Total
Per
Person
(H)
(E+F)
Grand
Total
(D+H)
1. “Outsourcing of repairing & maintenance of electrical activities for the period of 1 year”
i
Electrician/Sr.
Electrician 4 No.
ii
Electrician 8 No.
Note:-
1. Service tax and Education cess to be paid extra as applicable.
2. The tenderer should quote Administration charges as percentage of daily wages.
3. Administration charges must include TDS to be deducted i.e. minimum 2% as per present rate
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
4. Administration Charges & Charges for Uniform, ID card & Physical protection equipment's etc. must be
quoted in fixed value and not in percentage, otherwise offer will be ignored. 5. Documentary support/break-up with details be given for charges quoted against (C) & (F) columns above & zero
rates should not be quoted.
6. The said rate shall be quoted keeping in mind that the minimum wages notification issued by the govt./Dy. Chief.
Commissioner (central) as applicable and statutory compliance of all labour laws / regulations must be compliance
by the contractor / agency
7. Wages and other statutory requirements are required to be submitted as is mentioned in the table and any
deviation from the above would lead to the tender getting rejected.
Seal & Signature of the Tenderer
Address: _______________________________
Date: : _______________________________
________________________________________________________________________________________
Section XII: Questionnaire
The tenderer should furnish specific answers to all the questions/ issues mentioned below. In case a
question/ issue does not apply to a tenderer, the same should be answered with the remark “not
applicable”.
Wherever necessary and applicable, the tenderer shall enclose certified copy as documentary proof/
evidence to substantiate the corresponding statement.
In case a tenderer furnishes a wrong or evasive answer against any of the under mentioned question/
issues, its tender will be liable to be ignored.
1. Brief description and of goods and services offered:
2. Offer is valid for acceptance up to …………………………………………….
3. Your permanent Income Tax A/ C No. as allotted by the Income Tax Authority of Government of
India :
Please attach certified copy of your latest/ current Income Tax clearance certificate issued by the above
authority.
4. Status :
a. Are you currently registered with the Directorate General of Supplies & Disposals (DGS&D),
New Delhi, and/ or the National Small Industries Corporation (NSIC), New Delhi, and/ or the
present SPMCIL and/ or the Directorate of Industries of the concerned State Government for the
goods quoted? If so, indicate the date up to which you are registered and whether there is any
monetary limit imposed on your registration.
b. Are you currently registered under the Indian Companies Act, 1956 or any other similar Act?
Please attach certified copy(s) of your registration status etc. in case your answer(s) to above
queries is in affirmative.
5. Please indicate name & full address of your Banker(s) :
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
6. Please state whether business dealings with you currently stand suspended/ banned by any
Ministry/ Deptt. of Government of India or by any State Govt.…………………………..
(Signature with date)
……………………….
……………………….
(Full name, designation & address of the person duly authorized sign on behalf of the tenderer)
For and on behalf of
…………………………..
(Name, address and stamp of the tendering firm)
Section XV: Bank Guarantee Form for Performance Security
……………………………………………………… [Insert: Bank‟s name, and address of the issuing branch or
officer]
Beneficiary: …………………………….. [Insert: name and address of India Govt. Mint, Kolkata]
Date: ………………………….
PERFORMANCE GURANTEE No.:………………………………………..
WHEREAS ………………………………………………………………………………. (name and address of the
supplier) (hereinafter called “the supplier”) has undertaken, in pursuance of contract no…………………………….
dated …………. to supply (description of goods and services) (herein after called “the contract”).
AND WHEREAS it has been stipulated by you in the said contract that the supplier shall furnish you with a bank
guarantee by a scheduled commercial bank recognized by you for the sum specified therein as security for
compliance with its obligations in accordance with the contract;
AND WHEREAS we have agreed to give the supplier such a bank guarantee; NOW THEREFORE we hereby
affirm that we are guarantors and responsible to you, on behalf of the supplier, up to a total of ……………… ……
……… …… …………………. (amount of the guarantee in words and figures), and we undertake to pay you, upon
your first written demand declaring the supplier to be in default under the contract and without cavil or argument,
any sum or sums within the limits of (amount of guarantee) as aforesaid, without your needing to prove or to show
grounds or reasons for your demand or the sum specified therein.
We hereby waive the necessity of your demanding the said debt from the supplier before presenting us with the
demand. We further agree that no change or addition to or other modification of the terms of the contract to be
performed there under or of any of the contract documents which may be made between you and the supplier shall
in any way release us from any liability under this guarantee and we hereby waive notice of any such change,
addition or modification.
We undertake to pay Bank Note Press, Dewas up to the above amount upon receipt of its first written demand,
without Bank Note Press, Dewas having to substantiate its demand.
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
This Guarantee will remain in force for a period of sixty days after the currency of this contract and any demand in
respect thereof should reach the Bank not later than the above date.
…………………………….
(Signature with date of the authorized officer of the Bank)
………………………………………………………….
………………………………………………………….
Name and designation of the officer
…………………………………………………………. Seal, name & address of the Bank and address of the Branch
………………………………………………………….
Name and designation of the officer
………………………………………………………….
…………………………………………………………. Seal, name & address of the Bank and address of the Branch
________________________________________________________________________________________
Section VIII: Quality Control Requirements ---------------------
As per Scope of work mentioned in Section VII
(Outsourcing for operation and maintenance of Electrical Activities in Utility Area)
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
Section XVI: Contract Form Contract No…………. dated…………….
This is in continuation to this office‟ Notification of Award No……………..….. dated …….
1. Name & address of the Supplier: ……………………………………..
2. SPMCIL‟s Tender document No……… dated…………. and subsequent Amendment
No.…………., dated……… (If any), issued by SPMCIL
3. Supplier‟s Tender No……… dated…….. and subsequent communication(s) No…………
dated …….. (If any), exchanged between the supplier and SPMCIL in connection with this tender.
4. In addition to this Contract Form, the following documents etc, which are included in the
documents mentioned under paragraphs 2 and 3 above, shall also be deemed to form and be read
and construed as part of this contract:
(i) General Conditions of Contract;
(ii) Special Conditions of Contract;
(iii) List of Requirements;
(iv) Technical Specifications;
(v) Quality Control Requirements;
(vi) Tender Form furnished by the supplier;
(vii) Price Schedule(s) furnished by the supplier in its tender;
(viii) Manufacturers‟ Authorization Form (if applicable for this tender);
(ix) SPMCIL‟s Notification of Award
Note: The words and expressions used in this contract shall have the same meanings as are respectively
assigned to them in the conditions of contract referred to above. Further, the definitions and abbreviations
incorporated under clause 0 of Section –V - „General Conditions of Contract‟ of SPMCIL‟s Tender
document shall also apply to this contract.
5. Some terms, conditions, stipulations etc. out of the above-referred documents are reproduced below for
ready reference:
(i) Brief particulars of the goods and services which shall be supplied/ provided by the supplier are as
under:
Schedule
No.
Brief description of
goods/ services
Accounting
unit
Quantity to
be supplied
Unit Price
(in Rs.)
Total price
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
Any other additional services (if applicable) and cost thereof: ………………………..
Total value (in figure) ____________ (In words) ___________________________
(ii) Delivery schedule
(iii) Details of Performance Security
(iv) Quality Control
(a) Mode(s), stage(s) and place(s) of conducting inspections and tests.
(b) Designation and address of SPMCIL‟s inspecting officer
(v) Destination and despatch instructions
(vi) Consignee, including port consignee, if any
(vii) Warranty clause
(viii) Payment terms
(ix) Paying authority
……………………………….
(Signature, name and address of SPMCIL‟s authorized official)
For and on behalf of……….
Received and accepted this contract ……………………………………………………..
(Signature, name and address of the supplier‟s executive duly authorized to sign on behalf of the
supplier)
For and on behalf of ………………………
(Name and address of the supplier)
…………………….
(Seal of the supplier)
Date:
Place
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
Section XVII: Letter of Authority for attending a Bid
Opening
(Refer to clause 24.2 of GIT)
The General Manager,
Bank Note Press,
(A unit of Security Printing and Minting Corporation of India Limited)
Dewas (M.P.)- INDIA
Subject: Authorization for attending bid opening on ____________________ (date) in the Tender
of ___________________________________________________.
Following persons are hereby authorized to attend the bid opening for the tender mentioned above
on behalf of _____________________________________________ (Bidder) in order of
preference given below.
Order of Preference Name Specimen Signatures
I.
II.
Alternate Representative
Signatures of bidder or
Officer authorized to sign the bid
Documents on behalf of the bidder.
Note:
1. Maximum of two representatives will be permitted to attend bid opening. In cases where it is
restricted to one, first preference will be allowed. Alternate representative will be permitted
when regular representatives are not able to attend.
2. Permission for entry to the hall where bids are opened may be refused in case authorization as
prescribed above is not recovered.
______________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
SECTION XIX: Proforma of Bills for Payments
(Refer Clause 22.6 of GCC)
Name and Address of the Firm.................................................................................................
Bill No....................................................................Dated.......................................................
Purchase order..................................................No...................................Dated......................
Name and address of the consignee.........................................................................................
S.No Authority
for purchase
Description of
Stores
Number or
quantity
Rate
Rs. P.
Price per
Rs. P.
Amount
Total
1. C.S.T./Sales Tax Amount
2. Freight (if applicable)
3. Excise Duty (if applicable)
4. Packing and Forwarding charges (if applicable)
5. Others (Please specify)
6. PVC Amount (with calculation sheet enclosed)
7. (-) deduction/Discount
8. Net amount payable (in words Rs.)
Despatch detail RR No. other proof of despatch...............................................
Dated............................................................(enclosed)
Inspection Certificate No............................................Dated..................(enclosed)
Income Tax Clearance Certificate No...........................Dated..................(enclosed)
Modvat Certificate No...........................................................................(enclosed)
Excise Duty Gate pass........................................................................(enclosed)
Place and Date
Received Rs..............................(Rupees).........................................................
I hereby certify that the payment being claimed is strictly in terms of the contract and all
the obligations on the part of the supplier for claiming that payment has been fulfilled as
required under the contract.
Revenue stamp Signature and of Stamp Supplier
____________________________________________________________________________________________________ Regd. Office:-Jawahar Vyapar Bhawan, Janpath, New Delhi-110001 T01.1
ANNEXURE – I
MANDATORY CHECKLIST
(To be submitted along with Techno-commercial Bid)
NOTE:
The above check list duly filled must be submitted along with techno-commercial bid.
No price component has to be mentioned in above checklist, otherwise offer will be rejected.
Signature and Seal of bidder
Sr. No. Description Yes/No
1.
Tender submitted in two bids.
2. The Tender should be submitted in Hindi/English Language. The
authenticated copies of the documents in support of the applicant‟s
claims may be submitted in Hindi/English Language.
3. Tender Fee & EMD submitted in Techno-commercial Bid.
4. All experience, past performances related data e.g. purchase
order/contract copy, invoice copy, and experience certificate etc.
enclosed.
5. Provided the Names of Organization(s) / Firm(s) with Addresses &
Telephone Numbers, Fax Numbers, E-mail addresses to which they
have provided similar type of services annually during the last five
years.
6. Power of attorney / Authorization indicating that authorized
signatory is competent & legally authorized to submit the tender and
/or to enter into legally binding contract enclosed.
7. Sealed & signed copy of tender document submitted along with
techno-commercial bid as a token of acceptance of all terms &
conditions enclosed.
8. A Copy of the price bid proforma submitted along with Techno-
Commercial Bid leaving blank the price portion (i.e. showing the
unit, currency & total price of the Item / Services offered as xxxx)
so as to indicate the Item / Services being offered is enclosed.
9. Copy of PAN /TAN number/ VAT/TIN number enclosed.
10. Tender validity 120 days given.
BANK NOTE PRESS DEWAS - 455001 (M.P.) A Unit of Security Printing and Minting Corporation of India Limited
Miniratna Category - I CPSE
Wholly owned by Government of India
Tel : 07272-268253/268468 Fax : 07272-255111
Web : http://bnpdewas.spmcil.com
E-Mail : [email protected]
IN No. : U22213DL2006GOI144763