of 64
7/28/2019 ce12-01
1/64
www.aacei.o
ENGINEERING
January 20
THE JOURNAL OF AACE INTERNATIONAL -THE AUTHORITY FOR TOTAL COST MANAGEMENT
TM
COSTCOSTCOST
OFFSETTING DELAYS
THE OWNERS FRIEND
FORENSIC
SCHEDULE ANALYSIS:EXAMPLE IMPLEMENTATION PART II
CONSTRUCTIVE
ACCELERATION
THE BASICS OF
OFFSETTING DELAYS
THE OWNERS FRIEND
FORENSIC
SCHEDULE ANALYSIS:EXAMPLE IMPLEMENTATION PART II
CONSTRUCTIVE
ACCELERATION
THE BASICS OF
7/28/2019 ce12-01
2/64
Bending over backwardsto get a handle on costs?
www.ecosys.net
Project Cost Management
Capital Planning
Budgeting & Forecasting
Funds Management
Resource Management
Earned Value Management
Planning & Controls Software forProjects, Programs and the Enterprise:
Portfolio Management
Estimating
The data exists, but never quite as you need it. Its
spread across multiple systems and the contortions
you go through to produce your monthly reports
are enough to make a chiropractor rich. EcoSys EPC
is an easy-to-use, web-based project cost management
solution that will integrate your cost and schedule,
automate reporting, and deliver the very best visibility
into your project performance.
Ahhh. Now, doesnt that feel better?
7/28/2019 ce12-01
3/64COST ENGINEERING JANUARY 2012
4 The Basics of Constructive AccelerationJames G. Zack Jr., CFCC FRICS
15 Offsetting Delays The Owners FriendJohn C. Livengood, CFCC PSP
25 Forensic Schedule Analysis:Example Implementation Part IIMark C. Sanders, PE CCE PSP
2 AACE Inernaional Board o Direcors
2 Cos Engineering Journal Inormaion
14 AACEs 2012 Annual Meeing
53 Ask Your Candidaes 2012 Elecion
55 Proessional Services Direcory
55 Index o Adverisers
58 The AACE Inernaional Online Sore
60 Calendar o Evens
CONTENTS
TECHNICAL ARTICLES
ALSO FEATURED
COST ENGINEERING
THE AACE INTERNATIONAL ONLINE BUTTON - This editon
o he Cos Engineeringjournal has access o additonal ma-
erial on he AACE Inernatonal websie, www.aacei.org.
Anytme you see he symbol a cener, here is additonal
conen online associaed wih ha artcle or eaure. Direc
your browser o www.aacei.organd look or he online bu-
on o access additonal resources. I you are already reading
he elecronic version, jus click he online buon direcly.
7/28/2019 ce12-01
4/64
COST ENGINEERING
2 COST ENGINEERING JANUARY 2012
HEADQUARTERS1265 Suncres Towne Cenre Dr
Morganown, WV 26505-1876
800.858.COST ax - 304.291.5728
CONTENTSAACE INTERNATIONALBOARD OF DIRECTORS
PRESIDENTMichael R. Nosbisch, CCC PSP
562.733.2472 / [email protected]
PRESIDENT-ELECTMarlene Hyde, CCE EVP
303.940.3200 / [email protected]
PAST PRESIDENTSephen O. Revay, CCC CFCC
403.777.4900 / [email protected]
VICE PRESIDENT-ADMINISTRATIONMarin Darley, CCC FRICS
713.372.2426 / [email protected]
VICE PRESIDENT-FINANCEJohn J. Ciccarelli, PE CCE PSP
609.497.2285 / [email protected]
VICE PRESIDENT-TEC
George Whye, CCC CEP EVP301.957.7434 /[email protected]
VICE PRESIDENT-REGIONSJulie Owen, CCC PSP
213.922.7313 / [email protected]
DIRECTOR-REGION 1Ginee Basak, P.Eng. FAACE
403.708.7674 / [email protected]
DIRECTOR-REGION 2John C. Livengood, CFCC PSP
202.669.1360 / [email protected]
DIRECTOR-REGION 3James H. Carson, CCC CEP
770.444.9799 / [email protected]
DIRECTOR-REGION 4Duane R. Meyer, PE CCE
513.241.1230 x 620 / [email protected]
DIRECTOR-REGION 5Earl J. Seabrook, III, CCC
713.372.0521 / [email protected]
DIRECTOR-REGION 6Nicholas Kellar, CCC EVP PSP
DIRECTOR-REGION 7Philips Tharakan Mulackal, CCE EVP
+971.50.631.4830 / [email protected]
DIRECTOR-REGION 8Keih Webb
+61.8.93485045 / [email protected]
EXECUTIVE DIRECTORDennis G. Sork
304.296.8444 / [email protected]
Viewpoins expressed in columns, eaures, and aricles published in Cos Engineering journal are solely hose
o he auhors and do no represen an oicial posiion o AACE Inernaional. AACE Inernaional is no en-
dorsing or sponsoring he auhors work. All conen is presened solely or inormaional purposes. Columns,
eaures, and aricles no designaed as Technical Aricles are no subjec o he peer-review process.
Cos Engineering (ISSN: 0274-9696/12) is published monhly by AACE Inernaional, Inc, 209 Prairie Ave., Suie 100,
Morganown, WV 26501 USA. Periodicals posage paid a Morganown, WV, and a addiional mailing oice. POSTMASTER:
Send address changes o AACE Inernaional; 1265 Suncres Towne Cenre Dr, Morganown, WV 26505-1876 USA. Cusomer
#7012359 (APC), Publicaions Mail Agreemen No 40624074, Reurn undeliverable Canadian addresses o PO Box 503, RPO
Wes Beaver Creek, Richmond Hill, ON L4B 4R6. Single copies: US$9 members/ US$14 nonmembers (boh + shipping),
excluding special insers available o AACE members only. Subscripion raes: Unied Saes, US$72/year; all oher counries,
US$91/year. Overseas airmail delivery is available a US$99. Subscripions are acceped on an annual-year basis only. Copyrigh
2012 by AACE Inernaional, Inc. All righs reserved. This publicaion or any par hereo may no be reproduced in any ormwihou wrien permission rom he publisher. AACE assumes no responsibiliy or saemens and opinions advanced by he
conribuors o is publicaions. Views expressed by hem or he edior do no necessarily represen he oicial posiion oCos
Engineering, is sa, or AACE Inernaional, Inc. Printed in York, PA, USA. Cos Engineering is a reereed journal. All echnical
aricles are subjec o review by a minimum o hree expers in he ield. To submi a manuscrip or peer review, see auhor
guidelines a www.aacei.org and submi a 200 word or less absrac o [email protected].. PHOTOCOPY PERMISSION:
Auhorizaion o phoocopy aricles herein or inernal or personal use, or he inernal or personal use o speciic cliens, is
graned by AACE Inernaional, Inc., provided ha he base ee o US$4.00 is paid direcly o Copyrigh Clearance Cener, 222
Rosewood Drive, Danvers, MA 01923 USA. Telephone: 978.750.8400. For hose organizaions ha have been graned a
phoocopy license by CCC, a separae sysem o paymen has been arranged. The ee code or users o he ransacional
reporing service is ISSN-0274-9696/02 US$4.00. Paymen should be sen direcly o CCC. Copying or oher han personal or
inernal reerence use wihou he express permission o AACE is prohibied. E-mail requess or phoocopy permission on bulk
orders may be sen o [email protected]. ADVERTISING COPY: Conac Nework Media Parners., Execuive Plaza 1, 11350
McCormick Road, Suie 900; Hun Valley, MD 21031. Telephone: 410.584.1966. E-mail: [email protected] or
raes. Adverisers and adverising agencies assume liabiliy or all conen (including ex, represenaion, and illusraions) o
adverisemens prined and also assume responsibiliy or any claims arising hererom made agains he publisher. Thepublisher reserves he righ o rejec any adverising ha is no considered in keeping wih he publicaions mission and
sandards. The publisher reserves he righ o place he word advertisementwih copy which, in he publishers opinion,
resembles ediorial maer. All adverising acceped or publicaion in Cos Engineering is limied o subjecs ha direcly relae
o he cos managemen proession. Curren rae card available on reques. COST ENGINEERING DEADLINES: Submissions or
Cos Engineering mus be received a leas 8 weeks in advance o he issue dae. Send o: Edior, 1265 Suncres Towne Cenre
Dr, Morganown, WV 26505-1876 USA. Deadlines do no apply o echnical papers.
Policy Concerning Published Columns, Features, and Articles
Esablished 1958
Managing Edior Marvin [email protected]
Ar Direcor Noah [email protected]
Adverising Sales Mark SouNework Media Parners Inc.410.584.1966 ax - [email protected]
Vol. 54, No.1/January 2012
AACE Inernaional - The Auhoriy or Toal Cos ManagemenTM
OUR VISION - To be he recognized echnical auhoriy in cos and schedule managemen
or programs, projecs, producs, asses, and services.
OUR MISSION - The members o AACE enable organizaions around he world o achieve
hier invesmen expecaions by managing and conrolling projecs, programs, and por-
olios; we creae value by advancing echnical knowledge and proessional developmen.
7/28/2019 ce12-01
5/64
We invite you to apply on our website
bechtel.com/careers
a world of opportunity
7/28/2019 ce12-01
6/644 COST ENGINEERING JANUARY 2012
The consrucive acceleraion
claim is a creaion o he US
Federal Boards o Conrac
Appeals (he Boards). Prior
o 1978, he Boards were only
empowered o hear claims arising under
a conrac. A claim no arising under a
conrac was ypically classiied as breach
o conrac, somehing he Boards couldno hear. As a resul all such claims had o
be aken o he US Cour o Claims.
The consrucive acceleraion claim
was devised prior o 1978, in order o
give jurisdicion o he US ederal agency
appeals board as a claim on he conrac
and no or is breach.[1] One English
barriser, Proessor Ian Duncan Wallace,
has ermed consrucive acceleraion as
a, iciious docrine no ounded on
consensual or quasi-conracual basis[2].
Regardless o his opinion, he docrine o
consrucive acceleraion is a well
recognized legal heory in he US.
The Basics o Consrucion Acceleraion
The earlies cases issued by he
Boards, in he 1960s, esablished a
sandard six poin es o deerminewheher consrucive acceleraion
occurred on a conrac [3]. Various
auhors have summarized hese
requiremens as ollows.
The conracor mus have
encounered excusable delay or
delay or which a ime exension is
warraned under he erms o he
conrac (wheher he delay is
compensable is irrelevan).
The conracor mus imely submi
noice in accordance wih he
provisions o he conrac and ollow
up wih a proper reques or ime
exension.
The ime exension mus be denied,
in whole or in par, or oherwise
posponed (i.e., no responded o a
all, which aer some reasonable
period o ime is deemed a denial).
The owner or heir represenaive
mus ac by coercion, direcion, or in
some oher manner ha can
reasonably be consrued as an order
o complee he work wihin he
unexended ime.
The conracor mus provide noice
ha hey consrue his acion o be a
direcive o accelerae. And,
The conracor mus acually
accelerae he work, incur and
documen heir added coss [4].
I is noed ha some auhors
condense hese poins o ive, our, or
even hree. Nowihsanding wheher
hey are compressed or no, his sandard
se o rules mees he basic consrucion
claims equaionenilemen, causaion,
and damages.
(For a more horough discussion o
he docrine o consrucive acceleraion
see Consrucive Acceleraion: Waking
TECHNICAL ARTICLE
THE BASICS OF
CONSTRUCTIVE
ACCELERATIONJames G. Zack Jr., CFCC FRICS
Absrac: Consrucive acceleraion is a well recognized claim in he US. The USederal governmens Boards o Conrac Appeals long ago creaed his claim andesablished he basic rules o enilemen concerning his ype o claim. Thus, US-based conracors know wha mus be documened in order o recover in suchsiuaions. Bu when US conracors are working ouside he US and are acedwih his sor o siuaion, can hey recover in arbiraion or liigaion in oher ju-risdicions? This aricle examines consrucive acceleraion in various legal juris-dicions (boh common law and civil law) around he world o deermine whehera conracor is able o use his ype o claim o recover damages. This aricle wasirs presened a he 2011 AACE Inernaional Annual Meeing as manuscripCDR.521.
Key Words: Arbiraion, claims, civil law, common law, conracors, damages, and
liigaion
7/28/2019 ce12-01
7/64COST ENGINEERING JANUARY 2012
he Sleeping Gian by Thomas F. Peers
[5]; Reconciling Concurrency in
Schedule Delay and Consrucive
Acceleraion, by W. Sephen Dale and
Rober M. DOnorio [6]; and, A
Governmen Windall: ASBCAs Aack
on Concurren Delays as a Basis or
Consrucive Acceleraion, by W.
Sephen Dale and Kahryn T. Muldoon[7].)
Subsequen o 1978, wih he
passage o he Contract Disputes Act of
1978, he US Boards were given broader
jurisdicion over claims arising under
governmen conracs, including breach
o conrac claims [8]. Neverheless, he
legal docrine o consrucive
acceleraion remains irmly esablished
and has developed ino a well known
and relaively common claim on
consrucion projecs.
Is Consrucive Acceleraion
Recognized by Cours Ouside he US?The issue or his aricle is o
respond o he above quesion. I a
conracor is working ouside o he US
and encouners he siuaion se orh
above, do hey have he legal righ o ile
a consrucive acceleraion claim? The
issue arose some ime back when he
auhor was working wih English
barrisers on a claim in he Mideas.
When he auhor asked i he conracor
had iled a noice o consrucive
acceleraion, he barriser clien advised
ha, English law does no recognize
ha legal concep.
I occurred o he auhor ha
owners who reuse o issue ime
exensions when hey are due, orce
conracors ino a Hobbesian choice.
Eiher he conracor reuses o
accelerae and wais unil he end o he
projec o gamble ha hey can convince
an arbiraion panel or cour ha hey
did no cause he delay, and he ownerhas no righ o impose liquidaed
damages, or he conracor ops o
accelerae he work o complee on ime
and pursues damages rom he owner
or he cos o he acceleraion.
However, should he conracor
accelerae and hen learn hey are
working in a jurisdicion ha does no
recognize he concep o consrucive
acceleraion, hey may ace win
economic losseshe cos expended on
heir acceleraion eors, plus he lae
compleion damages imposed under he
conrac!
Les now look a various counries
around he globe o deermine wheher
he legal concep o consrucive
acceleraion is recognized and, i i is
no, is here anoher legal mechanism a
conracor can use o recover such cossin siuaions such as his?
AusraliaEven hough Ausralia is one o he
Commonwealh counries, is cours
dier rom English cours. While
Ausralian law does no recognize he
erm consrucive acceleraion, here is
a leading cour case, commonly cied,
where an Ausralian cour awarded
acceleraion damages o a conracor
despie he ac ha he owner never
ordered acceleraion o he work.In he Ausralian case o Perini
Paciic v Commonwealh o Ausralia
(1969), Mr. Jusice Macarlane, in he
Commercial Cour o New Souh Wales,
indicaed clearly ha his ype o claim
could only be on he basis o some
proven breach o conrac by he
owner;coupled, o course, wih proo
o damages in he orm o compleion o
ime by expendiure greaer han would
oherwise have been incurred. In ha
case, he breach consised o a reusal or
ailure by he ceriied o give anyconsideraion a all o he conracors
applicaions [9].
In his case, he conrac
adminisraor repeaedly reused o
award exensions o ime (EOT), and
he conracor acceleraed o complee
he projec on ime in order o avoid
being assessed liquidaed damages.
Under he erms o he conrac, he
owner had an implied duy o ensure
ha he conrac adminisraor was
properly adminisering he EOT
provisions o he conrac. The cour
ound ha he owner did no live up o
his obligaion and he proven breach
o he implied erms gave rise o a
claim or damages. The cour awarded
he cos o acceleraion o he conracor
[10].
As a resul o his ruling, where
he conracor eels obliged o accelerae
because claimed EOTs have been
rejeced or are no being approved in a
imely way, and he conracor eels i is
aced wih he need o accelerae o
avoid incurring penalies he ailure o
gran EOTs in a imely manner can be
inerpreed as an insrucion o
accelerae [11].
In oher cases, Ausralian cours
have looked o he English law rule
concerning, acs o prevenion. Shouldhe owner ac in some manner as o
delay he projec and hen reuse o
gran an appropriae ime exension, and
coerce he conracor ino acceleraion,
Ausralian cours are likely o award he
resuling damages o he conracor [12].
Conclusion: Even hough Ausralian
cours have no adoped he erm,
consrucive acceleraion, i a
conracor can prove ha he delay o
he projec was no caused by he
conracor; ha hey submied imely
ime exension requess; ha heconrac adminisraor ailed o gran he
appropriae ime exension; ha he
owner knew he conrac adminisraor
was no adminisering he conrac
correcly; hen he conracor can
successully argue he owner breached
heir implied duies and owes he
resuling damages.
In he alernaive, he conracor
may be able o pursue he claim under
he ac o prevenion heory common
in English law. In eiher even, he
conracor will sill be held o hesandard o proving heir damages.
BrazilBrazil is a civil law counry and
decisions o cours are no published nor
do hey have any precedenial value.
However, he auhor conaced a
Brazilian scheduling exper and claims
consulan o learn wheher he concep
o consrucive acceleraion is
recognized in Brazil.
I was repored ha, In Brazil,
recovery o coss by conracors has
always been a gray zone. I have
prepared claims or consrucive
acceleraion in wo power plan
projecs. In one, we managed o ge
some o he money back, bu in he
oher one, he [owner] alleged [a] orce
majeure and he case wen o cour wih
no recovery o he losses [13].
Conclusion: Brazilian law does no
recognize he concep o consrucive
7/28/2019 ce12-01
8/64
acceleraion. There appears o be lile
likelihood o recovery o such coss
legally.
CanadaCanadian cours have no expressly
recognized he erm, consrucive
acceleraion, as US cours have. One
Canadian aorney commened on his inhe ollowing manner.
Consideraion o consrucive
acceleraion expressly by Canadian
cours is rare In reviewing Canadian
cases on acceleraion, hose conracors
which have proven acs which look
remarkably like he shopping lis o
elemens o consrucive acceleraion
have ended o be successul wih heir
claims. On he oher hand, i one
reviews he claims which have been
denied, one can easily pick ou which o
he elemens is missing. This despie heac ha one will be hard pressed o ind
Canadian cases which have expressly
adoped he erm, consrucive
acceleraion, or have adoped he ive
lised crieria[14].
There are, however, wo benchmark
Canadian cases ha irmly esablished a
mechanism by which a conracor in a
consrucive acceleraion siuaion may
be able o recover.
In Morrison-Knudsen Co. Inc. v.
British Columbia Hydro and Power
Authority, he cour ound ha he
owner was in undamenal breach o
conrac respecing paymens or
acceleraion [15]. Boh he rial
cour and he appellae cour ound
ha (1) he owner reused o gran
ime exensions or boh owner
caused delays, as well as oher
delays beyond he conracors
conrol; and, (2) he owner
demanded on ime compleion o
he work.
As a resul, he cour deermined
ha he appellans (he owner)
conduc respecing paymen or
acceleraion consiued
undamenal breach (o conrac).
Likewise, in W.A. Stevenson
Construction (Western) Limited v.
Metro Canada Limited, he cour
ound ha he owner reused o
gran any imes exensions when
requesed by he conracor, boh
or owner caused and excusable
delay [16]. The cour also
deermined ha he owner issued
demands ha he conracor
accelerae he work, reminded he
conracor ha ime was o he
essence o he conrac and ha he
coss o acceleraion would be a he
conracors sole expense.
The cour concluded ha,
In a deliberae, anicipaory breach
o conrac by means o a policy
decision, he owner decided ha
he ime or compleion would no
be exended, no maer wha he
cause.
Conclusion: Despie he ac ha
Canadian cours have no adoped he
erm, consrucive acceleraion, i a
conracor can prove he siuaion meall o he six crieria se orh above, hen
hey can claim breach o conrac in
order o perec he claim and recover
heir acceleraion coss.
ChinaThe Peoples Republic o China does
no recognize he concep o
consrucive acceleraion in heir
Contract Law of The Peoples Republic of
China [17]. Nor is consrucive
acceleraion included in he Chinese
Construction Contract of Construction
Works (GF-1999-0201) [18].
Chinese consrucion law and
conracs disinguish beween
acceleraion, miigaion, and
expediing.
Acceleraion is an increase in
resources and inensiy o work wih
he aim o bringing he job in on
ime.
Miigaion means reallocaing
exising resources in order o
minimize cos and delay resuling
rom changed condiions.
Expediing is a resul o conracor
caused delay, and resuls in he
conracor aking measures o mee
he compleion dae a heir own
expense [19].
However,Article 284 of the Contract
Law of The Peoples Republic of China
mandaes he ollowing
Where due o he aul o he
employer, he projec is sopped or
posponed in he course o he
consrucion, he employer shall
adop measures o ose or reduce
he losses and compensae he
conracor or he losses and acual
expenses recurred hereo due osopping and idling o he labor
orce, changes in he ransporaion,
removal o he machinery and
equipmen, oversocking o
maerials and building
componens.
The auhor o he privae paper
reerred o above suggesed ha in
siuaions where owner caused delay has
occurred; he conracor has requesed
appropriae ime exensions; and he
owner has reused o gran exensions oime and demands on ime compleion;
he conracor needs o obain he
owners demand or on ime compleion
in wriing.
I all o his is done, hen he
conracor may be in a posiion o ile
sui or damages arguing, direced or
insruced acceleraion based on he
employers breach o conrac. I was
also suggesed ha Chinese culure and
business pracice may assis in resolving
such claims, as here is lile endency o
pursuing dispues in liigaion.
Conclusion: Chinese law does no
recognize consrucive acceleraion, bu
does require an owner o appropriaely
adjus he ime o compleion and pay
or delay damages or owner caused
delays. However, should he owner
reuse o issue appropriae ime
exensions and demand on ime
compleion, he conracor should insis
ha he on ime compleion insrucion
be pu in wriing. Once his is received,
he conracor is in a posiion o seek
recovery o acceleraion coss, arguing
ha he owner breached he conrac
(which incorporaes Chinese
consrucion law by reerence) and
insruced acceleraion.
ColombiaA privae e-mail response o he
auhors inquiry concerning consrucive
6 COST ENGINEERING JANUARY 2012
7/28/2019 ce12-01
9/64COST ENGINEERING JANUARY 2012
acceleraion in Colombia elicied he
ollowing response.
here is a subsanial parallel
beween US and Colombia, similar
seps, somewha dieren mix o
characers and a dieren emphasis
on all he pieces o handling claims
[20].
Conclusion: Despie he ac ha
Colombia is a civil law naion, i appears
rom he above ha heir legal sysem
may provide or recovery o acceleraion
coss in a consrucive acceleraion
siuaion; provided ha, he conracor
complies wih he six seps jusiying
consrucive acceleraion and can
documen each poin.
Egyp
The Arabic Republic o Egyp is a civillaw naion and as such, has no case law.
Consrucion projecs, generally, are
governed by Egyptian Civil Code [21]. In
response o he auhors inquiry
concerning he recogniion o
consrucive acceleraion under Egypian
law, one claims consulan working in
Egyp responded wih he ollowing.
From my 13 years o experience in
working in Egyp so ar, I can
generally ell you ha consrucive
acceleraion is no recognized here. here is also no recogniion o
delay analysis echniques eiher, so
he principle o an excusable delay
(poin 1 in he US condiions or
conracors recovery) does no
exis [22].
The auhor has worked in Egyp on
hree dieren projecswo in
Alexandria and one in Cairoand based
on his experience concurs ha Egypian
Civil Code oers relie o he conracor
only or owner caused delay.
There is anoher problem
concerning he concep o consrucive
acceleraion under Egyptian Civil Code.
Many aorneys argue ha he Saue o
Limiaions renders noice provisions in
Egypian conracs unenorceable by law
[23]. As such, many cours and
arbiraion panels ignore he noice
provisionshus eliminaing par o he
second poin, as well as he ih poin o
he six poin es or consrucive
acceleraion.
This argumen is counerbalanced
by oher Egypian aorneys who argue
ha i is a well esablished Civil Code
principle ha, he conrac is he law o
he paries.
Conclusion: Egypian law does no
recognize consrucive acceleraion. Nor
does i recognize he concep o
excusable delay and noice provisions
may or may no be enorced.
A conracor acing a consrucive
acceleraion siuaion probably canno
recover acceleraion coss incurred o
recover los ime resuling rom
excusable delay siuaions; bu may be
able o recover such coss incurred in
recovering los ime because o owner
caused delay under a breach o conracheory.
I, however, he conracor can
negoiae all six condiions relaed o
consrucive acceleraion ino he
conrac he Civil Code concep ha, he
conrac is he law is likely o prevail.
FranceFrance oo is a civil code counry, so
no case law as we know i in he US
exiss. French Civil Code gives judges
grea discreion o reduce or increase
conracually agreed penalies andliquidaed damages.
There are a number o cases
where French cours have reduced he
delay penalies o be paid by a
conracor because he delay was in oal
or in par aribuable o he behavior o
ohers, such as eiher he main
conracor or he owner[24].
Based on a reading o French law,
se orh in his aricle, he only way o
accelerae he work o he projec is o
oer an incenive or bonus or such
acceleraion. Accordingly, French law
does no recognize he concep o
consrucive acceleraion.
Conclusion: A conracor working
on a projec governed by French law who
encouners delay and an owner, who
reuses all requess or ime exension, is
beer o o no accelerae he work o
aemp o recover he los ime. French
cours have he power and he
predilecion o reduce liquidaed
damages or penalies when acual
damages are lower and acceleraion can
only be ordered by adding bonuses o
he cos o he conrac.
GermanyMos conracs in Germany are
execued under he AllgemeinenVertragsbedingungen fur die Ausfuhrung
von Bauleistgungen (VOB/B), he
German conrac Terms for the Execution
of Construction works.
The VOB/B is a preormulaed se o
erms and condiions designed or he
addiion and parial modiicaion o
German law as i applies o consrucion
conracs [25].
There is no recogniion o he
concep o consrucive acceleraion in
he VOB/B. Secion 6 o he VOB/B deals
wih he issue o hindrances and delay.Should he owner hinder or delay he
conracors perormance, he conracor
is obligaed o give noice o he owner
and he owner is obligaed exend he
deadline or compleion he work.
The conracor is also eniled o
seek recovery o reasonable damage
compensaion under Clause 6 o he
VOB/B, as well as 642 o he German
Civil Code. Should he owner reuse o
issue ime exensions and demand on
ime compleion he conracor may be
able o recover heir acceleraion coss. Conclusion: A conracor acing a
consrucive acceleraion siuaion may
be able o recover acceleraion coss
arguing acs o hindrance and breach
o conrac or ailure o issue ime
exensions in a imely manner.
Hong KongHong Kong cours, like many oher
Commonwealh cours, do no recognize
he concep o consrucive acceleraion.
Claims on his basis [consrucive
acceleraion] are common in he US, bu
in Hong Kong here is no such docrine
[26]. However, hey do subscribe o he
legal heory o miigaion o damages, a
concep ha is based upon UK law.
As one auhor poined ou,
conracors have or many years looked
o recover rom employers he addiional
coss o implemening delay miigaion
measures (addiional coss o normal
working excluding prolongaion) even
7/28/2019 ce12-01
10/64
where here was no employers
insrucion o implemen such
measures[10].
Addiionally, Hong Kong cours
recognize he conracors abiliy o
recover acceleraion coss incurred as a
resul o owner caused delay where he
owner reuses o gran ime exensions.
Like oher cours, Hong Kong cours
acknowledge his as a breach o
conrac. They do, however, uphold
noice provisions and require ha he
conracor documen he delay
miigaion measures and coss
accuraely.
Conclusion: Despie he lack o
accepance o he heory o consrucive
acceleraion, conracors caugh in such
a siuaion in Hong Kong, may sill be
able o recover damages using he
miigaion o delay or breach o conracheories.
IndiaIn response o he auhors inquiry
concerning he recogniion o
consrucive acceleraion in Indian
cours, he ollowing was provided:
Conracor is eniled o
acceleraion wih coss when/i:
Schedule is delayed due o orce
majeure and clien requires original
end dae o be me Clien is direccause o delay o schedule, bu sill
requires original dae o be me
There is no general (naional) law
which speciically prescribes when a
conracor can, or canno claim
acceleraion coss. [27]
Addiionally, Indian cours recognize
he ime a large concep, wherein i
here is an ac o hindrance by he owner
or heir agens, or orce majeure evens,
hen a ime exension is owed o he
conracor. Should he owner reuse o
gran such a ime exension, hen i can
be said ha ime is a large and as here
is no longer a dae rom which liquidaed
damages can be calculaed, he owner
loses heir righ o impose liquidaed
damages [28]. I he owner demands on
ime compleion he conracor may be
able o recover on he basis o breach o
conrac.
Conclusion: As much o Indian law
is drawn rom English common law i
appears ha Indian cours do no
recognize he docrine o consrucive
delay, bu are amenable o legal
argumens cenered on delay miigaion,
ime a large, and/or breach o
conracual obligaions.
IndonesiaIn anoher e-mail response o he
auhors inquiry, Mr. Asrizal Sabri, an
Indonesian projec manager, responded
wih he inormaion ha Indonesian
laws recognize he righ o conracors o
recover damages resuling rom
acceleraion resuling rom owner
caused delay or orce majeure evens
[29].
Reerence was made o Keppres No.
80 (Republic of Indonesia Laws) in
suppor o his saemen [30]. KeppresNo. 80 was he Indonesian governmens
aemp o align heir procuremen
process wih hose o oher naions and,
as such, he governmen impored legal
and conracual conceps rom many
oher counries. The e-mail response
also poined ou ha or a conracor o
recover such coss hey will need o
obain wrien documenaion ha he
owner has demanded acceleraion.
Conclusion: Alhough i is no clear
which legal heory conracors may rely
upon o recover consruciveacceleraion coss, wha appears o be
clear is ha i he conracor can prove
excusable delay, he owners reusal o
gran ime exensions, and he owners
demand ha he conracor ake acion
o recover he los ime, hen he
conracor may have a legal righ o
recover damages.
IrelandMany projecs in Ireland are
conraced or under RIAI, GDLA 82, or
IEI form of contract[31, 32, 33]. None o
hese conracs expressly recognize he
concep o consrucive acceleraion.
However, all o hem provide or
recovery o loss and expense or
damages, as well as ime exensions.
Some causes o delay may also
enile he conracor o claim loss and
expense or damages, under RIAI/GDLA
clauses 2 and/or 29(b) [as well as under
IEI clause 44] However here is no
provision in hose clauses or he
paymen o pure acceleraion coss. A
mere volunary decision by he
conracor o accelerae is no enough o
ound a claim or consrucive
acceleraion. There mus be some
elemen o undue coercion by he
employer, which compels he conracor
o accelerae [34].
Conclusion: I is no clear i Irish
cours will adop he concep o
consrucive acceleraion. Bu, i a
conracor can prove delay enilemen;
he owners reusal o allow an exension
o ime; coercion by he owner orcing
he conracor o accelerae work; and
acual damages, hen coss may be
recoverable under he loss and expense
or damages clauses oRIAI, GDLA 82 or
IEI contract. Addiionally, since Irish
cours are heavily inluenced by English
cours, he legal conceps o breach oconrac, delay miigaion and/or ime a
large may also assis in recovery o
damages.
MalaysiaMany projecs in are consruced
using he PAM, he JCT, or he ICE or o
conrac [35, 36, 37]. As such, Malaysian
conracs recognize he legal conceps o
ac o prevenion or ac o hindrance and
ime a large. The Malaysian Federal
Cour in Sim Chio Huat v Wong Ted Fui
deal wih a case where he conrac hada liquidaed damages provision bu did
no have a ime exension clause [38].
The cour ruled ha he owners delay in
providing he sie and he issuance o
exra work orders operaed o se ime a
large and render inoperaive he
liquidaed damages clause.
Mr. Dennis Oon Soon Lee, a
Malaysian consrucion manager, has
analyzed he issue o consrucive
acceleraion under Malaysian law and
concluded ha his concep is no
recognized. However, he also
deermined he ollowing.
where i can be shown ha he
conrac adminisraor has unreasonably
or unnecessarily delayed he gran [o]
exensions o ime, here is lile
diiculy in esablishing ha his is a
breach o conrac by he employer. In
cases which deal wih he ailure o gran
an exension o ime and he eec ha
his has on he liquidaed damages
8 COST ENGINEERING JANUARY 2012
7/28/2019 ce12-01
11/64COST ENGINEERING JANUARY 2012
provisions, i appears o be acceped
ha he said ailure by he conrac
adminisraor is a breach o conrac by
he employer. Tha a disincion needs
o be made beween an express reusal
or coninued ailure o deal promply
wih an exension o ime applicaion on
he par o he conrac adminisraor,
and an honesly held view or assessmen
ha no exension o ime is due. The
issue however is when can he conrac
adminisraor be considered o have
unreasonably or unnecessarily delayed
he gran o an exension o ime [39].
However, as noed by Mr. Oon Chee
Kheng in a horough aricle on ime
exensions and liquidaed damages
under Malaysian law,
I remains o be said ha even i
loss and expense or coss o
consrucive acceleraion is claimable,
his is sricly beyond he jurisdicion ohe Engineer/Archiec/S.O., and he
same can only be pursued in arbiraion
or liigaion. Loss and expense and
coss are boh conracual inancial
compensaion mechanisms and he
Engineer/Archiec/S.O. can only ceriy
hese arising rom consrucive
acceleraion i here are conracual
provisions o ha eec [40].
Conclusion: Malaysian cours do
no recognize he consrucive
acceleraion legal heory. They do,
however, acknowledge he legalconceps o acs o
prevenion/hindrance, ime a large and
breach o conrac. Thus, i a conracor
can prove enilemen o a ime
exension and reusal o he owner o
issue he ime exensions warraned by
he conrac, plus he damages incurred
by he conracors acceleraion eors,
hen he conracor may be able o
recover such damages bu will have o
do so in arbiraion or liigaion.
OmanOmans legal sysem is based on civil
code principles and, in paricular,
Egyptian Civil Code. Privaely inanced
conracs in Oman are generally
governed by Egyptian Civil Code.
However, Oman adoped a orm o
conrac general condiions based on he
Inernaional Federaion o Consuling
Engineers (FIDIC) documens. Public
works projec in Oman are subjec o his
laer se o condiions [41].
Consrucive acceleraion is no a
recognized concep under he FIDIC
documens as he FIDIC documen were
adaped rom he Insiue o Civil
Engineers (ICE) documens. As he ICE
documens were developed by an
English proessional sociey, i is no
unexpeced o ind ha hey do no
recognize his concep.
However, when working under a
FIDIC conrac, should he owner reuse
o issue appropriae ime exensions, he
conracor is no compelled o accelerae
heir work unless so ordered in wriing
by he owner. (I such an order is issued,
his becomes a direced acceleraion
under Clause 8 o he FIDIC documens.)
Under English law one o he
primary areas o concern wih respec o
hese provisions would be he poenialapplicabiliy o he docrine o acs o
prevenion. Under his docrine i here
is no provision or an exension o ime
or none is graned when i should have
been and i an employer prevens
hrough his own acions he conracor
rom compleing wihin he speciied
ime or compleion, ime becomes a
large and he conracor is given a
reasonable ime in which o complee
Peak v. McKinney(1969) 1 BLR 111 (CA).
Liquidaed damages all away [42].
In a siuaion where a conracor isworking on a privaely inanced conrac
subjec o Egyptian Civil Code and aces
consrucive acceleraion siuaion,
acceleraion coss may be recoverable in
accordance wih he earlier discussion o
Egypian law above.
Conclusion: Oman law does no
recognize he concep o consrucive
acceleraion as such. As many conracs
in Oman are execued under FIDIC
conracs a conracor in his siuaion is
no compelled o accelerae i hey are
delayed by ac o he owner. Theconracor can asser he argumen ha
he delay was an ac o prevenion and
ime is now a large (i.e., here no longer
exiss eiher a compleion dae or
liquidaed damages) and he conracor
is ree o inish he work wihin a
reasonable period o ime.
Should he conracor be working on
a privaely unded conrac, subjec o
he provisions o Egyptian Civil Code
hen a conracor acing a consrucive
acceleraion siuaion probably canno
recover acceleraion coss incurred o
recover los ime because o excusable
delay siuaions; bu may be able o
recover such coss incurred in recovering
los ime because o owner caused delay
under a breach o conrac heory.
SingaporeProjecs in Singapore are requenly
consruced under he JCT, ICE, or he
PSSCOCorm o conrac [43]. None o
hese conrac orms recognize or
acknowledge he concep o
consrucive acceleraion [44]. Like
Malaysian cours (discussed above)
cours in Singapore recognize he
conceps o ac o prevenion or ac o
hindrance, ime a large, and breach o
conrac [45].
Conclusion: The cours o Singaporedo no recognize he consrucive
acceleraion legal heory. They do,
however, acknowledge he legal
conceps o acs o
prevenion/hindrance, ime a large and
breach o conrac. Thus, i a conracor
can prove enilemen o a ime
exension and reusal o he owner o
issue he ime exensions warraned by
he conrac, plus damages incurred by
he conracors acceleraion eors,
hen he conracor may be able o
recover such damages.
Souh AricaSouh Arican law and cours do no
recognize he docrine o consrucive
acceleraion.
The argumen adoped by many
conracors in Souh Arica namely ha a
rejecion o an EOT reques which he
conracor believes is correc amouns o
an insrucion o accelerae and inish on
ime is simply incorrec. The reusal o
gran an EOT can amoun o a deemed
insrucion o accelerae. A claim or
consrucive acceleraion under English
law mus be based on ordinary principles
or breach o conrac and
damages[46].
However, i has been poined ou
ha under FIDIC, NEC, JBCC, and he
SAICE[47, 48, 49]:
The engineer owes a duy o care
owards he conracor in adminisering
7/28/2019 ce12-01
12/6410 COST ENGINEERING JANUARY 2012
he conrac o deermine such [ime]
exension and is obliged, no eniled, o
carry ou his uncion. I is he engineer
and no he employer who mus
deermine and gran he exension.
The engineer is obliged o reach a
decision and convey his decision o he
conracor wihin a reasonable period o
ime aer he exra or addiional work or
oher special circumsances have arisen
[50].
Conclusion: Based in his principle,
he ailure o he engineer o properly
adminiser he ime exension provisions
o he conrac is likely a breach o
conrac. Should he owner hen
demand on ime compleion hus
causing he conracor o accelerae
heir work, damages will arise which
should be recoverable as hey low rom
he breach o conrac. I would appear,
however, ha he conracor musobain he owners demand or on ime
compleion in wriing as Souh Arican
cours apparenly do no accep a
deemed insrucion o accelerae.
Sri LankaNo much is known concerning
consrucive acceleraion in Sri Lanka.
However, he ollowing was repored.
Sri Lankan Preceden:
O paricular ineres is he repor o
a hallmark case in Sri Lankainvolving he consrucion o
irrigaion canals. In ha case he
conracor was orced o spend a
large sum on duplicaing his
emporary equipmen because o
he ailure o he principal agen o
award an exension o ime
imeously. The ICC Arbiraion
awarded he conracor some US
$56 million being approximaely 95
percen o is proven coss o
consrucive acceleraion. Wha
makes his case o paricular
ineres is ha he law o he
conrac was Sri Lankan law and Sri
Lanka is one o he ew counries
ouside Souh Arica having a
Roman-Duch legal oundaion
[51].
Conclusion: Recovery o
consrucive acceleraion damages is
poenially possible in Sri Lanka, bu
based upon he above inormaion, he
circumsances under which such
damages may be recovered are no
known. Should a conracor begin o
become involved in such a siuaion,
conac wih compeen legal counsel is
requiredsooner raher han laer.
Trinidad and TobagoIn response o he auhors inquiry
concerning recogniion o he docrine
o consrucive acceleraion in Trinidad
and Tobago, Mr. Sanley Wes, Pas
Presiden o AACE Inernaionals
Caribbean Secion respondedTwo o
he senior lawyers who deal wih
conracs are no amiliar wih he
erm and as such have no knowledge o
any cour case or oher claims dealing
wih consrucive acceleraion [52].
Conclusion: Since he laws o
Trinidad and Tobago are based in Englishlaw, i is presumed ha even hough
Trinidadian cours do no recognize
consrucive acceleraion as a legal
docrine, hey would mos likely
subscribe o he conceps o ac o
hindrance or ac o prevenion, ime and
large and breach o conrac.
Unied Arab Emiraes (UAE)
In a shor bu very inormaive
aricle, Mr. Chris Larkin, an English
Charered Engineer, wih a law degree
and arbiraion qualiicaions, advisedha he docrine o consrucive
acceleraion is no recognized in he UAE
[53]. However, Mr. Larking noes ha
Article 246 o he UAE Federal Law No. 5
o 1985 (he Civil Code) conracs
mus be perormed in a manner
consisen wih he requiremens o
good aih
Mr. Larkin opined ha his applies
boh o he paries o he conrac, bu
also o he person who has he power o
award exensions o ime and ceriy
paymen applicaion. He noed, or
example, ha under he FIDIC Redbook,
4th Edition, he he engineer has a
duy o deermine he exension o ime
ha he conracor is airly eniled o.
In exercising his duy, he engineer mus
ac imparially wihin he erms o he
conrac
Mr. Larking suggesed ha i he
engineer did no perorm heir duy
airly, hen hey could be ound in
violaion oArticle 246. He goes on o
sugges ha, i here was an ac o
bad aih ha resuled in he conracor
incurring addiional coss, hen he
deauling pary or paries responsible
could be liable o pay compensaion.
He noed also ha Aricle 282 o he Civil
Code saes ha:
Any harm done o anoher shall
render he perperaor, even i he is
a minor, liable o make good he
harm.
Conclusion: Nowihsanding he
ac ha UAE law does no recognize he
docrine o consrucive acceleraion, i
is possible or a conracor o recover
damages under he UAE Civil Code i he
conracor ollows he requiremens o
he conrac concerning noice and ime
exension requess and can prove hahe engineer ailed in his duy o ac
imparially.
Unied Kingdom (UK)In a classic bi o undersaemen,
R.D. Pickles wroe
The English cours have been a
lile slow a recognizing a siuaion
where a claim or consrucive
acceleraion would be relevan
[54].
In ac, Proessor Ian Duncan
Wallace, edior oHudsons Building and
Engineering Conracs, has gone on
record by declaring he docrine o
consrucive acceleraion a iciious
docrine no ounded on consensual
or quasi-conracual basis and would
no be accepable in English Cours and
Commonwealh Cours [55]. Numerous
oher schedule and schedule delay exs
ou o he UK agree wih he saemen
ha he docrine o consrucive
acceleraion is no ye recognized in UK
cours [56].
Wha is acknowledged, however, is
he owner and engineers duy o
adminiser he conrac in accordance
wih he erms o he conrac. Thus, i
some acion o he owner or he
engineer consiues an ac o hindrance
or an ac o prevenion; he owner or
engineer reuses o gran an appropriae
ime exension; he conracor is
7/28/2019 ce12-01
13/64COST ENGINEERING JANUARY 2012
pressured or coerced o make up he los
ime; he conracor acceleraes and
incurs acual coss; hen under he legal
conceps o prevenion, ime a large
and breach o conrac, he conracor
may be able o recover heir acceleraion
coss. However, as one auhor poined
ou,
Under he Housing Grants,
Construction and Regeneration Act, he
conracor now has he opion o
address his uncerainy a an early sage
by reerring his claim or an exension o
ime o an adjudicaor during he course
o he conrac, raher han o he cour
or an arbiraor aer compleion [57].
This is probably he righ way o go,
given he problems wih acceleraion
[58].
Thus, conracors aced wih a
consrucive acceleraion siuaion can
seek adjudicaion, which ypically akes avery shor period o ime, whenever he
owner or engineer denies a ime
exension and aemps o make he
conracor recover he los ime.
I is also noed ha one English
cour case wihin he las ew years came
very close o acknowledging
consrucive acceleraion. In Motherwell
Bridge Construction Ltd v Micafil
Vacuumtechnik, he cour ruled ha
he claiman was eniled o he coss o
he measures aken o achieve
compleion earlier han conracuallynecessary [59, 60].
Conclusion: Even hough English
cours do no currenly recognize he
concep o consrucive acceleraion,
hey appear o be moving in his
direcion. I a conracor inds
hemselves in a consrucive
acceleraion siuaion, and he conrac
is under he jurisdicion o he Housing
Grants, Construction and Regeneration
Act, he irs sep should be o reer he
dispue o adjudicaion o seek a
decision by a neural decision maker. Inhe absence o his, conracors seeking
recovery o consrucive acceleraion
coss will need o documen acs o
prevenion or hindrance, coercion o
obain compleion earlier han should be
been allowed, and breach o conrac. I
he conracor in such a siuaion can
prove hese poins, hen hey should be
able o recover heir acceleraion coss.
Conclusions
In all counries ouside he US
included in his survey, he concep
o consrucive acceleraion is no
recognized, a leas under his name.
Bu in mos o he counries lised above,
conracors who have been
consrucively acceleraed because o
he reusal o he owner o gran imeexensions when warraned ollowed by
coercion o orce on ime compleion,
conracors may recover some or all o
he damages incurred using a number o
oher legal heories.
The common heme supporing
hese alernaive legal heories seems o
be he ollowing.
Fixed Period RequiremenThe
conrac mus have a Time of the
Essence Clause and a Time of
Completion requiremenaccompanied by some sor o lae
compleion damages clause. Aer
all, i ime is no imporan o he
projec owner, hen he conracor
is simply held o a sandard o
compleing he work wihin a
reasonable ime.
Conrac Provides or Exensions o
TimeThe conrac mus have
language which allows he owner o
exend ime under cerain
circumsances. Tha is, he owner
mus have he legal abiliy under he
conrac o gran ime exension. I
here is no clause providing or ime
exensions hen he owner canno
be said o have breached heir
obligaion by no graning such
exensions.
Mee he Six Sep Checklis or
Consrucive Acceleraion
Conracors seeking recovery o
acceleraion coss resuling rom anowners reusal o gran a ime
exension probably have o
demonsrae he ollowing o he
rier o ac.
Excusable delay was
encounered.
Noice was provided o he
owner and appropriae
ime exension requess
were submied.
The owner issued no ime
exension or less ime han
should have been allowed.
The owner hreaened or
coerced he conracor ino
acceleraing heir work in
order o recover some or
all o he los ime.
The conracor provided
noice o he owner ha
hey considered he
owners acions o be a
direcive o accelerae.
And,
Finally, he conracor did
acually accelerae and can
documen heir acions
and he resuling damage.
Arbiraion or Liigaion is Required
I appears rom he resuls o his
survey ha, unlike he US, his is noa claim ha can be negoiaed o
selemen on he job sie. Raher,
as mos counries deal wih his sor
o claim in he conex o breach o
conrac (as did he US prior o he
Contract Disputes Act of 1978), hen
he claim in mos counries will
mos likely have o go o arbiraion
or liigaion.
REFERENCES1. Bramble, Barry B. and Michael T.
Callahan, Consrucion DelayClaims, 2nd Edition, 6.8, Wiley LawPublicaions, New York, pages 178-
182, 1992.
2. Hudsons Building and Engineering
Conracs, 11th Edition, 7-050,Swee & Maxwell, London, England,
1995.
3. See, or example, Lewis Consr. Co.,
ASBCA 5509, 60-2 BCA 2732;Mechanical Uils., Inc., ASBCA 7345,
1962 BCA 13,260; and Elecronic
& Missile Faciliies, Inc., ASBCA
9031, 1964 BCA 4338.4. See Cibinic, John, Ralph C. Nash and
James F. Nagle, Adminisraion o
Governmen Conracs, 4th Edition,
pp. 445 458, George WashingonUniversiy, Washingon, D.C., 2006;
see also, Wickwire, John M.,
Thomas J. Driscoll, Sephen B.
Hurlbu and Mark J. Gro,
Consrucion Scheduling:
Preparaion, Liabiliy and Claims,
3rd Edition, 7.10(B), pp. 268 271,
7/28/2019 ce12-01
14/6412 COST ENGINEERING JANUARY 2012
Wolers Kluwer Law & Business,
New York, 2010.5. AACE Inernaional Transacions,
AACE Inernaional, Morganown,
WV, 2004.
6. Public Conrac Law Journal,Volume 39, No. 2, Winer 2010.
7. Procuremen Law, Summer 2009.
8. 41 U.S.C. 601-613, 1988.
9. Lyle, Bryce, What is ConstructiveAcceleration? MaserBuilders
KwaZulu-Naal, Augus 2009.
10. Rawling, Brian E., Delay Mitigation,
Brian E. Rawling & Associaes, Ld.,Winer 2005/6.
11. Weaver, Parick, Delay, Distruption
and Acceleration Costs, Mosaic
Projec Services Py Ld, SouhMelbourne, Vicoria, 2005.
12. Cremean, Damien J., B.A. Shnookal,
and Michael H. Whien, Brookings
on Building Conracs, 4th Edition,
Secion 6.8, LexisNexisBuerworhs, Ausralia, 2004.
13. Privae e-mail communicaion rom
Aldo Dorea Maos, Aldo MaosConsuling, April 20, 2010.
14. Grenier, Glenn, The Traps and
Pitfalls of Construction Delay Claims
in Ontario, Lang Michener LLP,Torono, Onario, 2005.
15. D.L.R. (3d) 186 (B.C.C.A.) 1978.
16. 27 C.L.R. 113 (B.C.S.C.) 1987
17. Adoped and promulgaed by heSecond Session o he Ninh
Naional Peoples Congress on
March 15, 1999.
18. Issued by he Minisry oConsrucion o he Peoples
Republic o China and he Bureau o
Indusrial and Commercial
Adminisraion o he PeoplesRepublic o China on December 24,
1999.
19. Zhang, JianHua, ConstructionAcceleration in China , anunpublished paper prepared in
response o he auhors inquiry
concerning consrucive
acceleraion in China, April 25, 2010.See also Richer, Irvin E.,
Inernaional Consrucion Claims:
Avoiding & Resolving Dispues,
McGraw Hill Publicaions, New York,pages 73-77, 1983.
20. E-mail response rom John Smih, a
recognized US consrucion claims
consulan and esiying exper,currenly reired and living in
Bogoa, Colombia, May 3, 2010.
21. Aricles 646 o 667.
22. E-mail response rom Waleed El
Nemr, April 20, 2010 andpresenaion slides by Dr. Shei El
Haggan, FIDIC Middle Eas Conrac
Users Conerence, Abu Dhabi,
February 25, 2010.23. Article 388, Egyptian Civil Code.
24. Colaiua, Virginie A., How French
Courts Discretionary Power to
Reduce Delay Penalities andLiquidated Damages May Affect
Acceleration of Works in
Construction Projects, IBA
Conerence, Session on Time andAcceleraion Issues Aecing
Inernaional Consrucion
Conracs, Madrid, 2009.
25. Osing, Dr. Sean, Time andAcceleration Issues Affecting
International Construction
Contracts: The German Approach,
paper presened a he IBA Annual
Conerence, Madrid, 2009.26. Molloy, John B., Constructive
Acceleration A Valid Claim? Hong
Kong Insiue o Surveyors, FeaureAricle, July 2002.
27. E-mail response rom Madhu
Ponnappan Pillai, AACE Regional
Direcor and projec managemenconsulan in India, April 22, 2010.
28. Westwood v. Secretary of State for
India (1863) 1 New Rep 262, ciing
Holme v. Guppy (1838) 3 M&W 387.See also: Roberts v. Bury
Commissioners (1870) LR 5 CP 310.
29. E-mail response rom Asrizal Sabri,
Indonesian projec manager, April20, 2010.
30. Presidenial Decree Number 80 o
2003.
31. Royal Insiue o he Archiecs oIreland.
32. Agreemen and Condiions o
Conrac or Building Work or use
by Governmen Deparmens andLocal Auhoriies, March 1982.
33. Insiuion o Engineers o Ireland,
Condiions o Conrac or use in
Connecion wih Works o CivilEngineering Consrucion, 3rd
Edition, 1980, revised and reprined
Ocober 1990.
34. Lyden, John M.E., Acceleration
Claims on Construction Projects in
Ireland, paper given o a meeing o
he Sociey o Consrucion Law and
he Sociey o Charered Surveyors,Cork, Ireland, March 14, 2005.
35. The Malaysian Insiue o
Archiecs Form, 2nd Edition, 1998,
modeled aer he JCT orm o
conrac bu no updaed asrequenly.
36. The Join Conrac Tribunal
Sandard Forms o Conrac, 2nd
Edition, 1998.37. The Insiuion o Civil Engineers
Conracs, 7th Edition, 1999.
38. 1 MLI 151, 1983.
39. Oon, Soon Lee, Dennis, Extension ofTime and Acceleration Claims, hesis
submied in ulillmen o he
requiremens or he award o he
degree o Maser o Science inConsrucion Conrac
Managemen, Faculy o Build
Environmen, Universii Teknologi,
Malaysia, March 2006.40. Khen, Oon Chee, Extension of Time
and Liquidated Damages in
Construction Contracts, paper
presened a a seminar on
Consrucion Conracs andArbiraion, sponsored by The
Insiuion o Engineers, Malaysia
(Perak Branch), Ipoh, Malaysia,Ocober 18, 2003.
41. Unpublished paper prepared by
legal counsel a Trowers & Hamlyns,
Musca, Oman, daed Ocober 21,2008 and presenaion slides by Dr.
Shei El Haggan, FIDIC Middle Eas
Conrac Users Conerence, Abu
Dhabi, February 25, 2010.42. Knuson, Rober, An English
Lawyers View of the New FIDIC
Rainbow Where is the Pot of Gold?
Privaely produced paper, London,June 2003.
43. The Singapore Public Secor
Sandard Condiions o Conrac,
3rd Edition, 2005.44. Sephenson, Andrew and Ian Bailey,
Concurrency Causation
Commonsense and Compensation,
IBA Conerence, InernaionalConsrucion Projecs Commiee,
Madrid, 2009.
45. Oon Soon Lee, Dennis, supra.
46. Mariz, M.J. and Andries P. Shue,APractical Approach to Calculate
Acceleration Costs on Construction
Projects in South Africa, 5h Pos
Graduae Conerence onConsrucion Indusry Developmen,
Deparmen o Quaniy Surveying
and Consrucion Managemen,
Universiy o he Free Sae,Bloemonein, Souh Arica, March
16-18, 2008.
7/28/2019 ce12-01
15/64COST ENGINEERING JANUARY 2012
47. The New Engineering Conrac,
Insiuion o Civil Engineers,November 1995.
48. The Join Building Conracs
Commiee, Sepember 2007.
49. The Souh Arican Insiuion o
Civil Engineers, 5th Edition, 1982.
50. Loos, P.C., Engineering and
Consrucion Law, Jua & Co. Ld.,
Cape Town, Souh Arica, 1985.51. Binningon, Chris, Sri Lankan
Precedent, The Civil Engineering
Conracor, January 2006.
52. E-mail rom Sanley Wes, PasPresiden, AACE Inernaional
Caribbean Secion, daed April 29,
2010.
53. Constructive Acceleration DemandsClear Intentions, ConsrucionManagemen Guide, Sepember 18,
2008, rerieved rom
hp://cmguide.org/archives.
54. Pickles, R.D., What Is ConstructiveAcceleration? Maser Builders
KwaZulu-Naal news, Augus 2009.
55. Hudsons Building and Engineering
Conracs, 11th Edition, 7-050,
Swee & Maxwell, London, England,
1995.
56. See, or example, Keane, P.J. and A.F.
Caleka, Delay Analysis inConstruction Contracts, Wiley-
Blackwell, London, 2008; and
Lowsley, Sephen and Chrisopher
Linne,About Time Delay Analysisin Construction, RICS Business
Services Limied, London, 2006.
57. Reerring o Section 108, Right to
Refer Disputes to Adjudication, ofthe Housing Grants Construction
and Regeneration Act of 1996, Part
II. This Ac has more recenly been
amended by he Local Democracy,Economic Developmen and
Consrucion Ac o 2009, which
requires ha a conrac speciically
include provision in wriing ohis eec.
58. Winer, Jeremy and Jacqueline
Mimms, Acceleration Claims, Baker
& McKenzie, March 2002. See also,
Gibson, Roger, Consrucion Delays,Exensions o Time and
Prolongaion Claims, Chaper 20,
Rouledge Taylor & Francis Group,London, 2008.
59. 81 Con LR 44; TCC, January 31, 2002.
60. Ndekugri, Issaka,A Legal Analysis of
Some Schedule-Related Disputes in
Construction Contracts, The
Consrucion and Building Research
Conerence o he Royal Insiuion
o Charered Surveyors, GeorgiaTech., Alana, Sepember 2007.
ABOUT THE AUTHOR
James G. Zack, Jr.,
CFCC FRICS, is wih
Navigan Consuling,
Inc.n He can be
conaced by sending
e-mail o:
Now: If schedules needed analysis,
Primavera would have included it.
See more at
http://ScheduleAnalyzer.com
What is the difference between
reviewing your P6 schedule andreviewing your P6 XER file?
Everything
% Interfaces Directly with Database
% Hundreds of Reports & Analyses
% Advanced Longest Path Analysis
% Built-in Report & Editing Facility
% Drill-down from Dashboard to P6
7/28/2019 ce12-01
16/64
7/28/2019 ce12-01
17/64COST ENGINEERING JANUARY 2012
TECHNICAL ARTICLE
The Oseing Delay Issue
Concurren delay is an
imporan issue in virually allconsrucion delay cases. The
sakes are high, because i
here are wo delays and hey can be
considered concurren, hen he
conracor is no eniled o delay
damages and he owner is no eniled o
liquidaed damages, alhough a non-
compensable ime exension is usually
graned [9].
Figure 2 illusraes a ypical
concurrency siuaion.
The auhors deiniion o
concurrency, including oseing delaysollows:
Concurren Delay is he
occurrence o wo or more delay
evens a he same ime one
an owner risk even, he oher a
conracor risk evenhe
eecs o which are el a he
same ime. The erm
concurren delay is oen used
o describe he siuaion where
wo or more delay evens arise
a dieren imes, so long as he
eecs o hem are el a he
same ime. This is generally
reerred o as oseing
concurren delays.
Concurrency is primarily a legal
heory daing rom he early 1900s
(alhough i was no called concurrency
hen). Mos o he conemporary
concurrency law we rely upon in he US
was developed in he 1960s hrough he
1980s. During his period, judicial
decisions releced a careul dissecion o
he hen available CPMs schedules ha
unorunaely generally made deailed
allocaion o responsibiliy impossible o
deermine, hence more indings o
concurren delay [2].
Ye, concurrency as a legal heory
ha is poorly undersood and
inconsisenly applied by cours and
expers [15, 22]. Concurrency has beencharacerized as, a risk allocaion
principle ha operaes o disribue coss
associaed wih conemporaneous delays
on a saus quo basis [6]. Concurrency
operaes in his manner because
hisorically he cours could no unangle
he complicaed ac paerns causing he
delay.
Oseing delays are an exreme
ype o concurren delay. They arise
when he wo delays mee he crieria o
OFFSETTING
DELAYS
THE OWNERS FRIENDJohn C. Livengood, CFCC PSP
Absrac: When dealing wih conracor delay claims, owners o consrucion proj-ecs oen use heir superior bargaining power o srike a deal beer han heacs or he law would permi. This is especially rue in cases where i is possibleor he owner o argue sequenial delays by he conracor should ose earlierdelays caused by he owner, making boh delays non-compensable. These delayshave he special name o oseing concurren delays. Concurren delays, paric-ularly delays associaed wih perormance o non-criical work, are poorly under-sood by he cours and schedule analyss alike. Savvy owners use his lack oundersanding when negoiaing selemens o delay claims by conracors. Thisaricle discusses he mos recen echnical issues associaed wih concurren delay,and shows how conusion has made he legal rulings on concurren delay unpre-
dicable, hus srenghening he owners bargaining posiion and allowing or hepopulariy o oseing delays claims. An earlier version o his aricle was irspresened as manuscrip CDR.609 a he 2011 AACE Inernaional Annual Meeingin Anaheim, Cali. The auhor has made some updaes and revisions since hapresenaion and hey are included wih his prining.
Key Words: Concurren delay, orensic schedule analysis, oseing delay and
sequenial delay
7/28/2019 ce12-01
18/64
concurrency, bu occur a widely
separaed imes. To illusrae, he same
basic ac paern will be used in igures
in his aricle:
The projec was a wo-building
complex wih a planned
simulaneous sar on boh
Buildings A and B. Bohbuildings had planned a nine-
monh duraionhey were on
co-criical pahs and boh
acually ook 10 monhs o
complee prior o
commissioning. When boh
buildings were complee, here
was a join wo monh
commissioning period leading
o subsanial compleion.
Figure 1 depics he ollowing
scenario, ypical o how he oseing
delays are negoiaed: An aggrieved
owner and delayed conracor hold a
negoiaing session aer consrucion is
complee on a wo-building complex.
The owner acknowledges ha i had
delayed sie access or one monh on
Building A, resuling in an acual 10-
monh duraion or ha building.
Neverheless, he owner believed ha
unrelaed delays o one monh
associaed wih he conracors poor
perormance in compleing mechanical
work on Building B resuling in a 10-
monh duraion, which balanced ou he
iniial delay on Building A.
The owner reasoned ha even had
he delay o Building A no occurred, he
oal projec would have been delayed a
monh because o he conracors delayon Building B. The owner oered a non-
compensable ime exension o one
monh.
Under he ollowing deiniion, he
erm concurren does no carry he
generally undersood meaning o, a he
same ime. As he erm is used in many
cases, concurren delays may occur
during any par o he projec
perormance period, no necessarily a
he same ime.
The period o concurrency is
he period o projec
perormance, no jus he
period during which any
individual delay may have
occurred [4].
Raher, concurren means under his
consrucion he impac a he end o he
projec is he same or each delay [19].
Essenially, he delays ha are being
looked a and balanced agains each
oher can occur a any ime during he
projec. We will reurn o his iming
problem aer discussing he more
general requiremens or concurrency, as
described in he AACE Inernaional
Recommended Pracice 29R-03 (2011)
Forensic Schedule Analysis Practice
Guide [FSAPG 29R-03], Subsection 4.2[1].
Whas Required or Concurren
DelayWhile FSAPG 29R-03 quoes ive
deiniions o concurren delay, i does
no adop any o hem. Raher, he
FSAPG 29R-03 deines seven crierion, all
o which are needed or a concurren
delay, as lised below:
1. Two or more delays ha areunrelaed, independen [6];
2. Eiher would have delayed he
projec even i he oher delay did
no exis [16];
3. Two or more delays ha are he
conracual responsibiliy o
dieren paries, bu one may be a
orce majeure even [6];
4. The alleged concurren delay mus
be involunary [13];
16 COST ENGINEERING JANUARY 2012
Figure 1 Concurren Delay wih Oseing Delays Recognized
7/28/2019 ce12-01
19/64
5. The work associaed wih he
alleged concurren delay mus be
subsanial and no easily curable;
6. The delays, each o which absen
he oher, mus independenly delay
he criical pah [12]; and,
7. The delays mus occur during or
impac he same ime analysis
period.
Figure 2 depics a ypical concurren
delay siuaion. Building A had a one
monh delay because o owner-caused
sie access. Building B was iniially
delayed because he specialized
equipmen and crews needed or ha
building were unavailable. Each delay,
absen he oher, delayed acual
subsanial compleion, i.e., he evens
were on he criical pah. None o he
delays were volunary and none were
easily curableexbook concurrency.
COST ENGINEERING JANUARY 2012
Figure 2 Concurren Delay During Same Measuremen Period
Figure 3 Concurren Delay Along a Single Criical Pah
7/28/2019 ce12-01
20/6418 COST ENGINEERING JANUARY 2012
The irs hree o he above crieriaare amiliar o all who have encounered
concurren delays and are generally
releced in he usually cied deiniions.
For exper analyss, much o he work o
esablishing or rebuing a concurrency
argumen revolves around he proo o
hese issues.
Equally imporan and discussed
only briely in he FSAPG 29R-03 is he
burden o proo associaed wih
concurrency. Concurrency is generally
an airmaive deense iniiaed aer
here has been an allegaion o delay [3,
6, 10]. Typically, one pary will allege
here was a delay, and he oher pary
will respond wih an allegaion o
concurrency. The pary iniially alleging
concurrency bears he burden o proo
or esablishing concurrency [8]. Then
he pary assering he original delay
oen presens is analysis showing a lack
o concurrency. As a pracical maer,
mos delay expers now rouinely
ideniy concurrency, or lack hereo, as
par o heir iniial analysis. FSAPG 29R-03 is wrien o relec ha ideniicaion
o concurrency is oen underaken as
par o he ypical schedule delay
analysis.
The ourh and ih crierion, added
by FSAPG 29R-03 in he 2011 ediion, are
common sense addiions. Crierion 4,
he concurren delay mus be
involunary is simply a relecion ha a
volunary delay oherwise meeing he
concurrency crieria would becharacerized as pacing, which is
discussed exensively in he FSAPG 29R-
03 in Subsecion 4.3 [1]. Crierion 5
relecs he pracical realiy ha neiher
an owner nor conracor should be
allowed o claim concurrency i he
alleged concurren delay is rivial.
The sixh crierion requires ha
boh alleged delays mus be on he
criical pah, even in he presence o he
oher delay. This is almos idenical o
he second crierion ha requires eiher
would delay he projec absen he
oher; however, here is a suble
dierence. Crierion 6 means you
canno jus subrac one o he delays o
see i he oher aecs compleion
because subracing one o he delays
changes he criical pah and could make
oher aciviy sequences criical [8].
So he es is ha boh delays have
o be on he as-buil criical pah. As
discussed below, his maer is one o he
key issues relaed o oseing delays.
The sevenh crierion herequiremen ha he delays be in he
same ime period is also discussed
laer in his aricle.
Oher Concurrency ConsideraionsFSAPG 29R-03 also discusses several
oher essenial issues associaed wih
concurrency he analys mus consider
when perorming an evaluaion. They
include:
Single or co-criical pahs;
Cause or eec; and,
Lowes loa or negaive loa
The irs issue is he need or co-
criical pahs in order o have
concurrency. Essenially, i asks i you
can have concurren delays when here
is only one criical pah? The answer is
Yes. Co-criical pahs are no required as
concurrency usually occurs when here is
only a single criical pah [6].
Concurrency in hese siuaions is more
closely associaed wih he mehod o
aciviy represenaion in he CPM
nework isel, and he ac ha such
neworks are only approximaions o he
real logic connecions beween
aciviies. As a resul, i is almos always
unnecessary and always unwieldy o pu
all he relaionships ino a schedule.
Such a schedule would be so large, even
on a moderae sized job, as o be
unusable. The soluion is o look a he
causes o he delay.For example, as shown in igure 3,
on a projec wih a single criical pah
saring wih he irs aciviy
mobilizaion, he owner is unable o
provide sie access on he required dae
o Building A. A he same ime and
unrelaed o he owners delay, he
conracor is unable o mobilize is crews
and equipmen, also o Building A. There
are wo concurren causes o delay o
Figure 4 Concurren Delay Under he Funcional Approach Wih Two Delays Wihin he Same Measuremen Period
7/28/2019 ce12-01
21/64
he single criical pah. These wo causes
could be depiced as separae aciviiesin he CPM nework prior o sar o
Building A criical pah. However, such a
level o deail is unnecessary in a CPM
even i i is necessary o ideniy and o
deermine concurrency. I is suicien o
recognize here are wo evens
(oherwise meeing he seven crieria)
causing a delay.
Closely relaed o his issue is he
second issue o cause or eec. Is he
concurrency being discussed associaed
wih he even ha causes he delay, or
he maniesaion o he delay isel?
This oen appears where here are non-
criical delays ha lead o a criical pah
delay. For example, assume a schedule
aciviy wih a planned duraion o seven
days has slow produciviy and exends
or anoher hree days or a oal
duraion o 10 days. The delay does no
manies isel unil he aciviy ails o be
compleed on he sevenh day. The
delays were earlier, bu he eecs o
hese delays do no appear unil he end
o he sevenh day. When is he delay orpurposes o deermining concurrency?
FSAPG 29R-03 does no ideniy a
preerred mehod in his siuaion, bu
his auhor believes ha i is generally
bes o measure concurrency a he
poin he delay is maniesed on he
criical paha he end o he sevenh
day in he example above. The
alernaive would be o invesigae he
iming o each o he causaive elemens
associaed wih he alleged delays. This
is oen impossible.FSAPG 29R-03 also ideniies ha
such an invesigaion may be impaced
by he placemen o measuring periods
since he causaive evens may occur
long beore he delay appears. The bes
soluion is o recognize here is no acual
delay a an aciviy level unil he aciviy
ails o complee on ime; however, a
deailed examinaion is sill required o
look a he causes o he delays since
hey aec he consideraion o pacing
and volunariness.
Regarding he hird issue, FSAPG
29R-03, Subsecion 4.2.D.2 has an
exensive discussion o he undamenal
issue o leas loa or negaive loa as i
relaes o criicaliy. The negaive loa
heory assumes criicaliy o any aciviy
ha has negaive oal loa relaive o a
conracual milesone. The negaive
loa approach has a cerain advanage in
ha conracors oen manage aciviies
wih negaive loa more closely and
recovery o hese aciviies is essenial o
he recovery o projec delay. The lowesloa pah heory provides or criicaliy
on he longes pah only, even i oher
secondary pahs are lae wih regard o a
conracual milesone.
Under his heory, all pahs shorer
han he longes pah (even hose wih
negaive oal loa) have posiive oal
loa wih respec o he longes pah
and are hereore non-criical. The issue
is so undamenal ha FSAPG 29R-03
ideniies i as an essenial consideraion
in ive o is nine delay analysismehodologies [1].
The dierence beween hese wo
heories has a signiican impac on
deermining concurrency. Under he
negaive loa heory, any aciviies wih
negaive loa occurring during he
measuremen period are poenial
candidaes or concurrency. This heory
suppors he applicaion o oseing
delays since any delay o negaive
aciviies would be a criical pah delay.
FSAPG 29R-03 ideniies ha mos
schedule delay analyss and FSAPG 29R-
03 isel generally ollows lowes loa
pah heory. This heory reduces he
poenial applicaion o oseing delays.
Same Time PeriodPerhaps he mos conroversial and
a he same ime mos imporan new
concep relaing o concurrency in
FSAPG 29R-03 are he conlicing
approaches o Funcional v. Lieral
Concurrency. Simply pu, i asks how ar
apar in ime can would-be concurrendelays be? This concep and
erminology was developed in FSAPG
29R-03 (2007) and while i had never
been separaely ideniied as an elemen
o concurrency, i has oen been an
underlying issue in cour cases [14].
Under he Funcional approach, he
delays mus occur in he same analysis
measuremen period. This means ha a
delay by he owner in he beginning o
COST ENGINEERING JANUARY 2012
Figure 5 No Concurrency Delay Under he Lieral Approach Wih Two Delays Separaed by One Day
7/28/2019 ce12-01
22/64
he measuremen period can be
concurren wih a delay by he
conracor in he end o he
measuremen period, see igure 4.
Under he Lieral approach he
concurren evens mus sar a he same
ime, bu need no be o idenical
duraion. I one o he delay evens
sars prior o he oher even, he irs
even creaes loa in he second even
prevening i rom being on he criical
pah [18]. While perec simulaneiy is
impossible, hey canno sar a exacly
he same ime, FSAPG 29R-03 recognizes
he measuremen period or mos
schedules is a day, so he alleged delays
mus sar on he same day. I he
measuremen period was an hour, as i is
in shu-down or ouage projecs, or a
week, as migh occur in cerain planning
projecs, he same rule applies, see
igure 5.The dierences beween hese wo
opposing approaches are ar-reaching.
The Funcional approach is closely
aligned wih an evaluaion period ha
oen coincides wih schedule updaes
by he conracor. Since mos
consrucion schedules are updaed or
inended o be updaed monhly, he
approach holds ha i he wo delays
occur in he same period and oher
seven crieria ideniied above are me,
here is concurrency. This approach
relecs he realiy o he monhly
updae, as well as he inheren
unreliabiliy in aemping o measure
evens oo precisely. Despie bes
eors, records rom he ield are oen
incomplee and do no measure evens
or progress wih daily accuracy. In mos
cases, he Funcional approach will
generae more days o concurren delay
because he ime period (generally a
monh) is relaively large. Under he
Funcional approach a delay in he irs
wo weeks o a monhly measuremen
period is concurren wih a wo week
delay a he end o ha same period,
assuming he oher concurrency
crierion are me.
Bu he Funcional approach also
has is disadvanages. The locaion o
he sar and end o he measuremenperiod used in he analysis has a
signiican impac on he deerminaion
o concurrency. I he dividing line
beween measuremen periods alls
beween he wo delays, here is no
concurrency. Figure 6 shows he
implicaions o he placemen o he
measuremen period and he alleged
delays. In Scenario 1, he wo delays all
in he same measuremen period,
resuling in concurren delays. In
Scenario 2, he delays, oherwise
idenical o he previous one, all in
dieren measuremen periods wih he
resul o hem no being concurren.
Oseing concurren delays, as we will
reurn o in a ew paragraphs, always
occur wihin he same measuremen
period, bu a measuremen period o
ha can be as long as he enire projec.
The Lieral approach also has
advanages and disadvanages. I
assumes ha boh planned and acual
aciviy measuremen is accurae o
wihin one day. As previously
menioned, his is oen no he case.
Ye, ypical CPM schedules are
developed, moniored, and updaed
wih a planned accuracy o a day, so i is
no unreasonable o measure o ha
accuracy.
Furher, in order o esablish hebasic seven elemens o concurrency, he
analys usually invesigaes he evens
surrounding he alleged delays in deail,
on a day-o-day basis, so as o esablish
he irs hree crieria. Once his
evaluaion has been made, i seems
absurd o hen disregard his deail in
characerizing non-simulaneous delays
as concurren.
20 COST ENGINEERING JANUARY 2012
Figure 6 Comparison o Two Delays and Two Dieren Measuremen Periods
7/28/2019 ce12-01
23/64
FSAPG 29R-03 akes no posiion on
wheher he Funcional or Lieral
approach is preerred. As discussed
below, he Funcional approach appears
o be more widely acceped in cour
decisions, bu a leas one exper reaise
published subsequen o he FSAPG 29R-
03 seems o suppor he Lieral approach
[23].
Concurren Delay is a Legal TheoryThere are wo conlicing viewpoins
in cour decisions regarding he ime
relaionship beween wo delay evens
[5]. The irs viewpoin adops a global
view o concurrency, one ha is
consisen wih oseing concurren
delays. These decisions ind sequenial
delays along he criical pah, even hose
ha are widely separaed in ime, are
concurren [7]. These delays ha occur
along dieren co-criical pahs in asequenial manner are concurren
because each would have delayed
compleion absen he oher. The
raional or his inding is ha he eec
o eiher individual delay is he same as
he combined eec o boh delays as
shown in igure 1.
A more complicaed siuaion
however occurs when he wo
sequenial delays occur along he same
criical pah. For example, assume he
owner delays Building A commencemen
by one monh. Laer, he conracor
delays work on Building A or a monh.
Since boh delays are on he same criical
pah hey migh be considered
concurren under a global view o
concurrency. However, he overall delay
o building A is now wo monhs, wih
each pary responsible or one monh.
This appears o be a sequenial non-
concurren delay. I is unclear rom any
repored cases wheher his would be
considered concurren, see igure 7.
These cases inding sequenial
concurren delay seem o generally be
older cases (some daing o he 1930s)
where he acual presenaions were
insuicien o allow apporionmen o
he delays beween he paries [14].
They do no disinguish beween co-
criical and single criical pahs. Onehopes ha wih modern CPM analysis
beer prepared cases resul in hese
oseing delay decisions no longer
being valid.
The second viewpoin in repored
cases discouns he global view o
concurrency, hus prevening indings o
concurren oseing delays [5]. Ye,
hese cases do no disinguish beween
lieral and uncional concurrency, eiher
implicily or explicily. In hese cases, he
cours rely on he ollowing wo
overlapping approaches o reach heir
decisions.
In he irs approach, hey
apporion delay responsibiliy
based on he acs and delay
analysis presened [20]. Such
an allocaion, i suicien,
permis a day-by-day allocaion
o responsibiliy. The cours
have ound ha since he
conracor is generally
aemping o prove he delay, i
mus generally prove
apporionmen beween he
owner and conracor, and
ailure o esablish
apporionmen will resul in a
inding agains he conracor
[24].
The second and more
successul approach is o sricly
consrue he criical pah. Such
a perspecive, given suicien
deail, will lead o he lieral
approach o concurrency.
Recall ha under he lieral
approach, he criical pah delay
ha sars irs creaes loa in
COST ENGINEERING JANUARY 2012
Figure 7 Oseing Concurren Delays Along a Single Criical Pah
7/28/2019 ce12-01
24/64
he remainder o he schedule.
In Sana Fe, Inc. [21], he board
saed: [I] he [governmens]
concurren delays aeced only
work ha was no on he criical
pah hey are no delays
wihin he meaning o he
[concurrency] rule This
sric approach has been
ollowed in oher cases, bu
only when here is suicien
evidence o suppor such an
analysis [17].
Are Oseing Delays Concurren
Delays?So now we know ha owners can
argue ha ime-separaed delays can be
concurrenly oseing delays because
according o some judicial decisions,
sequenial delays along he criical pah
can be considered concurren [11].Owners generally posi his siuaion in
negoiaions because owners oen have
poor schedule conrol policies, or worse
have airmaive policies ha leaves
deerminaions o delay quaniicaion
and enilemen unil he end o he
projec.
Recall in our iniial discussion, he
owner aemped o ose a delay in sie
access wih a subsequen conracor
delay. This aemp oen occurs
because he owner ails o resolve delays
as hey occur. The mos commonreasons are:
1. The owner, hrough poor
managemen pracices, simply
ails o ac on a conracors
delay reques. Such ailures
generally resul in