Projects (Engineering & Construction) Practice
Hong Kong Institute of Surveyors
"EOT and Liquidated Damages"
18 February 2014
Damon So, Partner
Extension of Time
www.hoganlovells.com
Time Obligations
1. No express agreement – reasonable time
2. Date agreed
a. Duty to complete by a certain date
b. Breach: damages/liquidated
damages
www.hoganlovells.com
The Prevention Principle
Set “at large”Reasonable
Time
Commencement Date
Employer’s delay
Contractual Completion Date
Liquidated Damages
Damages
www.hoganlovells.com
Extension of Time
WHY?
FOR CONTRACTOR?
It:
- avoids the “prevention principle”
- ensures certainty of date
- preserves LD's
FOR EMPLOYER
www.hoganlovells.com
HKIA Form (1986 Edition)
Clause 23
“... if in the opinion of the Architect the completion of the Works is likely to be or has been delayed beyond the Date for Completion … or beyond any extended time previously fixed …,
a.by force majeure, or
b.by reason of inclement weather …, or
c.by reason of civil commotion, local combination of workmen, strike or lockout …, or
d.by reason of Architect’s instructions issued …, or
e.by reason of the Main Contractor not having received in due time necessary instructions, drawings, details or levels from the Architect …, or
www.hoganlovells.com
HKIA Form (1986 Edition) (Cont'd)
f. by delay on the part of artists, tradesmen or others engaged by the Employer in executing work not forming
part of this Contract, or
...
then the Architect shall so soon as he is able to estimate the length of the delay beyond the date or time aforesaid make in writing a fair and reasonable extension of time for completion of the Works. …
www.hoganlovells.com
Relevant Events
a. Employer’s delays
e.g. variations, delay by their agents, delay in providing
instructions, drawings, details or level
b. Neutral events
e.g. force majeure, inclement weather, strikes,
c. What is not covered?
www.hoganlovells.com
Question
What if a delay by Employer is not covered by the provision?
www.hoganlovells.com
Notice Provisions
a. Two-stage notices
- notice of delay
- submission of particulars
b. Failure to submit notices
- damages
- loss of right to claim EOT
c. Condition Precedent
www.hoganlovells.com
Position in Australia
Gaymark Investments Pty Ltd v Walter Construction Group
Ltd, (1999) NTSC 143
Arbitration:
Claim by Walter:- variations- prolongation, disruption and accelerations costs
Counterclaim by Gaymark:- late completion- liquidated damages
www.hoganlovells.com
Time Provisions
Original Clause 35.4
- Superintendent has general power to extend time despite Contractor’s failure to comply with notice.
Clause 35.4 replaced by SC 19.1
- initial notice of 14 days after every cause of delay- second notice with particulars within 21 days of first notice
SC19.2
- Contractor shall only be entitled to an extension of time if SC19.1 is strictly complied with.
www.hoganlovells.com
Claim for liquidated damages
The Arbitrator found
- Gaymark caused 77 days delay to Walter
- “acts of prevention”
- Walter failed to comply with notice provisions
- no general power to grant EOT
- time set “at large”
- complete within a reasonable time
- no LD’s
www.hoganlovells.com
Arbitrator’s Reasoning
Three possible constructions:-
1. Implication of discretionary power similar to Clause 35.4
- care taken in amending the EOT provisions
- Superintendent considered his power being
exhausted once time bar was hit.
2. Too bad for the Contractor
- prolongation costs + liquidated damages
3. Risk taken by Employer
- EOT at Contractor's option
www.hoganlovells.com
Arbitrator’s Reasoning (Cont'd)
Extended Completion Date
Commencement Date
Original Completion Date
Delay by Gaymark
EOT claims
EOT Granted
Superintendent’s assessment
1. Discretionary power
2. Non-compliance
Reasonable time3. Optional
www.hoganlovells.com
Criticisms of Gaymark
IND Wallace QC (Hudson's):
1. Practical considerations ignored:
a. criticality better known to Contractor
b. Owner’s opportunity to reduce or avoid delay.
2. Judicial dislike of LD clauses no longer exists
3. Rejection of EOT based on failure to comply with notice rather than own wrong
4. First principle: contractual intention from language used
www.hoganlovells.com
Position in Hong Kong
Hsin Chong Construction (Asia) Limited v Henble Limited
[2006] HCCT
-rejected Gaymark
-cited submissions from Hudson's
www.hoganlovells.com
Position in Hong Kong (Con't)
W Hing Construction Co Ltd v Boost Investments Ltd
[2009] 2 HKLRD 501 (CFI)
-Did not follow Gaymark
-Contractor required to comply with contractual notice provisions for EOT; failure to comply meant no EOT
www.hoganlovells.com
Concurrent Delay
- Issue arises where there is more than one effective cause for delay
- E.g. where both employer and contractor, or contractor and sub-contractor cause or contribute to delaying events
- Should contractor/sub-contractor be entitled to full EOT caused by both events, or only to a pro-rated EOT for events not caused by contractor/sub-contractor?
www.hoganlovells.com
Position in Hong Kong
W Hing Construction Co Ltd v Boost Investments Ltd
[2009] 2 HKLRD 501(CFI)
-Considered Scottish case of City Inn Ltd v Shepherd Ltd [2008] BLR 269: apportionment of responsibility for delays caused by different parties
-No apportionment of EOT because contractor did not comply with contractual notice requirements for EOT
-Whether apportionment approach to be adopted in HK is open question
www.hoganlovells.com
Position in England
De Beers Ltd v Atos Origin IT Services [2011] BLR 274
-Where employer and contractor both responsible for concurrent delay, contractor entitled to EOT but cannot recover in respect of loss caused by delay
-Contractor would suffer the same loss due to causes within his control or for which he is contractually responsible
www.hoganlovells.com
Position in England (Con't)
Walter Lilly & Co v Mackay & DMW Developments
[2012] EWHC 1773
-Contractor is entitled to full EOT for delay caused by two or more events (if one of them is a relevant event in contract)
-Applied Malmaison approach
Liquidated Damages
www.hoganlovells.com
Meaning
- agreed sums payable upon breach
- genuine pre-estimate of loss
- cf “unliquidated damages” or general damages
- fixed remedy for contractor’s delay
e.g. $10,000 per day of delay after PC
www.hoganlovells.com
Effect
- exhaustive remedy on delay
- payable even where no actual loss is suffered
- liability capped at agreed damages
- if “nil” inserted as the rate of LD’s?
no LD’s recoverable for delay
Temloc v Errill Properties Ltd. (CA)
www.hoganlovells.com
Advantages
a. Certainty
b. Avoids expensive and difficult investigation
e.g. public works project
c. Causation/remoteness/foreseeability
d. Pre-agreed level of damages
www.hoganlovells.com
Defences
1. Time at large
2. Penalty
Defences successful
- revert to general damages
- may be capped at LD
www.hoganlovells.com
Penalty
Two conflicting policies
General rule:
- contract to be enforced
Exception:
- damages compensatory
- unjustifiable amount for breach
- not enforced by the Court
- onus on the party being sued upon it
www.hoganlovells.com
What is Penalty?
Dunlop Pneumatic Tyre Co Ltd v New Garage & Motor Co Ltd
[1915]
1. “penalty” or “liquidated damages”.
2. "in terrorem" of the offending party.
3. genuine pre-estimate of damage.
4. circumstances
5. Tests: breach of non-payment, greatest loss, single sum payable for different events, sectional completion
www.hoganlovells.com
Difficulty in estimating?
Philips Hong Kong Ltd v The AG of HK [1993] PC
a. virtuably impossible to calculate precisely in advance.
b. sensible approach by Government
c. Not enough to identify hypothetical situations
d. Is it a genuine pre-estimate?
e. What actually happens subsequently provides valuable evidence
www.hoganlovells.com
Genuine Pre-estimate
Alfred McAlpine Capital Projects v Tilebox [2005] EWHC 281
- not "genuiness or honesty" of party estimating
- objective test at the time of contracting
- substantial discrepancy between LD's and likely loss
- tendency to uphold commercial contractual terms
- echoed in Steria v Sigma Wireless Communications [2008] BLR 79
www.hoganlovells.com
Cascading Argument
Liberty Mercian v Dean & Dyball Construction [2008] (TCC)
- construction of 4 retail units, 5 sections
- LD's for each section
- possession of later section on completion of preceding section
- 4 weeks delay for the first section
- 20 weeks of LD's imposed
Court: nothing unfair
www.hoganlovells.com
City Inn Limited v Shepherd Construction Ltd.(2003) Inner House, Court of Session
Notice Provisions:-
a. Whenever Contractor received an instruction to carry out works which would require an adjustment to the contract sum or EOT, before executing the works, the Contractor should give notice with particulars to the Architect
b. Condition precedent to Contractor’s right to EOT
Shepherd failed to comply with those provisions
www.hoganlovells.com
Shepherd's Arguments
No Gaymark argument
Penalty argument :-
- procedural default
- no relation to LD’s imposed
- not a genuine pre-estimate of loss suffered as a result of breach
www.hoganlovells.com
The Court
a. LD’s imposed a a result of delay in completion
b. EOT provision only gave them a right to relief
c. Right lost because of failure to comply with notice provisions
d. LD’s not penalty
www.hoganlovells.com
Court's reasoning
DelayEOT Claims
Failed to comply with notice provisions
EOT entitlement
No EOT
The Court’s finding
LD’s
Shepherd’s argument
www.hoganlovells.com
Defeating Penalty
1. Incentive vs Penalty
2. Optional Completion Obligations
3. Lane and site rental
The End
www.hoganlovells.com
Hogan Lovells has offices in:
Abu DhabiAlicanteAmsterdamBaltimoreBeijingBerlinBrusselsBudapest*Caracas
Colorado SpringsDenverDubaiDusseldorfFrankfurtHamburgHanoiHo Chi Minh CityHong Kong
HoustonJeddah*LondonLos AngelesMadridMiamiMilanMoscowMunich
New YorkNorthern VirginiaParisPhiladelphiaPragueRiyadh*RomeSan FranciscoShanghai
Silicon ValleySingaporeTokyoUlaanbaatar*WarsawWashington DCZagreb*
"Hogan Lovells" or the "firm" refers to the international legal practice comprising Hogan Lovells International LLP, Hogan Lovells US LLP, Hogan Lovells Worldwide Group (a Swiss Verein), and their affiliated businesses, each of which is a separate legal entity. Hogan Lovells International LLP is a limited liability partnership registered in England and Wales with registered number OC323639. Registered office and principal place of business: Atlantic House, Holborn Viaduct, London EC1A 2FG. Hogan Lovells US LLP is a limited liability partnership registered in the District of Columbia.
The word "partner" is used to refer to a member of Hogan Lovells International LLP or a partner of Hogan Lovells US LLP, or an employee or consultant with equivalent standing and qualifications, and to a partner, member, employee or consultant in any of their affiliated businesses who has equivalent standing. Rankings and quotes from legal directories and other sources may refer to the former firms of Hogan & Hartson LLP and Lovells LLP. Where case studies are included, results achieved do not guarantee similar outcomes for other clients. New York State Notice: Attorney Advertising.
© Hogan Lovells 2011. All rights reserved.
* Associated offices
Damon SoPartnerDirect line: 2840 5018E-mail: [email protected]