Date post: | 16-Dec-2014 |
Category: |
Real Estate |
Upload: | sandip-garg |
View: | 2,978 times |
Download: | 2 times |
MEMORANDUM OF UNDERSTANDING
THIS MEMORANDUM OF UNDERSTANDING is made at Mumbai and
entered into this 31st day of December, 2007 between M/S. SHAH
CONSTRUCTION COMPANY, a partnership firm registered under the Indian
Partnership Act, 1932 having their office at 43, Deccan Court, S.V. Road, Bandra
(W), Mumbai - 400 050 hereinafter referred to as the 'DEVELOPERS' (which
expression shall unless repugnant to the context or meaning thereof mean and
include the partners for the time being constituting the said firm of M/s. Shah
Construction Company, their survivors or survivor and the heirs, executors and
administrators of such last survivor) of the One Part and THE IRS (MUMBAI) CO-
OPERATIVE HOUSING SOCIETY LTD. (PROPOSED) having its office at Aykar
Bhavan, Mumbai through its CHIEF PROMOTER SHRI V.S.SINGH and
PROMOTERS SHRI D.S.Benupani and SHRI JAYARAM RAIPURA (authorized in
this behalf by the members of the society in the General Body Meeting held on
26.11.2007) hereinafter referred to as the ‘SOCIETY’ (which expression shall unless
repugnant to the context or meaning thereof the members for the time being of the
1
said Society, its Chief Promoters and Promoters and their successors) of the Other
Part.
W H E R E A S :
(a) The City Industrial Development Corporation (hereinafter referred to as the
CIDCO) is the owner of interalia (i) Plot Nos.4, 5, 6 and 7 in all admeasuring
15,519 sq.mtrs. at Sector-22, Ulwa, Taluka – Panvel, District – Raigad, Navi
Mumbai and delinated on the plan thereof hereto annexed and marked
Annexure: A and thereon shown surrounded by red colour boundary line
and more particularly described in the First Schedule hereunder written and
hereinafter referred to as the ‘said Property’.
(b) The CIDCO has offered to grant the lease of the said Property under G.E.S.
12.5% scheme to the project affected persons (hereinafter referred to as the
Lessees of the said Property) whose land had been acquired by the CIDCO
earlier.
(c) The Developer have agreed to acquire said Property from the assignee of
original allottee for the consideration and upon the terms and conditions
recorded in the Memorandum of Understanding executed between the
Developer and the assignee of allottee.
(d) The Society is desirous of acquiring 150 residential premises in the vicinity of
Navi Mumbai for its members. Having came to know about the same the
Developers by their letter dated 12th October, 2007 gave their offer to the
Society to provide 150 flats as provided therein.
(e) Thereafter few meetings have been held between the Chief Promoter and
Promoters of the Society and Shri Kantilal Manilal Savla, the partner of the
Developers in connection with the proposal of providing 150 flats and after
discussion the parties hereto have agreed upon the main terms and
conditions for providing 150 flats to the members of the Society in the
buildings proposed to be constructed by the Developers on the said Property
and ultimately getting the lease of the land and the conveyance of the
building in favour of the Society which will be constituted after completion of
the project which are now reduced in writing as hereinafter appearing
(f) For the sake of brevity the said Property with the buildings to be constructed
thereon by the Developers are hereinafter referred to as the ‘said Project’.
2
NOW THIS MEMORANDUM OF UNDERSTANDING WITNESSETH AND IT
IS HEREBY AGREED BY AND BETWEEN THE PARTIES AS UNDER:-
1. ESSENCE OF THE MOU : The essence of this MOU is the desire of the
existing and former members of the Indian Revenue Service (IRS), either singly or
jointly with any other person, to acquire residential premises on ownership basis on
leasehold property and the offer of the Developers to acquire an appropriate land
i.e. the said Property with a clear legal title and construct the buildings thereon in
accordance with laws, byelaws and rules of the civic and other authorities
concerned. The Developers confirm that the property more particularly described in
First Schedule of this MOU is a leasehold property and being owned by CIDCO it is
free from all encumbrances non-agriculture land and is capable of development of
multi storeyed residential apartment blocks on the basis of floor space index of not
less than 1.5 subject to requisite approval from CIDCO/Municipal authorities or
Agencies. The Developers also confirm that the property more particularly
described in First Schedule is a part of Ulwe residential node being developed by
CIDCO with required infrastructure like water supply, roads, electricity, sewage and
drainage. The Developers also declare that as on date, the Floor Space Index
available in respect of the said Property proposed to be acquired for the project is
1.5 times of plot area + 10% balcony area only which shall be utilized fully and
efficiently and no part of the said floor space index has been utilized by the
developer elsewhere for any purpose whatsoever. The residual floor space index out
of the above Space Index of the said Property not consumed in the construction of
the buildings for the members shall be available to the Developers for disposal in
the open market.
2. PROPERTY: The Developers have agreed to provide to the Society and the
Society has agreed to acquire from the Developers for the allotment to its members
150 flats of different area as provided herein in the buildings proposed to be
constructed by the Developers on the said Property for the consideration to be
calculated at the rate of Rs.2500/- per sq.ft. of built up area as provided
hereinafter.
3. TYPE OF BUILDINGS AND AREA OF RESIDENTIAL PREMISES (FLATS) :
The Developers propose to construct the said Project of integrated Township
comprising of residential buildings consisting of Ground + 10 Upper Floors with Club
house, Recreation Ground and separate Commercial building with entertainment
center on the said Property. After receipt of the full consideration from the Society /
members of the Society the Developers will handover physical possession of the
respective flat to the member concerned and transfer all their rights and interest in
3
the residential buildings alongwith land underneath in favour of the Society. The
Developers will be entitled to retain, sale, transfer, assign or sublet the commercial
and residential premises if any available after the allotment of Flat to the members
of the Society to any party at their discretion at such consideration as they may
deem fit and proper. As discussed between the parties hereto the Developers
propose to construct Residential Premises of following area.
Type Carpet Area Built-up area
(with 33%)
2 ½ BHK Flat 840-860 sq.ft. 1117-1144 sq.ft.
3 BHK Flat 960-975 sq.ft. 1277-1297 sq.ft.
However there may be some variation in the area of the flats based on the final
plans.
4. METHOD OF CARPET AREA CALCULATION : The carpet area will be
Calculated in the following manner:
100% Carpet Measurement i.e. wall to wall including Balcony area if provided separately or enclosed balcony proposed in the plan.
50% Nitch below the windowsill and Dry Balcony which is free of FSI will be added in the Carpet Area of Flat while arriving at total carpet area of residential premises.
Note: Nitch and Dry Balcony chargeable area will not exceed 50 sq.ft. Per flat.
5. METHOD OF BUILT-UP AREA CALCULATION: The built-up area means the
labour charges paid by the Developers to their contractors for constructing building
which is outside measurement of the building and the constructed amenities such
as Club house, Health Club etc. and accessories structure like Sub-Station and
watchmen cabin, Lift Machine Room, Pump Room, Society Office etc. The
approximate carpet to built-up area ratio varies from 30% to 33% depending on
ultimate planning.
6. PRICE OF RESIDENTIAL PREMISES : The Developers have agreed to
provide to the members of the Society the residential premises (flats) at the price to
be calculated at the rate of Rs.2500/- per sq.ft. On the basis of presently planned
area of the flats as mentioned in Clause No. 2 hereinabove the tentative price of the
flats works out as under:
Type Built-up area Tentative price(with 33%)
2 ½ BHK Flat1117-1144 sq.ft. Rs.27,92,500/- to Rs.28,60,000/-
3 BHK Flat1277-1297 sq.ft. Rs.31,92,500/- to Rs.32,42,500/-
4
7. ADDITIONAL RESIDENTIAL PREMISES : The Society expect to get more
enrollment for the allotment of residential premises from their existing members
which will be made known to the Developer before starting of construction work on
site. The Develop undertake to provide additional 25% Tenements over and above
of 150 Residential Premises already enrolled by the member of the Society at same
price and on same terms and conditions till Developer initiate construction work on
site.
8. TERMS OF PAYMENT FOR THE CONSIDERATION AMOUNT : The
Tentative consideration amount for 3 BHK flat will be Rs.32,17,500/- for area
admeasuring 1,287.00 sq.ft. built-up area (approx) and for 2 ½ BHK Flat will be
Rs.28,25,000/- for area admeasuring 1,130.00 sq.ft. built-up area (approx) which is
calculated @ Rs.2,500/- per sq.ft. built-up area. The Society shall advice its
members and the members shall pay the consideration amount in the following
manner :
Installment amount for 3 BHK Flat
Installment amount for 2 ½ BHK Flat
i) Rs.1,00,000/- Rs.1,00,000/- being the earnest money shall be
paid by society on behalf of the
members on developer entering
into MOU for the purchase of
land, furnishing of appropriate
security (in the form of
immovable property) to the
satisfaction of the Society and
execution hereof (the payment
and receipt whereof the
Developers do hereby admit and
acknowledge and acquit, release
and discharge the Society from
the same and every part thereof
for ever).
ii) Rs.5,45,000/- Rs.4,65,000/- Being 20% of the consideration
amount to be paid by the
Society/ Members after
deducting earnest money
amount paid under clause 8(i) to
the Developers against Tripartite
Agreement proposed to be
5
executed between the CIDCO,
the Lessees of the said Property
and the Developers herein
iii) Rs.3,22,000/- Rs.2,83,000/- being 10% upon execution of
Agreement for Sale with each
individual members of the
Society in respect of their flats to
be paid by the members of the
Society.
Installment amount for 3 BHK Flat
Installment amount for 2 ½ BHK Flat
iv) Rs.3,22,000/- Rs.2,83,000/- being 10% on casting of plinth to
be paid by the members of the
Society.
v) Rs.80,500/- Rs.71,000/- being 2.5% on casting of the First
slab to be paid by the members
of the Society.
vi) Rs.80,500/- Rs.71,000/- being 2.5% on casting of the
Second slab to be paid by the
members of the Society.
vii) Rs.80,500/- Rs.71,000/- being 2.5% on casting of the
Third slab to be paid by the
members of the Society.
viii) Rs.80,500/- Rs.71,000/- being 2.5% on casting of the
Fourth slab to be paid by the
members of the Society.
ix) Rs.80,500/- Rs.71,000/- being 2.5% on casting of the Fifth
slab to be paid by the members
of the Society.
x) Rs.80,500/- Rs.71,000/- being 2.5% on casting of the
Sixth slab to be paid by the
6
members of the Society.
xi) Rs.80,500/- Rs.71,000/- being 2.5% on casting of the
Seventh slab to be paid by the
members of the Society.
xii) Rs.80,500/- Rs.71,000/- being 2.5% on casting of the
Eighth slab to be paid by the
members of the Society.
Installment amount for 3 BHK Flat
Installment amount for 2 ½ BHK Flat
xiii) Rs.80,500/- Rs.71,000/- being 2.5% on casting of the
Ninth slab to be paid by the
members of the Society.
xiv) Rs.80,500/- Rs.71,000/- being 2.5% on casting of the
Tenth slab to be paid by the
members of the Society.
xv) Rs.80,500/- Rs.71,000/- being 2.5% on casting of the
Eleventh slab to be paid by the
members of the Society.
xvi) Rs.2,41,000/- Rs.2,11,000/- Being 7½% on completion of
external and internal brickwork
and plaster to be paid by the
members of the Society.
xvii) Rs.1,61,000/- Rs.1,41,000/- being 5% on completion of
internal & external
plumbing ,electrification and
flooring and tiling of the building
on the said property .
xviii
)
Rs.3,21,000/- Rs.2,82,000/- being 10% upon completion of
the construction of the buildings
7
in all respect on the said
property to be paid by the
members of the society.
xix) Rs.3,20,000/- Rs.2,79,000/- being the balance amount
against physical possession of
the premises to be paid by the
members of the Society.
The actual total consideration payable by the members of the Society to the
Developers shall be worked out by the parties hereto within 15 days from the date
of the sanction of building plans by the authorities concerned. It is clarified that the
installments of consideration payable under clause 8 (iii) to (xix) shall be paid by
the members of the Society individually to the Developers under their respective
agreements for purchase of flat to be executed between the Developers, the
Society and the members.
9. COLLATERAL SECURITY : The Developer has agreed to provide Flat
No.________ on_________ Floor and Flat No._________ on ________ Floor in Wing ____ of
building known as ‘PRANAY SUDARSHAN’ constructed on property bearing
C.T.S.No. 5349 to 5366 of village Ghatkopar-Kirol being situated at Joshi Lane,
Ghatkopar (East) which is being developed by the associate concern of the
Developer by way of security against the payment of Earnest Money amount of
Rs.1,50,00,000/- (Rupees One Crore and Fifty Lacs only) which is agreed to be paid
by the Society on behalf of the members to the Developer as mentioned in clause
8(i) hereinabove. It is specifically agreed that the society shall have a lien on the
above referred residential premises till the execution of Tripartite Agreement
proposed to be executed between allottees of plots, CIDCO & the Developer or till
Developer refund the Earnest Money Deposit Amount with or without interest as
mentioned hereinafter in the event parties hereto agreed to cancel this MOU
whichever is earlier. The Developer shall not create any third party right of
whatsoever nature on the above referred premises during the pendancy of lien in
favour of the Society.
10. PRICE ESCALATION : The Developer undertake to provide 150 Residential
premises and the additional 25% residential premises to the members of the society
at the agreed price without asking any escalation in the price under any pretext of
whatsoever nature.
11. AGREEMENT BETWEEN THE CIDCO, THE LESSEE OF THE SAID
PROPERTY AND THE DEVELOPERS: After execution of this MOU the Developers
8
shall proceed with the work of execution of the Agreement to Lease between the
CIDCO and the Lessees of the said Property as well as Tripartitie Agreement
between the CIDCO, the Lessees of the said Property and the Developers. The
Developers hereby agrees to ensure the execution of Tripartitie Agreement between
the CIDCO, the Lessees of the said Property and the Developers at the time of
receipt of payment under clause 6 (ii) hereinabove. The entire consideration for
acquiring the development rights in respect of the said Property shall be borne by
the Developers.
12. AGREEMENT WITH THE MEMBERS AND LEASE DEED AND
CONVEYANCE IN FAVOUR OF SOCIETY: The Developers shall get prepared from
their Advocates and Solicitors the draft of the agreements for sale of the flats to be
executed between the Developers and the members of the Society. The Developers
shall furnish to the Society the draft of such agreement sufficiently in advance and
in the event there are any suggestions by the Society the same shall be discussed
in the joint meeting to be held between the office bearers of the Society, the
Advocates for the Society, the partners of the Developers and their Advocates and
Solicitors. The Society shall ensure that within 30 days from the date of sanction of
the building plans each of its members shall execute agreement for sale in respect
of the flat allotted to them after paying requisite Stamp Duty & lodge the same for
registration with concerned Sub – Registrar of Assurances within the prescribed
time. However the Developer undertakes to admit the documents with the
concerned Sub-Registrar of Assurances as and when requested by the members.
13. OTHER COSTS NOT INCLUDED IN THE PREMISES PRICE: It is specifically
agreed that in addition to the price of the each flat to be paid by the members of
the Society at the rate of Rs.2500/- per sq.ft. of built up area, the member of the
Society shall be liable to pay the following amounts over and above of the
consideration amount to the Developers as is mentioned herein below:
For3 BHK Flat
For2 ½ BHK
Flat
(i) Rs.5,000/- Rs.5,000/- Legal charges for Agreement for Sale of flats and lease of land and conveyance of buildings in favour of the Society.
(ii) Rs.350/- Rs.350/- Share money payable by each member which includes entrance fee.
(iii) Rs.4,000/- Rs.4,000/- Society formation charges.
(iv) Rs.46,332/- Rs.40,680/- 12 months Maintenance Deposit at the rate of Rs.3/- per sq.ft. of carpet area (if the Developers do post possession maintenance).
(v) Rs.64,350/- Rs.56,500/- Corpus fund @ Rs.50/- per sq.ft. carpet area for working capital of the Society.
9
----------------- ----------------Rs.1,20,032/
-========
====
Rs.1,06,530/-
============
In addition to the above amounts each member will have to pay the Stamp Duty
and Registration Charges in respect of the Agreement for Sale of flat agreed to be
purchased by him.
14. TITLE: After execution of the Tripartite Agreement between the CIDCO, the
Lessees of the said Property and the Developers as provided hereinabove the
Developers shall make out a marketable title to the said Property and the necessary
Title Certificate issued by the Advocates and Solicitors for the Developers shall be
annexed to the Agreement for Sale of flats to be executed between the Developers,
the Society and the members of the Society.
15. DEVELOPMENT AND CONSTRUCTION AT THE COST OF DEVELOPERS:
The Developers shall appoint their own Architects, R.C.C. consultants and other
professional agents for the development of the said Property and construction of
buildings thereon. Within 15 days from the date of execution of Tripartite
Agreement between the CIDCO, the Lessee of the said Property and the Developers
as above, the Developers shall get prepared from their architects the proposed
Layout plan and proposed building plans and submit the same to the Society for its
approval. The Society specifically agrees and undertakes to approve such plans
within 15 days from date of receipt of such plans and the Developers, at their own
cost, shall get prepared revised layout and building plans, incorporating the
suggestions, if any, of the society. The Developers at their own costs, charges and
expenses shall get the building plans sanctioned and obtain all the necessary
permissions, approvals, exemptions and sanctions from CIDCO/Municipal
Corporation for development of the said Property and for the construction of
buildings thereon. The entire development of the said Project in pursuance of this
MOU and in accordance with the sanctioned and amended sanctioned plans that
may be approved by the authorities concerned shall be carried out by the
Developers at their own cost, charges and expenses. The Developers shall take
steps and obtain the requisite sanctions of the layout plans and building plans as
approved by the society from the local, municipal and any other authority
concerned within a period of 12 months from the date of this MOU or within such
extended time, as may be agreed to by the society. The Developers shall
commence the construction within 3 months from the date of sanction of the
building plans by the authority concerned. The Developers shall complete the
development of the said Property and construction of buildings thereon within 24
months from the date of execution of Tripartite Agreement as mentioned
10
hereinabove. The completion of the development of the said property shall be
deemed to include all measures to integrate the water supply, electrical, sewage
system & other infrastructure, if any, of the proposed buildings with the sewage,
water supply and electrical infrastructure provided in the area by the authority
concerned. The Developers shall strictly comply with the terms and conditions of
the sanctioned plans and various permissions, approvals and orders as applicable.
The Developers alone shall be liable to bear and pay the professional fees, cost,
charges and expenses of Architects, R.C.C. consultants and other professional
agents appointed by them. The Society if so desire may appoint its own Architects,
R.C.C. consultants and other professional agents provided however the professional
fees, cost, charges and expenses of such professional shall be borne and paid by
the Society alone. Suggestions, if any, made by the society shall be considered by
the developer and to the extent practicable will be incorporated or implemented.
However the Developers shall not be responsible for any delay on the part of the
authorities concerned in providing any infrastructural facilities such as water, road,
electricity, sewage etc. IF required the Developers will construct the necessary soak
pit and septic tanks for sewage disposal and subject to the availability of the water
the Developers will provide water for flushing through borewell.
16. PARKING: The Developers propose to provide one parking for each
residential premise constructed in the said Project. The open to sky parking on
ground level or at podium level if proposed will be allotted by the Developers to the
Society at free of cost. It is specifically agreed by and between the parties hereto
that the covered or stilt parking at ground or podium level in the said Project will be
allotted by the Developers at the rate of Rs.2,00,000/- per parking to the members
of the Society.
17. AMENITIES TO BE PROVIDED TO THE FLATS: It is hereby specifically
agreed by and between the parties hereto that the Developers shall complete the
construction of the buildings on the said Property in accordance with the
plans/amended plans that may be sanctioned by the authorities concerned and the
Developers shall provide the amenities as specified in Second Schedule hereunder
written.
18. PROJECT DURATION: The Developers propose to complete the construction
of buildings on the said Property within 24 months from the date of obtaining
physical possession of the said Property from the CIDCO. However in the event of
circumstances beyond the control of the Developers, the Developers shall be
entitled to the reasonable extension of time for completion of construction of
buildings.
11
19. TIMELY PAYMENT: The Society hereby specifically agrees and undertakes
to see that each of its members acquiring the flat in the said Project makes
payment of the installments of consideration and other amounts payable by them to
the Developers in respect of their respective flats so that the Developers can carry
on the development of the said Property and construction of buildings thereon
smoothly and in timely manner. The Society and its members are fully aware that
the timely payment of the amounts payable under this MOU to the Developers shall
be the essence of the contract. In the event of any delay in payment of the amounts
due and payable to the Developers the member concerned shall be liable to pay the
interest to the Developers at the rate of 18 % per annum for the period of delay.
20. COMPENSATION FOR DELAY: In the event Developer is unable to provide
physical possession of the premises within prescribed time frame subject to force
measure condition in such case the Developer have agreed to pay 18% interest
compounded annually on the amount paid by the members of the Society for such
delayed period.
21. FULL CO-OPERATION : The parties hereto shall fully co-operate with each
other in development of the said Project in pursuance of this MOU and each of the
parties hereto shall sign and execute such further and other agreements, letters,
papers, plans and documents, etc as may be reasonably required by the other
party.
22. DEVELOPERS ENTITLED TO FULLY DEVELOP THE SAID PROPERTY: It is
specifically agreed by and between the parties hereto that the developers shall be
entitled to fully develop said Property by consuming and utilising the entire
available F.S.I. in respect of the said Property and will convey the land representing
undivided share of members to the society and if any additional F.S.I.over and
above 1.5 times of plot area + 10% Balcony area permitted under the law becomes
available in respect of the said Property by virtue of any change or amendment in
any law, bye-laws or building regulations then in that event the Society and the
Developers alone shall be entitled to consume and utilise such additional F.S.I. on
the said Property in the proportion of the total area of flats occupied by the
members enrolled by the Society and the total area of flats occupied by the persons
to whom the flats are sold by the Developers. It is also agreed by the society that
the Developer shall have first right of refusal for utilization of such additional F.S.I.
on the same plot for construction of additional area for which Developer will
compensate the amount equivalent to the prevailing market rate of FSI to the
Society or its members as the case may be.
12
23. PAYMENT OF TAXES: All the property taxes, outgoings, dues etc. in respect
of the said Property till the date of completion of construction and handingover
possession of the buildings and flats respectively shall be borne and paid by the
Developers alone and the same for the period thereafter shall be borne and paid by
the Society and its members alone.
24. POSSESSION OF FLATS : Upon the flats and the buildings being ready for
occupation the Developers shall intimate the Society and the members concerned
in writing to take possession of the flats and the Society shall ensure that the
members concerned takes possession of his respective flat within 30 days from the
date of receipt of intimation from the Developers failing which the member
concerned shall be liable to bear and pay all the taxes, charges, outgoings, etc in
respect of his flat as well as his prorata share of taxes, charges, outgoings, etc in
respect of the building after expiry of period of 30 days from the date of receipt of
intimation from the Developers.
25. REGISTRATION OF SOCIETY: The Society hereby agrees and undertakes to
cause all its members to sign and execute all the necessary applications, forms,
papers and documents for registration of the Society and get itself duly registered
under the Maharashtra Co-operative Societies Act. The Developers shall fully co-
operate with the Society and its members in getting the Society registered.
26. CONVEYANCE OF PROPERTY IN FAVOUR OF SOCIETY : The
Developer undertakes to convey lease hold right alongwith building constructed
thereon in favour of the society within 6 months from the date of completion of the
entire construction work on site or from the date of issue of occupation certificate
by the Planning Authority whichever is later and in the event developer differ to
convey the building and the leasehold right in favour of the society within
prescribed time frame in such case, upon the expiry of 6 months as mentioned
hereinabove it will be deemed to have been conveyed the leasehold right alongwith
building thereon in favour of the society by the developers.
27. OFFER OF FLATS AT RS.2,500/- per Sq. ft. ONLY DUE TO GROUP
BOOKING :
In view of the group booking by the Society the Developers are committed to
provide to the Society the flats at the confessional rate of Rs.2,500/- per sq. ft. and
upon the terms and conditions provided herein only to those members who have
enrolled their name on or before the execution of this M.O.U. and thereafter the
Developers shall be entitled to sell the additional Flats and commercial premises in
open market as such terms & Conditions as the Developer may deem fit & proper.
However the Society & its members shall have first right of refusal for such
13
Residential Premises and commercial premises for the first 30 days from the date
of such offer by the Developer and in the event of the Society’s fails to buy such
flats and commercial premises within that period the Developers shall be entitled to
sell such flats and commercial premises to such persons as they may deem fit and
proper without any further reference and upon receipt of the intimation from the
Developers the Society shall admit such purchasers as its members by charging
only Rs.350/- as share money and entrance fees.
28. ALTERNATE LOCATION:
In the event due to any reason whatsoever if the Developers are unable to acquire
the said Property, the Developers shall be entitled to offer alternate site at one
place in the Sector No.19, 20, 21 and 24 of Ulwa node for construction of buildings
to provide the flats for the members of the Society.
29. CONSTRUCTION OF THE SAID PROJECT AT PAR WITH PRANAY VIDYA
The Chief Promoter, the Promoters and the Members of the Society have visited the
Pranay Vidya project at Kandivali completed by the Developers. It is specifically
agreed by the Developers that they shall complete the construction of the said
project with the same workmanship, planning, elevation and use same quality
material in line with their building known as Pranay Vidya situated at Sai Baba
Nagar, behind Raghu Leela Shopping Complex Kandivali (West).
30. TIME PERIOD FOR EXECUTION OF DOCUMENTS:
The Developers have already informed the Society that CIDCO may execute
Agreement to Lease in favor of the allotee within 3 months time from the date of
this MOU. The Developers shall get executed Tripartite Agreement between the
CIDCO the said Lesses and the Developers within 6 months from the date of this
MOU and the Developers shall be entitled to extension of further period of 3 months
for this purpose. However in the event inspite of their best efforts if the Developers
are unable to acquire the said Property or any other Property at an alternate
location as provided hereinabove within 12 months from the date hereof then in
that event the Society at their option shall be entitled to cancel this M.O.U. and ask
for the refund of Earnest money Paid under this M.O.U. with 18% interest from the
date of receipt of the payment by the Developer.
31. STAMP DUTY AND REGISTRATION CHARGES: As proper stamp duty will
be paid on the individual agreement for sale of the flats to be executed between the
Developers, the Society and the members of the Society as well as on the Deed of
Lease of the said Property and conveyance of the building constructed on the said
Property as provided hereinabove this MOU has been prepared on Rs.100/- stamp
paper. The stamp duty and registration charges in respect of the Tripartitie
14
Agreement to be executed by and between the CIDCO, the Lessees of the said
Property and the Developers shall be borne and paid by the Developers alone.
32. REFUND TO MEMBERS : The Developer undertakes that in the event that
the Developers are unable to make out a marketable title of the said property
and/or get the Tripartitie Agreement with CIDCO executed and/or get the requisite
approval from the authorities concerned of the layout and building plans within 12
months from the date of the MOU or any further extended period as may be
mutually agreed, any sum paid by the member of the society or by the society, on
behalf of its members, shall be, at the option of the individual member be refunded
to them with 18% interest accruing with effect from the date of the payment of the
amount to the Developer till the date of receipt of refund by the individual member.
However, refund for any withdrawal of membership not covered by this clause will
be a subject matter of negotiation and decision between the individual member and
the developer.
33. DISCLOSURES : The Developers have made and undertake to make full and
true disclosure in respect of title of the said Property proposed to be acquired for
the construction of residential premises for the members of the society and produce
title certificate with detail disclosure of their Advocate and Solicitor prior to
execution of Agreement for Sale in respect of the Residential Premises with each
individual members of the society. The Developers shall give inspection to the Chief
Promoter/Promoter of the Society of all the documents of title relating to the said
Property, permissions, orders and sanctions received from any authority relating to
the project and plans, designs etc. prepared by the Architects and, Structural
Engineer or any other Agency associated, in any manner with the project and also
such other documents as are specified under the Maharashtra Ownership Flats
(Regulation of Construction, Civil, Management and Transfer) Act,1963 and Rules
made thereunder. The Developer also undertakes to provide a status report of the
progress of construction and any other relevant issue in writing to the Chief
Promoter on the 1st January and 1st July of every year till the completion of
development and construction of the said property.
34. WITHDRAWAL : In the event that any member resigns from the society due
to the circumstances mentioned in Clause 27 or for any other reason, the Developer
shall first offer the flat allotted to such outgoing member to the Society to enroll
new member in respect of such flat at a specified price (which may or may not
include any premium or over and above the rates specified in Clause 3 above) for
any new member and if such right is not exercised by the Society within 30 days
from the receipt of the offer, the Developers will be at liberty to sell such flat to a
person of their choice and the Society shall admit such non-member as a member
15
of the Society on the payment of only Rs.250/- as share money and Rs.100/- as
entrance fees.
35. UNDERTAKING : The Developers shall prior to the handingover of the
possession of the residential premises to the individual members shall obtain all
requisite clearances including permission for occupation from the authorities
concerned. The Developers shall also certify that all infrastructural systems such as
lifts, electrical system, drainage system, sewage system, water supply system, etc.
have been adequately tested for proper functioning and have been fully integrated
with the civic infrastructure of the area provided by the CIDCO Authorities. Further if
within a period of 3 years from the date of handingover the flat to the individual
members, the flat purchaser brings to the notice of the Developers any defect in the
flat or the building in which the flats are the situated or the material used therein or
any unauthorized change in the construction of the said building in which the flats
are situated, then such defects or changes shall be rectified by the Developers at
their own cost and in case it is nor possible to rectify such defects or unauthorized
changes then the flat purchasers would be entitled to receive from the developer
reasonable compensation for such defect and change provided however the
Developers shall not be responsible for any defects arising due to negligence of the
member concerned or due to any changes in the flats or the buildings made by the
member/s and/or the Society.
36. RESOLUTION : In pursuance of a Resolution passed in the General Body
Meeting of Members of the Society held on 26th November 2007, the Executive
Committee has nominated SHRI V.S.SINGH as CHIEF PROMOTER and SHRI
D.S.BENUPANI and SHRI JAYARAM RAIPURA as PROMOTERS, and has
authorised Chief Promoter and Promoters to sign this MOU, letters and other
necessary papers and documents in respect of Residential Premises proposed to be
acquired for the members of society.
37. SPECIAL PURPOSE VEHICLE : The Developers reserve the right to execute
this contract in any of their associate or newly formed company wherein the
partners of M/s. Shah Construction Company have controlling interest either
through themselves or through their any of the family member. In the event
Developers choose to execute this contract in any of their associate company in
such case the amount of Earnest Money paid under this MOU will be considered as
deemed to have been paid to their associates company and this MOU also will be
considered as deemed to have been executed by their associate company.
38. ARBITRATION : Any disputes or differences and questions whatever which
may arise pursuant to or concerning this Memorandum of Understanding or any
16
meaning or interpretation hereof or the construction or application hereof or any
clause or things herein contained or other matter or things herein contained or
other matter or things in any way relating to the affairs under these presents shall
be referred to the arbitration of single Arbitrator if the parties hereto agree upon
one otherwise to the two Arbitrator one to be appointed by the society and one to
be appointed by the Developer. In such an event both the Arbitrators shall appoint a
third Arbitrator before entering upon the reference. Such Arbitration shall be in
Mumbai and shall be subject to the provisions of Arbitration & Conciliation Act, 1996
or any modification or reenactment therefore for the time being the force.
IN WITNESS WHEREOF the parties hereto have set and subscribed their
respective hands to this M.O.U. the day and year first hereinabove written.
THE FIRST SCHEDULE HEREINABOVE REFERRED TO:
ALL THOSE pieces or parcels of land bearing Plot Nos.4, 5, 6 and 7 in all
admeasuring 15,519 sq.mtrs. situated at Sector-22, Ulwa, Taluka : Panvel, District :
Raigad, Navi Mumbai and bounded as follows:-
On or towards East : by
On or towards West : by
On or towards North : by
On or towards South : by
THE SECOND SCHEDULE HEREINABOVE REFERRED TO:
Construction specification
RCC framework structure of M250 standard having earthquake resistance design, all
outerwalls of 150 mm thick brick masonry and internal wall of 100mm thick brick
masonry structure with underground tank and overhead tank for each
building/wing. Each building/wing will be provided with 2 lifts of OTIS/Schindler
Brand.
Amenities to the Flats
1. Flooring : Marbogranite tiles flooring in entire Flat Area.
2. Kitchen Platform : Granite platform with stainless steel sink.
3. Window sil : Granite/Marble Window sil.
17
4. Tiles in Kitchen : Dedo upto full height above of granite platform will
be covered with ceramic tiles.
5. W.C.and Bath : Full height covered with glaze tiles of branded
quality.
6. Electrification : Concealed copper wiring by providing points in line
with flats constructed for sale.
7. Plumbing : Concealed plumbing with Jaguar middle range
fitting in bathroom and W C area
8. Door and Window : Main door will be panel door with safety latch,
magic eye and key hole and all other door will be
flush door having veneer finish duly polished with
melamine polish.
: Aluminium sliding window fabricated out of door
section with 5mm thick glass covered with
M.S.fabricated safety grill.
: Bathroom/ WC door will be made out of Aluminium
door section with Acrylic sheet.
9. Telecommu- : Internet cabeling and Intercom cabeling upto main
nication facility hub, Videophone to each flat.
10. Entrance Lobby : AC entrance lobby with security guard table and
chair along with visitors’ chairs.
11. Compound paving : Entire compound will be covered with checkered
tiles and sufficiently lighted with decorative garden
light.
12. Borewell : Flushing water will be provided through borewell
subject to water quality test report.
18
13. Staircase trade and: Green Marble in combination with Jaisalmer stone
riser with landing
and midlanding
14. Lift Lobby area : Lift Lobby area will be finished with granite flooring
in pattern and Lift vertical surface will be cladded
with Ceramic tiles.
15. Other Amenities : Solar Heating Panels, Water recycling system.
SIGNED AND DELIVERED by the )
Withinnamed 'DEVELOPERS' )
M/S. SHAH CONSTRUCTION ) For M/S. SHAH CONSTRUCTION
COMPANY ) COMPANY
Through their partner )
SHRI KANTILAL MANILAL SHAH )
alias SAVLA )
In the presence of........ ) Partner
1.
2.
SIGNED AND DELIVERED by the )
Withinnamed 'SOCIETY' )
THE IRS (MUMBAI) CO-OPERATIVE )
HOUSING SOCIETY LTD.(PROPOSED) )
through its Chief Promoter SHRI V.S. )
SINGH and Promoters SHRI D.S. )
BENUPANI and SHRI JAYARAM )
RAIPURA )
In the presence of........ )
1.
2.
RECEIVED of and from withinnamed )
19
The Society prior to and upon execution )
(i) Rs.____________/- by Cheque No.___________)
Dated ____/____/2007 (ii) Rs.___________/- by )
Cheque No.__________dated ____/____/2007 )
both the cheques drawn on __________________ )
________________________________________in all )
Aggregating to Rs.1,50,00,000/- (Rupees One)
Crore Fifty Lacs only) paid on behalf of the )
Members being the amount payable to us as )
withinmentioned. ) Rs.1,50,00,000/-
==============Witnesses: WE SAY RECEIVED
1. For M/S. SHAH CONSTRUCTION COMPANY
2.
Partner
20
===============================
=========
DATED THIS DAY OF , 2007
===============================
=========
M/S. SHAH CONSTRUCTION COMPANY ...Developers
AND
THE IRS (MUMBAI) CO-OPERATIVE HOUSING SOCIETY LTD. (PROPOSED)
... Society
MEMORANDUM
OF
UNDERSTANDING