P-1 PROJECT: COMPLETION TIME: PROPOSAL TO THE STATE OF HAWAII DEPARTMENT OF TRANSPORTATION JOB H.C. 50113.1 DEMOLITION OF QUONSET HUT HILO HARBOR, HAWAII All work for the project (H.C. 50113.1) shall be completed within two hundred seventy (270) CALENDAR days from the date indicated in the Notice to Proceed (NTP) from the Department. LIQUIDATED DAMAGES: The amount of liquidated damages that will be assessed for failure to complete DEMOLITION OF QUONSET HUT, HILO HARBOR, HAWAII, JOB H.C. 50113.1, in the time stated above, is Two Thousand One Hundred Thirty-One Dollars and 20/100 ($2,131.20) per calendar day (or portion thereof). DESIGN PROJECT MANAGER: Sharilyn Ikeda, Project Manager Department of Transportation Harbors Division 79 S. Nimitz Hwy. Honolulu HI 96813 Ph: (808) 586-2458 FAX: (808) 587-1864
Transcript
P-1
PROJECT:
COMPLETION TIME:
PROPOSAL TO THE
STATE OF HAWAII
DEPARTMENT OF TRANSPORTATION
JOB H.C. 50113.1 DEMOLITION OF QUONSET HUT HILO HARBOR, HAWAII
All work for the project (H.C. 50113.1) shall be completed within two hundred seventy (270) CALENDAR days from the date indicated in the Notice to Proceed (NTP) from the Department.
LIQUIDATED DAMAGES: The amount of liquidated damages that will be assessed for failure to complete DEMOLITION OF QUONSET HUT, HILO HARBOR, HAWAII, JOB H.C. 50113.1, in the time stated above, is Two Thousand One Hundred Thirty-One Dollars and 20/100 ($2,131.20) per calendar day (or portion thereof).
DESIGN PROJECT MANAGER: Sharilyn Ikeda, Project Manager Department of Transportation Harbors Division 79 S. Nimitz Hwy. Honolulu HI 96813 Ph: (808) 586-2458 FAX: (808) 587-1864
Director of Transportation 869 Punchbowl Street Honolulu, Hawaii 96813
Dear Sir:
The undersigned bidder declares the following:
1. It has not, either directly or indirectly, entered into any agreement, participated in any collusion, or otherwise taken any action in restraint of free competitive bidding in connection with this proposal.
2. It has not been assisted or represented on this matter by any individual who has, in a State capacity, been involved in the subject matter of this contract within the past two years.
3. It has not and will not, either directly or indirectly offered or given a gratuity (i.e .. an entertainment or gift) to any State or County employee to obtain a contract or favorable treatment under a contract.
The undersigned bidder further agrees to the following:
1. If this proposal is accepted, it shall execute a contract with the Department to provide all necessary labor, machinery, tools, equipment, apparatus and any other means of construction, to do all the work and to furnish all the materials specified in the contract in the manner and within the time therein prescribed in the contract, and that it shall accept in full payment therefore the sum of the unit and/or lump sum prices as set forth in the attached proposal schedule for the actual quantities of work performed and materials furnished and furnish satisfactory security in accordance with Section 103D-324, Hawaii Revised Statutes, within 10 days after the award of the contract or within such time as the Director of Transportation may allow after the undersigned has received the contract documents for execution, and is fully aware that non-compliance with the aforementioned terms will result in the forfeiture of the full amount of the bid guarantee required under Section 103D-323, Hawaii Revised Statutes.
2. That the quantities given in the attached proposal schedule are approximate only and are intended principally to serve as a guide in determining and comparing the bids.
3. That the Department does not either expressly or by implication, agree that the actual amount of work will correspond therewith, but reserves the right to increase or decrease the amount of any class or portion of the work, or to omit portions of the work, as may be deemed necessary or advisable by the Director of Transportation, and that all increased or decreased quantities of work shall be performed at the unit prices set forth in the attached proposal schedule except as provided for in the specifications.
P-2 rll/2016
4. In case of a discrepancy between unit prices and the totals in said Proposal Schedule, the unit prices shall prevail.
5. Agrees to begin work within 10 working days after the date of notification to commence with the work, which date is in the notice to proceed, and shall finish the entire project within the time prescribed.
6. The Director of Transportation reserves the right to reject any or all bids and to waive any defects when in the Director's opinion such rejections or waiver will be for the best interest of the public.
The bidder acknowledges receipt of and certifies that it has completely examined the following listed items: the Hawaii Department of Transportation, Air and Water Transportation Facilities Division General Provisions for Construction Projects dated 2016, the Notice to Bidders, the Special Provisions, if any, the Technical Provisions, the Proposal, the Contract and Bond Forms, and the Project Plans.
In accordance with Section 103D-323, Hawaii Revised Statutes, this proposal is accompanied with a bid security in the amount of 5% of the total amount bid, in the form checked below. (Check applicable bid security submitted with bid.)
__ Surety Bid Bond (Use standard form),
-- Cash,
__ Cashier's Check,
__ Certified Check, or
(Fill in other acceptable security.)
P-3 rll/2016
1.
2.
3.
4.
5.
6.
7.
8.
9.
1.
2.
3.
The undersigned bidder acknowledges receipt of any addendum issued by the Department by recording in the space below the date of receipt.
In accordance with Section 103D-302, Hawaii Revised Statutes, the undersigned as bidder has listed the name of each person or firm, who will be engaged by the bidder on the project as Joint Contractor or Subcontractor and the nature of work to be done by each. It is understood that failure to comply with the aforementioned requirements may be cause for rejection of the bid submitted.
Name of Subcontractor Nature and Scope of Work
Name of Joint Contractor Nature and Scope of Work
("None" or if left blank indicates no Subcontractor or Joint Contractor; if more space is needed, attach additional sheets.)
P-4 rll/2016
The undersigned hereby certifies that the bid prices contained in the attached proposal schedule have been carefully checked and are submitted as correct and final.
This declaration is made with the understanding that the undersigned is subject to the penalty of perjury under the laws of the United States and is in violation of the Hawaii Penal Code, Section 710-1063, unsworn falsification to authorities, of the Hawaii Revised Statutes, for knowingly rendering a false declaration.
NOTE:
Bidder
By _____________________ _ Authorized Signature
Title
Business Address
Business Telephone
Date
Contact Person and Phone Number (If different from above.)
If bidder is a CORPORATION, the legal name of the corporation shall be set forth above, the corporate seal affixed, together with the signature(s) of the officer(s) authorized to sign contracts for the corporation. Please attach to this page current (not more than six months old) evidence of the authority of the officer(s) to sign for the corporation.
If bidder is a PARTNERSHIP, the true name of the partnership shall be set forth above, with the signature(s) of the general partner(s). Please attach to this page current (not more than six months old) evidence of the authority of the partner authorized to sign for the partnership.
If bidder is an INDIVIDUAL, the bidder's signature shall be placed above.
If signature is by an agent, other than an officer of a corporation or a partner of a partnership, a POWER OF ATTORNEY must be on file with the Department before opening bids or submitted with the bid. Otherwise, the Department may reject the bid as irregular and unauthorized.
P-5 rll/2016
PREFERENCES
Bidders agree that preferences shall be taken into consideration to determine the low bidder in accordance with said Sections and the rules promulgated, however, the award of contract will be in the amount of the bid offered exclusive of any preferences.
A. HAW All PRODUCTS PREFERENCE
It is understood that certain Hawaii Products may be acceptable for use in this project and that, pursuant to Sections 103D-1002, HRS, which provides preference for Hawaii Products,£! bidder proposing to use such Hawaii products shall so designate in the schedule provided below.
If a bidder proposes to use Hawaii Products, the bidder must so designate in said schedule by entering the cost of such product in the appropriate space provided. Failure on the part of the bidder to designate the use of Hawaii products will automatically void any preference for that product.
Persons desiring to qualify product(s) not currently on the list, shall complete form SP0-38, Certification for Hawaii Product Preference in accordance with the Special Provisions of these specifications.
It is understood by the bidder that if the bidder elects to furnish qualified Hawaii Products, and is awarded the contract, then fails to use such products or meet the requirements of such preference, the bidder shall be subject to the statutory penalties, provided in Section 103D-1002, Hawaii Revised Statute, and such other remedies as may be available to the State.
( ) Yes, I propose to use Hawaii Products and claim the Hawaii Products Preference. I have filled in the table on the following pages as applicable.
B. APPRENTICESHIP PROGRAMS PREFERENCE
In accordance with ACT 17, SLH 2009 - Apprenticeship Program, a 5% bid adjustment for bidders that are parties to apprenticeship agreements pursuant to Hawaii Revised Statutes (HRS) Section 103-55.6 may be applied to the bidder's price for evaluation purposes
Any bidder seeking this preference must be a party to an apprenticeship agreement registered with the Department of Labor and Industrial Relations at the time the offer is made for each apprenticeable trade the bidder will employ to construct the public works projects for which the offer is being made.
The bidder is responsible for complying with all submission requirements for registration of its apprenticeship program before requesting the preference.
( ) Yes, I wish to be considered for the Apprenticeship Programs Preference. I have included Certification Form(s) 1 with my bid.
C. RECYCLED PRODUCT PREFERENCE
Recycled product preference shall not apply to this proposal.
H.C. 50148.1 P-6 r5/31/2017
Product Category
Aggregates - Basaltic Termite Barrier
Aggregates and Sand - Basalt, Rock, Cinder, Limestone and Coral
Aggregates - Recycled Asphalt and Concrete
I As2halt and Paving Materials
DESIGNATION OF APPROVED HA WAIi PRODUCTS* TO BE USED *CONSTRUCTION PRODUCTS AND SOIL AMENDMENTS/PRODUCTS
Product Subcategory as
applicable
I
Manufacturer
Ameron International Corporation (Oahu)(Maui) Pohaku Pa'a dba HC&D LLC (Oahu) Ameron International Corporation (Oahu)(Maui) CTS Earthmovirnr, Inc. rHawaii) Delta Construction Comoration (Oahu) Edwin Deluz Trucking & Gravel LLC
(Hawaii) Goodfellow Bros, Inc. ( All Islands) Grace Pacific (Oahu(Hawaii) (Kauai) GW Construction (Hawaii) Hawaiian Cement (Oahu) (Maui) Jas. W. Glover, Ltd. ffiawaii)JK auai) Kauai Agm:entes rK auai) Pohaku Pa' a LLC dba HC&D LLC (Oahu) rMaui) Puna Rock Co., LTD. (Hawaii) Sanford's Service Center, Inc. ffiawaii) Snhere, LLC (Oahu) Tileco, Inc. (Oahu) (Hawaii) rMaui) rKauai) Tri-L Construction, Inc. (Molokai) West Hawaii Concrete (Hawaii) Yamada and Sons Inc. (Hawaii) Glover Honsador (Kauai) Grace Pacific (Oahu) Jas. W. Glover, Ltd. ffiawaii)JOahu) West Oahu Airn-regate Co. Inc. (Oahu) Ala Imua LLC (Oahu)
H.C. 50148.1 P-7
Cost FOB Jobsite, Unloaded Including Applicable General Excise & Use Taxes
(a)
$
$
$ $ $
$ $ $ $ $ $ $
$ $ $ $ $ $ $ $ $ $ $ $ $
10% Credit (b) (a) X (b)
I $ $ $
$ $ $ $ $ $ $
$ $ $ $ $ $ $ $ $ $ $ $
I I $
r6/29/2017
Cement and Concrete Products
Black Maui Rose LLC (Maui) Black Plumeria LLC (Oahu) GP Roadway Solutions, Inc. (All Islands) Grace Pacific Corporation (Hawaii)(Oahu) (Kauai) Halawa Asphalt LLC (Oahu) Jas. W. Glover, Ltd. ffiawaii)JKauai) Maui Asphalt X-IV, LLC (Maui)(Molokai) Maui Paving LLC (Maui) (Molokai) Road and Highway Builders (Oahu) Walker-Moody Pavement Products &
.... Equipment (All Islands) Yamada and Sons, Inc. dba YS Rock and Con-A!rn· of Hawaii ffiawaii) Ameron International Corporation (Oahu) (Maui) BOMAT, Ltd. (All Islands) Glover Honsador (Kauai) Hawaiian Cement (Oahu)(Maui) Island Ready Mix Concrete, Inc. (Oahu) Jas. W. Glover, Ltd. ffiawaii)(Kauai) Jensen Enterprises (All Islands) Kiewit Infrastructure West Co. (Oahu) Kohala Coast Concrete & Precast LLC
{Hawaii) Pohaku Pa'a LLC dba HC&D LLC (Oahu) (Maui) Road and Highway Builders, LLC (Oahu) Tri-L Construction, Inc. (Molokai) 0. Thronas, Inc. (Kauai) Tileco, Inc. (Oahu)(Hawaii)(Maui)(Kauai) West Hawaii Concrete (Hawaii) Yamada and Sons, Inc. (Hawaii)
H.C. 50148.1 P-8
$ $ $ $ $ $
$ $ $ $ $ $ $ $ $ $ $ $
$ $
$ $
$ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $
$ $
$ $ $ $ $ $ $ $ $ $ $ $
$ $
r6/29/2017
Precast Concrete Products
Environmental Sewage -Treatment Innovative System Septic Tanks (ESIS)
_(All Islands) Hawaii Concrete Products, Inc. (Oahu) Hawaii Precast, Inc .
. JAll Islands) Kohala Coast Concrete & Precast LLC (Hawaii) Ramtek Fabrication Co., Inc. ( All Islands) Walker Industries, Ltd. ( Oahu )(Hawaii)(Maui)(K auai) Environmental Waste Management Systems, Inc. (Oahu)(Hawaii)(Maui)(Kauai) Ameron International Corporation
..(Oahu) Walker Industries, Ltd. (All Islands) Universal Associates, Inc. <Oahu)
HPM Building Suonly (All Islands) Ameron International Corporation (Oahu) Bluewater Marine and Dock Specialties ( All Islands) High Seas Welding LLC dba JS Marine ( All Islands) GP Roadway Solutions, Inc. ( All Islands) Safety Systems and Signs Hawaii, Inc. (All Islands) I Big Rock Manufacturing {All Islands}
H.C. 50148.1 P-9
$ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $ $
DI$ I $ 1$ ID!$ I
I
$ $
I
$ $
I $ D$
r6/29/2017
Soil Amendments, Mulch, Compost
Compost Filter
Eko Systems Inc. (Oahu) (Maui) (Hawaii)rK auai) Island Toosoil LLC (All Islands) Kauai Nursery & Landscaping, Inc. ( All Islands) Molokai Seed Co. (All Islands) Sanford's Service Center, Inc. (Hawaii) EnviroTech BioSolutions Hawaii, Inc. (All Islands) ·certified Erosion Control Hawaii LLC (All Islands)
H.C. 50148.1 P-10
TOTAL
$ $
$ $ $ $ $ $
$ $
$ $
1$ I
r6/29/2017
H.C. 50113.1 HAIP-10 04/29/20
DEMOLITION OF QUONSET HUT HILO HARBOR, HAWAII
PROPOSAL SCHEDULE
JOB H.C. 50113.1
Item No. Unit
Approx. Quantity Description
Unit Price Bid Amount Bid
1 Lump Sum Job Installation, Maintenance, Monitoring and Removal of Best Management Practices
L.S. $ __________
2 Lump Sum Job Additional Water Pollution, Dust and Erosion and Sediment Control
L.S. $ __________
3 Lump Sum Job
Site Utility Service Connection Confirmation and Disconnection of Utility Services to the Quonset Hut
L.S. $ __________
4 Lump Sum Job Coordination with HELCO for Disconnection of Electrical Service
L.S. $ __________
5 Lump Sum Job Removal of Existing Fence L.S. $ __________
6 Lump Sum Job Removal of Existing Landscape Areas Adjacent to the Quonset Hut
L.S. $ __________
7 Lump Sum Job Removal of Existing Modular Office Trailer
L.S. $ __________
8 Lump Sum Job Removal of Matson Container L.S. $ __________
9 Lump Sum Job Demolish Quonset Hut Structure, base CMU Wall and Adjacent Sheds
L.S. $ __________
10 Lump Sum Job Demolish Quonset Hut Concrete Foundation Pad
L.S. $ __________
11 Lump Sum Job Demolish Stand-Alone Roof Structure
L.S. $ __________
H.C. 50113.1 HAIP-11 04/29/20
Item No. Unit
Approx. Quantity Description
Unit Price Bid Amount Bid
12 Lump Sum Job Hot-Mix Asphalt Base Course L.S. $ __________
13 Lump Sum Job Aggregate Subbase L.S. $ __________
14 Lump Sum Job Hot-Mix Asphalt Concrete Pavement, Mix III
L.S. $ __________
15 Lump Sum Job Backfill and Repair Holes in Asphalt Concrete Pavement
L.S. $ __________
16 Lump Sum Job Daily Collection and Hauling of Demolition Solid Waste and Debris to West Hawaii Landfill
L.S. $ __________
17 Allowance Job Tipping Fee for Disposal of Solid Waste at West Hawaii Landfill
Allow. $ _15,000.00__
18 Lump Sum Job
Excavation, characterization, profiling, and hauling of grossly contaminated soils for demolition and removal work inclusive of excavation, stockpiling, hauling, disposal, equipment, tools, labor, materials and incidentals necessary to complete the work.
L.S. $ __________
19 Lump Sum Job
Excavation, characterization, profiling, and hauling of non-grossly contaminated soils for demolition and removal work inclusive of excavation, stockpiling, hauling, disposal, equipment, tools, labor, materials and incidentals necessary to complete the work.
L.S. $ __________
H.C. 50113.1 HAI P-12 04/29/20
20 Lump Sum Job
Cost of separating petroleum grossly and non-grossly contaminated material for demolition and removal work, including, but not limited to concrete building foundations, concrete footings, asphalt concrete pavement, underground utility structures, and loose material removed as part of the demolition and removal work. Costs shall include physically separating material, loss of production, protective wear, safety plan, and other costs related to petroleum contamination.
L.S. $ __________
21 Lump Sum Job Preparation of Planning Documents, inclusive of EHMP
L.S. $ __________
22 Lump Sum Job Contractors Environmental Qualified Consultant
L.S. $ __________
23 Lump Sum Job Setup, maintenance, and removal of soil staging area for non-grossly contaminated soils.
L.S. $ __________
24 Lump Sum Job Setup, maintenance, and removal of soil staging area for grossly contaminated soils.
L.S. $ __________
25 Lump Sum Job Setup, maintenance, and removal of staging area for contaminated sediment.
L.S. $ __________
26 Lump Sum Job Setup, maintenance, and removal of staging area for excavated landfill debris.
L.S. $ __________
27 Allowance Job Removal and disposal of oily sheen/product from groundwater, during back-trenching.
Allow. $ _10,000.00_
H.C. 50113.1 HAIP-13 04/29/20
28 Lump Sum Job Lead-Containing Paint Control Measures
L.S. $ __________
29 Lump Sum Job Ambient Air Monitoring L.S. $ __________
30 Lump Sum Job Site Clean-up and De-Mobilization L.S. $ __________
31 Lump Sum Job Field-Posted Drawings L.S. $ __________
32 Lump Sum Job Mobilization L.S. $ __________
Total Sum Part A - Job H.C. 50113.1 $ __________
HAIH.C. 50113.2P-14 04/29/20
DEMOLITION OF PIER 2/3 SHED HILO HARBOR, HAWAII
PROPOSAL SCHEDULE
JOB H.C. 50113.2
Item No. Unit
Approx. Quantity Description
Unit Price Bid Amount Bid
1 Lump Sum Job Installation, Maintenance, Monitoring and Removal of Best Management Practices
L.S. $ __________
2 Lump Sum Job Additional Water Pollution, Dust and Erosion and Sediment Control
L.S. $ __________
3 Lump Sum Job
Site Utility Service Connection Confirmation and Disconnection of Utility Services to the Pier 2/3 Shed
L.S. $ __________
4 Lump Sum Job Locate and remove existing electrical conduits from structure
L.S. $ __________
5 Lump Sum Job Locate and remove existing mechanical piping from structure
L.S. $ __________
6 Lump Sum Job
Remove all siding, roofing materials, roof sheathing, doors, door framing, windows, window framing, louvers, gutters, downspouts, girts and purlins for all three structures
L.S. $ __________
7 Lump Sum Job Remove all columns, beams and concrete pedestals between Column Lines C and D
L.S. $ __________
8 Lump Sum Job
Remove existing offices between Column Lines C and D, and existing offices between Column Lines A and B
L.S. $ __________
9 Lump Sum Job
Remove X-bracing and roof beams along Grid Lines 1 thru 8, and between Column Lines B and C
L.S. $ __________
HAIH.C. 50113.2P-15 04/29/20
Item No. Unit
Approx. Quantity Description
Unit Price Bid Amount Bid
10 Lump Sum Job Remove columns and beams along Grid Line 8, between Column Lines B and C
L.S. $ __________
11 Lump Sum Job Remove columns and beams along Grid Line 1, between Column Lines B and C
L.S. $ __________
12 Lump Sum Job Remove all columns along Column Line C except for Columns at Grid Lines 4 and 7
Temporary shore all columns along Column Lines A and B except for Columns at Grid Lines 9, 11, 13, 15, and 17
L.S. $ __________
15 Lump Sum Job Permanently shore columns at Grid Lines 9, 11, 13, 15 and 17
L.S. $ __________
16 Lump Sum Job
Remove roof truss and clearstory as an assembly, one bay at a time. Store trusses on pier deck until workers can dismantle trusses.
L.S. $ __________
17 Lump Sum Job Dismantle trusses on pier deck after removing from shed roof.
L.S. $ __________
18 Lump Sum Job Remove all vertical bracing along Column Lines A and B
L.S. $ __________
19 Lump Sum Job
Remove all columns along Column Lines A and B except those columns noted in Item 29 above
L.S. $ __________
20 Lump Sum Job
Remove all short concrete walls along Column Lines A, B, and C, and along Grid Lines 1 and 18. Cut off rebar dowels 2 inches below the top of floor slab elevation.
L.S. $ __________
HAIH.C. 50113.2P-16 04/29/20
Item No. Unit
Approx. Quantity Description
Unit Price Bid Amount Bid
21 Lump Sum Job Remove all column anchor bolts to an elevation 2-inches below top of floor slab, total of 180
L.S. $ __________
22 Lump Sum Job
Remove all concrete bollards that protect the entrance doorways and the concrete blocks at the base of the various piping risers and downspouts
L.S. $ __________
23 Lump Sum Job Prepare and patch all deck slab concrete where rebar dowels and anchor bolts have been removed
L.S. $ __________
24 Lump Sum Job Install bollards at each remaining column and at electrical panel
L.S. $ __________
25 Lump Sum Job Electrical Work L.S. $ __________
26 Allowance Job HELCO Service Charge Allow. $ _10,000.00_
27 Lump Sum Job Daily Collection and Hauling of Demolition Solid Waste and Debris to West Hawaii Landfill
L.S. $ __________
28 Allowance Job Tipping Fee for Disposal of Solid Waste at West Hawaii Landfill
Allow. $ _15,000.00_
29 Lump Sum Job Restore site to pre-construction condition including repairs to pier deck
L.S. $ __________
30 Lump Sum Job
Excavation, characterization, profiling, and hauling of grossly contaminated soils for demolition and removal work inclusive of excavation, stockpiling, hauling, disposal, equipment, tools, labor, materials and incidentals necessary to complete the work.
L.S. $ __________
HAIH.C. 50113.2P-17 04/29/20
31 Lump Sum Job
Excavation, characterization, profiling, and hauling of non-grossly contaminated soils for demolition and removal work inclusive of excavation, stockpiling, hauling, disposal, equipment, tools, labor, materials and incidentals necessary to complete the work.
L.S. $ __________
32 Lump Sum Job
Cost of separating petroleum grossly and non-grossly contaminated material for demolition and removal work, including, but not limited to concrete building foundations, concrete footings, asphalt concrete pavement, underground utility structures, and loose material removed as part of the demolition and removal work. Costs shall include physically separating material, loss of production, protective wear, safety plan, and other costs related to petroleum contamination.
L.S. $ __________
33 Lump Sum Job Preparation of Planning Documents, inclusive of EHMP
L.S. $ __________
34 Lump Sum Job Contractors Environmental Qualified Consultant
L.S. $ __________
35 Lump Sum Job Setup, maintenance, and removal of soil staging area for non-grossly contaminated soils.
L.S. $ __________
36 Lump Sum Job Setup, maintenance, and removal of soil staging area for grossly contaminated soils.
L.S. $ __________
37 Lump Sum Job Setup, maintenance, and removal of staging area for contaminated sediment.
L.S. $ __________
38 Lump Sum Job Setup, maintenance, and removal of staging area for excavated landfill debris.
L.S. $ __________
HAIH.C. 50113.2P-18 04/29/20
39 Allowance Job Removal and disposal of oily sheen/product from groundwater, during back-trenching.
Allow. $ _10,000.00_
40 Lump Sum Job Lead-Containing Paint Control Measures
L.S. $ __________
41 Lump Sum Job Ambient Air Monitoring L.S. $ __________
42 Allowance Job
Tapping, draining, cleaning, testing, and disposal of fuel pipelines, inclusive of disposal characterization analyses for residual fuel, disposal of residual fuel, disposal characterization analyses for sludge, rinsate, and solids, disposal of sludge, rinsate, and solids generated during cleaning of the underground pipelines, all equipment, tools, materials, labor, and appurtenances required to complete the work.
Allow. $ _10,000.00_
43 Lump Sum Job Site Clean-up and De-Mobilization L.S. $ __________
44 Lump Sum Job Purchase and delivery of Trailers (3 EA.) to yard (No installation)
L.S. $ __________
45 Lump Sum Job Mobilization L.S. $ __________
Total Sum Part B - Job H.C. 50113.2 $ __________
HAIH.C. 50113.2P-19 04/29/20
NOTES:
A. Bid to include all Federal, State and local taxes.
B. To be considered, Bidders must bid on the Basic Bid.
C. Bids will be evaluated on the basis of the Total Sum Bid. If the lowest Total Sum Bid is less than or approximately equal to the funds available for this project, an award will be made to the lowest responsible bidder.
D. However, if the lowest Total Sum Bid exceeds the funds available for the project, the State reserves the right to negotiate with the lowest responsible bidder as permitted under Section 103D-302, Hawaii Revised Statutes, as amended, to reduce the scope of work and award the contract thereof.
E. No additional compensation will be made by the State for losses, including overhead and profit, resulting from reduced scope of work
F. Contract time shall remain the same whether or not the overall scope of work is decreased.
G. The Bidder’s attention is directed to Section 2.11 Bid Security and Section 2.24 Requirement of Contract Bonds of the "General Provisions".
SUMMARY PROPOSAL SCHEDULE
DEMOLITION OF QUONSET HUT, HILO HARBOR, HAWAII, JOB H.C. 50113.1
AND
DEMOLITION OF PIER 2/3 SHED, HILO HARBOR, HAWAII, JOB H.C. 50113.2
A TOTAL SUM BID PART A ‐ JOB H.C. 50113.1
$_________________________________
(Amount from H.C. 50113.1 page P‐13)
B TOTAL SUM BID PART B ‐ JOB H.C. 50113.2
$_________________________________
(Amount from H.C. 50113.2 page P‐18)
TOTAL SUM BID (A+B)
$_________________________________
P‐20
STATE OF HAWAII
DEPARTMENT OF TRANSPORTATION
FORMS
Contents:
Performance Bond (Surety)
Performance Bond
Labor and Material Payment Bond (Surety)
Labor and Material Payment Bond
Chapter 104 Compliance Certificate
Certification of Compliance for Employment of State Residents
PERFORMANCE BOND (SURETY) (6/21/07) KNOW TO ALL BY THESE PRESENTS: That _________________________________________________________________,
(Full Legal Name and Street Address of Contractor) as Contractor, hereinafter called Principal, and ______________________________________ ____________________________________________________________________________
(Name and Street Address of Bonding Company) as Surety, hereinafter called Surety, a corporation(s) authorized to transact business as a surety in the State of Hawaii, are held and firmly bound unto the ______________________, (State/County Entity) its successors and assigns, hereinafter called Obligee, in the amount of __________________ ____________________________________________________________________________ DOLLARS ($__________________), to which payment Principal and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the above-bound Principal has signed a Contract with Obligee on ___________________, for the following project: hereinafter called Contract, which Contract is incorporated herein by reference and made a part hereof. NOW THEREFORE, the condition of this obligation is such that: If the Principal shall promptly and faithfully perform, and fully complete the Contract in strict accordance with the terms of the Contract as said Contract may be modified or amended from time to time; then this obligation shall be void; otherwise to remain in full force and effect.
-1-
Surety to this Bond hereby stipulates and agrees that no changes, extensions of time, alterations, or additions to the terms of the Contract, including the work to be performed thereunder, and the specifications or drawings accompanying same, shall in any way affect its obligation on this bond, and it does hereby waive notice of any such changes, extensions of time, alterations, or additions, and agrees that they shall become part of the Contract. In the event of Default by the Principal, of the obligations under the Contract, then after written Notice of Default from the Obligee to the Surety and the Principal and subject to the limitation of the penal sum of this bond, Surety shall remedy the Default, or take over the work to be performed under the Contract and complete such work, or pay moneys to the Obligee in satisfaction of the surety's performance obligation on this bond. Signed this ________ day of _______________, _______. (Seal) ___________________________________ Name of Principal (Contractor) * __________________________________ Signature ___________________________________ Title (Seal) ___________________________________ Name of Surety * ___________________________________ Signature
___________________________________
Title *ALL SIGNATURES MUST BE ACKNOWLEDGED BY A NOTARY PUBLIC
-2-
PB-1 r11/17/98
PERFORMANCE BOND
KNOW ALL BY THESE PRESENTS:
That we,________________________________________________________________ (full legal name and street address of Contractor)
as Contractor, hereinafter called Contractor, is held and firmly bound unto the
its successors and assigns, as Obligee, hereinafter called Obligee, in the amount
_________________________________________DOLLARS ($_________________________), (Dollar amount of Contract)
lawful money of the United States of America, for the payment of which to the said Obligee, well and truly to be made, Contractor binds itself, its heir, executors, administrators, successors and assigns, firmly by these presents. Said amount is evidenced by:
Legal Tender;
Share Certificate unconditionally assigned to or made payable at sight to ______________________________________________________________________
Certificate of Deposit, No. ___________, dated ______________________________ issued by ______________________________________________________________ drawn on ______________________________________________________________ a bank, savings institution or credit union insured by the Federal Deposit Insurance Corporation or the National Credit Union Administration, payable at sight or unconditionally assigned to _______________;
Cashier's Check No. __________, dated ___________________________________ drawn on ______________________________________________________________ a bank, savings institution or credit union insured by the Federal Deposit Insurance Corporation or the National Credit Union Administration, payable at sight or unconditionally assigned to _______________________________;
Teller's Check No. ___________, dated ____________________________________ drawn on ______________________________________________________________ a bank, savings institution or credit union insured by the Federal Deposit Insurance Corporation or the National Credit Union Administration, payable at sight or unconditionally assigned to __________________________;
Treasurer's Check No. ____________, dated _______________________________ drawn on ______________________________________________________________ a bank, savings institution or credit union insured by the Federal Deposit Insurance Corporation or the National Credit Union Administration, payable at sight or unconditionally assigned to __________________________;
Official Check No. _____________, dated __________________________________ drawn on ______________________________________________________________ a bank, savings institution or credit union insured by the Federal Deposit Insurance Corporation or the National Credit Union Administration, payable at sight or unconditionally assigned to ___________________________;
Certified Check No. ______________, dated ________________________________ accepted by a bank, savings institution or credit union insured by the Federal Deposit Insurance Corporation or the National Credit Union Administration, payable at sight or unconditionally assigned to _______________;
PB-2 r11/17/98
WHEREAS:
The Contractor has by written agreement dated ______________________ entered into a contract with Obligee for the following Project:_________________________________________ ____________________________________________________________________________________________________________________________________________________________hereinafter called Contract, which Contract is incorporated herein by reference and made a part hereof.
NOW THEREFORE,
The Condition of this obligation is such that, if Contractor shall promptly and faithfully perform the Contract in accordance with, in all respects, the stipulations, agreements, covenants and conditions of the Contract as it now exists or may be modified according to its terms, and shall deliver the Project to the Obligee, or to its successors or assigns, fully completed as in the Contract specified and free from all liens and claims and without further cost, expense or charge to the Obligee, its officers, agents, successors or assigns, free and harmless from all suits or actions of every nature and kind which may be brought for or on account of any injury or damage, direct or indirect, arising or growing out of the doing of said work or the repair or maintenance thereof or the manner of doing the same or the neglect of the Contractor or its agents or servants or the improper performance of the Contract by the Contractor or its agents or servants or from any other cause, then this obligation shall be void; otherwise it shall be and remain in full force and effect.
AND IT IS HEREBY STIPULATED AND AGREED that suit on this bond may be brought before a court of competent jurisdiction without a jury, and that the sum or sums specified in the said Contract as liquidated damages, if any, shall be forfeited to the Obligee, its successors or assigns, in the event of a breach of any, or all, or any part of, covenants, agreements, conditions, or stipulations contained in the Contract or in this bond in accordance with the terms thereof.
The amount of this bond may be reduced by and to the extent of any payment or payments made in good faith hereunder.
Signed and sealed this ______________ day of ___________________________, ______.
(Seal) ___________________________________________Name of Contractor
*ALL SIGNATURES MUST BE ACKNOWLEDGED BY A NOTARY PUBLIC
LABOR AND MATERIAL PAYMENT BOND (SURETY) (6/21/07) KNOW TO ALL BY THESE PRESENTS: That _________________________________________________________________,
(Full Legal Name and Street Address of Contractor) as Contractor, hereinafter called Principal, and ______________________________________ ___________________________________________________________________________,
(Name and Street Address of Bonding Company) as Surety, hereinafter called Surety, a corporation(s) authorized to transact business as a surety in the State of Hawaii, are held and firmly bound unto the ______________________, (State/County Entity) its successors and assigns, hereinafter called Obligee, in the amount of _________________ ____________________________________________________________________________________ Dollars ($______________), to which payment Principal and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the above-bound Principal has signed Contract with the Obligee on ____________________ for the following project: hereinafter called Contract, which Contract is incorporated herein by reference and made a part hereof. NOW THEREFORE, the condition of this obligation is such that if the Principal shall promptly make payment to any Claimant, as hereinafter defined, for all labor and materials supplied to the Principal for use in the performance of the Contract, then this obligation shall be void; otherwise to remain in full force and effect. 1. Surety to this Bond hereby stipulates and agrees that no changes, extensions of time, alterations, or additions to the terms of the Contract, including the work to be performed thereunder, and the specifications or drawings accompanying same, shall in any way affect its obligation on this bond, and it does hereby waive notice of any such changes, extensions of time, alterations, or additions, and agrees that they shall become part of the Contract. 2. A "Claimant" shall be defined herein as any person who has furnished labor or materials to the Principal for the work provided in the Contract.
-1-
Every Claimant who has not been paid amounts due for labor and materials furnished for work provided in the Contract may institute an action against the Principal and its Surety on this bond at the time and in the manner prescribed in Section 103D-324, Hawaii Revised Statutes, and have the rights and claims adjudicated in the action, and judgment rendered thereon; subject to the Obligee's priority on this bond. If the full amount of the liability of the Surety on this bond is insufficient to pay the full amount of the claims, then after paying the full amount due the Obligee, the remainder shall be distributed pro rata among the claimants. Signed this _______ day of ______________, _______. (Seal) ___________________________________ Name of Principal (Contractor) * ___________________________________ Signature ___________________________________ Title (Seal) ___________________________________ Name of Surety * __________________________________ Signature __________________________________ Title *ALL SIGNATURES MUST BE ACKNOWLEDGED BY A NOTARY PUBLIC
-2-
CHAPTER 104, HRS COMPLIANCE CERTIFICATE
The undersigned bidder does hereby certify to the following:
1. Individuals engaged in the performance of the contract on the job site shall be
paid:
A. Not less than the wages that the director of labor and industrial relations
shall have determined to be prevailing for corresponding classes of laborers and
mechanics employed on public works projects; and
B. Overtime compensation at one and one-half times the basic hourly rate
plus fringe benefits for hours worked on Saturday, Sunday, or a legal holiday of
the State or in excess of eight hours on any other day.
2. All applicable laws of the federal and state governments relating to workers’
compensation, unemployment compensation, payment of wages, and safety shall be fully
complied with.
DATED at Honolulu, Hawaii, this day of .
Name of Corporation, Partnership, or Individual
Signature and Title of Signer
Subscribed and sworn before me this day of . Notary Public, Judicial Circuit, State of Hawaii My Commission Expires:
![BYU Hawaii Curriculum Proposal Number [10-19] Section 1 ...](https://static.documents.pub/doc/80x56/621a508d4b7b547b974090c5/byu-hawaii-curriculum-proposal-number-10-19-section-1-.jpg)
![Brigham Young University - Hawaii Campus · 2019-03-20 · Form modified 2-15-18 . 2 . BYU Hawaii Curriculum Proposal Number [18-10] Section 2 – Overview (Support) Modular Curriculum](https://static.documents.pub/doc/80x56/5f0a8c917e708231d42c2dfa/brigham-young-university-hawaii-campus-2019-03-20-form-modified-2-15-18-2.jpg)
