ANNEXURE [ ] - CONTRACT TO BE EXECUTED
Supply and Services Agreement
Dated
Australian Energy Market Operator (“AEMO”)
[insert party name] (“Supplier”)
Supply and Services Agreement Contents
Supply and Services Agreement 18 February 2016
i
Details 1
General terms 3
1 Scope 3
1.1 System and Services 3 1.2 Compliance with reasonable directions 3 1.3 AEMO Inputs 3
2 Project Plan and delay management 3
2.1 Project Plan 3 2.2 Adherence to Project Plan 3 2.3 Suspension of work 4 2.4 Notice of delay 4 2.5 Extension of Timetable 4 2.6 Failure to notify delay 4 2.7 Liquidated damages 4 2.8 AEMO may grant extensions 4
3 Provision of Services 5
3.1 Time for provision of Services 5 3.2 Maintenance Services 5
4 System Integration 5
4.1 Integration with AEMO Systems 5 4.2 End-to-end integration 5 4.3 Specific responsibilities 5
5 Equipment 6
5.1 Equipment must be new 6 5.2 Design and standard 6 5.3 Title and Risk 6 5.4 Delivery 6
6 Acceptance Testing 7
6.1 Acceptance Test Plan 7 6.2 Acceptance Tests 7 6.3 Defects 7 6.4 Re-performance of Acceptance Tests 8 6.5 Failure to agree a reduction in price 8 6.6 No deemed Acceptance 8 6.7 No waiver 8 6.8 Reliance on Supplier 8
7 Warranties 9
7.1 Mutual warranties 9 7.2 General warranties 9 7.3 Software and Equipment warranties 10 7.4 Defect warranty 10
Supply and Services Agreement 18 February 2016
ii
7.5 Defect rectification 10 7.6 Failure to rectify 10 7.7 OEM Warranties 11 7.8 No other representations or warranties 11
8 Service Levels 11
8.1 Service Levels 11 8.2 Failure to meet a Service Level 11 8.3 Documentation to be updated 12
9 Variations to the Services 12
9.1 Request for variation 12 9.2 Proposal 12 9.3 Agreement to proposal 12
10 Additional Services 12
10.1 AEMO may request additional services 12 10.2 Supplier Proposal 12 10.3 Receipt of Supplier Proposal 13 10.4 Accepted Supplier Proposal 13 10.5 Extended System warranty 13 10.6 Third party suppliers 13 10.7 No unauthorised changes 13
11 Personnel 14
11.1 Supplier Personnel 14 11.2 Supplier Personnel to perform Services 14 11.3 Key Personnel 14 11.4 Removal and replacement of Key Personnel 14 11.5 Contacts 15
12 Compliance with laws 15
12.1 Laws 15 12.2 AEMO premises 16
13 Intellectual Property Rights 16
13.1 Licence 16 13.2 Third party software 16 13.3 Intellectual Property warranties 17 13.4 Intellectual Property indemnity 17 13.5 Third Party Claims 17 13.6 Handling of claims 18
14 Fees, Invoices and Payment 18
14.1 Fees 18 14.2 Rendering invoices 18 14.3 Valid invoices 18 14.4 Set-off 19 14.5 Payment 19 14.6 No change to Fees and charges 19
15 Taxes 19
15.1 Taxes 19 15.2 Evidence of payment 19
Supply and Services Agreement 18 February 2016
iii
15.3 GST 20 15.4 Withholding tax 20 15.5 No other amounts payable 20
16 Confidentiality, Privacy and Security 20
16.1 Disclosure of Confidential Information 20 16.2 Disclosure by Recipient of Confidential Information 21 16.3 Use of Confidential Information 21 16.4 Excluded Information 21 16.5 Return of Confidential Information 21 16.6 Announcements or releases 21 16.7 No disclosure of terms of this agreement 22 16.8 Survival 22 16.9 Security 22
17 Indemnities 22
17.1 Indemnity 22 17.2 Nature of indemnities 22 17.3 Reduced indemnity 22
18 Liability 23
18.1 Limit of Supplier’s liability 23 18.2 Unlimited liability 23 18.3 AEMO’s liability 23 18.4 Excluded liability 23
19 Term and Termination 23
19.1 Term 23 19.2 Termination by Supplier for cause 24 19.3 Termination for insolvency 24 19.4 Cancellation of Maintenance Services 24 19.5 Termination for cause by AEMO 24 19.6 Termination by AEMO 24 19.7 Non-exclusive remedies of AEMO 24 19.8 Partial termination 25 19.9 Disengagement 25 19.10 Term of the Licence 25
20 Force majeure 26
20.1 Force Majeure Event 26 20.2 Reasonable mitigation by Supplier 26 20.3 Procedure for Force Majeure Events 26 20.4 Effect on Fees 26 20.5 Termination 26
21 Insurance 26
21.1 Public Liability Insurance 26 21.2 Worker’s Compensation Insurance 27 21.3 Evidence of currency 27
22 Novation, assignment and subcontracting 27
22.1 Novation and assignment 27 22.2 Subcontracting 27
Supply and Services Agreement 18 February 2016
iv
23 Governance 27
23.1 Meetings and reports 27 23.2 Form of Reports 27 23.3 Retention of Records 28 23.4 Disputes 28
24 Notices 28
24.1 Form 28 24.2 Delivery 28 24.3 When effective 28 24.4 Receipt 28
25 General 29
25.1 Independent contractor 29 25.2 Entire agreement 29 25.3 Variation and waiver 29 25.4 Discretion in exercising rights 29 25.5 Partial exercise of rights 29 25.6 Approvals and consents 29 25.7 Remedies cumulative 29 25.8 No merger 29 25.9 Rights and obligations are unaffected 29 25.10 Construction 30 25.11 Counterparts 30 25.12 Survival 30
26 Governing Law 30
27 Interpretation 30
27.1 Definitions 30 27.2 References to certain general terms 38 27.3 Headings 39 27.4 Inconsistency 39
Schedule 1 - Specifications 40
Schedule 2 - Services 42
Schedule 3 - Service Levels 48
Schedule 4 - Fees 50
Schedule 5 - Project Plan 53
Schedule 6 - Software and Equipment 54
Schedule 7 - Dispute Resolution Process 55
Schedule 8 - AEMO Inputs 57
Schedule 9 - Original Equipment Manufacturer (OEM) warranties 57
Signing page 58
Supply and Services Agreement
Supply and Services Agreement 18 February 2016
1
Details
Interpretation – definitions are at the end of the General terms
Parties AEMO and Supplier
AEMO Name Australian Energy Market Operator Ltd
ABN ABN 94 072 010 327
Address Level 22, 230 Collins Street, Melbourne Vic
3000
Telephone +61 7 3347 3004
Fax
Attention Terry Day
AEMO Contact Manager - IT Grid Systems, Operations
Supplier1 Name [insert name]
ABN [insert ABN]
Address [insert address]
Telephone [insert telephone number]
Email [insert email address]
Fax [insert fax number]
Attention [insert title]
Supplier Contact [insert title]
1 Note to respondents: depending on the respondent’s corporate group structure, AEMO may require the successful respondent’s holding or parent company to provide financial and performance guarantees in a form satisfactory to AEMO. Respondents must indicate their compliance with this requirement in their completed Proposed Contract Changes.
Supply and Services Agreement 18 February 2016
2
Recitals A AEMO wishes to:
acquire two computer room air conditioning
(CRAC) units;
have that CRAC units installed (including
removal and disposal of current UPS air-
conditioning systems and associated materials),
commissioned and integrated with certain existing
systems; and
have the new system maintained; and
acquire training services in relation to the new
CRAC units.
B Following a tender process AEMO has selected the
Supplier to supply, install and integrate the CRAC units
and to provide the required maintenance and training
services, as further described in, and on the terms of, this
agreement.
C The Supplier has represented to AEMO that it is an
experienced provider of such units and services.
D The Supplier has agreed to provide the units and related
services as further described in, and on the terms of, this
agreement.
Governing law Victoria
Date of
agreement
See signing page
Public Liability
Insurance
$20 million per occurrence
Supply and Services Agreement
Supply and Services Agreement 18 February 2016
3
General terms
1 Scope
1.1 System and Services
Supplier will provide AEMO with:
(a) the System;
(b) the Deliverables; and
(c) the Services,
in accordance with this agreement.
1.2 Compliance with reasonable directions
The Supplier will, in carrying out its obligations under this agreement,
comply with all reasonable directions of AEMO.
1.3 AEMO Inputs
AEMO will provide the Supplier with the inputs described in Schedule 8.
The provision of those inputs (“AEMO Inputs”), together with the
performance of its other express obligations under this agreement, constitutes
AEMO’s entire responsibilities in relation to the performance of this
agreement.
2 Project Plan and delay management
2.1 Project Plan
The High Level Project Plan is set out in paragraph 1.1 of Schedule 5. Within
30 days of the Commencement Date, the Supplier must deliver a Detailed
Project Plan including Payment Milestones and other key dates consistent
with the High Level Project Plan.
2.2 Adherence to Project Plan
The Supplier must meet its obligations under the Project Plan2 by the times
set out in that plan.
2 Note to respondents: AEMO will require a satisfactorily detailed Project Plan to be agreed before signing and attached as Schedule 5.
Supply and Services Agreement 18 February 2016
4
2.3 Suspension of work
From time to time AEMO may, for operational or other reasons, require the
Supplier to suspend work at the AEMO Site. The Supplier will comply with
any such requirement notified to it by AEMO. If the Supplier requires an
extension of time as a result of such suspension, the Supplier must notify
AEMO in accordance with clause 2.4.
2.4 Notice of delay
As soon as it becomes apparent that any obligation under this agreement
might not be met by the date required under the Project Plan, the Supplier
must promptly notify AEMO. The notice must include:
(a) the cause of the delay;
(b) the steps the Supplier is taking to minimise the delay; and
(c) any extension of time requested to meet the affected milestones or
obligations under clause 2.5.
2.5 Extension of Timetable
To the extent to that any delay notified under clause 2.4 is attributable to a
cause beyond the reasonable control of the Supplier (including a suspension
of work under clause 2.3), AEMO will extend the time for meeting any
affected milestone or obligation by a period reasonably necessary to
overcome the effects of the delay. The Project Plan will be revised to reflect
any such extension.
2.6 Failure to notify delay
If the Supplier fails to notify AEMO of a delay in accordance with clause 2.4:
(a) AEMO is not obliged to grant an extension of time for completion of
any affected milestone or obligation;
(b) the Supplier must perform its obligations according to the Project
Plan; and
(c) any principle of law or equity that might otherwise make the date for
achievement of an obligation uncertain will not apply.
2.7 Liquidated damages
If the System does not achieve Acceptance by the Practical Completion Date,
the Supplier will pay liquidated damages to AEMO in accordance with
paragraph 4 of Schedule 4.
2.8 AEMO may grant extensions
Notwithstanding anything in this agreement, AEMO may at any time grant an
extension of time to the Supplier for the performance of obligations.
Supply and Services Agreement 18 February 2016
5
3 Provision of Services
3.1 Time for provision of Services
The Supplier will provide the Services in accordance with the dates specified
in the Project Plan.
3.2 Maintenance Services
(a) If requested to do so in writing by AEMO, the Supplier will provide
Maintenance Services for 12 months from the Practical Completion
Date.
(b) AEMO will pay Supplier Maintenance Services Fee for provision of
the Maintenance Services (subject to any AEMO entitlement to
receive Service Level Rebates).
4 System Integration
4.1 Integration with AEMO Systems
The Supplier will integrate the System with AEMO Systems in a manner that:
(a) allows continuous, efficient and transparent operation of the System
and AEMO Systems;
(b) avoids any adverse effect on the functionality or performance of
AEMO Systems (other than effects disclosed in the integration
specifications); and
(c) avoids adverse end-user impact.
4.2 End-to-end integration
The Supplier will undertake full end-to-end integration of the System with
AEMO Systems, including the development of any necessary interfaces
between the relevant systems.
4.3 Specific responsibilities
Without limiting the generality of clauses 4.1 and 4.2, the Supplier must:
(a) undertake all integration activities as required to achieve the goals set
out in clauses 4.1 and 4.2;
(b) develop integration strategies and specifications acceptable to
AEMO;
(c) work collaboratively with other parties whose equipment, software or
systems interface with the System;
(d) provide support (including relevant interface specifications and other
information relevant to the integration activities) to third party
suppliers who supply AEMO Systems or any other systems,
networks, equipment or services which interface with the System;
Supply and Services Agreement 18 February 2016
6
(e) interface the System with AEMO Systems;
(f) ensure end-to-end interworking and system performance between the
System and those components with which the System interfaces; and
(g) notify AEMO as soon as practicable of any problems the Supplier
becomes aware of concerning the integration of AEMO Systems with
the System.
5 Equipment
5.1 Equipment must be new
All Equipment that forms part of the System must be new on delivery.
5.2 Design and standard
All Equipment that forms part of the System must be of first grade design and
manufacture and must comply with the relevant Australian Standards
Association specifications.
5.3 Title and Risk
(a) Title in any Equipment or Deliverables passes to AEMO on payment
of the Payment Milestone relating to the Equipment or Deliverable.
(b) Subject to the Supplier’s obligations to indemnify AEMO under
clause 17.1, risk of loss of, or damage to, any Equipment or
Deliverables passes to AEMO on delivery of the relevant item of
Equipment or Deliverable to AEMO.
5.4 Delivery
(a) The Supplier will prepare equipment and materials for transportation
in a manner that will protect them from damage during transit. The
Supplier will obtain and maintain appropriate insurance on
deliverables during transportation, unloading, placement, and
installation at the AEMO Site.
(b) Delivery shall take place Monday through Friday between 8:00 am
and 4:00 pm. No deliveries shall be made on public holidays
applicable at the delivery site. The Supplier shall notify AEMO
representative at least 48 hours prior to the delivery time to arrange
for AEMO representative to be on site at the time of delivery.
(c) The Supplier shall be responsible for site inspection and determining
the best route for moving the Equipment at the AEMO Site. The
Supplier shall identify to AEMO representative any problem areas
along the route and work to resolve the problem to mutual
satisfaction. The Supplier shall provide floor, wall, and ceiling
protection to prevent damage to elevators, doorways, flooring, and
corridors.
Supply and Services Agreement 18 February 2016
7
6 Acceptance Testing
6.1 Acceptance Test Plan
(a) The Acceptance Test Plan is provided in Appendix 2, or as otherwise
agreed by the parties.
6.2 Acceptance Tests
(a) Supplier will perform Acceptance Tests within the Acceptance Test
Period.
(b) Where a Deliverable passes Acceptance Tests, the Supplier will issue
a certificate to AEMO Accepting the Deliverable (“Acceptance
Certificate”).
(c) When the System passes its final Acceptance Tests required for the
Practical Completion Date, the Supplier will issue a final notice to
AEMO Accepting the System (“Final Acceptance Certificate”).
(d) If a Deliverable or the System does not pass Acceptance Tests,
AEMO:
(i) will issue a notice to the Supplier rejecting the Deliverable or
the System (as relevant) (“Rejection Notice”), which
includes a list of Defects; and
(ii) within 5 Business Days of receiving the Rejection Notice, the
Supplier must correct the Defects (or, at AEMO’s election,
provide substitute Deliverables or a substitute System), and
the Acceptance Tests will then be repeated for the corrected
(or substituted) System or Deliverable.
6.3 Defects
If any Defects remain in the System or in a Deliverable following Acceptance
Tests or otherwise at the end of an Acceptance Test Period, without limiting
any other right or remedy, AEMO may:
(a) provide the Supplier with a list of Defects and the Supplier must,
within 5 days of receiving the list, correct the Defects and repeat the
Acceptance Tests;
(b) Accept the Deliverable or the System at a reduced price;
(c) rectify, or have rectified, any Defect in the Deliverable or the System
at the Supplier’s expense and set off such expenses against any
amount due to Supplier (or otherwise recover that amount as a debt
due and payable by Supplier); or
(d) by notice, terminate this agreement.
Supply and Services Agreement 18 February 2016
8
6.4 Re-performance of Acceptance Tests
If AEMO exercises its right under clause 6.3(a), the Supplier will repeat the
relevant Acceptance Tests. The Acceptance Test Period for the repeated
Acceptance Tests will be the same duration as the original Acceptance Test
Period and testing will begin no later than 7 days after the date on which
Supplier corrects the Defects in accordance with clause 6.3(a).
6.5 Failure to agree a reduction in price
If AEMO intends to exercise its right under clause 6.3(b) and the parties do
not agree on a reduced price within 7 days of AEMO notifying the Supplier
that it intends exercising such right, AEMO may, without limiting any of its
rights or remedies, terminate this agreement immediately by giving notice.
6.6 No deemed Acceptance
Neither the System, nor any Deliverable, will be taken as having been
Accepted, and AEMO does not waive any rights under clause 6 or otherwise
under this agreement if:
(a) AEMO fails to provide a list of Defects under clause 6.3; or
(b) AEMO uses the Deliverable or the System.
6.7 No waiver
The Supplier agrees that Acceptance of a Deliverable or the System by
AEMO is without prejudice to any of AEMO’s rights or remedies under this
agreement and does not affect the Supplier’s obligations to:
(a) supply Deliverables and a System that conform to the requirements of
this agreement; or
(b) to correct Defects.
6.8 Reliance on Supplier
The Supplier acknowledges and agrees that:
(a) AEMO has engaged the Supplier in reliance on the Supplier’s
representations that it has the necessary skills and expertise to deliver
the System, the Deliverables and the Services as contemplated by and
on the terms of this agreement;
(b) Acceptance or approval by AEMO of any Deliverable or
Documentation prepared by the Supplier does not in any way
diminish or reduce AEMO’s reliance on the Supplier, or the
Supplier’s obligations under this agreement to deliver a System,
Deliverables and Services that conform to the requirements of this
agreement.
Supply and Services Agreement 18 February 2016
9
7 Warranties
7.1 Mutual warranties
Each party warrants that:
(a) it has full capacity and authority to enter into and to perform this
agreement;
(b) this agreement is executed by a duly authorised representative; and
(c) once duly signed this agreement will constitute legal, valid and
binding obligations.
7.2 General warranties
The Supplier represents, warrants and undertakes to AEMO that:
(a) it will perform its obligations under this agreement in accordance
with industry best practice;
(b) it has been given adequate opportunity and access to undertake (and
has undertaken) appropriate due diligence to investigate what is
required by it to deliver the Deliverables effectively and efficiently,
deliver and integrate the System and perform the Services as required
under this agreement;
(c) AEMO Inputs are an exhaustive list of the only inputs to be provided
by AEMO to enable the Supplier to perform its obligations under this
agreement;
(d) all of the Supplier’s representations and statements as set out in this
agreement are true and correct and are not misleading or deceptive;
(e) it will comply with all laws, and any mandatory codes of conduct
applicable to it that are related in any way to the System or the
Services.
Supply and Services Agreement 18 February 2016
10
7.3 Software and Equipment warranties3
Supplier warrants that there is, or will be, no software in the System other
than the Licensed Software and the Third Party Software listed in Schedule 6
and that such Licensed Software and Third Party Software is all that is
required for AEMO to use and enjoy all of the benefits of Services and
Deliverables and the System, as contemplated by this agreement.
7.4 Defect warranty
Supplier represents, warrants and undertakes to AEMO that:
(a) the Deliverables and the System:
(i) will conform to all of the requirements set out in this
agreement;
(ii) will be fit for the purposes stated in and contemplated by this
agreement;
(iii) will comply with all applicable laws; and
(iv) will be free from any Defects;
(b) the Services will be provided with due care and skill; and
(c) the System:
(i) will be integrated successfully and will function correctly
with AEMO Systems; and
(ii) will meet the functionality and performance requirements set
out in Schedule 1.
7.5 Defect rectification
Without limiting any of its other obligations under this agreement, the
Supplier will correct all Defects occurring in any Deliverable or in the System
(or, at AEMO’s sole option, replace any Deliverable that demonstrates any
Defect) during the Warranty Period, at no additional cost to AEMO. In
performing Defect rectification, the Supplier will meet or exceed the Service
Levels set out in paragraph 1 of Schedule 3.
7.6 Failure to rectify
If the Supplier fails to correct any Defect (or, at AEMO’s sole option, replace
any defective or non-conforming Deliverable as required under clause 7.5),
AEMO may itself correct the Defect (or replace the defective or non-
conforming Deliverable), or have a third party correct the Defect or replace
3 Note to respondents: Respondents must clearly indicate whether any software is required for the continued operation of the air-conditioning units or associated equipment including any third party software or software which the supplier will develop as part of the services. If software is not required for the units or associated equipment, clauses and references related to software in the agreement will not be required.
Supply and Services Agreement 18 February 2016
11
the defective or non-conforming Deliverable. The Supplier will pay AEMO’s
costs and expenses incurred in correcting Defects or replacing Deliverables,
or in procuring Defect correction or replacement of Deliverables, under this
clause 7.6.
7.7 OEM Warranties
The System and certain components of the System will be covered by
warranties offered by the original equipment manufacturer or their authorised
reseller (“OEM Warranty”) as specified in Schedule 9. Supplier will ensure
the OEM Warranties are either in the name of, or are directly enforceable by,
AEMO. The Supplier will provide all necessary assistance to assist AEMO in
making any claim under an OEM Warranty. OEM Warranties are in addition
to, and in no way diminish or derogate from, the Supplier’s warranty
obligations under clauses 7.2 to 7.6 or otherwise under or in connection with
this agreement.
7.8 No other representations or warranties
The Supplier acknowledges that, in entering into this agreement, it has not
relied on any representations or warranties about its subject matter except as
expressly provided by the terms of this agreement.
8 Service Levels
8.1 Service Levels
The Supplier must provide the Services so as to meet or exceed the Service
Levels.
8.2 Failure to meet a Service Level
If during any Maintenance Services Term the Supplier:
(a) fails to meet a Service Level on two or more occasions in any month
then, without limiting any other right or remedy, AEMO will be
entitled to a Service Level Rebate of [insert rebate];4
(b) fails to meet a Service Level Target on four or more occasions in any
month, without limiting any other right or remedy, AEMO will be
entitled to a Service Level Rebate of [insert rebate];
4 Note to respondents: an appropriate Service Level Rebate regime will be negotiated with the successful respondent. As a guide, AEMO expects that where the respondent is engaged to provide the Maintenance Services and AEMO pays Maintenance Services Fees, Service Level Rebates will consist of a 10% per cent reduction in the monthly fees in the relevant month for each breach of a Service Level, up to a maximum rebate of 100% of the monthly fees in that month for repeated Service Level failures. Respondents should therefore, in their compliance statement against this clause, respond specifically to these requirements.
Supply and Services Agreement 18 February 2016
12
(c) fails to meet a Service Level on 5 or more occasions in any month; or
(d) correct a Severity Level 1 Defect (as described in Schedule 3) within
the time provided for in Schedule 3 on more than two occasions in
any month
without limiting any other right or remedy, AEMO may terminate this
agreement immediately by giving notice.
8.3 Documentation to be updated
If any change is made to the System or to any Software or other Deliverable
that results in the Documentation not correctly reflecting the functionality of
the System, the Software or the Deliverable, the Supplier must, within 7 days
of the change being made, update the Documentation so that it correctly
reflects current functionality.
9 Variations to the Services
9.1 Request for variation
Either party may request a variation in the nature, scope or timing of the
Services.
9.2 Proposal
Upon the issue of a request under clause 9.1, the Supplier must prepare a
proposal detailing the impact of the request on the Services, Service Levels,
Fees, Practical Completion Date and any other relevant issues.
9.3 Agreement to proposal
The Supplier must not commence to deliver any work other than the Services
until AEMO has agreed to the proposal.
10 Additional Services
10.1 AEMO may request additional services
AEMO may request the Supplier to perform additional services (“Additional
Services”) by giving notice to the Supplier specifying the proposed new
services (“Services Request”).
10.2 Supplier Proposal
The Supplier will submit a proposal (“Supplier Proposal”) in response to the
Services Request within 10 Business Days (or other agreed period) of receipt
of the Services Request that includes:
(a) a quote for the cost of implementing the Services Request based on
the time and materials rates set out in Schedule 4, including any costs
savings arising out of the change;
(b) an impact analysis of the Additional Services on the System and its
ability to meet the Specifications;
Supply and Services Agreement 18 February 2016
13
(c) a proposed project plan and timetable for implementation of the
Services Request, including any impact on the Project Plan; and
(d) any other information reasonably requested by AEMO relevant to the
Services Request.
10.3 Receipt of Supplier Proposal
Within 20 Business Days of receipt of a Supplier Proposal, AEMO must
notify the Supplier that it:
(a) accepts the Supplier Proposal, in which case the parties must execute
and date the Supplier Proposal;
(b) wishes to negotiate with the Supplier, in which case the parties will
use their best endeavours to negotiate in good faith changes to the
Supplier Proposal; or
(c) rejects the Supplier Proposal.
10.4 Accepted Supplier Proposal
If a Supplier Proposal has been accepted by AEMO in accordance with
clause 10.3(a), the services and fees set out in the Supplier Proposal will form
part of this agreement and the Additional Services described in the Supplier
Proposal will be Services provided on the terms of this agreement.
10.5 Extended System warranty
Where Additional Services involving any change to the System (including
integration of the System with any AEMO Systems) are Accepted by AEMO:
(a) during the System Warranty Period, the System Warranty Period will
be extended to apply for the period ending 12 months after the date of
issue by AEMO of the final Acceptance Certificate for those
Additional Services;
(b) after any System Warranty Period has expired, the applicable
Warranty Period is twelve months from the date of Acceptance.
10.6 Third party suppliers
Nothing in this agreement prevents AEMO from procuring any Deliverables,
Software or Additional Services from third party suppliers.
10.7 No unauthorised changes
Notwithstanding anything in this agreement, the Supplier is not entitled to be
paid for any work performed by it beyond the current scope of this agreement
unless clause 10 is complied with.
Supply and Services Agreement 18 February 2016
14
11 Personnel
11.1 Supplier Personnel
(a) The Supplier will provide sufficient resources, including personnel,
equipment and facilities, and will continue a program of management
and maintenance of those resources, to enable it to fulfil its
obligations under this agreement.
(b) Until at least the expiry of the Warranty Period, the Supplier will
ensure that the Supplier Contact, (or another senior member of
Supplier’s staff who has been involved in implementation of the
System and the Services who is acceptable to AEMO) continues to
act as a dedicated account manager available to respond to Defects
and to other questions AEMO may have about the System, the
Services and this agreement.
11.2 Supplier Personnel to perform Services
The Supplier must:
(a) ensure that Supplier Personnel do not represent themselves as being,
or allow another person, by act or omission, to be under the
misapprehension that any of them are, an employee, partner or agent
of AEMO;
(b) ensure that Supplier Personnel comply with this agreement;
(c) after receiving notice from AEMO requiring the Supplier to remove
any Supplier Personnel (which may be given in AEMO’s absolute
discretion), immediately cease the involvement of those Supplier
Personnel in the performance of the Services and promptly provide
replacements suitable to AEMO; and
(d) provide prompt notice to AEMO if any Supplier Personnel are unable
to undertake work in respect of the Services or comply with any
reasonable direction by AEMO, including promptly providing a
replacement suitable to AEMO.
11.3 Key Personnel
Supplier will use the Key Personnel to perform the roles described in
paragraph 4 of Schedule 2 in the performance of this agreement.
11.4 Removal and replacement of Key Personnel
The Supplier must not remove or replace Key Personnel without AEMO’s
consent. AEMO may require the removal and prompt replacement of Key
Personnel who are not performing their roles to AEMO’s reasonable
satisfaction. Any person who replaces Key Personnel must have comparable
qualifications and experience and be reasonably acceptable to AEMO.
Supply and Services Agreement 18 February 2016
15
11.5 Contacts
(a) The parties will each nominate a person to act as their primary points
of contact with each other in relation to the day-to-day management
and administration of this agreement (“Contact”).
(b) Each party’s Contact as at the Commencement Date is as specified in
the Details. Each party will notify the other of any changes to their
respective Contacts.
(c) The Supplier Contact must:
(i) represent Supplier in all matters relating to the supply of the
System, the Deliverables and the Services;
(ii) be responsible for overseeing the supply of the System, the
Deliverables and the Services;
(iii) act as agent for the Supplier and have authority to give or
receive communications, grant consents and issue instructions
on behalf of the Supplier;
(iv) be available at all reasonable times for consultation with the
AEMO Contact or any officer of AEMO in relation to the
supply of the System, the Deliverables and the Services, and
any other matter relating to this agreement; and
(v) communicate with AEMO through the AEMO Contact.
(d) The Supplier must fully inform itself of AEMO’s requirements from
time to time.
(e) The Supplier must keep the AEMO Contact fully informed as to
matters affecting the cost, timing, quality or ability of the Supplier to
provide the Deliverables, the System and the Services, and as to any
additional matters on which AEMO specifically requests that the
Supplier reports.
(f) The Supplier acknowledges that the AEMO Contact is not an
authorised officer of AEMO for the purposes of clause 25.3 and is
not authorised to give consents under clause 13.6.
12 Compliance with laws
12.1 Laws
In performing its obligations under this agreement the Supplier will comply
with all applicable laws including occupational health, safety and
environmental laws.
Supply and Services Agreement 18 February 2016
16
12.2 AEMO premises
(a) When the Supplier is required to be present at any AEMO premises or
facilities in connection with the provision of Services under this
agreement, the Supplier will at all times comply with:
(i) AEMO’s policies and procedures applicable to the use of and
access to such premises or facilities, including (without
limiting its obligations under clause 12.1) all applicable
occupational health, safety and environmental laws; and
(ii) any reasonable direction of any authorised AEMO person in
relation to such policies.
(b) The Supplier must ensure that it does not cause, that none of its
Representatives causes, and that none of the Equipment, System, the
Deliverables or the Services in any way causes, any personal injury,
death or loss of or damage to real or tangible personal property under
or in connection with this agreement.
(c) The Supplier must, where appropriate, supply adequate health and
safety information concerning any Equipment included in or used in
connection with any Services, System or Deliverables provided under
this agreement and ensure that they will be safe when properly used,
supplied, maintained and stored. The Supplier must at all times keep
AEMO informed of all relevant information which becomes known to
the Supplier concerning their use, supply, maintenance and storage.
(d) All information to be provided to AEMO in accordance with
paragraph (c) must be provided to AEMO’s Contact.
13 Intellectual Property Rights
13.1 Licence
The Supplier grants AEMO a perpetual, non-exclusive, irrevocable licence to:
(a) use and reproduce the Licensed Software and Developed Software
(either alone or with other software or documentation) and all other
Deliverables in any manner, anywhere in the world and for any
purpose;
(b) permit any person to assist AEMO to do any of the things referred to
in paragraph (a); and
(c) sublicense any of the rights described in paragraph (a) or (b) to any
person.
13.2 Third party software
(a) At the date of this agreement:
(i) AEMO consents to the use of the Third Party Software listed
at paragraph 1.2 of Schedule 6; and
Supply and Services Agreement 18 February 2016
17
(ii) unless otherwise agreed by AEMO, the Supplier will procure
a licence for AEMO to use that Third Party Software on
terms acceptable to AEMO.
(b) The Supplier will obtain AEMO’s consent before using additional
Third Party Software as part of the System.
(c) If AEMO consents to the use of additional Third Party Software
under clause 13.2(b) the Supplier will:
(i) update the list of Third Party Software at paragraph 1.2 of
Schedule 6; and
(ii) procure a licence for AEMO to use such additional Third
Party Software on terms acceptable to AEMO.
13.3 Intellectual Property warranties
The Supplier warrants that none of:
(a) supply by it and AEMO’s use of the Services, the Deliverables and
the System;
(b) AEMO’s exercise of the Developed Intellectual Property Rights; or
(c) AEMO’s exercise of any Intellectual Property Rights in the Licensed
Software under clause 13.1, (including use by persons under clause
13.1(b) and by sublicensees under clause 13.1(c)),
(together the “Warranted IP”) will infringe any rights (including Intellectual
Property Rights and Moral Rights) of any other person, or constitute a misuse
of any person’s Confidential Information.
13.4 Intellectual Property indemnity
The Supplier indemnifies AEMO and its Representatives (“those
Indemnified”) against any loss, damage, injury, liability, cost or expense
(including legal costs and expenses on a full indemnity basis) suffered or
incurred by any of those Indemnified, to the extent such loss, damage, injury,
liability, cost or expense is suffered or incurred as a result of any Claim
against any of those Indemnified that any of the Warranted IP infringes the
Intellectual Property Rights of any person (“Third Party Claim”).
13.5 Third Party Claims
Without limiting AEMO’s rights under clauses 13.3 and 13.4, if a Third Party
Claim arises the Supplier must (at AEMO’s option):
(a) procure the right for AEMO to continue using the infringing item; or
(b) replace or modify the infringing item so that it becomes non-
infringing,
within 30 days of being notified of the Third Party Claim.
Supply and Services Agreement 18 February 2016
18
13.6 Handling of claims
(a) AEMO will notify the Supplier promptly of any alleged Third Party
Claim.
(b) The Supplier will be responsible for the defence of any Third Party
Claim. On request, AEMO will provide the Supplier with reasonable
assistance with the Third Party Claim, provided the Supplier meets
AEMO’s costs of doing do.
(c) The Supplier must not agree to any settlement of a Third Party Claim
that would involve AEMO doing or refraining from doing anything
without AEMO’s consent.
14 Fees, Invoices and Payment
14.1 Fees
In consideration of the Supplier’s performance of its obligations under this
agreement, AEMO will pay the Supplier the Fees in accordance with this
agreement.
14.2 Rendering invoices
Unless otherwise agreed, invoices may only be rendered to AEMO once
AEMO has issued an Acceptance Certificate in respect of achievement by the
Supplier of a Payment Milestone. AEMO is not required to make any
payment to the Supplier until all of the requirements of this agreement have
been satisfied in respect of the Deliverables and Services (as relevant) to be
provided at the relevant Payment Milestone and an invoice has been properly
rendered to AEMO by the Supplier in accordance with clause 14. If the
Supplier is providing Maintenance Services, invoices for the Maintenance
Services Fees may be rendered at the intervals specified in Schedule 4. No
Maintenance Services Fees will be payable in relation to Defects.
14.3 Valid invoices
Invoices must comply with clause 14.1, be properly completed by the
Supplier, forwarded to the billing address specified in paragraph 3.1 of
Schedule 4 and state the following:
(a) the name of any relevant Payment Milestone and the claimed date of
completion of the Payment Milestone;
(b) particulars of the Deliverables and Services (as relevant), including
the dates of their supply; and
(c) the amount of GST (if any) included in the amount invoiced.
Supply and Services Agreement 18 February 2016
19
Invoices rendered to AEMO must be accompanied by a copy of the
Acceptance Certificate applicable to the relevant Payment Milestone, signed
by AEMO.
14.4 Set-off
AEMO may set off or deduct from any amount due to the Supplier all or any
amount owed by Supplier to AEMO for any reason, including any amount
owed to AEMO in relation to:
(a) any sum in dispute between the parties;
(b) any liquidated damages for late delivery to which AEMO is entitled
under this agreement;
(c) any Service Level Rebates to which AEMO is entitled under this
agreement;
(d) any Deliverable that has been rejected by AEMO or which AEMO
has refused to take delivery of.
14.5 Payment
Subject to the requirements of clause 14, AEMO will pay each properly
rendered invoice within 30 days of its receipt.
14.6 No change to Fees and charges
Fees and charges payable by AEMO under this agreement are fixed for the
Term and must not be varied without AEMO’s written consent, which may be
withheld or granted in AEMO’s absolute discretion.
15 Taxes
15.1 Taxes
The Supplier is responsible for all Taxes arising from or relating to this
agreement and must pay:
(a) Taxes that are imposed on the Supplier, directly to the relevant
Government Agency; and
(b) Taxes that are imposed on AEMO, directly to the relevant
Government Agency on behalf of AEMO,
on or before the latest date that the Tax is due for payment without incurring
any penalty or additional tax for late payment.
15.2 Evidence of payment
Where the Supplier pays Taxes imposed on AEMO under clause 15.1(b), the
Supplier must provide to AEMO notification evidencing, to the satisfaction of
AEMO, the full and timely payment of the relevant Taxes. Such notice must
be provided within 3 days of a payment by Supplier pursuant to clause
15.1(b).
Supply and Services Agreement 18 February 2016
20
15.3 GST
The parties agree that:
(a) unless expressly stated otherwise, the consideration specified in this
agreement does not include any amount of GST;
(b) if a supply under this agreement is subject to GST, and the
consideration payable or to be provided for the supply is not
expressed to include GST, the party receiving the supply must pay to
the party making the supply an additional amount equal to the
Amount of the Consideration multiplied by the applicable GST rate;
(c) the additional amount is payable at the same time as the consideration
for the supply is payable or is to be provided, however, the additional
amount need not be paid until the party making the supply gives the
party receiving the supply a Tax Invoice;
(d) if the additional amount differs from the amount of GST payable by
the party making the supply, the parties must adjust the additional
amount; and
(e) if a party is entitled to be reimbursed or indemnified under this
agreement, the amount to be reimbursed or indemnified does not
include any amount for GST for which the party is entitled to an Input
Tax Credit.
15.4 Withholding tax
If a law requires AEMO to deduct an amount in respect of Taxes from a
payment under this agreement:
(a) AEMO agrees to deduct the amount for the Taxes; and
(b) AEMO agrees to pay an amount equal to the amount deducted to the
relevant Government Agency in accordance with applicable law and
give the original receipts to Supplier.
15.5 No other amounts payable
Other than payment of the relevant amounts under clause 15, there are no
other amounts payable by AEMO under this agreement.
16 Confidentiality, Privacy and Security
16.1 Disclosure of Confidential Information
No Confidential Information of a party (“Disclosing Party”) may be
disclosed by the party receiving the Confidential Information (“Recipient”)
to any person except:
(a) to Representatives of the Recipient or its Related Bodies Corporate
requiring the information for the purposes of this agreement;
Supply and Services Agreement 18 February 2016
21
(b) with the consent of the Disclosing Party which consent may be given
or withheld in its absolute discretion;
(c) if the Recipient is required to do so by law or by a stock exchange;
(a) where AEMO is the Recipient, if required to do so by any
Government Agency, including disclosing Confidential Information
to a Representative of the Government Agency at the direction of a
Government Agency; or
(d) if the Recipient is required to do so in connection with legal
proceedings relating to this agreement.
16.2 Disclosure by Recipient of Confidential Information
Any party disclosing information under clauses 16.1(a) or 16.1(b) must use
all reasonable endeavours to ensure that persons receiving Confidential
Information from it do not disclose the information except in the
circumstances permitted in clause 16.1.
16.3 Use of Confidential Information
A Recipient must not use Confidential Information except to the extent
necessary for the purposes of exercising its rights or performing its
obligations under this agreement.
16.4 Excluded Information
Clauses 16.1, 16.2 and 16.3 do not apply to the Excluded Information.
16.5 Return of Confidential Information
(a) Subject to paragraph (b), a Recipient must, on the request of the
Disclosing Party, promptly deliver to the Disclosing Party all
documents or other materials containing or referring to the
Confidential Information of the Disclosing Party in its possession,
power or control or in the possession, power or control of persons
who have received Confidential Information from it under clauses
16.1(a) or 16.1(b).
(b) Nothing in paragraph (a) or otherwise in this agreement prevents
AEMO from retaining, using or disclosing Software, Documentation
or other Deliverables as permitted under this agreement.
16.6 Announcements or releases
(a) The Supplier must not make press or other announcements or releases
relating to this agreement and the transactions the subject of this
agreement without AEMO’s approval as to the form and manner of
the announcement or release unless and to the extent that the
announcement or release is required to be made by the Supplier by
law or by a stock exchange.
(b) AEMO may at any time and at its discretion make any press or other
announcements or releases relating to this agreement and the
Supply and Services Agreement 18 February 2016
22
transactions the subject of this agreement without requiring the
Supplier’s approval.
16.7 No disclosure of terms of this agreement
Except as otherwise agreed or required by law, by any regulatory authority, or
by any Government Agency, no party will disclose the terms of this
agreement to any person other than its employees, accountants, auditors,
financial advisers or legal advisers on a confidential basis.
16.8 Survival
Clause 16 will survive termination (for whatever reason) or expiry of this
agreement.
16.9 Security
The Supplier must comply with AEMO’s security and office regulations
when on AEMO’s premises or accessing any of AEMO’s computer systems.
AEMO will make a copy of the regulations available on request by the
Supplier.
17 Indemnities
17.1 Indemnity
The Supplier indemnifies AEMO and its Representatives (“those
Indemnified”) against any loss, damage, injury, liability, cost or expense
(including legal costs and expenses on a full indemnity basis) suffered or
incurred by any of those Indemnified, to the extent such loss, damage, injury,
liability, cost or expense is suffered or incurred as a result of:
(a) any injury to, or death of any person and any loss of, or damage to, a
any person’s real or personal property caused or contributed to by the
Supplier or a Representative of the Supplier; or
(b) fraud by the Supplier or by a Representative of the Supplier,
in connection with the Supplier’s performance of its obligations under and in
connection with this agreement.
17.2 Nature of indemnities
The indemnities in this agreement are continuing obligations, independent
from the Supplier’s other obligations under this agreement and continue after
this agreement ends. It is not necessary for AEMO to incur expense or make
payment before enforcing a right of indemnity under this agreement.
17.3 Reduced indemnity
Supplier Supplier’s liability to indemnify those Indemnified under this
agreement will be reduced proportionally to the extent that a negligent act or
omission of any of those Indemnified suffering loss, damage, costs or expense
has contributed to the relevant loss, damage, costs or expense.
Supply and Services Agreement 18 February 2016
23
18 Liability
18.1 Limit of Supplier’s liability
Subject to clauses 18.2 and 18.4, the Supplier’s total liability to AEMO under
or in connection with this agreement (whether in contract, tort (including
negligence), under statute or otherwise) is limited to $20 million.
18.2 Unlimited liability
Clause 18.1 does not limit the Supplier’s liability under or in connection with
this agreement in relation to:
(a) its obligations to indemnify AEMO and its Representatives under
clauses 13.4 and 17; or
(b) liability arising from any breach by Supplier of clauses:
(i) 16; and
(ii) 21.
18.3 AEMO’s liability
(a) AEMO’s total liability to the Supplier under or in connection with
this agreement (whether in contract, tort (including negligence), under
statute or otherwise), is limited to the Fees paid or payable for
Services or Deliverables that have actually been provided by Supplier
in accordance with this agreement.
18.4 Excluded liability
(a) Subject to clause 18.4(b), neither party will be liable (whether in
contract, tort (including negligence), under statute or otherwise) to the
other party for:
(i) loss of profits, business, revenue, goodwill, opportunity or
anticipated savings; or
(ii) for any other such form of indirect or consequential loss or
damage.
(b) The Supplier will be liable for loss of the type described in clause
18.4(a) to the extent that it is insurable under the insurances the
Supplier is required to maintain under clause 21, and in respect of any
of the liabilities contemplated by clause 18.2.
19 Term and Termination
19.1 Term
This agreement commences on the Commencement Date and continues until
the parties have performed all of their obligations under this agreement
(including, if applicable, during the Maintenance Services Term), subject to
earlier termination in accordance with this agreement (“Term”).
Supply and Services Agreement 18 February 2016
24
19.2 Termination by Supplier for cause
The Supplier is only entitled to terminate this agreement on the grounds of
breach by AEMO where AEMO has failed to pay Fees in excess of $25,000
which are not the subject of a Dispute under clause 23.4, for a period in
excess of 30 Business Days after service of notice by the Supplier demanding
payment to AEMO.
19.3 Termination for insolvency
Either party may terminate this agreement immediately by giving notice if the
other party or a Related Body Corporate of the other party becomes (or
threatens to become) Insolvent.
19.4 Cancellation of Maintenance Services
AEMO may, at any time, cancel the provision of Maintenance Services by
providing the Supplier with no less than 90 days’ notice. On cancellation, the
Supplier is no longer required to provide the Maintenance Services and
AEMO will not be required to pay the Maintenance Services Fees.
19.5 Termination for cause by AEMO
AEMO may terminate this agreement immediately by notice to the Supplier if
the Supplier commits a material breach of this agreement and:
(a) the breach is not capable of being cured; or
(b) the breach is capable of being cured but the Supplier fails to cure the
breach within 30 days of receiving a notice requiring it to rectify the
breach.
19.6 Termination by AEMO
Without limiting clause 19.4, AEMO may terminate this agreement as
provided in clauses 6.3, 6.5 and 8.2(c).
19.7 Non-exclusive remedies of AEMO
If this agreement terminates due to breach by the Supplier, AEMO may,
without limiting any other right or remedy, do any one or more of the
following:
(a) if this agreement is terminated under clauses 6.3 or 6.5, AEMO may
recover from the Supplier (as a debt) the amount of any payments
made to the Supplier under this agreement together with interest
calculated from the payment date to the date of refund at the 30 day
Australian Treasury Bill rate plus 5%;
(b) AEMO may recover from the Supplier (as a debt) the amount of any
payments made to Supplier under this agreement for:
(i) any Deliverables or any part of the System not delivered; or
(ii) Services not provided,
Supply and Services Agreement 18 February 2016
25
together with interest calculated from the payment date to the date of
refund at the 30 day Australian Treasury Bill rate plus 5%;
(c) AEMO may purchase, from alternative suppliers, a system similar to
the System or services similar to the Services (“Agreement Items”)
and the Supplier will be liable to pay AEMO:
(i) the purchase price of the Agreement Items less the amount
payable to the Supplier for them, plus any amounts paid to the
Supplier for them; and
(ii) any costs involved in doing so; and
(d) AEMO may set off, or recover as a debt, any loss or damage suffered
or incurred by AEMO as a consequence of the termination of this
agreement, whether or not the loss or damage arose from one or more
breaches that gave rise to the right to terminate or from the
termination itself.
19.8 Partial termination
(a) In any of the circumstances in clause 19 in which AEMO may
terminate this agreement, AEMO may instead terminate any part of
this agreement (including part complete Deliverables or any part of
the Services).
(b) Supplier must continue to deliver the remainder of the System and
Deliverables and provide the remainder of the Services.
(c) Any such partial termination will lead to a reduction in the Fees for
the remainder of the System, Deliverables or Services and the parties
will agree in good faith all required consequential amendments.
(d) Subject to any consequential amendments required to this agreement
as a result of the partial termination, the parties will be subject to the
same rights and obligations as existed before the partial termination.
19.9 Disengagement
On termination of this agreement or cancellation of the Maintenance Services
under clause 19.4, the Supplier must do all things necessary, execute all
documents required and provide AEMO with all assistance AEMO
reasonably considers necessary or desirable, to enable services similar to the
Services to be provided to AEMO internally or by a replacement supplier, in
a manner that ensures orderly transition on exit and continuity of service to
AEMO, at AEMO’s cost. The Supplier must use reasonable endeavours to
minimise any such costs to AEMO.
19.10 Term of the Licence
The licence in clause 13.1 survives the termination (for any reason) or expiry
of this agreement.
Supply and Services Agreement 18 February 2016
26
20 Force majeure
20.1 Force Majeure Event
Neither party will be liable to the other for any delay or non-performance of
its obligations under this agreement to the extent to which it arises from any
Force Majeure Event.
20.2 Reasonable mitigation by Supplier
The Supplier must take all reasonable precautions, and implement reasonable
alternative measures in accordance with best industry practice to avoid or
mitigate the effects of any Force Majeure Event, including implementing
business continuity or disaster recovery plans and procedures.
20.3 Procedure for Force Majeure Events
A party whose performance under this agreement is affected by a Force
Majeure Event must:
(a) promptly notify the other party in writing of the Force Majeure Event
and the cause and the likely duration of any consequential delay or
non-performance of its obligations; and
(b) use all reasonable endeavours to avoid or mitigate the effect of the
event on the other party and the performance of the affected party’s
obligations and resume full performance of its obligations as soon as
reasonably possible, at no cost to the other party.
20.4 Effect on Fees
If the Supplier is affected by a Force Majeure Event, AEMO will not be
obliged to pay the Fees which relate to the Supplier’s obligations that are
affected by that Force Majeure Event for so long as the affected obligations
remain unperformed.
20.5 Termination
If a Force Majeure Event continues for a period of 20 Business Days or more,
AEMO may by notice to the Supplier terminate this agreement if the Force
Majeure Event materially affects the performance of this agreement or
materially impacts on the business of AEMO.
21 Insurance
21.1 Public Liability Insurance
The Supplier must maintain Public Liability Insurance for at least the
amounts specified in the Contract Details with an insurer reasonably
acceptable to AEMO during the period it provides the Deliverables, the
System and the Services.
Supply and Services Agreement 18 February 2016
27
21.2 Worker’s Compensation Insurance
During the Term, the Supplier must maintain worker’s compensation
insurance in accordance with applicable statutory requirements that cover the
Supplier for claims against it by any person employed or hired by the
Supplier who provides Services in relation to this agreement.
21.3 Evidence of currency
The Supplier must provide AEMO with evidence of the currency of the
required insurance on request.
22 Novation, assignment and subcontracting
22.1 Novation and assignment
(a) The Supplier must not novate, assign or otherwise deal with any of its
rights or obligations under this agreement without AEMO’s prior
consent.
(b) AEMO may novate, assign or otherwise deal with any of its rights or
obligations under this agreement upon giving notice to the Supplier
and the Supplier will promptly execute any documents necessary to
give effect to this.
22.2 Subcontracting
(a) The Supplier must not subcontract the performance of any of its
obligations under this agreement without AEMO’s consent. AEMO
consents to the use of the subcontractors listed at paragraph 5 of
Schedule 2, for the scope of work described in that paragraph.
(b) The Supplier remains responsible for the performance of any
obligations that it subcontracts and for the acts and omissions of its
subcontractors as if they were the Supplier’s acts and omissions.
23 Governance
23.1 Meetings and reports
The Supplier will ensure that the Supplier Contact (and other relevant
Supplier Personnel as AEMO may from time to time require) are available to
attend meetings on a regular basis as required by AEMO.
23.2 Form of Reports
(a) All Reports must be in the form reasonably required by AEMO from
time to time.
(b) If the form or content of a Report is not in accordance with this
agreement, AEMO may, without limiting any of its rights under this
agreement, require the Supplier to submit a revised Report
satisfactory to AEMO within 5 Business Days.
Supply and Services Agreement 18 February 2016
28
23.3 Retention of Records
The Supplier must retain all records relevant to this agreement and to the
Supplier’s performance of its obligations under this agreement for at least
seven years following the expiry or termination of this agreement.
23.4 Disputes
If a Dispute arises under this agreement, the parties will follow the process
described in Schedule 7.
24 Notices
24.1 Form
Unless expressly stated otherwise in this agreement, all notices, certificates,
consents, approvals, agreements, waivers and other communications under
this agreement (“Notices”) must be in writing, signed by the sender (if an
individual) or an authorised officer of the sender and marked for the attention
of the person shown in the Details or, if the recipient has notified otherwise,
then marked for attention in the last way notified.
24.2 Delivery
Notices must be:
(a) left at the address shown in the Details;
(b) sent by prepaid ordinary post (airmail if appropriate) to the address
shown in the Details;
(c) sent by fax to the fax number shown in the Details; or
(d) sent by electronic message to the email address shown in the Details.
If the intended recipient has notified a change of postal address or changed
fax number or email address, then the communications must be to that
address or number or email address.
24.3 When effective
Notices take effect from the time they are received unless a later time is
specified.
24.4 Receipt
Notices are taken to have been received:
(a) if sent by post, three days after posting (or seven days after posting if
sent to or from a place outside Australia);
(b) if sent by fax, at the time shown in the transmission report as the time
that the whole fax was sent; and
Supply and Services Agreement 18 February 2016
29
(c) if sent by electronic message, at the time shown in a report by the
computer from which the electronic message was sent, indicating that the
message was delivered in its entirety to the electronic mail address of the
recipient.
25 General
25.1 Independent contractor
The Supplier is engaged as a contractor and not as an agent of AEMO.
25.2 Entire agreement
This agreement constitutes the entire agreement between the parties relating
to its subject matter and supersedes all prior understandings, arrangements
and agreements between the parties.
25.3 Variation and waiver
A provision of this agreement or a right created under it, may not be varied or
waived except in writing, signed by an authorised officer of the party or
parties to be bound.
25.4 Discretion in exercising rights
A party may exercise a right or remedy or give or refuse its consent in any
way it considers appropriate (including by imposing conditions), unless this
agreement expressly states otherwise.
25.5 Partial exercise of rights
If a party does not exercise a right or remedy fully or at a given time, the
party may still exercise it later.
25.6 Approvals and consents
By giving its approval or consent, a party does not make or give any warranty
or representation as to any circumstance relating to the subject matter of the
consent or approval.
25.7 Remedies cumulative
The rights and remedies provided in this agreement are in addition to other
rights and remedies given by law independently of this agreement.
25.8 No merger
The warranties in this agreement do not merge under any circumstances
(including Acceptance).
25.9 Rights and obligations are unaffected
Rights given to the parties under this agreement and the parties’ liabilities
under it are not affected by anything which might otherwise affect them by
law.
Supply and Services Agreement 18 February 2016
30
25.10 Construction
No rule of construction applies to the disadvantage of a party because that
party was responsible for the preparation of, or seeks to rely on, this
agreement or any part of it.
25.11 Counterparts
This agreement may consist of a number of copies, each signed by one or
more parties to the agreement. If so, the signed copies are treated as making
up the one document and the date on which the last counterpart is executed
will be the date of the agreement.
25.12 Survival
Clauses 7, 13.3 to 13.6, 16, 17, 19, 25, 26 and 27 and any other provisions of
this agreement that expressly (or by necessary implication) survive the
termination (for any reason) or expiry of this agreement, survive such
termination or expiry, as do any rights and remedies that have accrued before
termination.
26 Governing Law
This agreement is governed by the law in force in the place specified in the
Details. Each party submits to the non-exclusive jurisdiction of the courts of
that place.
27 Interpretation
27.1 Definitions
The following meanings apply unless the contrary intention appears:
Acceptance means acceptance of the System or a Deliverable under clause 6.
Acceptance Certificate means a notice issued by AEMO under clause 6.2(b).
Acceptance Tests means testing the System and Deliverables for Defects.
Acceptance Test Period means the period for conducting Acceptance Tests
specified in the Project Plan.
Acceptance Test Plan means the plan agreed by the parties as described in
clause 6.1.
Additional Services has the meaning given in clause 10.1.
AEMO Contact means the person appointed by AEMO as its Contact as
described in clause 11.5.
AEMO Inputs has the meaning given in clause 1.3.
AEMO Material means all Material provided by AEMO to Supplier for the
purposes of this agreement.
Supply and Services Agreement 18 February 2016
31
AEMO Personnel means all employees, agents, officers and directors of
AEMO.
AEMO Site means the AEMO location where Supplier is required under this
agreement to deliver the System and to provide the Services as specified at
paragraph 4 of Schedule 1.
AEMO Systems means the systems listed in paragraph 5 of Schedule 1.
Amount of the Consideration means:
(a) the amount of any payment in connection with a supply; and
(b) in relation to non-monetary consideration in connection with a
supply, the GST Exclusive Market Value of that consideration as
reasonably determined by the party making the supply.
Business Day means a day other than a Saturday, a Sunday or a public
holiday in Melbourne, Victoria or Sydney, New South Wales or Brisbane,
Queensland.
Claim means any allegation, claim, proceeding, suit or demand.
Commencement Date means the date of this agreement as specified in the
Details.
Confidential Information means all Information disclosed to the Recipient
by the Discloser or disclosed by a third party which the Discloser is required
to keep confidential, including:
(a) any drawings provided by AEMO to the Supplier; and
(b) information which, either orally or in writing, is designated or
indicated as being the proprietary or confidential information of the
Discloser or any of its Related Bodies Corporate or a third party to
whom the Discloser owes an obligation of confidentiality; and
(c) information derived or produced partly or wholly from the
Information including without limitation any calculation, conclusion,
summary or computer modelling; and
(d) information which is capable of protection at law or in equity as
confidential information,
whether the Information was disclosed:
(e) orally, in writing or in electronic or machine readable form;
(f) before, on or after the date of this agreement; or
(g) by the Disclosing Party, any of its Representatives, any of its Related
Bodies Corporate, any Representatives of its Related Bodies
Corporate or by any third person.
Contact has the meaning given in clause 11.5(a).
Supply and Services Agreement 18 February 2016
32
Controller has the meaning it has in the Corporations Act.
Corporations Act means the Corporations Act 2001 (Cth).
Decommissioning Services means all Services pertaining to the
decommissioning and removal of existing AEMO Systems, including the
Services identified at paragraph 1.1 of Schedule 2.
Defect means:
(a) a failure of the System or any Deliverable to meet any of the
requirements of this agreement, including the Specifications; or
(b) any part of the System (including data written by the System):
(i) causes an error message to be displayed by the system that it
is running on or being accessed from;
(ii) results in the System doing something that it was not designed
to do; or
(iii) results in the System not doing something that it was designed
to do; or
(c) any defect covered by an OEM Warranty.
Deliverables means:
(a) the deliverables listed in paragraph 3 of Schedule 1, including the
Documentation and the System (and each part of the System);
(b) New Releases and Updates; and
(c) any deliverables provided as part of or in connection with any
Additional Services.
Detailed Project Plan means the Project Plan to be developed and approved
by AEMO as described in clause 2.1 and in paragraph 1.2 of Schedule 5.
Details means the section in this agreement headed “Details”.
Developed Intellectual Property Rights means Intellectual Property Rights
created by or on behalf of Supplier (or any sub-contractor) in performing
obligations under this agreement (including any Intellectual Property Rights
in the Developed Software).
Developed Software means software developed by Supplier (or any sub-
contractor) under this agreement as part of the performance of this agreement
by Supplier, including any software developed to interface and integrate the
System, and including the software specified at paragraph 1 of Schedule 6.
Disclosing Party has the meaning given in clause 16.1.
Dispute includes any dispute, controversy, difference or claim arising out of
or in connection with this agreement or the subject matter of this agreement,
Supply and Services Agreement 18 February 2016
33
including any question concerning its formation, validity, interpretation,
breach or termination.
Documentation means:
(a) the documentation described in paragraph 3 of Schedule 1; and
(b) any other documentation provided to AEMO by, or on behalf of,
Supplier under this agreement; and
(c) any changes (including additions) to the documentation described in
paragraphs (a) and (b).
Equipment means the equipment that forms part of the System, including the
Equipment listed at paragraph 2 of Schedule 6.
Excluded Information means Confidential Information which:
(a) is in or becomes part of the public domain otherwise than through
breach of this agreement or an obligation of confidence owed to the
Disclosing Party or any Related Body Corporate or Representative of
the Disclosing Party; or
(b) the Recipient can prove by contemporaneous written documentation
was already known to it at the time of disclosure by the Disclosing
Party or its Representatives (unless such knowledge arose from
disclosure of information in breach of an obligation of
confidentiality); or
(c) the Recipient acquires from a source other than the Disclosing Party
or any Related Body Corporate or Representative of the Disclosing
Party where such source is entitled to disclose it.
Fees means the fees set out in Schedule 4.
Final Acceptance Certificate means a notice issued by AEMO under clause
6.2(c).
Force Majeure Event means:
(a) natural disaster, governmental intervention, war, fire, flood,
explosion, theft of material items, civil commotion, armed hostilities,
act of terrorism, revolution;
(b) blockade, picket, embargo, strike, lock-out, sit-in, industrial or trade
dispute to the extent to which those things do not involve employees
of the party claiming relief;
(c) any event including any act or omission of any third party (other than
a subcontractor) beyond its reasonable control which could not
reasonably be planned for or avoided.
Government Agency means any governmental, semi-governmental,
administrative, fiscal, judicial or quasi-judicial body, department,
commission, authority, tribunal, agency or entity having jurisdiction over, or
Supply and Services Agreement 18 February 2016
34
any administrative responsibilities for or in connection with, AEMO or this
agreement.
GST means the tax imposed by the GST Act and the related imposition Acts
of the Commonwealth.
GST Act means the A New Tax System (Goods and Services Tax) Act 1999
(Cth), as amended from time to time.
GST Exclusive Market Value has the meaning given in the GST Act.
High Level Project Plan means the Project Plan set out at paragraph 1.1 of
Schedule 5.
Information means all information regardless of its Material Form, relating
to or developed in connection with:
(a) the business, technology or other affairs of the Disclosing Party or
any Related Body Corporate of the Disclosing Party;
(b) any systems, technology, ideas, concepts, know-how, techniques,
designs, specifications, blueprints, tracings, diagrams, models,
functions, capabilities and designs (including computer software,
manufacturing processes or other information embodied in drawings
or specifications), intellectual property or any other information which
is marked “confidential” or is otherwise indicated to be subject to an
obligation of confidence, owned or used by or licensed to the
Disclosing Party or a Related Body Corporate of the Disclosing Party.
Input Tax Credit has the meaning given in the GST Act.
A person is Insolvent if:
(a) it is (or states that it is) an insolvent under administration or insolvent
(each as defined in the Corporations Act);
(b) it has had a Controller appointed, or is in liquidation, in provisional
liquidation, under administration or wound up or has had a Receiver
appointed to any part of its property;
(c) it is subject to any arrangement, assignment, moratorium or
composition, protected from creditors under any statute or dissolved
(in each case, other than to carry out a reconstruction or amalgamation
while solvent on terms approved by the other parties to this
agreement);
(d) an application or order has been made, resolution passed, proposal put
forward, or any other action taken, in each case in connection with
that person, which is preparatory to or could result in any of (a), (b) or
(c);
(e) it is taken (under section 459(F)(1) of the Corporations Act) to have
failed to comply with a statutory demand;
Supply and Services Agreement 18 February 2016
35
(f) it is the subject of an event described in section 459(C)(2)(b) or
section 585 of the Corporations Act (or it makes a statement from
which another party to this agreement reasonably deduces it is so
subject);
(g) it is otherwise unable to pay its debts when they fall due; or
(h) something having a substantially similar effect to any or all of (a) to
(g) happens in connection with that person under the law of any
jurisdiction.
Intellectual Property Rights means all intellectual property rights including
current and future registered and unregistered rights in respect of copyright,
designs, circuit layouts, trade marks, trade secrets, know-how, confidential
information, patents, invention and discoveries and all other intellectual
property as defined in article 2 of the convention establishing the World
Intellectual Property Organisation 1967.
Key Personnel and their roles are identified in paragraph 4 of Schedule 2.
Licensed Software means all software or Documentation owned by, or
licensed to, Supplier or a sub-contractor and listed in paragraph 1.1 of
Schedule 6.
Maintenance Services means the services described in paragraph Error!
Reference source not found. of Schedule 2.
Maintenance Services Fees means the fees payable by AEMO for the
Maintenance Services, as described in Schedule 4.
Maintenance Services Term means the period commencing on the Go Live
Date and ending on the expiry of a period of twelve months, and continuing
thereafter until terminated by AEMO in accordance with clause Error!
Reference source not found..
Material includes information embodied or encoded in any form and
includes any form of storage from which the information can be reproduced.
Moral Rights means any moral rights including the rights described in
Article 6 of the Berne Convention for Protection of Literary and Artistic
Works 1886 (as amended and revised from time to time), being “droit moral”
or other analogous rights arising under any statute (including the Copyright
Act 1968 (Cth) or any other law of the Commonwealth of Australia), that
exist or that may come to exist, anywhere in the world.
New Release means software (other than an Update) that has been provided
primarily to provide an extension, alteration, improvement, or additional
functionality to the System or to the Software.
OEM Warranty has the meaning given in clause 7.7.
Payment Milestone means any date for provision of a Deliverable, a Service
or the System under the Project Plan, which is identified as a Payment
Milestone in the table set out at paragraph 2 of Schedule 4.
Supply and Services Agreement 18 February 2016
36
Practical Completion Date means the date on which the System is to be
fully installed and commissioned, as shown in paragraph 2 of Schedule 4.
Problem has the meaning given to it in Schedule 2.
Project means delivery of the System and Services by the Supplier in
accordance with and on the terms of this agreement.
Project Phase means a phase of the Project identified in the High Level
Project Plan.
Project Plan means the High Level Project Plan set out in Schedule 5 and,
when approved by AEMO, the Detailed Project Plan.
Receiver includes a receiver or receiver and manager.
Recipient has the meaning given in clause 16.1.
Rejection Notice means a notice issued by AEMO under clause 6.2(d)(i).
Related Body Corporate has the meaning given in the Corporations Act.
Reports means the reports specified in paragraph 3 of Schedule 1, and any
other reports that AEMO may reasonably require.
Representative of a party includes an employee, agent, officer, director,
auditor, adviser, partner, consultant, joint-venturer or sub-contractor of that
party (excluding, in the case of AEMO’s Representatives, Supplier).
Services means the services that Supplier is required to provide under this
agreement, including the following services specified in Schedule 2:
(a) the Decommissioning Services;
(b) the Supply and Installation Services;
(c) the Maintenance Services; and
(d) the Training Services.
“Services” includes all additional incidental services that the Supplier must
perform or provide to ensure that the System and the Services are delivered as
required by this agreement.
Service Level means a service level set out in Schedule 3.
Service Level Rebate means a fee rebate to which AEMO is entitled for a
Service Level failure in accordance with clause 8.2.
Services Request has the meaning given in clause 10.1.
Set Off means set off against either or both of:
(a) any or all of the amounts that AEMO owes to Supplier under this or
any other agreement; and
Supply and Services Agreement 18 February 2016
37
(b) any future payment obligations to Supplier under this or any other
agreement.
Software means the software that forms part of the System, including the
Licensed Software, the Third Party Software and the Developed Software
described at paragraph 1 of Schedule 6.
Source Code means:
(a) computer programs expressed in a source language or form which can
be interpreted or compiled and then executed by a computer as
commands; and
(b) all documentation and tools reasonably required to enable a person
familiar with computer programming to read, understand and modify
such computer programs.
Specifications means all of the requirements of this agreement, including the
functional and technical specifications as set out in Schedule 1 and the
Service Levels as set out in Schedule 3. Any Documentation containing any
technical information about or description of the System will be deemed to
form part of the Specifications. In the event of any inconsistency between
such Documentation and any requirements or specifications set out in this
agreement, the requirements or specifications set out in this agreement will
prevail.
Supplier Contact means the person appointed by the Supplier as its Contact
as described in clause 11.5.
Supplier Personnel means all employees, agents, consultants and contractors
of the Supplier or of any subcontractor, including all Key Personnel.
Supplier Proposal has the meaning given in clause 10.2.
Supply and Installation Services means all services pertaining to the supply,
installation and commissioning of the System, including the services
identified at paragraph 1.1 of Schedule 2.
System means:
(a) the combination of Software, Equipment and Services which
comprise a system that meets the Specifications; and
(b) any changes or additions (including Updates and New Releases) to
the Software, Equipment and Services referred to in paragraph (a).
System Warranty Period has the meaning given in paragraph (b) of the
definition of Warranty Period.
Tax Invoice has the meaning given in the GST Act.
Taxes means taxes, levies, imposts, charges and duties (including, stamp and
transaction duties) imposed by any Government Agency, together with any
related interest, penalties, fines and expenses in connection with them except
Supply and Services Agreement 18 February 2016
38
if imposed on, or calculated having regard to, the overall net income of
AEMO, but excluding GST.
Term has the meaning given in clause 19.1.
Third Party Software means all of the Software listed at paragraph 1.2 of
Schedule 6.
Training Services means the services set out in paragraph 3 of Schedule 2.
Update means software containing patches, bug fixes, Defect corrections,
changes, corrections for Problems and operating improvements since the last
issued Update that has been provided for the primary purpose of rectifying
Defects.
Warranted IP has the meaning given in clause 13.3.
Warranty Period means:
(a) in respect of a Deliverable, or a New Release or an Update, the period
commencing on the date of Acceptance of the Deliverable (or the
New Release or Update, as relevant) and ending 12 months later; and
(b) in respect of the System when complete in accordance with all of the
requirements of this agreement, the period commencing on the date of
issue by AEMO of the Final Acceptance Certificate and ending 12
months later, subject to extension under clause 10.5 (“System
Warranty Period”).
27.2 References to certain general terms
Unless the contrary intention appears, a reference in this agreement to:
(a) (variation or replacement) a document (including this agreement)
includes any variation or replacement of it;
(b) (clauses, annexures and schedules) a clause, Schedule, Annexure,
Attachment or Exhibit is a reference to a clause in, or a Schedule,
Annexure, Attachment or Exhibit to, this agreement;
(c) (singular includes plural) the singular includes the plural and vice
versa;
(d) (person) the word “person” includes an individual, a firm, a body
corporate, a partnership, joint venture, an unincorporated body or
association, or any Government Agency;
(e) (executors, administrators, successors) a particular person includes
a reference to the person’s executors. administrators, successors and
substitutes (including, persons taking by novation) and assigns;
(f) (reference to a group of persons) a group of persons or things is a
reference to any two or more of them jointly and to each of them
individually;
Supply and Services Agreement 18 February 2016
39
(g) (dollars) an amount of money is a reference to the lawful currency of
Australia;
(h) (calculation of time) a period of time that dates from a given day or
the day of an act or event is to be calculated exclusive of that day;
(i) (reference to a day) a day is to a calendar day and is to be interpreted
as the period of time commencing at midnight and ending 24 hours
later;
(j) (meaning not limited) the words “include”, “including”, “for
example” or “such as” are not to be interpreted as words of limitation,
and when such words introduce an example, they do not limit the
meaning of the words to which the example relates, or to examples of
a similar kind;
(k) (next day) if an act under this agreement to be done by a party on or
by a given day is done after 5.30pm on that day, it is taken to be done
on the next day;
(l) (time of day) time is a reference to Melbourne time; and
(m) (words and phrases) where a word or phrase is given a particular
meaning, other parts of speech or grammatical forms of that word or
phrase have corresponding meanings.
27.3 Headings
Headings are included for convenience only and do not affect the
interpretation of this agreement.
27.4 Inconsistency
If there is an inconsistency between a provision in clauses 1 to 27 and a
provision in a Schedule, Annexure, Attachment or Exhibit, the provision in
clauses 1 to 27 prevails to the extent of the inconsistency.
EXECUTED as an agreement
Supply and Services Agreement
Supply and Services Agreement 18 February 2016
40
Schedule 1 - Specifications
1 Functionality
Supplier will deliver a System at the AEMO Site, with the following
functionality:
[Refer to Invitation to Tender – Details to be inserted]
The System shall comply with requirements listed in Appendix 1.
2 Performance
The System must meet the following performance requirements:
[Refer to Invitation to Tender – Details to be inserted]
3 Deliverables
Supplier will deliver the following Deliverables, Documentation and Reports:
The Instruction Manuals shall be prepared and submitted for inspection thirty
(30) Business Days before the date set for Practical Completion. All
alterations required shall be made and the manuals resubmitted before
Practical Completion is achieved.
The manuals, to be supplied in hard backed binders, shall comprise one (1)
set of record drawings and three (3) complete sets of instructions for
operation and maintaining the service.
Binders shall be 3 post hinged 250 mm x 320 mm hard vinyl covers of
adequate thickness, lettered in a contrasting colour on the face with the name
of the project and titled
"Mechanical Services - Operation and Maintenance".
Record drawings shall be "As Installed" full size prints folded to binder size
and heavily reinforced at the retaining posts.
The instruction for operating and maintaining the services shall detail:
• The installed services and describe the interrelated operation and use of the
systems in the various parts of the building.
Supply and Services Agreement 18 February 2016
41
• Safety features of equipment and controls.
• "As Installed" drawings.
4 AEMO Site
2 – 4 Elizabeth Macarthur Drive
Bella Vista, NSW 2153
Attention: Mohideen Gafoor
5 AEMO Systems
The System shall interface with AEMO Systems including the Energy
Management System (“EMS”), and other applications as required by AEMO.
Supply and Services Agreement 18 February 2016
42
Schedule 2 - Services
1 Services
1.1 Decommissioning Services
Decommissioning Services shall include the decommissioning, removal and
disposal of the existing UPS air conditioning systems at the AEMO Site in
accordance with sound environmental practices.
The Supplier shall use best endeavours to dispose of the existing UPS air
conditioning systems to maximise the recycling of components and minimise
the quantity of components disposed of at landfill.
The Supplier Contact will certify that the Decommissioning Services have
been performed in accordance with the requirements of this clause.
1.2 Supply and Installation Services
Supply and Installation Services at the AEMO Site shall include:
[Refer to Invitation to Tender - Details to be inserted]
2 Maintenance Services
2.1 General
Supplier will provide the Maintenance Services in accordance with the
Service Levels set out in Schedule 3.
2.2 Provision of Maintenance Services
Supplier will as part of the Maintenance Services:
(a) provide System support in the manner more fully described in
paragraph 2.3;
Supply and Services Agreement 18 February 2016
43
(b) Respond, Restore and Resolve Defects in accordance with the Service
Levels;
(c) provide a help desk to act as a point of contact for AEMO to request
Maintenance Services as more fully described in this Schedule;
(d) maintain the Documentation in the manner more fully described in
paragraph 2.6.
2.3 System support
Supplier will:
(b) maintain the System to keep it in good order and repair and furnish all
material and labour necessary for that purpose;
(c) replace or repair any item of Equipment which may prove defective;
(d) provide support (including problem determination, fix, repairs, testing
and implementation);
(e) make changes to the System to rectify Defects;
(f) keep detailed logs of all Defects, all remedial action taken and all
replaced parts, and provide copies to AEMO at AEMO’s request;
(g) carry out preventative maintenance in accordance with the
manufacturer’s specifications for the Equipment;
(h) implement engineering and safety changes for all Equipment as it
becomes available;
(i) make changes to the System that are required to maintain the
operability of the System in accordance with its Documentation and
Specifications after the implementation of New Releases of system
software and/or custom operations software including any coding
changes necessary;
(j) make changes to the System that Supplier elects to undertake to
improve the efficiency of the maintenance function;
(k) perform work necessary to test maintenance releases of interfacing
upstream or downstream systems;
(l) perform all work, including capacity upgrades, associated with
facilities management and configuration of application environments
for production support, maintenance and test environments;
(m) perform all work necessary to ensure all code associated with the
current release under maintenance and future maintenance releases is
configured and reproducible as deployed in production;
(n) provide feedback and status reports on the status of any unresolved
Defect reports in accordance with the frequency agreed between the
parties. Feedback and updates will be provided via telephone (and
Supply and Services Agreement 18 February 2016
44
any other means agreed between the parties in writing) to AEMO and
status updates must continue until Restoration or Resolution of the
Defect or as agreed by the parties;
(o) provide appropriately skilled and available technical support and
resources to solve problems relating to the installation,
commissioning and operations of the System;
(p) provide all services necessary to rectify Defects in the System so as to
maintain the operation of the System in accordance with its
Specifications, Documentation and the Service Levels including all
necessary testing;
(q) make provision for pre-tested spare parts, special tools and test
equipment;
(r) co-ordinate, where necessary, the provision of System support or on-
site assistance.
In connection with the Maintenance Services:
(s) “Respond” means a representative of Supplier responds to a Defect
report or other request for assistance from AEMO;
(t) “Restore” means restoration of functionality by means of a
temporary work-around; and
(u) “Resolve” means the Defect has been fully rectified.
(v) “Response”, “Restoration” and “Resolution” have cognate
meanings.
2.4 System support staff
The Supplier will ensure that all Supplier Personnel providing Maintenance
Services:
(a) are technically certified, skilled personnel who are experienced in the
handling of the System and all supported versions of the Software;
(b) can perform the Maintenance Services in relation to the System and
all versions of the Software to AEMO’s reasonable satisfaction;
(c) are fully conversant with the System and the Software; and
(d) have direct escalation to technical expertise to escalate resolution of
issues.
2.5 Trouble Reports
(a) AEMO will provide the Supplier with a “Trouble Report” in respect
of each Defect of which AEMO becomes aware, which may be given
by phone by email or by online access to an appropriate website (if
applicable) as agreed between the parties.
Supply and Services Agreement 18 February 2016
45
(b) The form and content of Trouble Reports provided by AEMO will be
agreed between the parties, but will, at a minimum, include:
(i) the type and classification of the relevant Defect;
(ii) if applicable, the time and date at which the relevant Defect
was reported by end user to AEMO;
(iii) if known, the time and date at which the relevant Defect
occurred;
(iv) a summary of the initial diagnostic procedures undertaken by
AEMO in respect of the relevant Defect and the results of
such procedures;
(v) a description of the suspected Defect;
(vi) whether the problem can be reproduced; and
(vii) if it can be reproduced, the steps required to reproduce the
problem.
(c) AEMO will record the date and time it provides the Supplier with a
Trouble Report and the date and time of the Supplier’s Response to
the Trouble Report.
(d) The Supplier will analyse, work to fix and resolve the cause of the
Defect, and deliver a documented, implementable and tested
Resolution to the Defect in accordance with the Service Levels.
Supplier will use all available troubleshooting techniques to analyse
problems up to and including reverse-engineering if necessary.
(e) A Trouble Report is taken to be Restored or Resolved when AEMO
agrees that the Supplier has provided a successful Restoration or
Resolution for the Defect.
(f) The Supplier acknowledges that the severity of a Defect can increase
or decrease at AEMO’s discretion according to changes in the impact
to AEMO and end users.
(g) The Supplier will prepare and maintain and provide AEMO with
access to a list of all unresolved Trouble Reports, including any
actions taken by Supplier to resolve such Trouble Reports. Supplier
will include Trouble Reports on such list on a real-time basis as such
reports are received from AEMO, and will continually update the list
as new Trouble Reports are received from AEMO or existing Trouble
Reports are resolved.
2.6 Documentation
Without limiting the Supplier’s obligations under this agreement, the Supplier
will amend or substitute the Documentation in order to address and
adequately explain the implications of:
Supply and Services Agreement 18 February 2016
46
(a) any substitution or modification of the Software or the System, if
such substitution or modification is likely to result in varying
operational procedures involving the use of the Software or the
System; and
(b) any Restoration or Resolution of a Defect or error in the Software or
2.7 Replacement and spare parts
(a) Title in all replacement parts for the System will pass to AEMO on
installation into the System. Title in parts replaced will pass to
Supplier on removal from the System by Supplier at the request of
AEMO.
(b) Supplier warrants that all replacement and spare parts provided by
Supplier under this agreement will be new.
(c) The Supplier shall provide to AEMO a list of recommended normal
maintenance replacement parts and any other devices necessary to
maintain the System over a ten year period from the Commencement
Date. The parts shall include lamp replacements, filters and shall be
listed by manufacturer and model number, with unit prices for
individual components, sub-assemblies, cards, and a total price for the
recommended package. The recommended list shall be based on
expected Mean-Time-Between-Failures of supplied System
equipment.
3 Training Services
At the AEMO Site, the Supplier will train up to [Insert number] persons (or
as otherwise agreed by the parties) as nominated by AEMO in the use and
maintenance of the Software and the System.
Training Services (and the associated materials) must be designed to take
each participant through how to use and maintain the Software and the
System, including explaining in a step by step manner what all of the major
functions are, what they are used for, how and when to carry them out, and
information regarding the installation, expansion and maintenance of the
System.
The training program will provide AEMO personnel with a thorough
understanding of the System, and prepare them to be self-sufficient in the
operation and routine maintenance of the display system.
Training Services must be carried out, and associated materials produced,
based on an assumption that the participants have no knowledge of the
Software or the System or the terminology associated with it.
Equipment Training
(a) Equipment Training shall familiarize AEMO's staff with the System
installation, operation, interfaces and cabling, equipment adjustment,
component level repair procedures, and recommended preventive
maintenance procedures.
Supply and Services Agreement 18 February 2016
47
Software Training
(b) The Software Training course shall enable AEMO's personnel to
operate, maintain, configure, and update the system software and
firmware provided with the System. The courses shall provide the
participants with thorough training on all system software and
software maintenance tools, diagnostics, external interfaces, and
techniques relating to the display controller.
Training Schedule
(c) The courses shall be given shortly after the installation of the System,
but prior to final acceptance. The hardware and software courses
shall not conflict, to allow overlap of participation. The Supplier shall
develop, and submit for AEMO's approval, a training schedule that
will provide training in a sequence appropriate to the overall system
implementation.
Training Manuals
(d) The Supplier will provide each person that attends training with one
copy of all of the materials (in both paper and electronic form) used
in performing the training, such as operating and maintenance
manuals, fabrication drawings and installation procedures, and field
update bulletins for all hardware and software.
(e) The Supplier shall prepare course guides and submit them to AEMO
for review and approval at least one week prior to the start of the
training courses. Upon completion of the training courses the course
guides, training manuals, and any other training aids used shall
become the property of AEMO.
4 Key Personnel
[To be inserted in accordance with respondent’s ITT response (Personnel).]
5 Approved sub-contractors
[To be inserted in accordance with respondent’s ITT response (Personnel)]
Supply and Services Agreement
Supply and Services Agreement 18 February 2016
48
Schedule 3 - Service Levels
1 Service Levels
1.1 Availability - Maintenance Services
The Supplier’s telephone helpdesk must be available 24 hours a day, 7 days a
week, including public holidays. Maintenance Services shall be available on-
site within one working day of request.
1.2 First level support and second level support
AEMO shall provide first level support, including being first point of contact
for system queries, and undertaking minor repairs.
Where a query cannot be satisfactorily resolved by AEMO, it will contact the
supplier for second level support including non-routine queries requiring
specialised knowledge or expertise.
1.3 Response times
The Maintenance Services must meet the following response, follow up and
resolution times:
Service Level5 Service Level Target
Call Type Respond 1 Follow up 2 Resolution 3
Severity Level 1: Whole
system inoperative or
malfunctioned
[TBC] [TBC] [TBC]
Severity Level 2:
Two or more units
inoperative or
malfunctioned
[TBC] [TBC] [TBC]
Severity Level 3:
One unit inoperative or
malfunctioned
[TBC] [TBC] [TBC]
Respond 1
System installation or
operation question
[TBC]
System maintenance or [TBC]
5 Note to respondents: Respondents must provide timeframes for Respond, Follow up and Resolution for all Service Level.
Supply and Services Agreement 18 February 2016
49
technical question
1 For Severity Levels 1-3, measured from the time that AEMO notifies the
helpdesk to the time that one of the Supplier’s technical support staff
responds (ie calls back, faxes back, sends a reply email). For questions,
measured from the time that AEMO asks the question to the time that it is
satisfactorily answered.
2 Starts when AEMO notifies the helpdesk of the defect/problem and must be
continued until the Call Type is resolved.
3 Resolution period commences from when AEMO notifies the helpdesk of
the defect/problem.
1.4 Other
AEMO has the sole right (which it must exercise in good faith) to determine
when a Defect has been Restored or Resolved.
1.5 Service Level Review
When requested by AEMO, the parties will review the Service Levels and
mutually agree whether to:
(w) add to, delete or change the Services to be measured and the
corresponding Service Levels to reflect changes in AEMO’s business
operations; and
(x) improve the existing Service Levels, where warranted, to reflect
operational or technical improvements.
Supply and Services Agreement
Supply and Services Agreement 18 February 2016
50
Schedule 4 - Fees
1 Fees
All fees are to be provided in Australian dollars.
[To be completed in accordance with the successful Tenderer’s response]
1.1 [System]
[To be inserted in accordance with successful Tenderer’s response.]
1.2 Maintenance Services Fees
[Note: Rectification of Defects will be at no additional costs]
[To be inserted in accordance with successful Tenderer’s response.
The agreed basis for payment of Maintenance Services Fees (e.g.,
monthly/quarterly in arrears will be set out here.]
1.3 Time and materials rates
[To be inserted in accordance with successful Tenderer’s response.]
2 Payment Milestones
[Notes:
(a) [To be inserted in accordance with successful Tenderer’s
response.].
(b) [AEMO may also, in its discretion, consider securing the successful
respondent’s performance by means of an unconditional bank
guarantee (or guarantees) which AEMO could draw upon in the
event of Supplier default. Such guarantee or guarantees would need
to satisfy certain minimum requirements, including:
(i) being issued by a financial institution registered in this
jurisdiction and having a branch in Melbourne;
(ii) the guarantee must be callable on demand by presentation
of an appropriate notice at such local bank branch,
and must otherwise be in a form that is acceptable to AEMO.]
Supply and Services Agreement 18 February 2016
51
Milestone Due Date Payment Amount
1 Execution of the Agreement At date of signature
2 Delivery of all components
to AEMO Site
[Insert Date]
3 Final Acceptance Certificate
and handover
[Insert Date] (or when
Acceptance Certificate
is issued)
4 Practical Completion Date
(subject to Milestone 3)
[Insert Date]
5 Expiry of Warranty Period [Insert Date]
3 Billing and payment details
3.1 AEMO’s billing address
[Details to be inserted]
3.2 Supplier’s payment details
[Details to be inserted]
[If AEMO requires payment by Electronic Funds Transfer, relevant details
to be inserted here - see note against clause 14.5 (Payment).]
4 Liquidated Damages
4.1 Liquidated Damages
If the Supplier fails to meet the Practical Completion Date, liquidated
damages will be applied one (1) Business Days after the Practical Completion
Date, calculated from the Practical Completion Date until the Supplier meets
all the requirements of the Practical Completion Date, at the rate of $1000 per
day.
4.2 Right of set off
AEMO may, without prejudice to any of its other rights under this agreement:
(a) deduct the liquidated damages from any amount owing to Supplier
under this agreement; or
(b) recover the amount as a debt due to AEMO by Supplier.
Supply and Services Agreement 18 February 2016
52
4.3 Liquidated damages not a penalty
The parties agree that any liquidated damages payable under paragraph 4 are
a genuine pre-estimate of damage and it is not intended by either of the
parties that the liquidated damages be regarded as a penalty.
4.4 Other remedies
The Supplier agrees that payment of liquidated damages are without prejudice
to any other rights of AEMO under this agreement or at law or in equity,
including the right to obtain further damages as a result of delay by the
Supplier.
Supply and Services Agreement
Supply and Services Agreement 18 February 2016
53
Schedule 5 - Project Plan
[Project Plan to be inserted. Project Plan will be consistent with the Payment
Milestones set out in Schedule 4 (Fees).]
1 Project Plan Requirements
1.1 High Level Project Plan
[Note to Tenderers: the High Level Project Plan will be agreed to and
inserted here before signing.]
1.2 Detailed Project Plan
(a) Detailed Project Plans must include:
(i) a detailed description of the relevant Services;
(ii) a detailed description of Deliverables and Equipment to be
delivered;
(iii) detailed timelines and completion dates for all Services,
Deliverables and Equipment to be delivered; and
(iv) detailed timelines for acceptance tests, installation
completion, and delivery of warranty and maintenance
services.
(b) Detailed Project Plans must be sufficiently complete and detailed so
as to allow AEMO (or its nominee) to closely monitor the Supplier’s
progress in completing its obligations, should be in a form that would
ordinarily be used by a competent professional organisation
delivering complex air-conditioning systems and must otherwise be
satisfactory to AEMO (or to its nominee).
Supply and Services Agreement
Supply and Services Agreement 18 February 2016
54
Schedule 6 - Software and Equipment
1 Software
1.1 Licensed Software
[Insert list]
1.2 Third Party Software
[Insert list]
2 Equipment
[Insert list]
Supply and Services Agreement 18 February 2016
55
Schedule 7 - Dispute Resolution Process
1 Negotiation
(a) A party (“Initiating Party”) claiming that a Dispute has arisen must
give the other party (“Recipient Party”) a notice setting out brief
details of the Dispute (“Dispute Notice”). Within 5 Business Days of
service of a Dispute Notice, the Recipient Party must give the
Initiating Party a notice setting out brief details of the Recipient
Party’s position on the Dispute (“Reply Notice”).
(b) If Dispute and Reply Notices are given, each party’s Contact must
meet at least once within 10 Business Days of service of a Reply
Notice and enter into good faith discussions with the objective of
settling the Dispute.
2 Escalation
(a) If the Dispute is not resolved in accordance with paragraph 1, either
party may, by notice, escalate the Dispute to the following senior
representatives of each party for resolution:
(i) for AEMO: [insert position]; and
(ii) for Supplier: [insert position].
(b) The senior representatives of each party will be provided with any
Dispute Notice and Reply Notice served under paragraph 1. If it
wishes to do so, the Initiating Party may serve an additional notice
setting out further brief details of the Dispute (“Further Dispute
Notice”), but must do so no later than 10 Business Days before any
meeting of the senior representatives. No later than 5 Business Days
before this meeting, the Recipient Party may give the Initiating Party
a notice setting out brief details of the Recipient Party’s position on
matters raised in the additional notice (“Further Reply Notice”).
(c) If Dispute and Reply Notices (or Further Dispute and Reply Notices)
are given, the senior representatives specified in paragraph 2(a) will
meet at least once within 25 Business Days of service of the notice of
escalation under paragraph 2(a) and enter into good faith discussions
with the objective of settling the Dispute.
3 Mediation
If the Dispute is not resolved in accordance with paragraphs 1 and 2, the
parties may agree to submit the Dispute to mediation in accordance with the
Australian Commercial Disputes Centre (ACDC) Guidelines for Commercial
Agreement. Such mediation will be conducted in Melbourne, Australia.
Supply and Services Agreement 18 February 2016
56
4 Appointment of mediator
The parties will agree on the appointment of mediator. If the parties do not
agree on the mediator to be appointed within 10 Business Days of either party
referring the Dispute to mediation, the mediator is to be appointed by the
ACDC in accordance with the ACDC Guidelines.
5 Termination of mediation
The mediation process will terminate within 30 days of the appointment of
the mediator, upon which either party will be entitled to proceed to take
whatever action it sees fit in connection with the Dispute, including
commencing litigation.
6 No proceedings
(a) Except in cases where it seeks urgent interlocutory relief, each party
agrees that it will not commence any legal proceedings or take any
other action in relation to the Dispute, without first following the
procedures set out in paragraphs 1 to 5.
(b) Nothing in this Schedule 7 will prevent a party from exercising any of
its other rights under this agreement, including a right of termination.
Supply and Services Agreement
Supply and Services Agreement 18 February 2016
57
Schedule 8 - AEMO Inputs
AEMO will supply the following inputs as part of the delivery of services by the
Supplier:
(a) review and approval of Supplier’s designs and supporting
documentation;
(b) review and approval of Supplier's acceptance testing plans and
procedures;
(c) relevant information to assist with interfacing with AEMO Systems;
Schedule 9 - Original Equipment Manufacturer (OEM) warranties
[Insert list of components covered and if applicable attach original equipment
manufacturer warranties]
Supply and Services Agreement
58
Signing page
DATED:______________________ 2016
SIGNED by [INSERT NAME] as
authorised representative for
AUSTRALIAN ENERGY
MARKET OPERATOR in the
presence of:
............................................................
Signature of witness
............................................................
Name of witness (block letters)
)
)
)
)
)
)
)
)
)
)
)
)
)
)
............................................................
By executing this agreement the
signatory warrants that the signatory
is duly authorised to execute this
agreement on behalf of
AUSTRALIAN ENERGY
MARKET OPERATOR
SIGNED by [INSERT NAME] as
authorised representative for
[INSERT SUPPLIER’S FULL
COMPANY NAME] in the presence
of:
............................................................
Signature of witness
............................................................
Name of witness (block letters)
)
)
)
)
)
)
)
)
)
)
)
)
)
)
............................................................
By executing this agreement the
signatory warrants that the signatory
is duly authorised to execute this
agreement on behalf of [INSERT
SUPPLIER’S FULL COMPANY
NAME]
Supply and Services Agreement 18 February 2016
59
Appendix 1 – Technical Specification
[Refer to the Invitation to Tender including Drawings – to be inserted]
Supply and Services Agreement 18 February 2016
60
Appendix 2 - Acceptance Test Plan
General
(a) Following installation of the System, the Supplier shall present the finished
System to AEMO for acceptance inspection and testing. Inspection and
testing shall not be deemed complete until AEMO provides written approval
of the installation and acceptance of successful testing.
(b) Acceptance Testing shall consist of an Installation Inspection, Integration
Test, and an Interface Test as follows:
Installation Inspection
(a) Upon completion of the installation by the Supplier, the Supplier shall present
the System for inspection.
(b) The Supplier must provide written approval of the successful completion of
Installation Inspection to AEMO before the Supplier can proceed to the
Integration Test, and Interface Test.
Integration Test
(a) Following the successful completion of the Installation Inspection, an AEMO
witnessed Integration Test shall be conducted by the Supplier in accordance
with AEMO approved test plan and procedures including testing all required
functional capabilities of the System.
(b) AEMO must provide written approval of the successful completion of
Integration Test.
Interface Test
(a) [Details to be inserted]