Calhoun: The NPS Institutional Archive
Theses and Dissertations Thesis Collection
1990
Time in construction contracts: A comparison of
selected general conditions provisions for
construction contracts as used by various public and
private agencies
Coleman, Bryce C.
http://hdl.handle.net/10945/24314
This document was downloaded on March 04, 2013 at 09:49:52
Author(s) Coleman, Bryce C.
Title Time in construction contracts :a comparison of selected general conditions provisionsfor construction contracts as used by various public and private agencies
Publisher
Issue Date 1990
URL http://hdl.handle.net/10945/24314
( ... ~ ~~. -~
•.'
(!)
Time in Construction Contracts:
A Comparison of Selected General Conditions Provisions for Construction
00 0 ~
en N N <! I
0 <(
Contracts as Used by Various Public and Private Agencies
by
Bryce C. Coleman
A research report submitted in partial fulfillment
of the requirements for the degree of
Master of science in Civil Engineering
Department of Civil Engineering University of Washington
9 August1990
OTIC
SELECTE NOV 0 5 1990
~D
\ ., .. •'
Time in Construction Contracts:
A Comparison of Selected General Conditions Provisions for Construction
Contracts as Used by Various Public and Private Agencies
by
Bryce C. Coleman
A research report submitted in partial fulfillment
Approved by
of the requirements for the degree of
Master of science in Civil Engineering
Department o1 Civil Engineering University of Washington
9 August1990
. Jimmie Hinze Chairperson, Supervisory Committee
Department of Civil Engineering
University of Washington
Abstract
A Comparison of Selected General Conditions Provisions for Construction
Contracts as Used by Various Public and Private Agencies
by
Bryce C. Coleman Or. Jimmie Hinze Chairperson, Supervisory Committee
A research study was conducted to examine the methods being used by selected Federal agencies, State Departments of Transportation, and Cities to address time in their contract documents. The data for this study was obtained by review of construction contract general provisions as provided by the various contracting offices. This study examines the general conditions provisions of various owners, compares and analyzes each type of clause, and makes recommendations on fairness of the clause to both parties to the contract. The information derived from this study can be used as reference material by those agencies in the process of, or contemplating, revising their current contract documents concerned with time in construction contracting.
~----- ~---- ·--------------- --1 t1 ·:C•· ' ' ~ " - I '---- - .. .. I r;lj·_:;·· ~:-:, .. ' ; ... _____ J_____ .
v·: · 1 ·-. •• i_ ~ .i . ~. ' ' f
' 8~-~-.-.. :.~ _-:.::_: :: ... --- ~
ou.:- _____ ro. ______ ! Dl'l'i'•' ' ' I ·' v .•. • . . I ~--. ---------- ------1
t----A~ ~·~ ··~~ . , ·.-~ ~---~~ '"' .. '· ..
01:;t : '-'~- ,_ : .. ·:
~t _j
In presenting this research report in partial fulfillment of the requirements for
the degree of Master of Science in Civil Engineering in the Department of Civil
Engineering at the University of Washington, I agree that reproduction of any part of
this report is allowable for scholarly purposes only. This is consistent with "fair use"
as defined by the U. S. Copyright Law. All other reproductions for any other purposes
shall not be allowed without my written permission.
Approved by Bryce C. Coleman
Table of Contents
I. List of Tables/Figures 1
II. Introduction 3
Ill. Literature Review 7
A. Introduction 7
B. General 7
c. References 1 1
IV. Research Methodology 1 2
A Introduction 1 2
B. Development of Clause Checklist 1 3
c. Proyjsjons Checklist 1 3
D. .Saul 21
E. Objective 21
F. Sample 21
v. Analysis of General Conditions Provisions 23
A Data Ana!ysjs 23
VI. Research Results 24
A General 24
B Pefinjtjons and pre-award Clauses 24
Holidays 24
Modjfjcalion and Withdrawal of Bjds 28
Award and Execution of Contract 32
Proposal Guaranties 36
~clice 1e P[Qceea am:l CcDl[acl Slao Oale 42
C Post Award Clauses
Sch9dyle and Pre-constryctjon Conference
Materjals Testjng
Contract Tjme
Limjtatjons of Qperatjons
Working pays
Differing Site Condjtjons
Adyerse Weather
Ijme Extensions
Clajms
Suspensjoos
Ligujdated Damages
lnadeguate Maintenance
Termjnatjoo
Payments
VII. Conclusions
VIII. Recommendations
IX. Appendix A: State Summary Sheets
X Appendix B: Other Agency Summary Sheets
XI Appendix C: Georgia Disputes Resolution Provisions
45
45
51
54
57
60
68
75
78
83
88
99
104
108
11 6
120
123
126
165
204
I. List of Tables/Figures
Figure 1 . Clause Checklist
Table 1: Are holidays listed in the provisions and if so, how many holidays does the agency observe?
Table 2: May the contractor Withdraw or Modify a bid any time prior to bid opening?
14
25
29
Table 3: How long after bid opening can the agency award the contract? 3 3
Table 4: Can the contractor withdraw a bid if the contract award is not made in the stated time? 3 3
Table 5: How long after award are bid guaranties of unsuccessful bidders returned? 3 7
Table 6: How long does the contractor have to return the signed contract to the agency? 3 8
Table 7: What is forfeited if the contractor does not return the signed contract within the required number of days? . 3 8
Table 8: What is the effective date of the Notice to Proceed (NTP)? 43
Table 9: How is the contract start date define as? 43
Table 10: How soon after bid opening must the contractor submit a schedule a project schedule? 4 6
Table 11: Is a pre-construction conference required prior to start of work? . 4 7
Table 12: Must all materials be tested and inspected prior to incorporation into the work? . 52
Table 13: What is the basis of contract time? 55
Table 14: Does the agency have a winter exclusion period? 55
Table 15: May the agency require no work be performed on ___ ? 58
Table 16: Does Saturday count as a working day if worked? . 6 1
Table 16a:Does Sunday or Holiday count as working day if worked? 61
Table 17: For working day contracts, how often does the agency submit a record of days charged for the contractor to review? 6 2
1
Table 18: For working day contracts, how long does the contractor have to take exception to the agency log of days charged? . 6 2
Table 19: For working day contracts, are weather delays excluded from time charges? 6 3
Table 20: In the case of differing site conditions must the contractor notify the agency prior to disturbing? . 6 9
Table 21: Do the contract provisions contain a Differing Site Conditions clause and if so, is the clause the standard clause? . 71
Table 22: Is Adverse Weather Defined in the Contract Provisions?. 7 6
Table 23: Does the contract allow for time extensions and if so will the contract time be extended for weather delays? . 8 0
Table 24: Are claims clauses present in the contract documents? 8 4
Table 25: When must claims be submitted to the agency? 8 4
Table 26: Can the agency suspend work and if so do they use a standard clause? 8 9
Table 27: Is there a clause for suspension of work if historical or archeological finds are encountered? 8 9
Table 28: Are liquidated damages included in the provisions and if so are separate values used for calendar day vs working day or completion date type contracts? . . 1 0 0
Table 29: How quickly must the contractor respond to notice of inadequate maintenance of the project?. 1 0 5
Table 30: Can the agency terminate the contract for convenience? . 1 0 9
Table 31: How long does the contractor have to respond to/or correct deficiencies prior to the agency termination of the contract? . . 1 1 1
Table 32: How long does the surety have to take over work prior to agency performing or have work performed by others? 111
Table 33: How often are progress payments made? 11 7
2
II. Introduction
The purpose of this research study is to present a comparison of the time related
general conditions provisions contract clauses being used by selected federal, state, city
and other agencies. These general conditions provisions clauses include those that relate
to the time for performance of the contract and those that deal with actions required at
specific points in time within a contract.
Most contracts are quite specific regarding the amount of construction time
allowed to complete the work. This time constraint allows for finance planning, business
and use planning, and ensures an appropriate performance effort by the contractor.
Contract time may be expressed in terms of working days, calendar days or as a fixed
completion date. The term "calendar days• includes Saturdays, Sundays and Holidays.
"Working days" normally include any day that the contractor can work on the job but
excludes Saturdays, Sundays and Holidays. Required actions and timeframes for
performance are generally spelled out and the penalties for failure to meet these
constraints are detailed.
Time is important in construction contracting. Typical contracts state that "time
is of the essence•. This is a statement by the owner that performance is expected within
the proscribed period of time and that failure to complete the contract within the time
allowed will result in damages to the owner. Many contracts provide for the payment of
"liquidated damages• by the contractor to the owner for failure to complete on time or, in
some cases, to complete portions of the work that interface with other contract
schedules. Liquidated damages are a direct cost to the contractor and can have a major
impact on the profit or loss on a particular contract. Indirect costs may also increase
with elapsed time, including unanticipated overhead expenses, lower cash flow~.
3
delayed revenues, and increased borrowing costs. The contractor may also experience a
decrease in the firm's reputation within the industry and among clients. All of these
factors can decrease the contractor's ability to obtain additional work and or remain in
business.
The owner will also be affected by late completion of a contract. The owner may
lose revenue, manufacturing service operations may be delayed, and other contracts may
be adversely impacted. On a public works contract the public may be denied use of the
facility, with the costs associated with lost use by the public being a major impact.
Within the contract documents, the general provisions or general conditions
typically contain the various clauses related to the overall issue of time as administered
in the contract. Clauses in the general provisions will define contract time and will state
many different factors that can impact how contract time will be charged. Other clauses
will state actions required of the contractor at specific points within or leading to the
contract. The relationship between the contractor and the owner on issues of time will
be governed by these clauses.
There are several major and minor contract clauses that affect contract time.
These clauses include: Differing Site Conditions, Time Extensions, Claims/Disputes,
Default, Prosecution and Progress, Suspensions, HistoricaVArcheological Preservation,
and Termination for Convenience. Most aspects of how contract time will be controlled
are contained in these clauses. Other clauses in the general conditions will also require
actions by the contractor or owner at certain points in the flow of contract time. These
include: Bid Modification/Withdrawal, Contract Award, Bid Guarantees, Failure to
Return Signed Contract, Progress Schedules, Pre-construction Conference, Material
Testing and Acceptance, and Failure to Maintain Project.
4
Many contractors do not spend enough time considering the contents of these
clauses as they are not concerned about the general conditions provisions or wboiler
platew but only about the technical aspects of the job. Not all wboiler plate" is the same
and unwary contractors can be in for some nasty surprises if they do not carefully read
and understand the various clauses. The large and ever increasing volume of delay
claims are to a large part resultant from a failure to understand and or follow the
requirements of the various time provisions in the contract general conditions
provisions.
The owner too must be aware of what clauses are contained in the general
conditions of the contract. &,me owners are not interested in dealing with increased cost
or changes during construction and so try to limit the ability of the contractor to
increase the price or time of a contract. These owners use restrictive language in their
construction contract general conditions that limit change and flexibility. This type of
contract is an attempt to limit the risk of the owner and reallocate most of the risk of
construction to the contractor. Other owners are more receptive to sharing the risk and
use less restrictive language in their general conditions. It is important for owners to
understand that greater risk placed on the contractor results in an increase in the bid
amount. Thus, if owners are willing to share the risks on construction projects, they
can expect lower bids from the contractors. A contract that provides for shared risk
typically also results in more of a team approach to the project as there is a greatly
lessened adversarial relationship.
It can be seen that it is in the best interest of both parties to a construction
contract that the work be completed within the schedule and on time. Many of the general
conditions provisions deal with time and the uncertainty of the construction process.
5
The owner, in drafting the provisions, is proportioning risk with the contractor. Some
owners are more willing than others to assu,ne some of the risk in expectation of lower
bid prices. This study will examine the general conditions provislons of various owners,
compare and analyze each type of clause, and make recommendations on fairness of the
clauses to both parties to the contract.
6
Ill. LITERATURE REVIEW
A. lntrodyction
A literature search revealed that the subject of time in construction contract
documents has not been extensively studied. Much has been written on the subject of
scheduling methods and techniques but almost nothing exists in the literature on how
contract clauses that affect time can impact contracts. Much of the published material
that could be found dealt in a general nature with the various contract clauses and claims
avoidance or resolution.
B. General
Most construction contracts involve time as a key part of the contract. It is
stated that "time is of the essence of the contract" or words of similar import. This
signifies that the stipulated completion date or time is considered to be an essential part
of the contract and an important part of the contractors obligation to the owner.
Contractors who fail to complete the contract in the stipulated time will incur an
indebtedness for damages incurred by the owner (Clough 1975).
Time in construction contracts is most often discussed in connection with
scheduling. The contract documents may call for the contractor to use a specific type of
schedule or may leave the choice up to the contractor. If no specific technique is
specified in the contract, the contractor may chose between using a bar chart or a
network schedule. Whatever the choice, the schedule should be submitted to the owner
for review and approval even if not required by the contract documents. Submission of
the schedule for approval notifies the owner of how the contractor intends to proceed
with the work. Once approved, it is hoped that the owner will be able to cooperate with
the contractor in achieving the planned schedule (McDonald and Baldwin 1989).
7
Claims litigation is often where the importance of time provisions are learned by
contractors. In addition to the provisions that directly affect contract time, there are a
number of notice and action provisions that require steps to be taken at specific points in
time. Failure to provide a required notice or take a required action can result in a
contractor losing entitlement to an otherwise valid claim. The contract documents must
be carefully reviewed and all notice requirements noted. A contractor's failure to notify
an owner of a differing site condition or of an entitlement to a time extension within the
time parameters established by contract will result in the loss of compensation to the
contractor. A contractor should make a check list of all notice requirements as a
protection against waiver of claims (Medved February 1989).
In their paper, "Time and Weather Provisions in Construction Contracts of State
Highway Agencies", Hinze and Couey looked at some of the general conditions clauses that
deal with contract time. Their survey of the 50 State Highway Agencies (SHAs), looked
at weather provisions, contract time definition, liquidated damages, and progress
schedule requirements. It was determined that there was little consistency within the
SHAs on their practices concerning time in their construction contracts. There was a
great deal of variation in the amount of risk that each state was willing to take as part of
the construction contract process. Many states assumed the risk associated with
inclement weather while others placed this risk on the contractor. With all other
factors being equal, it is expected that projects in states where more risk is passed to
the contractor, the contractor's bids will also be higher.
Construction delays can be very costly to both the owner and the contractor.
Delays can be caused by many factors and it is necessary to balance the risk between the
parties of a contract. Many owners have tried to shift the risks associated with
8
construction to the contractor. Most construction contracts are adhesion contracts that
are drawn by the owner and cannot be changed by the contractor. The owner drafts the
general conditions provisions and determines the allocation of risk. Exculpatory clauses
such as •Hold Harmless•, •No Damage for Delays•, and •Errors and Omissions• are used
to shift risk to the contractor. Contractors are accustomed to risk taking. When
presented harsh contract terms on the take it or leave it basis, common in most
construction contract bidding, they add what is hoped to be a large enough contingency
and hope for fair treatment by the owner. Improving contract language to more clearly
and fairly allocate risk will result inimproved working relations and lower bids
(National Research Council, 1978}.
Construction delays are either excusable compensable, excusable
noncompensable, or nonexcusable. A compensable delay allows one party to the contract
to recover damages from the other. Delays caused by factors beyond the control of the
contracting parties, such as acts of God, national emergencies, and sometimes unforeseen
labor disputes, are typical examples of noncompensable delays. Neither the llwner or the
contractor can recover damages against the other for delays of this type. The contract
general conditions must be carefully examined in order to determine the terms and
definitions for each type of delay and the associated remedies (Medved, January 1989).
Most contracts by federal and state agencies do excuse some delays due to
unsuitable weather. The relief granted to an contractor to a large extent depends on the
definition of contract time contained in the contract. Many working day contracts will
excuse the contractor from all delays due to inclement weather. Where contract time is
defined as calendar days or by a fixed completion date, relief is normally only granted
for unusually severe weather. In all cases it is up to the contractor to be aware of the
9
requirements and provide the proper documentation when requesting an extension of
contract time. ·unusual• weather refers to conditions that are encountered with a
greater frequency than cou!d normally be assumed for the contract period. ·severe•
weather refers to conditions that exceed an established norm. In order for contractors to
establish a case for a time extension due to severe or unusual weather they must
demonstrate, by use of historical data, that the weather encountered is beyond the
expected norms for the period involved. This typically involves the collection and
presentation of data from the national weather service (1 0 to 20 years of past data)
that shows the norm for a given locale for given seasons (lsom, 1985).
1 0
C. References
1. Clough, Richard H., Construction Contracting, 3rd ed., (New York: Wiley
1975), pp. 126
2. McDonald, Phillip B. and Baldwin, George C., Builder's and Contractor's
Handbook of Constructjon Clajms, (New Jersey: Prentice Hall, 1989), pp. 131-135
3. Medved, George M., How to Wjn a Delay Claims Case, (Highway & Heavy
Construction, v132 February 1989), pp. 40-43
4. Hinze, Jimmie and Couey, James E., Time and Weather Provjsjons jn
Construction Contracts of State Highway Agencies, (Paper No. 88 0477, Transportation
Researvn Board, 1989), pp. 4-7
5. Exploratory Study on Responsibility. Liability. and Accountability for Rjsks
in Construction, (The National Research Council, 1978) pp. 92-99
6. Medved, George M., How to Protect yourself In Delay Clajms Cases, (Highway
& Heavy Construction, v132 January 1989), pp. 58-61
7. lsom, Sam, Weather delay time extensions: Contract Administratjon for
Contractors, (Highway & Heavy Construction, v128 July 1985), pp. 41
1 1
IV. RESEARCH MEIHOPOLOGY
A. Introduction
Results of a study done by James E. Couey in 1987 showed that there was
significant variation in the way each State Highway Agency (SHA) addressed time in
construction contracts. Couey had used a survey of the SHAs to obtain data for his study.
Some states had included copies of their general conditions contract clauses with their
responses to the survey. A review of the responses received, some of which indicated
that perceptions varied from the provisions, indicated that variation in the SHAs general
conditions would provide fertile ground for further study. This became the central
theme for the study undertaken.
This study differed from Couey's study in two basic aspects. First, this study was
broader in scope, covering all provisions that relate to time. Second, this study did not
consist of information provided by survey respondents. but through the detailed
examination of selected contract provisions as used by the SHAs. Copies of the general
conditions provisions were requested from all 50 SHAs. General conditions provisions
were also requested from a list of cities, federal and other agencies. The general
conditions provisions of each agency, pertaining to time were then reviewed.
A direct review of the general conditions provisions was utilized vs interviews or
surveys for several reasons:
1. Direct review of the provisions would allow for consistent treatment of the
time provisions of each agency. One person would review all the provisions and
the interpretation of the time provisions would be consistent.
2. In the time available for the study, a large number of agency construction
contract general conditions provisions could be obtained.
1 2
3. Interviews or surveys provide data reflecting the perceptions of the person
being interviewed or surveyed which may be different from the actual contract
provisions.
B. Development of Contract Clause Checklist
After reviewing four sets of SHA general conditions provisions a checklist was
developed to assist in tabulating the data. Each clause that impacted contract time or
required contractor action at a point in time was noted. The time provisions on the
checklist were listed in rough chronological order in the contracting process. The
contracting process was followed from pre-award through default or final payment. The
checklist was used for the review of each set of general conditions provisions. The
checklist allowed the reviewer to make notations when a provision was similar to those
of other agencies and it provided room for additional comments, such· as unique aspects
not included in the provisions of other agency documents. See figure 1 for a copy of the
checklist used.
C. Provisions Checklist
pre-award
How many Holidays? _ List Unusual Days: Holidays to be recognized
in the construction contracts were noted and any unusual days were listed. Unusual days
were any days other than: New Years Day, Martin Luther King Day, Presidents Day,
Memorial Day, Independence Day, Labor Day, Columbus Day, Thanksgiving Day, and
Christmas Day. The total number of recognized Holidays was listed as were the unusual
days.
Adverse weather defined. Yes_ No_ : Did the provisions define
adverse weather? Yes was checked only if the definition was clearly stated and the
1 3
Agency ---------------- Spec Date ______ _
How many Holidays? __ List Unusual days:
Adverse Weather defined Yes__ No __ Withdraw/Modify bid any time prior to bid opening? __ Other: Contract to be awarded within_ days after bid opening. Other: Can contractor withdraw bid if not awarded within stated time? Yes __ No __ Bid Guarantees returned within __ days after Bid Opening. No Mention How long to return signed contract to agency? __ Days. NTP date? When Mailed __ When Received__ When Signed __ Other: Contract Start Date: _________________ __ Bid Guarantee forfeited if contract not received back by agency within __ days? Yes_ No_ Bid difference forfeited if contract not received back by agency? Yes_ No_ Schedule due within __ days after award. Other:
Schedule of prices due within_ days after award. Pre-construction conference required before start of work? Yes No_ Materials to be tested and approved prior to use? Yes_ No_ Winter exclusion period? Yes_ No_ Period _________________ _ Contract time basis: Working day __ Calendar day_ Completion date_Combination_ May agency require no work on Sundays? Yes_ No_ May agency require no work on holidays? Yes_ No_ May agency require no work on day before or after holiday? Yes No_ Sunday or Holiday count as working day if worked? Yes_ No_ For working day basis who tracks time? How often submitted for review? ___ _ Does basis include weather delays? Yes_ No __ How long to review and take exception?
How quickly must contractor respond to notice of inadequate maintenance of project? ____ _ Differing site conditions: Adjustment to contract price tor differing site condition? Yes_ No_ Notify owner prior to disturbing?__ Request for additional compensation due when? __
Time Extensions: Time extensions Allowed Yes_ No_ When are requests for time extension due? ______ _ Extension for weather delay? Yes_ No_ Claims: Claims allowed? Yes_ No_ When must they be submitted?
Suspensions: Can agency suspend? Yes_ No_ Can contractor suspend? Yes_ No_ Suspension clause for historical or archaeological finds? Yes __ No __ What notice requirements?
Uquidated damages provided for late completion? Yes No Separate values for calendar day vs working or completion date? Yes_ No_ Defaults: How long does contractor have to respond to/or correct deficiencies prior to agency terminating contract? __ _ Termination: Termination tor convenience of agency? Yes_ No_ Restrictions? __ __
After termination how long does surety have to take over work? __ _ Payments: How often made? ______ _
Other:
Figure 1
14
determination was not left up to the engineer.
Withdraw/modify bid any time prior to bid opening?_ Other: This
noted the use of a provision which would allow a contractor to modify or withdraw a
submitted bid prior to the stipulated bid opening time.
Contract to be awarded within _ days after bid opening. Other:
This tracked how long agencies had to award contracts after the bids had been opened.
Contractors could not withdraw their bids during this period. As this wording is
generally fairly standard it was used instead of how long bids would remain valid. The
clause where this information was contained also normally stated the conditions under
which a contractor could withdraw a bid.
Can contractor withdraw bid If not awarded within stated time?
Yes_ No_ : This noted if a contractor can withdraw a bid if the contract is not
awarded within the stated time. If the answer is yes the clause limits an agency's ability
to a guarantee of the bid price only for the stated period.
Bid guarantees returned within _ days after bid opening. No
Mention _ : The number of days after bid opening that any required bid guarantees
will be returned to other than the low contractor.
How long to return signed contract to agency? _ Days : This
tabulates the number of days that the contractor has to return the signed contract to the
agency. This requirement is assumed to include the submission of the required bonds.
NTP date? When Mailed _ When Received _ When Signed_
Other: Information was collected to record the effective date of the Notice To Proceed.
Contract Start Date : This is the date that the contract time
starts to be charged. For liquidated damages to be avoided, the project must be completed
15
in the requisite time beginning with the contract start date.
Bid guarantee forfeited If contract not received back by agency
within _ days? Yes _ No This shows the number of days the
contractor has to return the signed contract to the agency. A yes response indicated that
the contractor would forfeit the bid guarantee as liquidated damages if the contract and
required bonds are not returned to the agency in the specified time.
Bid difference forfeited If contract not received back by agency?
Yes _ No_ : A yes response to this question indicates that only the difference
between the contractor's bid and the next low bid will be forfeited if the contractor fails
to enter into the contract within the required time frame.
Post Award
Schedule due within _days after award. Other: This records the
number of days after award the contractor has to submit a schedule. Any requirements
other than a specific number of days, are also listed.
Schedule of prices due within _ days after award: This lists the
number of days the contractor has to submit a schedule of values for payment purposes
to the agency.
Pre-construction conference required before start of work Yes _
No _ : A yes response to this question indicates that the contractor is required to
meet with the agency prior to start of work.
Materials to be tested and approved prior to use? Yes No
A yes indicates that the agency requires all materials incorporated in the job to be tested
and approved prior to their incorporation into the job. A no indicates that while testing
1 6
t
•
and inspection may be required it was not required prior to the materials being used.
Winter exclusion period? Yes _ No _ Period A
yes indicates that the agency uses a winter exclusion period. If the agency uses an
exclusion period, the included dates were recorded here.
Contract time basis: working day _ calendar day_ Completion
date _ Combination _ : Defines what the agency uses as the basis of time in the
contract clauses. Agencies can use working days only, calendar days only, a fixed
completion date or any combination.
May the agency require no work on Sundays? Yes _ No _ : A yes
response indicates that the agency can require that the contractor not perform contract
work on Sundays.
May the agency require no work on holidays? Yes _ No _ : A yes
response indicates that the agency can require that the contractor not perform contract
work on holidays.
May the agency require no work on day before or after holiday?
Yes _ No _ : A yes response indicates that the agency can require that the
contractor not perform contract work on the day before or after a holiday. This has a
greater impact on completion date and calendar day contracts .
Sunday or holiday count as working day If worked? Yes No
For working day contracts the agency may or may not charge a Sunday or holiday as a
working day if the contractor works. A yes response indicates the agency does charge
working days for any Sunday or holiday on which work is performed.
For working day basis who tracks time? How often
submitted for review? __ _ On working day contracts, this tracks whether
1 7
the contractor or agency keep track of contract time and how often that record of time
charged against the contract is submitted to the other party for review.
Does basis include weather delays? Yes No On working day
contracts, the time charged as working days may exclude periods when the weather, or
effects of recent weather, may prevent the contractor from working. A yes response to
the question indicates that the agency does not charge working days when weather
conditions prevent the contractor from working on the controlling items of work. A no
response indicates the basis does not include weather delays and the contractor will be
charged with working days during periods of adverse weather.
How long to review and take exception? : This tracks the time period the
contractor has to respond to the agency log of working days report if exceptions are to be
noted. If the contractor does not take exception, then the working days charged are
agreed to.
How quickly must contractor respond to notice of Inadequate
maintenance of project? __ Contracts may contain a requirement for the
contractor to respond to an agency notification of inadequate maintenance. Adequate
maintenance is defined as keeping the roadway and structures in satisfactory condition at
all times including maintaining the previous course or subgrade during all construction
operations. If this clause is present in the agency provisions, the time for the
contractor to respond to the notice is noted.
Differing site conditions: If the contract contains a differing site conditions
clause it is noted.
Adjustment to contract price for differing site condition? Yes _
No This tracks whether the contract allows an adjustment to the contract price in
1 8
case of a differing site condition. While most of the time this adjustment would be under
a differing site condition clause it may be under the changes clause if no differing site
condition clause is used.
Request for additional compensation due when? : Deadlines for
submission of contractor proposals for adjustment to the contract due to differing site
conditions are noted.
Time Extensions: Time extensions allowed Yes No A yes
response indicates time extensions are permitted under the contract.
When are requests for time extension due? Deadlines for the
submission of contractor proposals for adjustment to the contract in contract time are
noted.
Extension for weather delay? Yes No This is a yes no listing
for contracts that allowed full or partial relief from weather delays. Any special
conditions were noted in the question regarding the allowance of time extensions.
Claims: Claims allowed? Yes _ No _ : When must they be
submitted? If the contract allowed claims by the contractor for disputed work or
interference by the agency a yes is checked. Any submission deadlines are noted.
Suspensions: Can agency suspend? Yes No Yes is checked if
the agency can suspend the contract.
Can contractor suspend? Yes No This lists whether the
contractor can suspend work on the contract.
Suspension clause for historical or archeological finds? Yes
No Records the presence of a provision requiring suspension of work due to
historical or archeologist finds. Any notice or co •• lpensation request time frames were
19
noted.
What notice requirements? This allows listing of what notice the
contractor is required to give to the agency if the contractor feels the contract has been
suspended by an act of the agency. The time frame for submission of any request for
adjustment to the contract for suspension is also listed.
Liquidated damages provided for late completion? Yes No
If the provisions contain a liquidated damages clause the yes is checked.
Separate values for calendar day vs working day or completion
date? Yes _ No _ : This tracks those agencies that include different values of
damages for working day vs other types of contracts.
The termination provisions in a contract can be either termination for
convenience or termination for default or may contain both types of provisions.
Termination: Termination for convenience of agency? Yes_ No
This tracks those agencies that include a termination for convenience clause in their
provisions.
How long does contractor have to respond to/or correct deficiencies
prior to agency terminating contract This lists the notice
requirements of those agencies that include a termination for default clause in their
provisions.
After termination how long does surety have to take over work?
This tracks response time frames in agencies where the surety is given additional notice
prior to the agency terminating the sureties right to perform for a defaulted contractor.
Payments: How often made? __ How fast will payment be made?
The frequency of progress payments is listed and any statement on how fast the payment
20
•
•
•
•
•
•
•
would be made is noted.
D. ~
Agencies selected for review were all 50 State Highway Agencies, a cross section
of 13 medium to large cities, the Federal Bureau of Reclamation, the U.S. Navy and the
standard form adopted by the American Institute of Architects (AlA). These agencies
were selected because of the large volume of construction they administer each year
using their construction contract general conditions provisions. With the exception of
the AlA, all the agencies are public agencies and the general conditions provisions
reviewed apply to co11petitive bidding. The AlA standard documents were added to this
list because more contracts are awarded using the AlA documents than any other standard
form.
E. Objective
The objective of this review w<:s to obtain an in depth comparison of the clauses
used by the agencies. Thq checklist assisted in tabulation of the data and noted the
variations that warranted further analysis. Couey's study had indicated that there were
differences between agency practices, as stated by interviews, and the requirements
actually contained in the provisions. Direct review of the agency provisions allowed the
collection of data without discrepancies between agency practices and actual documents .
Trends in clause use could be identified and typical clauses listed for use as reference
material.
F. Sample
Within the Federal Government all agencies must use the Federal Acquisition
Regulations (FAR) for procurement of construction. Under these regulations the FAR
clauses cannot be changed from agency to agency. Each federal agency is permitted to
21
•
•
t
•
•
•
•
develop and use their its own supplemental conditions to tailor the contract to the
construction requirements of the agency. It can be assumed that construction contracts
within the federal agencies are fairly consistent in the wording of the supplemental
clauses. For the State Highway Agencies each state has developed its own contract
clauses. The only common contact for all SHAs is the Federal Highway Administration.
Some requirements are mandated for use by states as a result of accepting federal money.
Variations of practices within a state exist but it is again assumed that the practices of
districts within a particular state are fairly consistent. By reviewing general
conditions provisions from all 50 states, the study would be a complete analysis of all
SHA provisions .
For the cities, each city functions in an independent fashion. There may be some
contact with the SHA in which the city is located but it was expected that there would be
much more variation in the wording of time provisions. The sample size need be only
large enough to illustrate some of the clauses variations used by cities.
The AlA general conditions provisions are in standard use across the country. The
same provisions may be used in Alaska, Florida or Hawaii. The documents are the same
regardless where used. It is this universal use which makes its review important when
looking at time provisions .
22
V. Analysis of General Conditions provisions
A. Data Analysjs
Each set of general conditions was reviewed in detail. Provisions dealing with
time were noted and data transferred to the contract checklist that had been developed.
Information on each item on the contract checklist was then transferred to a spreadsheet
where the data from each agency was logged. The spreadsheets were then used to tabulate
the data for each checklist item. Additional written comments on the checklists are used
where appropriate in the written discussion on each of the items from the checklist. The
tabulations of the agency data were separated between the SHAs and the remaining
agencies since it was desirous to look at the SHAs as a separate group. Trends and
differences in the tabulated data were highlighted for further analysis and presentation
in the detailed discussion of each checklist item. The spreadsheet logs are included as
appendix A for the SHAs and appendix B for the other agencies. The logs may be
reviewed to determine each agencies position on individual items on the checklists.
Detailed statistical analysis was not warranted as it was important only to note
the agency trends and variations for further analysis. Detailed statistical analysis would
not be significant.
23
VI. Research Results
A. General
The results of each item in the contract checklist will be presented in rough
chronological order in the life of a contract when the provisions would most apply.
Items dealing with pre-award will be presented before post-award items. For major
clauses, each item will be introduced, results will be presented (including example
provisions), impacts of the provisions bill be given with conclusions stated. Items
relating to major clauses will be presented together. Clause names used as headings are
representative of the information contained in the various agency clauses although titles
used by the agencies may be somewhat different. Review of each agency's position on
each item presented can be found in tabulated form the appendices. Appendix A has the
spreadsheets used for tabulation of the SHA data while Appendix B contains the
spreadsheets used for tabulation of the other agency data.
B. Defjnjtjons and Pre-award Clauses
Holidays
Introduction
While contractors may all be familiar with the holidays observed in their
present place of residence and work, the nature of construction is that the location of the
work varies. It is not unusual for contractors to bid on work in locations where the
company is not familiar with the agency they will be wor'.<ing for. A contractor who
reviews a potential job before preparing a schedule must be aware of the holidays
observed by the agency. Holidays observed by states may be different from cities within
the state and they may differ from state to state. Table 1 is a summary of holidays as
found in the review.
24
Table 1: Are holidays listed in the provisions and if so, how many holidays does the
agency observe?
A!Jerct Not Listed 8 9 1 0 1 1 12 13 14 Other
SHAs 22 2 6 5 7 3 2 2
Cities 1 0 1 1 1
BLM X
Navy X
AlA X
25
Many states indicate the number and specific dates of holidays they will observe.
The holidays observed by particular states were most often found in the definition
section of the general conditions provision. Others were found in the section dealing with
prosecution and progress of the work. Slightly more than half of the SHAs list their
holidays in the specifications. The remainder observed holidays as set forth in state
law. It can be seen that there is a significant variation in the number of holidays
observed by each agency. The specific holidays themselves are of interest. Some of the
variation is regional while some states have unique days they observe. Most states
observe the nine Federal holidays: New Years Day, Martin Luther King Day, Presidents
Day, Memorial Day, Independence Day, Labor Day, Columbus Day, Thanksgiving Day, and
Christmas Day. Many of the Southern SHAs observe Robert E. Lee's Birthday,
Confederate Memorial Day and Jefferson Davis's Birthday. Good Friday, election day, and
the day after Thanksgiving are also popular holidays. Many of the other differences
reflect important events within the states, e. g., Benningston Battle Day in Vermont,
West Virginia Day in West Virginia, and Stewards Day in Alaska.
Other Agencjes
Most of the other agencies do not list observed holidays. Good Friday observed by
Chicago and the day after Thanksgiving observed by El Paso were the only non typical
days listed. The Federal agencies observe the nine holidays listed above. Holidays are not
listed in the basic AlA document.
Impact and Conclusions
Holidays vary widely between agencies. While uniformity in observed holidays is
seemingly not important, it is important for agencies to recognize that contractors may
26
not be familiar with the agency or the impact that different agency holidays may have on
contractors. Contractors may be required to pay workers for time off on many of the
listed holidays. Inspectors and engineers may not be available if the contractor elects to
work on a holiday. In some cases the contractor will be prohibited from working on
listed holidays. If not prepared for these conditions a contractor can find a projected
schedule costly to meet.
27
IJ
•
•
•
•
•
•
•
Modification and Withdrawal of Bids
lntrodyction
The preparation and submission of a bid by a contractor is a very complex task.
Quotes from many subcontractors and material suppliers may not be submitted to the
contractor bidding on a project until shortly before the bid submittal time. The use of
spreadsheet programs to compile bids has reduced the probability of errors in the
arithmetic of the bid process but still many unknowns remain unresolved until shortly
before bid submittal. As a consequence of this process, contractors may submit bids that
are based on assumptions or approximations of the quotes they will receive from
subcontractors and suppliers. As the actual quotes are received, the bids become more
exact. With the time necessary to finalize a bid often being very short, contractors may
submit bids with contingencies to cover the unknown quotes. If a contract contains a
provision allowing withdrawal or modification of the contractor proposals, the
contractor can ensure a bid is submitted and then revise or withdraw it if necessary.
The results displayed in Table 2 show the usage of a provision allowing modification or
withdrawal of bids.
Most SHAs include provisions allowing contractors to modify or withdraw bids .
There is a great deal of similarity in the wording of the provisions with some provisions
allowing telegraphic modifications and others limiting modifications or withdrawals to
written requests. The provision used by the state of Mississippi is typical of the clauses
used. The clause states:
28
Table 2: May the contractor Withdraw or Modify a bid any time prior to bid opening?
AQency Yes f\b No Mention
SH6o 47 3 *
Cities 8 5
BLM X
Navy X
AlA X
* New York, Pennsylvania, Rhode Island
•
•
•
• 29 •
•
•
•
•
•
•
•
•
•
Withdrawal or Revision of Proposals (1 02.1 0 Mississippi)
A bidder may withdraw or revise a proposal after it has been deposited with the Department, provided the request for such withdrawal or revision is received by the Director, in writing or by telegram, before the time set for opening of proposals.
Other SHA's include additional wording that allows a contractor to withdraw
unopened proposals, after the time set for bid opening, where if bids have been
submitted on multiple projects all opening at the same time. If the contractor is the
apparent low bidder on one of the project, the contractor can withdraw any unopened
bids on other projects that have bids opening at that time. Of the three SHAs that do not
allow bids to be modified any time prior to bid opening, Rhode Island will accept
modifications or requests for modifications up to two hours prior to bid opening. New
York will not allow a bid to be modified or withdrawn once the bid has been submitted.
Pennsylvania will accept modifications or requests for modifications up to 9 AM of the
day bids are to be opened .
Other Agencjes
Provisions used by other agencies are similar to those used by the majority of
the SHAs. As can be seen in Table 2, some agencies do not have a provision that deals
with withdrawal or modification of bids.
Impact and Conclusjons
Contractors are more likely to bid and be timely with their bids if solicitations
contain provisions allowing tor withdrawal or modification of bids. If a mistake is made
and discovered prior to bid opening or a contractor feels too uncomfortable with an
assumption made in the bid process it can be changed or withdrawn. Allowing
contractors to withdraw or modify bids prior to the opening of any bids increases the
comfort a contractor has with the bid process. This will reduce contingencies in bids
30
submitted and should result in increased bidding. The agency will therefore receive the
benefit of greater competition and should get lower prices.
31
•
•
•
•
•
•
Award and Execution of Contract
Introduction
General conditions provisions dealing with the award and execution of a contract
typically state either how long the contractors bids will remain open or how long after
bid opening the agency has to award the contract. Initial review showed that most of the
states used language similar to the second wording. Regardless of the wording, what is
important is how long the contractors bid is good for.
Contract time will start sometime after award and the number of days for
completion is stated in the solicitation. Contractors must account for the time between
submission of bids and award of the contract. Labor, material and equipment costs can
change with time so it is important for the contractor to know how long after bid opening
the contract can be awarded. It is not fair to ask the contractor to carry the risk of
changing costs for an indefinite period. The time after bid opening if therefore
frequently fixed so that the risk can be identified. Time for award of the contract after
bid opening is shown in Table 3. Many agencies that have a fixed time for award also
allow the contractor to withdraw a bid if award is not made in this fixed period. The
number of agencies that allow the contractor to withdraw bids if the contract is not
awarded in the stated period is presented in Table 4 .
~
Time for award varies between the most 30 and 60 days with half the SHAs
awarding contracts within 30 days. Up to sixty days is not an unreasonable amount of
time to keep a contractor waiting for award of a contract. Most provisions used are
similar most states will allow a contractor to withdraw a bid if the contract cannot be
awarded within the stated period. The provision used by the state of Illinois is typical.
32
•
I
•
•
•
•
Table 3: How long after bid opening can the agency award the contract?
Agency 30 Days 40 Days 45 Days 50 Days 60 Days 90 Days Not Listed or Other
SHAs 26 2 9 1 7 5
Cities 1 1 3 1 8
BLM
Navy
AlA
X
X
X
Table 4: Can the contractor withdraw a bid if the contract award is not made in the stated
time?
Agency
SHAs
Cities
BLM
Navy
AlA
Yes
37
2
X
X
33
No Mention
1 3
1 1
X
•
•
•
•
•
•
•
•
•
•
•
The clause states: Award of Contract (1 03.02 Illinois)
The award of contract will be made within 45 calendar days after the opening of proposals to the lowest responsible and qualified bidder whose proposal complies with all the requirements prescribed. The successful bidder will be notified by letter that his/her bid has been accepted, and that he/she has been awarded the contract.
If a contract is not awarded within 45 days after the opening of proposals, bidders may file a written request with the Department for the withdrawal of their bid, and the Department will permit such withdrawal.
Of the SHAs that do not specifically allow the contractor to withdraw a bid if
award is not made in the stated time, it is expected that the instructions to bidders on an
individual contract solicitation would contain information on how long the agency has to
award a contract or how long bids must remain open.
Other agencjes
Most cities do not state either the time to award a the contract or whether the
contractor can withdraw a bid if no award is made. As stated for the SHAs this
information would most likely be found in the instructions to bidders in individual
solicitations. The two federal agencies require bids to be open for 60 days vs the more
common time of 30 days used by most of the SHAs. First hand experience by the author
indicates that the larger federal agencies require more time to evaluate proposals and
make award. Since most SHAs pre-qualify bidders and the federal agencies do not, this is
not surprising. There is very little information on bidding in the AlA document.
Impact and Conclusions
Price quotes from material suppliers and subcontractors are subject to change
with time. In periods of economic change prices can go up or down in a short span of
time. The contractor can manage costs over time associated with the completion of the
34
•
•
•
•
•
•
•
•
•
•
•
contract but is at the mercy of the agency until the contract is awarded. Only one agency
held contractor bids open for more than 60 days. Things can change so fast in the
economy that 60 days is probably the upper limit of what is fair and reasonable. The
longer the agency has to award a contract after bid opening, the more costs for
contingencies the contractor must include in the bid. Prompt and speedy award of
contracts can allow the contractor to lock in material and subcontract prices. Using
shorter times for award an agency runs the risk of not being able to award the contract
prior to bids expiring. On the contractors side a shorter time for award means the
contractor is more likely to reduce or eliminate contingencies since costs can be fixed
with subs and suppliers. An agency willing to push for quick action on award can realize
a price. savings on construction awards .
35
•
•
•
•
•
•
•
•
•
•
Proposal Guaranties
lntrodyctjon
Most agencies that use competitive bidding procedures require each bidder to
submit a proposal guaranty with the bid. The guaranty is usually in an amount of 5% to
20% of the contractors bid. The purpose of this guaranty or bid bond is to ensure that
the low responsible bidder enters into a contract with the agency upon award and
furnishes the required payment and performance bonds. The agency usually specifies the
guaranty may be in the form of a certified check, cashier's check, or in the form of a bid
bond on forms acceptable to the agency. The guar~nty is returned to the unsuccessful
bidders at some point in time as stated in the provisions. Timeframes for returning of
bid guaranties are presented in Table 5.
The apparent low bidder is notified of the intent to award and forwarded a
contract and bond forms to fill out. The provisions will state a period of time in which
the contractor must complete the bonds, and return them with the signed contract to the
agency. If the contractor fails to enter into the contract or fails to return it in the
specified time, the agency may make claim upon the bid guaranty. The claim on the
guaranty may be either a forfeiture of the guaranty as liquidated damages or forfeiture of
the difference between the low anc second low bid. The time in which to return tile
signed contract is presented in Table 6. Consequences of failure to return the contract in
the required time are presented in Table 7.
~
All SHA'a require bidders to provide a bid guaranty with a bid. Time frames
stated for their return varied from immediately after bid opening to after award of the
contract. Guaranties of the two or three low bidders are retained until after award in all
36
Table 5: How soon after award are bid guaranties of unsuccessful bidders returned?
After After 3 Days After 1 0 Days After 15 Days After Only checks Agency award bid opening bid opening bid opening bid opening returned Other Not Stated
SHAs 9 1 4 2 2 2 8 8 5
Cities 4 2 1 1 1 4
BLM X
Navy X . "
AlA (")
X
• • • • • • • • • • I •
• Table 6: How long does the contractor have to return the signed contract to the agency? •
Agency 8 Days 1 0 Days 15 Days 20 Days 30 Days Other Not Usted
• SHAs 1 16 19 8 3 3.
Cities 8 1 3 1
BLM X
• Navy X
AlA X
• • Indiana, Nevada, Ohio
Table 7: What is forfeited if the contractor does not return the signed contract within ., the required number of days?
Agency Bid Guarantee Bid Difference Forfeited as LD's Forfeited No Mention Other
• SHAs 47 1 • 2**
Cities 1 1 2
BLM X
• Navy X
AJA X
• • Alabama
•• Indiana, Nevada
• 38 •
•
•
•
•
•
•
•
cases. Of all the agencies reviewed, only New York State required a certified or cashier's
check and would not accept a bid bond. The provision from Arizona is typical of those
agencies that only return checks.
Return of Proposal Guaranty (1 03.04 Arizona)
Proposal guaranties in the form of certified or cashiers checks will be returned immediately following the opening and checking of proposals, except that of the lowest qualified bidder; however, the Department may also retain the proposal guaranty of the second lowest qualified bidder at its discretion. Proposal guaranties in the form of certified or cashier's checks that have been retained will be returned promptly upon completion of both of the following actions: Award of the contract; the filing with the Department of satisfactory bond and contract forms executed by the bidder .
The provision from Texas is representative of those agencies that will return guaranties
some time after bid opening.
Return of Proposal Guaranty (3.3 Texas)
The proposal guaranty of the three lowest bidders may be retained until after the contract has been awarded, executed, and bonds made. Proposal guaranty [sic] of all except the three lowest bidders will be returned within 72 hours after the bids are opened .
Most SHAs require the signed contract be returned to the agency within 15 days
of the notice of the award of the contract as shown in Table 6. The agencies are fairly
consistent in the time they give a contractor to obtain bonds and return the signed
contract. There is very little variation in the wording of the provisions used. The
provisions of Wisconsin, presented below, illustrate the key points of the provisions:
Execution of the Contract (1 03.6 Wisconsin)
The contract shall be executed by the bidder, and the contract bond shall be executed by the principal and the sureties, and both shall be presented to the Administrator within 15 days after the date of notice of the award of the contract...
39
t
I
•
•
•
•
•
•
Failure to Execute the Contract (1 03.7 Wisconsin)
Failure on the part of the successful bidder to supply any information requested in the special provisions and to execute a contract and an acceptable contract bond, as provided in Subsection 103.06 within 15 days after the date of notice of the award of the contract will, at the discretion of the Administrator, be just cause for the annulment of the award and the forfeiture of the proposal guaranty to the State, not as a penalty but in payment of liquidated damages sustained as a result of such failure.
Alabama is the only state in which a low bidder who fails to enter into a contract forfeits
the difference between the low and second low bids. The Alabama clause, 1 03.08 states:
Failure to Execute Contract (1 03.08 Alabama)
Should the successful bidder or bidders to whom the contract is awarded fail to execute a contract and furnish acceptable contract security as provided by Articles 103.05, 103.06, and 1 03.7, the Director shall retain from the proposal guaranty if it be a certified check or recover from the principal or the sureties if the guaranty be a bid bond, the difference between the amount of the contract as awarded and the amount of the proposal of the next lowest responsible bidder but not to exceed the total amount of the proposal guaranty shall be so retained or recovered as liquidated damages for such default. Any sums so retained or recovered shall be the property of the State. In the event of the death of the successful bidder (if an individual and not a partnership or corporation) between the date of the opening of the bids and the 1 0 days following the date of award of the contract as allowed in Articles 1 03.05 and 103.06 for furnishing contract security and executing contract, the Director will return the proposal guaranty intact to the estate of the deceased successful bidder.
When the successful bidder or bidders fail to execute a contract, and the contract is awarded to the next lowest bidder, the original low bidder will be prohibited from doing any work on the contract, either as a subcontractor or in any other capacity. The original low bidder will also be prohibited from bidding on the project if it is readvertised for letting. These restrictions shall apply to any other name under which the same person, individual, partnership, company, firm, corporation, association, cooperative, or other legal entity may be operating in which the principal owners are involved.
Failure by the Department to return to the successful bidder his approved contract and to issue a work order as required by law shall be just cause, unless both parties agree in writing to a stipulated extension in time for
40
•
•
•
I
•
issuance of a work order, for the successful bidder to withdraw his bid, contract, and bonds, without forfeiture of certified check or bid bond.
In this clause, the SHA can also bar the contractor from working on a contract in
any capacity if it does not enter into a contract. Some of the other SHAs have similar
provisions.
Other Agencjes
The provisions of the cities are all similar to the majority of those used by the
SHAs. As confirmed by Table 7 most cities will collect the bid guaranty as liquidated
damages if the contractor will not enter into a contract with the city. Provisions for
time to return the contract to the agency and time to return bid guaranties are also quite
similar. The federal agencies use provisions similar to Alabama in that they only collect
the bid difference between the low and second low bidder in the case of a failure to enter
into a contract. Provisions prohibiting defaulting bidders from working on a contract if
readvertised are also the same. The AlA documents are silent on bid guaranties.
Impact and Conclusjoos
The time the agency holds bid guaranties prior to returning them only has an
impact on the contractor if a bid bond is not used. The time value of the money locked up
in a certified check or cashier's check will increase a contractor's bid. The cost for a bid
bond is typically included in the cost of performance and payment bonds. If a contractor
does not get the low bid then there is typically no cost for the bid bond. From an agency
standpoint, recovery of funds from a bond may appear more difficult than from a
certified check. Insistence on checks instead of allowing bonds results in higher bids. An
agency must balance the prospect of collection difficulties with the benefits of reduced
bids. If the number of bidders that fail to enter into contracts is small, then the effect of
lower bids would be considerable.
41
t
•
•
•
•
•
•
•
•
•
Notice to Proceed and Contract Start Date
lotroductjon
After the contractor has returned the signed contract, the agency may notify the
contractor to proceed with the work with a Notice to Proceed (NTP}. The notice to the
contractor may be called either a notice of award or a notice to proceed but has the same
effect. It notifies the contractor of the decision to award and gives the terms under which
the contract time will start. Most states indicate in their provisions that the award of
the contract is not effective until the contract has been executed by all parties.
Execution by the agency, which follows the execution by the contractor, may require
several weeks so the NTP frequently starts the contract time clock for the project. The
effective date of the NTP may be when mailed, when received or when signed. The
contract start date may be stated in the NTP or may automatically begin a stipulated
number of days after the NTP. Finally, some agencies define the contract start date as
the date the contract is executed by all parties. The provisions were reviewed in regard
to the effective dates of NTPs used by agencies (see Table 8). Agency practices on
contract start dates are presented in Table 9.
The effective date of the Notice to Proceed for most SHAs is the date the NTP is
signed by the agency. Contract start date is most often stated in the NTP. Although there
is considerable variation between states, the provisions used by Connecticut are typical
for those states that use the NTP to define the contract start date .
Notice to Proceed (1.03.08 Connecticut)
The contractor will be bound to the performance of the contract when given notice to proceed with the work on April 1 or no later than 45 calendar days after the date of execution of the contract by the contractor
42
• Table 8: What is the effective date of the Notice to Proceed (NTP)?
• AIJeOOJ When Mailed When Received When Signed Not Stated
SHAs 9 4 32 5
• Cities 2 6 5
BLM X
Navy X
• AlA X
• Table 9: How is the contract start date defined as?
10 Days 15 Days 30 Days
• AgeOOJ As stated in NTP after NTP after NTP after NTP When Signed Other
SHAs 25 4 5 1 9 6
Cities 9 2 1 1
• BLM X
Navy X
AJA X
•
•
• 43 •
•
•
•
•
•
•
•
•
•
•
•
or the deposition of the performance contract bond and payment bond, whichever is last ...
Start of Work (1.08.02 Connecticut)
The Notice to Proceed issued to the contractor by the commissioner or his authorized representative will stipulate the date on which it is expected that the contractor will begin construction and from which date contract time will be charged. In no case, however, shall the contractor begin work prior to the date stipulated in the Notice to Proceed.
Other Agencjes
Usage of NTPs by the cities is similar to the usage by the states except very few
of the cities define the effective date of the NTP. Rather, the contract start date is
defined in the NTP. The federal agencies define the date of the NTP as the date when
mailed. The NTP is a notice of award and is mailed while awaiting the contractor
submission of bonds and return of the signed contract. Contract start date is 15 days
after the date of the notice of award. The AlA provides for the contract start date to be
given in the notice to proceed to the contractor.
Impact and Conclusjons
The use of a NTP allows the contractor to start to organize the project and
implement the plan for construction while awaiting the signed contract. In most cases
the receipt of the NTP obligates the agency to the contract and the contractor is expected
to begin the work. Establishment of the contract start date is important as time charges
begin at that point. Agency use of NTPs and the establishment of contract start dates vary
considerably but this is understandable when the type of time charges used by agencies
are reviewed. Agency location, expected weather and contract type are all factors that
the agency must consider when setting the start date of the contract. Contractors must
carefully review the provisions to know when to anticipate the construction effort to
begin.
44
•
•
•
•
•
•
•
•
•
•
C. post Award Clauses
Schedule and Pre-construction Conference Requirements
Introduction
In most contracts, immediately after the provisions concerning the award of the
contract, several requirements are imposed on the contractor for submissions to and
meetings with the agency. Most agencies require that the contractor submit a schedule
showing the sequence of activities for performing the work. Often the schedule must be
provided to the agency at or prior to a pre-construction conference where contract
administration and project planning and interaction are discussed. Required schedules
can be fairly simple or very detailed. The type of schedule required is outside the scope
of this study; however, the time frame of any required submission is of interest.
Required time frames for submission of project schedules are summarized in Table 10.
If the schedule is submitted to the agency prior to any required pre-construction
conference, the agency has time to review the schedule and can be prepared to discuss and
or approve it at the conference. Requirements for a pre-construction conference are
shown in Table 11 .
Most SHAs require a schedule although there is much variation on when it is
required. Only 5 SHAs do not state the requirements for their schedule. The schedule
clause from Illinois is typical of most SHAs.
Progress Schedule (108.02 Illinois)
After award of the contract and prior to starting work, the Contractor shall submit to the Engineer a satisfactory progress schedule or critical path schedule which shall show the proposed sequence of work, and how the Contractor proposes to complete the various items of work within the number of working days set up in the contract or on or before the completion date specified in the contract.
45
•
Table 10: How soon must the contr:tctor submit a project schedule?
Prior to Aljency starting work
SHAs 1 0
Cities 4
BLM
Navy
AJA
• •
At or prior to the PreConstruction conference
1 0
• •
1 0 Days 15 Days 20 Days 30 Days after Award after award after award after award Other Not Stated
5 7 1 2 1 0 5
3 3 3
X
X
X
• • • • •
~
o:r
•
•
•
•
•
•
•
•
•
•
•
•
The Table 11: Is a pre-construction conference required prior to start of work?
SHAs
Cities
BLM
Navy
AlA
Yes
27
s X
X
47
23
8
X
•
•
•
•
•
•
•
•
•
•
This schedule shall be used as a basis for establishing 'the controlling item of construction operations and for checking the progress of the work. The controlling item shall be defined as the item which must be completP~ either partially or completely to permit continuation of prog•P .. : ~~ -.itall be the responsibility of the Contractor to show the intended rate of production for each controlling item listed on the schedule during the period such item is controlling.
The contractor shall confer with the Engineer at regular intervals in regard to the prosecution of the work in accordance with the progress schedule or critical path schedule.
One of the more interesting schedule clauses is that used by the state of
Mississippi. The Mississippi clause states:
Prosecution and Progress (1 08.03 Mississippi)
The Department will furnish the successful bidder a progress schedule developed in the determination of contract time. Such progress schedule may be used as the approved contract progress schedule or the successful bidder may submit for approval his own proposed progress schedule. The schedule will be in the form of a bar graph diagram indicating the various controlling phases of the work ...
Here the state's schedule will become the approved schedule if the contractor elects to
use it or fails to take action to provide one. Pre-construction conferences are required
by about half of the SHAs. Clauses requiring a conference are all similar with the only
variance being in the time for the conference. The clause used by South Carolina is one
of the better examples. It states:
Pre-construction Conference (1 08.02 South Carolina)
After receipt of the notice of award and prior to the beginning of construction, the Engineer and the Contractor shall establish a mutually agreeable date on which a pre-construction conference will be held. The Contractor shall have present at the pre-construction conference the project superintendent, and other representatives or responsible officials who will be involved during the construction of the project, including representatives of any subcontractors. Officials of local county and municipal governments, representatives of affected utility companies and other affected agencies will be requested by the Engineer to attend in
48
•
•
•
•
•
•
•
•
•
•
•
order that a working understanding can be established, thus providing for the coordination of the work among the various parties and allowing the work to proceed with minimum delay .
The conference discussion of the project will include such matters as the Contractor's plans and schedules, right-of-way, agreements affecting the construction, compliance with permits which have been issued, unusual conditions, compliance with all applicable requirements such as erosion control, pollution controls and other pertinent items conducive to better progress and efficiency of operations. Construction pay items will be discussed so that all parties understand the type of materials required, the method of construction, and the method of measuring and paying for the items of work.
Other Agencjes
Three of the thirteen cities do not state what submission requirements exist for
schedules. Of those that do require schedules, clauses used by the cities are similar to
those used by the SHAs. As with the SHAs, approximately half of the cities also require
a pre-construction conference. Clauses again show little variation from the SHAs. Both
federal agencies require schedules and pre-construction conferences while the AlA
document only requires a schedule. The AlA clause requires that the schedule be
submitted immediately upon award for the Architects approval.
Impact and Conclusions
The pre-construction conference provides a forum for the contractor and the
agency to discuss administrative details and agree on the resolution of problems. While
only about half the agencies require such meetings, contractors should insist on a pre-
construction conference prior to the start of work. It is extremely important that both
the contractor and the agency understand and agree on the administration of the contract
between the two parties. This is also when the agency can inform the contractor of the
relative importance of various work items. Relationships are defined at the conference
and expectations can be more clearly stated. If the schedule is submitted for agency
review prior to the conference, then the agency can provide comments and make the
49
•
•
•
•
•
•
•
•
•
•
•
contractor aware of problems while there is time to make changes to the schedule
without delaying the project or adversely impacting the contractor. Failure to have a
pre-construction conference puts both parties to the contract at greater risk for
misunderstandings which lead to conflict and confrontations. Establishment of the
contract team at an early date greatly reduces the likelihood of claims and disputes later
in the project. If contractor and the agency are in agreement on the schedule, better
cooperation in avoiding adverse impact to the schedule can be expected .
50
•
•
•
•
•
•
•
•
•
•
•
Materials Testing
Introduction
Prior to the contractor performing any actual construction work, most contracts
require that the contractor submit materials for testing and approval. If the contractor
proceeds to install any material without prior approval, the contractor may be required
to remove the materials installed. The number of agencies that require materials to be
tested and approved prior to incorporation into the work is presented in Table 12 .
As can be seen in Table 12, 47 of the SHAs require that materials be tested and
approved prior to incorporation into the work. The 3 agencies that do not, do require
that materials be tested and approved but the requirement is ongoing in the contract.
Their provisions on material testing are similar to the other SHAs except there is no
requirement for prior approval of materials and test results. The agency can test
materials at any time and non-conforming materials must be removed. The clause used
by Montana is typical of those states that require all materials to be tested prior to
incorporation of the work. The clause states:
Samples, Tests, Cited Specifications (1 06.03 Montana)
All materials will be inspected, tested, and accepted by the Engineer before incorporation into the work. Work in which untested and unaccepted materials are used without approval or written permission of the Engineer shall be performed at the Contractor's risk and may be considered as unacceptable and unauthorized and will not be paid for ....
Other Agencjes
Of all the other documents examined, only one city and the AlA require materials
to be tested prior to the contractor using them. The other agencies require that
materials comply with the specifications and testing be performed, but the requirement
51
Table 12: Must all materials be tested and inspected prior to incorporation in the work?
Agency Yes r-ob
SHAs 47 3 *
Cities 1 12
BLM X
• Navy X
AlA X
• * Colorado, Nevada, Washington
•
•
•
•
• 52
•
•
•
•
•
•
•
•
•
is not prior to incorporation into the work.
Impact and Conclysjons
Submission of materials and data for testing and approval can be a lengthy
process. Agencies need to be aware of the testing requirements that are included in the
contract when time for completion is determined. If the agency does not consider the
time for processing submittals and testing of materials, the time given the contractor
for completion may not be reasonable. Contractors need to check whether they can
incorporate materials prior to testing when preparing a schedule and bidding on a
project. A failure to acknowledge these requirements may result in the payment of
liquidated damages at the end of the job .
53
•
•
•
•
•
•
•
•
•
•
•
Contract Time
lntrodyctjoo
The definition of contract time varies among the agencies. Contract time may be
defined in terms of calendar days, working days, or a fixed completion date. Many
agencies use more than one type of accounting depending on the type, size and length of
time for a contract. Most federal agencies use calendar days while most SHA's use
working days. Table 13 presents the allocation of time for construction for the various
agencies. The determination of the means of allocation of time charges depends on many
factors. Time of year, geographic location, complexity of work are among the factors
that must be considered. Time of year and geographic location are considered from a
weather standpoint. Many states in northern and eastern locations use a winter
exclusion period in their contracts. A winter exclusion period consists of a block of time
during the winter months during which no contract time is consumed. Table 14 presents
the number of agencies that use such a period.
~
Thirty-two of the SHAs may use any of the three methods of allocating contract
time. Eleven of the states do not use working days at all. Two states use working days
only and two use calendar days only. Twenty-seven of the SHAs use a winter exclusion
period. Most of these agencies are in the North and East where winter weather is more
severe. Of these twenty-seven, all but Vermont and West Virginia will allow the
contractor to work in the exclusion period without time charges to the contract.
Vermont does not allow any work in the exclusion period. West Virginia allows work but
will charge contract time for any days worked in the period. States in the areas that do
not use a winter exclusion period tend to use working day contracts and exempt days
54
•
•
•
•
•
•
•
•
•
•
•
Table 13: What is the basis of contract time?
Completion Date Working Day Calendar Day Calendar Day Working or Working Day or or
Agency Only Day Only or Calendar Day Calendar Day Completion Date
SHAs 2. 2** 32 5 9
Cities 6 4 2 1
BLM X
Navy X
AlA X
• New York, North Carolina
** Texas, Washington
Table 14: Does the agency have a winter exclusion period and if so does work performed during this period count towards contract time?
Work in period counts Exclusion Period towards contract time
Agency Yes l'b Yes l'b NOt
SHAs 27 23 1 * 25 2 4 * *
Cities 2 1 1 2 1 1
BLM X X
Navy X X
AlA X X
* West Virginia
** Vermont does not allow any work in the exclusion period
55
•
•
•
•
•
•
•
•
•
•
•
where weather keeps the contractor from working .
Other Aqencjes
Cities show more of a trend towards the use of calendar days. Seven of the 13
cities use calendar days to the exclusion of working days. Four cities use working days
only. The federal agencies and the AlA use calendar days only. Only two cities use a
winter exclusion period, both in the North East, and neither will charge time for work
done in the exclusion period .
Impact and Conclusions
Agencies that include a winter exclusion period in their contracts typically
expect severe weather during the winter months. Agencies have recognized that exterior
work may not be possible during the winter months. Contract time may or may not be
charged during the winter exclusion period when work is actually performed.
Contractors need to be aware that winter work may not be permitted .
Contract time defined in calendar days or as a completion date is the easiest to
track. There are no disputes to the passage of time. For working day contracts, the
agency tracks time and it is frequently subject to interpretation. On the other hand,
working day contracts tend to be less risky to the contractor since the effects of weather
are typically removed from the charge of contract time .
56
•
•
•
•
•
•
•
•
•
•
•
Limitation on Operations
Introduction
Agencies sometimes require that the contractor not perform contract work on
Sundays, holidays, or the day prior to or following a holiday. These days where the
contractor might otherwise work will not be available to the contractor. Normal
planning may not call for work on these days but delays in the progress of the work may
make it desirable to the contractor. Provisions have not restricted work on Saturdays,
thereby permitting work on Saturday as make-up days or overtime work on Saturday to
achieve constraints programmed without being charged for the time. Agency practices
are shown in Table 15 .
Half of the agencies contractually have the power to require no work to be
performed on Sundays and Holidays. Only twelve can require that no work be performed
the day before or after a holiday. Most clauses indicate that the contractor can request
permission to work on these days but the agency may prohibit work. The Maine clause
on limitation of operations is one of the better examples of clauses restricting the
contractor from working on Sundays or holidays. It states:
Limitation of Operations (108.04 Maine)
...Unless otherwise specified, the Contractor shall not carry on construction operations on Sundays or Holidays, unless of an emergency nature. The Contractor may work on Martin Luther King Day, Washington's Birthday, Patriots Day and Columbus Day without first obtaining permission of the Chief Engineer. Permission to work on Sundays and other Holidays must be obtained prior to the Sunday or Holiday. In addition, If so directed, the Contractor shall suspend all work, other than maintaining the roadway for traffic, on all portions of the project open to traffic, at such other times as the Engineer deems necessary. Working day or calendar days will not be charged against the Contractor during any such suspension period .
57
• Table 15: May the agency require no work be performed on ?
• Day Preceding or
Sunday Holidays Following a Holiday Agency Yes N:> Yes N:> Yes N:>
• SHAs 25 25 25 25 12 38
Cities 8 5 7 6 1 3
BLM X X X
• Navy X X X
AJA X X X
•
•
•
•
•
•
• 58
•
•
•
•
•
•
•
•
•
•
•
Other Aaencjes
Approximately half of the other agencies restrict work on Sundays and holidays .
It was interesting to note that none of the other agencies had clauses that could restrict
work on the day prior to or after a holiday. The AlA document was the least restrictive of
documents in that no restrictions were placed on days that could be worked.
Impact and Conclusjons
Agency use of provisions that limit contractor operations increase contractor
risk as the ability to overcome delays is reduced. The contractors only option is to
increase labor when work days may not be increased. This reduces the contractor's
flexibility and may result in an increase in contractor bids. SHAs and cities use these
clauses to reduce impact on the Public. In private contracting the owner may not use
these clauses in hopes of quicker project completion .
59
•
•
•
•
•
•
•
•
•
•
•
Working Days
lntroductjon
The definition of working days on a working day contract should be of
considerable interest to the contracting parties. For all contracts that use working days,
the agency tracks and charges time. The contract provisions define working days and how
time will be charged. Most agencies define working days as any day except (Saturdays,
Sundays, and Holidays), the contractor performs or could be performing work on the
contract.
Working days may be charged for Saturdays, Sundays, and Holidays if the
contractor works on those days or the time may "belong" to the contractor. Table 16 and
Table 16a. present the agency practices in regards to charging of contract time for these
days. The agency typically records the time and normally provides the contractor with a
periodic record of time charged. The contractor is given a period of time to take
exception to the time charges of the agency. Table 17 is a summary of the frequency
with which the agency presents the contractor with a record of time charged. Table 18
shows the time in which the contractor has to take exception to the agency log of days
charged.
The agency basis for charging time on working day contracts may exclude days of
adverse weather. Table 19 records the agency practices on excluding weather delays.
~
The SHA's showed a slight bias towards charging the contractor a working day if
the contractor works a Saturday, Sunday or Holiday. Charging contract time on these
days means that if the contractor falls behind schedule, it is not possible to catch up by
working weekends or holidays. Adding crews and equipment is the only alternative to
60
•
•
• Table 16: Does Saturday count as a working day if worked?
Agency Yes 1\b Not Stated Nt\
SHAs 1 6 13 1 0 1 1
• Cities 2 y 7
BLM X
• Navy X
AlA X
• Table 16a: Does Sunday or Holiday count as working day if worked?
Agency Yes 1\b Nt\
• SHAs 23 1 6 1 1
Cities 4 2 7
BLM X
• Navy X
AlA X
•
•
61 •
•
Table 17: For working day contracts, how often does the agency submit a record of days
• charged for the contractor to review?
Twice No Mention
• Agency Weekly Monthly Monthly or Other N«\
SHAs 24 3 6 6 1 1
Cities 2 1 3 7
• BLM X
Navy X
AlA X
• Table 18: For working day contracts, how long does the contractor have to take exception
to the agency log of days charged?
• em 1 0 1 5
Agency Week Days Days Other No Mention N«\
SHAs 1 7 7 4 • Cities 3 3 7
BLM X
• Navy X
AJA X
• • Alabama, Colorado, Michigan
•
62
•
• Table 19: For working day contracts, are weather delays excluded from time charges?
• Agency Yes 1\b No Mention Nt\
SHAs 31 2 * 6 1 1
• Cities 5 1 7
BLM X
Navy X • AlA X
• * West Virginia, Wyoming
•
•
••
•
•
• 63
•
•
•
•
•
•
•
•
•
•
•
regain time. The working day clause from Illinois is typical of clauses used by the SHA's .
The clause states: Working Days (1 08.04 Illinois)
When the contract provides a specified number of working days or a completion date with a guaranteed number of working days, the charging of working days shall start when the Contractor begins actual construction work, and in no case later than 1 0 days after the execution and approval of the contract, unless otherwise provided in the contract.
A working day shall be defined as any calendar day between May 1 and December 15 inclusive except Saturdays, Sundays or holidays observed by the Contractor's entire work force in Illinois. The length of a working day will be determined by the Engineer from the number of working hours established by actual job practice by the Contractor for the current controlling item, except that not less than eight hours will be considered in the determination .
A full working day will be charged for any day described in the foregoing on which conditions are such that the Contractor could be expected to do a full day's work on the controlling item. A full working day will be charged on days when the Contractor could be working on a controlling item, but elects not to work, or elects to work elsewhere .
No allowance will be made for delay or suspension of the work due to the fault of the Contractor.
The Engineer will determine which days are workable .
(a) A partial working day of one-quarter, one-half or three-quarters shall be charged under the following conditions:
(1) When weather conditions do not permit the completion of a full day's work on the controlling item .
(2) When job conditions due to recent weather do not permit full efficiency of the men or equipment which are working on the controlling Item.
(3) A shortage of help which is beyond the Contractor's control prevents reasonable progress on a controlling item.
(4) When any condition over which the Contractor has no control prevents completing a full day's production on the controlling item .
( b ) No working day shall be charged under the following conditions:
64
•
•
•
•
•
•
•
•
•
•
•
(1) When adverse weather prevents work on the controlling item .
(2) When job conditions due to recent weather prevent work on the controlling item.
(3) When work has been suspended by an act or omission of the Department or Engineer .
(4) When strikes, lock-outs, extraordinary delays caused by utility and Railroad work, extraordinary delays in transportation or inability to procure critical materials suspend work on the controlling item, as long as these delays are not due to any fault of the Contractor .
(5) When any condition over which the Contractor has no control causes suspension of work on the controlling item.
One copy of the "Weekly Report of the Resident Engineer" will be mailed to the Contractor's office weekly. Any disagreement with the working day charges shown must be expressed in writing to the Engineer within seven days of receipt of the Report giving detailed reasons for the disagreement. The final resolution of such disagreement will be made by the Engineer.
In this case the clause states a weekly report will be mailed to the contractor and the
contractor has one week to take exception. Time charges will include any day the
contractor works and exclude the winter exception period and Saturdays, Sundays, and
holidays if not worked. Weather delays are exempted from time charges .
The clause from Delaware will not charge the contractor working days for
working Saturdays but does charge for Sundays and holidays if worked. The clause states:
Working Days (101.73 Delaware)
A working day is defined as a calendar day exclusive of Saturdays, Sundays, or State legal holidays when the contractor can prosecute the work. Working days will not be charged if the contractor elects to work on Saturdays, but will be charged if he is permitted to work on Sundays or State legal holidays. Time charges in the form of working days will start when the contractor begins actual construction work and in no case later than ten days after the written notice to proceed with the work ...
... Working days will not be charged under the following conditions: 1. If the contractor elects not to work, when the condition of the ground,
65
•
•
•
•
•
•
•
•
•
•
•
weather conditions, or other conditions beyond the control of the contractor make it impossible in the opinion of the Engineer to carry on any work in accordance with the work schedule . 2. When operations are suspended due to an act or omission on the part of the Department. 3. On working day and calendar day contracts no time will be charged for work performed during December 16 to March 15 inclusive. When the contractor performs work during the period from December 16 to March 15 inclusive, he must secure authorization from the Engineer sufficiently in advance of the proposed work to provide for proper inspection. The number of working days allowed for the completion of the project are shown in the proposal.
The contractor is also given the option of working during the winter exclusion period
without being charged contract time. Weekly submittal of the record of time charged to
the contractor is used by most states that use working days. The majority of SHAs allow
the contractor one week for review of the record of time charged.
For the two states that do not include weather delays in the basis for contract
time charged, both will exempt weather delays that are an act of God. Weather of normal
intensity, temperature and frequency is not included.
Other Agencies
Other agency practices parallel the SHAs with working days. The exception to
this is shown on Table 18 where it can be seen that half of the cities that use working
days do not mention how frequently a copy of the record of contract time charges will be
forwarded to the contractor. Working days are not used by the federal agencies and
neither are they indicated in the AlA documents.
Impact and Conclusions
The contractor and the agency need to know prior to starting work how contract
time will be charged. Some of the definitions used by the agencies do not clearly state if
time will be charged for Saturdays, Sundays, and holidays if worked. Time charges
during the winter exclusion period are clear, i. e., there is no charge of time If the
66
•
•
•
•
•
•
•
•
•
•
•
contractor cannot or will not perform work. If the contractor elects to work during this
period, many agency provisions are not clear if time will be charged. Review periods
for the record of time charged are varied and a contractor could lose entitlement to an
exception if the contractor does not respond within the agency required time. Allowing
the contractor to work on Saturdays, Sundays, and holidays without charging contract
time reduces risk for the contractor. The agency is not giving the contractor any more
time than was expected and the contractor gains some flexibility in scheduling work. If
the provisions are not clear both parties have increased risk for disputes and claims .
67
•
•
•
•
•
•
•
•
•
•
•
Differing Site Conditions
lntrodyctjon
In the course of a construction project, it is not unlikely that some aspect of the
work will be different from that which is shown in the plans or could normally be
expected. In many contracts, the contract vehicle that is in place to deal with these
changed conditions is a •oiffering Site Conditions· clause. It may also be called a changed
conditions clause but the wording is basically the same. This type of clause causes the
owner to assume the risk that conditions at the site will not differ from those shown in
the plans or that no unexpected hidden physical conditions exist on the project.
The clauses generally cover two types of situations the contractor may encounter .
The first situation includes subsurface or latent physical conditions at the site which
differ materially from those indicated in the contract documents, namely the plans and
specifications. An example of this type of condition is soils differing from those
represented in the plans. The second situation is unknown physical conditions at the
site, of an unusual nature, differing materially from those ordinarily encountered and
generally recognized as being inherent in the work of the being performed. This part of
the clause would cover situations where the contractor encounters a physical condition
that a prudent contractor could not reasonably anticipate after having examined the site
and being experienced in the type of work involved. An example of this is a foundation
contractor encountering an underground stream, during excavation for the foundation of
a building, where the site showed no evidence of the stream prior to excavation .
Another key part of the clause is that the contractor, upon discovering a differing
site condition, must inform the owner's representative and seek direction before
continuing work in the area. As shown in table 20, all agencies that use a differing site
68
• Table 20: In the case of differing site conditions must the contractor notify the agency
prior to disturbing?
Agency Yes No Mention
SHAs 42 8
• Cities 8 5
BLM X
Navy X
• AJA X
•
•
•
•
•
•
69 •
•
•
•
•
•
•
•
•
•
•
•
conditions clause require that the contractor notify the engineer on the project that a
differing site condition has been encountered prior to disturbing it.
For the SHAs, 42 states use a differing site conditions clause. The review
indicated that 36 of these states use a standard differing site conditions clause (see Table
21 ). This clause is frequently located in the supplemental clauses as a set of three
clauses, including the Suspensions clause and a clause on Alteration in the Character of
the Work. The following clause used by Iowa is typical of the standard clauses used by
the SHAs:
Differing Site Conditions (Iowa 1989)
During the progress of work, if subsurface or latent physical conditions are encountered at the site differing materially from those indicated in the Contract or if unknown physical conditions of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent in the work provided for in the Contract, are encountered at the site, the party discovering such conditions shall promptly notify the other party in writing of the specific differing conditions before they are disturbed and before the affected work is performed .
Upon written notification, the Engineer will investigate the conditions, and if he/she determines that the conditions materially differ and cause an increase or decrease in the cost or time required for the performance of any work under the contract, an adjustment, excluding loss of anticipated profits, will be made and the contract modified in writing accordingly. The Engineer will notify the Contractor of his/her determination whether or not an adjustment of the contract is warranted.
No contract adjustment which results in a benefit to the Contractor will be allowed unless the Contractor has provided the required written nt ;ice .
No contract adjustment will be allowed under this clause for any effects caused on unchanged work .
70
__________________________________ .......
•
•
•
•
•
•
•
•
•
•
•
Table 21: Do the contract provisions contain a Differing Site Conditions clause and if so,
is the clause the standard clause?
Agency
SHAs
Cities
BLM
Navy
AJA
Yes
42
8
X
X
X
Use Standard Clause
8 • 36
5 2
• Connectcut, Georgia, Kentucky, Nevada, New York, Pennsylvania, Rhode Island, South Dakota
71
•
•
•
•
•
•
•
•
•
•
•
For the SHAs that do not use a differing site conditions clause, all except New
York State have clauses that would allow a contractor to attempt recovery for increased
time and cost associated with a differing site conditions. The New York clause
specifically places much of the risk associated with a differing site condition on the
contractor. Portions of the New York clause Delays, Inefficiencies, and
Interference (Article 13, New York ) are shown below:
... A. The Contractor further agrees that he has included in his bid prices for the various items of the contract any additional costs for delays, inefficiencies, or interferences affecting the performance or scheduling of contract work caused by, or attributable to, the following instances:
... 11. Unforeseen or unanticipated surface and subsurface conditions .
... C. The provisions of this Article apply only to claims for extra or additional costs attributable to delays, inefficiencies, or interferences and do not preclude determinations by the Commissioner allowing reimbursement for additional direct costs for extra work pursuant to §105-14 .
Here the contractor may not recover any of the costs associated with delays or
inefficiencies on the job as a result of a differing site condition. The costs associated
with idled equipment while awaiting direction can be significant. The contractor who is
working under this clause would prudently increase bid prices to include a contingency
amount to cover any doubt concerning the site conditions .
In the other states that do not use a Differing Site Conditions clause, recovery of
costs for unforeseen work may be through the extra work clause. The Georgia Clause is a
typical example of an extra work clause that may allow recovery. The clause states:
Extra Work (1 04.04 Georgia)
The contractor shall perform unforeseen work, for which there is no price included in the contract, whenever it is necessary or desirable in order to complete fully the work as contemplated. Such work shall be
72
•
•
•
•
•
•
•
•
•
•
•
performed in accordance with the specifications and as directed, and will be paid for as provided in 109.05 .
Other Agencies
As can be seen from table 21 , eleven of the sixteen other agencies use a differing
site condition clause. Wording of the clause is much more varied than that used by most
of the SHAs. Some cities add other actions the contractor must perform to obtain
adjustment to the contract in the case of a differing site condition. The city of Dallas
clause is an interesting case in point. Their clause states:
Differing Site Conditions (Dallas 4.3.6)
If: (1) concealed subsurface conditions are encountered in the course of performance of the work, (2) concealed or unknown conditions in an existing structure are at variance with conditions indicated by the Contract Documents, or (3) unknown physical conditions are encountered below the surface of the ground in an existing structure which are of an unusual nature and materially different from those ordinarily encountered and generally recognized as inherent in the character of the work, the Contract Sum may be adjusted if the Owner and the Architect determine that: (a) the Contractor used reasonable diligence to fully inspect the work site, and (b) the concealed items can be considered extra work to the extent that additional new construction beyond the scope of the Contract Documents is required. Otherwise, any cost adjustment associated with the concealed items will not be considered. Jobsite information and reports provided by the Owner and/or Architect in the Project Manual or otherwise shall be utilized by the Contractor at his own risk, and Owner and Architect neither guarantee nor warrant any information shown therein.
In this clause, the contractor can obtain relief from the condition only if it can be
considered extra work with additional new construction beyond the scope of the Contract
Documents required. A concealed condition that requires the contractor to change work
methods or equipment would not result in an adjustment to the contract. Additional new
construction is required. Soft ground discovered on a scraper project requiring that a
contractor to use a drag line for excavation would not result in an adjustment to the
contract. Soft ground that requires a contractor to drive piles for a foundation, for
73
•
•
•
•
•
•
•
•
•
•
•
which no piles were required in the contract, would qualify for an adjustment to the
contract.
The clauses used by the BLM, Navy, and AlA are all similar to the standard clause
used by the SHAs. The differing site condition clause used by the federal agencies is
mandated for use in the Federal Acquisition Regulations and will be identical in all
federal contracts.
Impact and Conclusjons
Use of a differing site condition by an agency is an assumption of risk. The
agency's purpose is to eliminate contingencies from contractors bids for unforseeable or
unknown conditions. The owner is assuming this risk in anticipation of lower bid prices
from contractors. While most of the agencies reviewed do use a fairly standard clause,
the variations and additional conditions that can be imposed on the contractor make it
important that a c.ontractor understand the provision if it is contained in a contract.
74
•
•
•
•
•
•
•
•
•
•
•
Adverse Weather
!ntroductjon
Weather and its impact must be considered on every construction project. The
policies of an agency concerning weather can •make or break· a contractor. Provisions
relating to time extensions often indicate that the contractor may receive an extension of
time if adverse weather delays the completion of a project. Even though the provisions
indicate that the contractor may receive an extension for adverse weather, few agencies
define the term. Table 22 shows just how few agencies define adverse weather. • Yes• is
checked in the table only if the definition is clearly stated and the determination is not
left up to the engineer .
Only four out of fifty SHAs define adverse weather to the extent that the engineer
does not have the determination of what weather conditions are adverse. The
Massachusetts provision Determination and Extension of Contract Time for
Completion (8.1 0 ) is one of the SHA provisions clear on this point. The clause
states: ... D. When delay occurs due to reasonable cause.; beyond the control and without fault of the contractor, including but not restricted to •Acts of God•, ... the time for completion of work shall be extended in whatever amount is determined by the Engineer to be equitable .
An •Act of Go~ as used in this article is construed to mean an earthquake, flood, cyclone, or other cataclysmic phenomenon of nature beyond the power of the Contractor to foresee or make preparation in defense of. A rain, wind:storm, or other natural phenomenon of normal intensity, based on United States Weather Bureau reports, for the particular locality and for the particular season of the year in which the work is being prosecuted, shall not be construed as an ·Act of God• and no extension of time will be granted for the delays resulting therefrom ...
75
•
• * Florida, Indiana, Massachusttes, Ohio
•
•
•
•
•
• 76
•
•
•
•
•
•
•
•
•
•
•
Other Agencjes
The other agencies Tend to do a better job of defining adverse weather. In the AlA
document, clause 4.3.8, Claims for Additional Time, the contractor is advised that
if adverse weather is the basis for a claim for additional time the contractor must
support the contention that the weather was adverse. The clause states:
Claims for Additional Time (4.3.8 AlA 201)
... 4.3.8.2 If adverse weather conditions are the basis for a Claim for additional time, such claim shall be documented by data substantiating that weathsr conditions were abnormal for the period of time and could not have been reasonably anticipated, and that weather conditions had an adverse effect on the scheduled construction.
Here the adverse weather is defined as conditions which are abnormal for the period of
time and could not have been reasonably anticipated. The determination of what
constitutes adverse weather is clearly defined and not left up to a decision of the engineer
or architect.
Impact and Conclusjons
The next section will look at tirue extensions and if agencies will grant additional
time due to adverse weather. The definition of adverse weather is not clear the most of
the provisions used. With the determination left up to the Engineer in most cases,
contractors may not be fairly treated. If the clause states that time extensions will be
granted for periods of adverse weather, the term •adverse weather- needs to be defined
so there is no disagreement between the parties. The lack of a clear definition increases
the risk to the contractor in situations where there need be no disagreements .
77
•
•
•
•
•
•
•
•
•
•
•
Time Extensions
lntroductjon
Time extensions to the contract may be granted under many different contract
clauses including: Time Extensions, Damages for Delay, Termination for Default, and
Suspensions. Time extensions are granted to a contractor for excusable delays. These
are delays that are not the fault of the contractor. The clauses usually indicate that
additional contract time will be granted when the contractor is delayed because of
"Unforseeable causes beyond the control and without the fault or negligence of the
contractor". These causes may include acts of the agency in its administration of the
contract. Contractors must review the provision of the contract to determine how and if
time extensions will be granted. Almost all agencies will grant additional time under
some clause although many agencies limit the ability of the contractor to recover
monetary damages for delays the contractor may have suffered. In reviewing the agency
documents, all agencies have provisions that will grant the contractor additional time
under some conditions. Agency documents were reviewed specifically to determine if
contractors would be granted additional contract time for weather delays. Agency
practices on time extension for weather delays are presented in Table 23. Delays due to
agency practices or direction will be covered in the discussion of the "Suspensions"
clause.
Agency time frame requirements for submission of time extension requests were
examined and found to vary considerably. No tabular presentation is possible due to this
variation but agency requirements are indicated in the tabulation spreadsheets in
Appendices A and B. Some of the more common requirements were that requests for time
extensions be submitted anytime prior to completion or from 7 to 1 0 days after the
78
• Table 23: Does the contract allow for time extensions and if so will the contract time be
• extended for weather delays?
Time Extension allowed Extend for weather Delays Agency Yes 1\b Yes 1\b
• SHAs 50 43 7 •
Cities 13 13
BLM X X
• Navy X X
AJA X X
• * Connectcut, Idaho, Indiana, Kentucky, North Carolina, Pennsylvania, South Carolina
•
•
•
•
• 79
•
•
•
•
•
•
•
•
•
•
•
•
end of the delay .
All SHAs granted additional contract time under some conditions. Most agencies
will extend the contract for delays associated with adverse weather. Some agencies us a
seasonal weighting of days to determine if the contractor will be aliowed a time extension
due to adverse weather. Typical of the clauses that use a seasonal weighting of days is
the clause used by Ohio. The clause states:
Date for Completion (108.06 Ohio)
.. .If the Contractor finds it impossible for reasons beyond his control to complete the work by the date as specified or as extended in accordance with the provisions of this subsection, he may make a written request to the Engineer for an extension of time setting forth therein the reasons which he believes will justify the granting of his request. Requests for extensions of time shall be filed in writing by the Contractor with the Engineer not more than 30 days following the termination of the delay. The Contractor's plea that insufficient time was specified is not a valid reason for extension of time. If the Director finds that the work was delayed because of conditions beyond the control and without the fault of the Contractor, he may extend the time for completion in such amount as the conditions justify.
Delays caused by weather or seasonal conditions should be anticipated and will be considered as the basis for an extension of time only when the actual work days lost exceeds the number of work days lost each month due to inclement weather as determined by the following schedule:
Month
May June July August September October November
Number of Work Days Lost Due to Weather
5 5 4 4 5 6 6
The time between December 1 and April 30 is considered winter months and no extensions will be granted for this time. A work day will be counted as lost if the Contractor's efficiency is reduced more than 50
80
•
•
•
•
•
•
•
•
•
•
•
percent on the critical Item under construction at that time. Weekends and holidays will not be counted as lost work days ...
Contracts on a working day basis typically exempt adverse weather. Of the SHAs
that do not allow time extensions for weather delays this requirement may apply
only to non-working day contracts. Indiana which may use contracts allocating
time by any of the three basis, will not grant a time extension for weather delays
on calendar day or completion date contracts. The Indiana Clause states:
Determination and Extension of Contract Time (1 08.06 Indiana)
...If the contract time is on a calendar day basis or has a fixed calendar date for completion, no extension of time will be considered for unsuitable weather or conditions resulting therefrom ....
Some SHAs will grant additional contract time for weather delays only if the weather is
unusually severe. The Florida clause is a good example of this type of clause:
Computation of Contract Time (8.7 Florida)
...Rains or other inclement weather conditions and related adverse soil conditions will be considered as the basis for granting of a time extension only when such conditions are unseasonable, provided that the project records indicate that they did in fact delay one or more controlling items of work ...
Other Agencjes
All other agencies reviewed granted time extensions due to adverse weather.
Provisions for about half of the agencies defined adverse weather and would grant a time
extension only if the weather was unseasonable.
Impact and Conclusjons
Agencies that define adverse weather and will grant a time extension for
unusually severe weather only increase the contractor's risk as the contractor must now
make a guess for how weather will impact the job. Better than average weather will
result in the contractor completing the job early and probably with a greater profit.
81
•
•
•
•
•
•
•
•
•
•
•
Unusually severe weather will cause the contractor to be delayed and while a time
extension will be granted, there is no compensation for increased job costs. Contract
provisions that grant a contractor time extensions for any weather delay greatly reduce
the contractors risk as possible liquidated damages are avoided for typical weather
delays. Agencies may be able to reduce bid prices if provisions are included to extend the
contract time for weather delays. Agencies that use working day contracts and exempt
weather delays from the time charged to the contract should expect to receive better bid
prices versus calender day or completion contracts where expected inclement weather is
not a valid reason for a time extension .
82
•
•
•
•
•
•
•
•
•
•
•
Claims
lntroductjon
Claims in construction contracts are increasing in fre4uency and cost. Most
agencies recognize that claims are a fact of life and, consequently, include a claims
clause in their contracts. A claims clause allows contractors to present disputes to the
agency for resolution without having to resort to litigation as a first step. All agencies
that have a claims clause require that the contractor notify the agency of any work that
is in dispute prior to performing disputed work. If the required notification is not
given, the contractor may waive entitlement to compensation for the work. Table 24
presents the number of agencies that have a claims clause. Agency time frames for
submission of claims and disputes resolution procedures vary considerably from agency
to agency. Some agencies clearly state submission requirements and many do not.
Claims submission requirements are detailed on Table 25. The part of the provisions
dealing with notification prior to performing work for which a claim will be made is
fairly standard in most agencies. Some claims clauses also provide a detailed dispute
resolution process.
Forty-five SHAs have claims clauses in their contract provisions. For the five
states that do not have claims clauses in their provisions, the contractor may still be
able to recover for disputed work but the avenue for recovery is through litigation in
the courts. Language for the initial notice requirements is similar in all agencies. The
language used in the first paragraph of the North Dakota clause is typical of the start of
most claims clauses. The clause states:
83
•
•
•
•
•
•
•
•
•
•
•
Table 24: Are claims clauses present in the contract documents?
Agency
SHAs
Cities
BLM
Navy
AlA
Yes
45
9
X
X
X
5 *
2
* Connectcut, Illinois, Nebraska, Nevada, Texas
Table 25: When must claims be submitted to the agency?
Agency 10 Days 30 Days 60 Days 120 Days
SHAs 1 4 8 2
Cities 2 1
BLM
Navy
AJA
84
Other
3
X
Not listed
35
7
X
X
•
•
•
•
•
•
•
•
•
•
•
Claims for Extra Compensation (1 04.03 North Dakota)
If the contractor deems additional compensation is warranted for work or materials not covered in the contract or not ordered by the engineer as •extra work,• according to section 109.04, the contractor shall, prior to beginning work on which the claim will be based, notify the engineer in writing of the intent to make claim and the basis for such claim for additional compensation. If the basis for the claim does not become apparent until the contractor has proceeded with the work and it is not feasible to stop the work, the contractor shall immediately notify the engineer that work is continuing and that written notification of the intent to make claim will be submitted within 10 calendar days. Failure of the contractor to give required notification and to provide the engineer proper facilities and assistance in keeping strict account of actual costs will constitute a waiver of c!aim for additional compensation in connection with the work already performed. Notification of a claim, and the fact that the engineer has kept account of the costs involved, shall not be construed as proving or substantiating the claim's validity .
All claims by the contractor for additional compensation shall be submitted in writing within 120 days after completion of the work on which the claim is based ....
Here the notice period is clearly stated and the contractor is given a time limit for
submission of the claim after the work on which the claim is based. The clause goes on
to detail the disputes resolution procedure. Disputes resolution procedures are quite
different from SHA to SHA. The Georgia clauses on dispute resolution are particularly
thourough and the claims process is very well defined. See appendix C for a copy of the
claims provision used by the State of Georgia .
Other Agencjes
Of the other agencies reviewed, only two did not have a claims clause in the
contract provisions. As discussed with the SHAs, recovery for disputed work on
projects of these two agencies may still be possible through the courts. Some of the
claims provisions used by the cities are of interest. The clause used by the city of
Cincinnati is one of the better clauses used by the Cities.
85
•
•
•
•
•
•
•
•
•
•
•
Claims for Adjustments and Disputes (Cincinnati 1 05.17)
All disputes arising under this Contract or its interpretation, whether involving law or fact or both, or extra work, and all claims for alleged breach of contract shall within ten days of commencement of the dispute be presented by the contractor to the city for decision. Such notice need not detail the amount of the claim but shall state the facts surrounding the claim in sufficient detail to identify the claim, together with its character and scope. In the meantime the contractor shall proceed with the work. Any claim not presented within the time limit specified within this paragraph shall be deemed to have been waived, except that if the claim is of a continuing character and notice of the claim is not given within ten days of its commencement, the claim will be considered only for a period commencing ten days prior to the receipt by the city of notice thereof .
The contractor shall submit in detail the claim and the proof thereof. Each decision by the City bill be in writing and will be delivered to the contractor .
If the contractor does not agree with any decision of the city, the contractor shall in no case allow the disputes to delay the work but shall notify the city promptly that the contractor is proceeding with the work under protest and the contractor may then except the matter in question from the final release .
The clause allows the contractor an avenue for disputed work and reasonable time
frames to submit notice and proposals. The claims clause used in the AlA document is
somewhat different. The AlA clause states:
Time limits on Claims (AlA 201- 4.3.3)
Claims by either party must be made within 21 days after occurrence of the event giving rise tc such claim or within 21 days after the claimant first recognizes the condition giving rit:~e to the claim whichever is later. Claims must be made by written notice. An additional claim made after the initial claim has been implemented by change order will not be considered unless submitted in a timely manner .
In this clause the owner may not know about a potential claim until three weeks after
the event or condition giving rise to claim. This increases the risk for the owner and
may result in the contractor •blind siding• the owner with a claim that is brought to the
86
•
•
•
•
•
•
•
•
•
•
owner's attention after three weeks worth of work has been completed. Resolution of the
dispute at this point may be much more costly.
Impact and Conclusjons
Construction disputes are here to stay. Owners must understand that early
resolution of claims is desirable and results in decreased costs. Using claims clauses in
the provisions provides an avenue for this process and may help settle disputed issues.
If there is an administrative avenue prior to seeking relief in the courts contractors are
more likely to settle and this will reduce costs for both parties. Contractors need to
review the claims provisions and determine the required notification time limits so as
to not waive an otherwise valid claim. The great variety of disputes resolution
prov1:sions (other than the notification requirement) illustrate the many different
attitudes of owners. Ignoring the reality of claims and not using provisions to deal with
them within the contract forces costly litigation. Claims provisions need to be fair and
provide for a review of the dispute at a level above the administrative office dealing with
the dispute. Times for the agency to respond and review claims need to be more clearly
defined for some agencies .
87
•
•
•
•
•
•
•
•
•
•
•
Suspensions
lntroductjon
The general conditions provisions of most agencies contain clauses that give the
agencies the ability to suspend work on the CC\'ltracts. Suspensions may be due to the
fault of the contractor or due to the fault of the agency. The most important components
of these clauses concern the general nature of suspensions and the ability of the
contractor to recover costs associated with agency suspensions. If contractors cannot
recover damages for agency delays, contract contingencies go up. Most contracts contain
provisions for the owner to suspend work when the contractor is not in compliance with
the contract. Other provisions detail how the contractor may recover costs if delayed
without fault of the contractor. Table 26 addresses agency use of suspension clauses by
agencies. In addition to the clauses already mentioned, some agencies have clauses
dealing with the discovery of historical or archeoiogical artifacts. There is no standard
language in these clauses and contractors may or may not be able to recover costs
associated with delays associated with archeological finds. The frequency of agency use
of clauses for archeological or historical finds in presented in Table 27.
Another type of clause used by some agencies associated with suspensions clauses
are ·No Damage for Delay• clauses. Use of this type of clause is declining since the
courts take a narrow view of the use of such exculpatory language in contracts. Only one
SHA still uses this type of clause although several of the city documents also included
them .
As can be seen in Table 26, all SHAs have suspensions clauses. A significant
number (31) of ihe agencies use a standard clause that frequently appears in a standard
88
•
• Table 26: Can the agency suspend work and if so do they use a standard clause?
Agency Yes Use Standard Clause
• SHAs 50 31
Cities 8 5
BLM X • Navy X
AJA X
• Table 27: Is there a clause for suspension of work if historical or archeological finds
• are encountered?
Agency Yes f\b
• SHAs 27 23
Cities 3 1 0
BLM X
• Navy X
AJA X
•
•
• 89
•
•
•
•
•
•
•
•
•
three clause packet in the supplemental specifications. The manner of its incorporation
suggests that the three clauses, (Suspensions, Differing Site Conditions. Alteration to
Character of the Work) are clauses provided by the Federal Highway Administration for
use by the states when federal moneys are involved. The clause used by Iowa is
representative of the standard clause in use by many of the agencies. Th~ clause states:
Suspensions of work ordered by the Engineer (Iowa)
If the performance of all or any portion of the work is suspended or delayed by the Engineer in writing for an unreasonable period of time (not originally anticipated, customary, or inherent to the construction industry) and the Contractor believes that additional compensation and/or contract time is due as a result of such suspension or delay, the Contract.lr shall submit to the Engineer in writing a request for adjustment within 7 calendar days of receipt of the notice to resume work. The request shall set forth the reasons and support for such adjustment.
Upon receipt, the Engineer will evaluate the Contractor's request. If the Engineer agrees that the cost and/or time required for the performance of the contract has been increased rc; a result of such suspension anc the suspension was caused by conditions beyond the control of and not the fault of the Contractor, its suppliers, or Subcontractors at any approved tier, and not caused by weather, the Engineer will make an adjustment (excluding profit) and modify the contract in wnling accordingly. The Engineer will notify the Contractor of his/her determination in whether or not an adjustment of the contract is warranted .
No contract adjustment will be allowed unless the Contractor has submitted the request for adjustment within the time prescribed.
No contract adjustment will be allowed under this clause to the extent that performance would have been suspended or delayed by any other cause, or for which an adjustment is provioed for or excluded under any other term or condition of this contract.
The clause allows the contractor to recover costs associated with suspensions with the
exception of profit. This clause is quite fair and allows the contra:tor to request
adjustments for any •unreasonable• period and the agency will review and make a
determination of entitlement.
90
New York uses clauses that are much more restrictive. In the New York clause,
no recovery other than additional time is allowed. The clause states:
Delays. Inefficiencies. and Interference (Article 13, New York )
The Contractor agrees to make no claim for extra or additional costs attributable to any delays, inefficiencies, or interference in the performance of this contract occasioned by any act or omission to act by the State or any of its representatives except as provided in Subsection (B) of this Article. The Contractor also agrees that any such delay, inefficiency, or interference shall be compensated for solely by an extension of time to complete the performance of the work in accordance with the provisions of §108-04 in the Standard Specification. In the event the contractor completes the work prior to the contract completion date set forth in the proposal, the Contractor hereby agrees to make no claim for extra costs due to delays, interference or inefficiencies in the performance of the work except as provided in §(B) of this Article.
A. The Contractor further agrees that he has included in his bid prices for the various items of the contract any additional costs for delays, inefficiencies, or interference affecting the performance or scheduling of contract work caused by, or attributable to, the following instances:
1. The work or the presence on the contract site of any third party, including but not limited to that of other contractors or personnel employed by the State, by other public bodies, by railroad, transportation or utility companies or corporations, or by private enterprises, or any delay in progressing such work by any third party.
2. The existence of any facility or appurtenance owned, operated, or maintained by any third party.
3. The act, or failure to act, of any other public or governmental body, including, but not limited to, approvals, permits, restrictions, regulations or ordinances.
4. Restraining orders, injunctions, or judgements issued by a court.
5. Any labor boycott, strike, picketing or similar situation.
6. Any shortages of supplies of materials required by the contract work.
7. Climatic conditions, storms, floods, droughts, tidal waves, fires, hurricanes, earthquakes, landslides, or other catastrophes. However, payment may be made for repairing damage to the work caused by •occurrences· as provided in §1 07-09.
91
8. Determinations by the Department to open certain sections of the project to traffic before completion of the entire contract work.
9. Increases in contract quantities, additional contract work, or extra work or for delays in the review or issuance of orders-on-contract, or shop drawings, or field change sheets. However, payment for performance of extra work will be made pursuant to §109-05.
10. Failure of the State to provide individual rights-or-way parcels for an extended period of time beyond that indicated by the contract, if such unavailability, as determined by the Commissioner, does not significantly affect the scheduled completion of the contract.
11. Unforeseen or unanticipated surface and subsurface conditions.
12. Stop work orders issued by the Engineer. pursuant to § 1 05-01.
13. Any situation which was, or should have been within, the contemplation of the parties at the time of entering into the contract.
B. The Contractor agrees that the only claims he may make for extra compensation caused by delay. inefficiencies, or interference affecting the performance or the scheduling of contract work will be sotely limited to those arising out of the following instances:
1. The issuance by the Commissioner of a stop work order relative to a substantial portion of work, which the Commissioner determines to significantly affect the scheduled completion of the contract, other than those order issued pursuant to §1 05-01.
2. The unavailability of critical rights-of-way parcels for such an extended period of time beyond that indicated in the contract which the Commissioner determines to significantly affect the scheduled completion of the contract.
In all of such instances, compensation to be considered will be limited to documented additional direct field costs, including field supervision, escalation of costs for labor, materials, and rental equipment, and for such other related additional costs. In no case will additional costs for home office overhead, idle equipment, profit, or financing be allowed. Failure of the Contractor to adequately progress the completion of the work will be considered in determining whether the foregoing instances are the primary causes of delay. In all of such instances, for any claim asserted undet this section, the Contractor shall keep detailed written records of the costs and agrees to make them available to the Department at any time for the purposes of audit and review.
Any dispute relating to such claims shall be promptly submitted to the
92
Commissioner in writing and the Commissioner's determination shall be final and binding on the Contractor. Failure by the Contractor to promptly notify the Commissioner In writing or to maintain and furnish cost records of such claims shall constitute a waiver of the claim.
C. The provisions of this Article apply only to claims for extra or additional costs attributable to delays, inefficiencies, or interference and do not preclude determinations by the Commissioner allowing reimbursement for additional direct costs for extra work pursuant to §105-14.
This clause is very restrictive and severely limits the ability of the contractor to
recover for agency suspensions and delays. If the contractor had developed methods and
procedures to allow an early finish to the contract and a resultant savings in overhead,
any delays by the state that did not cause the contractor to complete the project past the
completion date are non-compensable. This type of language greatly inflates bid prices
and or reduces profits and puts the contractor and agency in an adversarial relationship
at the start of the contract.
states:
Another state that uses harsh contract language is Delaware. The Delaware clause
No Claims for Delay Damage (1 05.21 Delaware)
Any delay in prosecution of the work which is either granted by the Department or deemed to be owed to the contractor by reason of any delay caused by reason beyond the contractor's control, or to which the contractor is deemed to be entitled as a result of a contract claim, as determined by the Department, an arbitrator and/or judicial proceeding, shall entitle the contractor and shall be strictly limited to relief provided in Section 105.20. The contractor shall only be entitled to recover an equivalent extension of time for any delay caused wholly or in part by reasons beyond the contractor's or Department's control and the contractor shall not be entitled to recover any damages for any such delay caused by whatever reason. In the event, a delay may be caused wholly by actions of the Department, such extensions in time shall be granted In an amount equivalent to the actual delay caused by the Department and the contractor shall not be entitled to an additional compensation therefore, other than equivalent extensions of time and only such costs allowed by Section 105.20.
93
No payment of compensation of any kind shall be made to the contractor for damages because of any hindrance or delay from any cause in the progress of work, whether such hindrance or delay be avoidable or unavoidable. Any finding by any administrative officer, arbitrator and/or judgs that a delay was caused either wholly or in part by actions of someone other than the contractor shall only entitle the contractor to equivalent extensions of time and only such costs allowed by Section 105.20.
As in the New York clause, the ability of the contractor to recover for agency
suspensions is severely limited. This is a typical •No Damage for Delay• clause and
illustrates the restrictions on the costs to which the contractor should be entitled.
As can be seen from Table 27, a little more than half of the SHAs have suspension
provisions relating to the discovery of historical or archeological artifacts. These
clauses as a rule are poorly written and do not adequately provide for compensation to be
given to the contractor. As an example, the clause used by Maine states:
Historical Deposits (1 07.25 )
Activities that would cause a disturbance to any object of archaeological, paleontological or other historical interest shall immediately cease and shall not be resumed until an investigation of the deposit has been completed and the removal of articles of interest has been accomplished. Should such a deposit be uncovered the Contractor or the engineer shall notify the Department immediately.
The first indication of archaeolo~ical deposits may be the burial grounds or campsites of Indians, revealing the bones of the dead and their implements. The first indications of paleontological deposits may be the exposure of marine fossils or shells found mainly in clay deposits. Indications of deposits of more recent historical interest may be the exposure of dumps in landfill areas, abandoned campfire sites and building foundations.
Delay of the Contractor's operations in the event of the above shall not be compensated for directly and shall be considered incidental to general items in the contract but may be justification for adjustment of working days or calendar days if a delay involves one or more working days or calendar days.
The Contractor's attention is directed to Chapter 398 of MRS Title 27 §371, which places the ownership with the State of Maine of artifacts, specimens and material which are public property by virtue of
94
having been found on, In or beneath State controlled lands.
Here the contractor cannot recover for delays caused by the discovery of historical finds.
When a contractor envisions losing money as a result of historical and archeological
finds, few encounters will be reported. There is no incentive for the contractor to
cooperate with the intent of the clause since fair compensation will not be forthcoming.
states:
One of the better examples is the clause used by Colorado. The Colorado clause
Archaeological and Paleontological Discoveries (1 07.23 Colorado )
When the Contractor's operations encounter plant or animal Tossils, remains or prehistoric or historic structures, prehistoric or historic artifacts (bottle dumps, charcoal from subsurface hearths, old pottery, potsherds, stone tools, arrowheads, etc.), the Contractor's affected operations shall immediately cease. The Contractor shall notify the Engineer of the discovery of these materials. When ordered to proceed, the Contractor shall conduct operations in the vicinity of the discoveries as directed. The work will be paid for by the Division as provided in subsection 104.02 when contract unit prices exist, or as extra work as provided in subsection 1 04.04 when no unit prices exist. Delays to the Contractor because of the materials encountered may be cause for extension of contract time in accordance with subsection 108.06.
As a result of this clause, the contractor has some hope of recovering costs associated
with a delay while awaiting direction on the project.
One last suspension clause that is of interest is that used by the state of Florida.
The clause has a unique provision that allows the contractor to suspend the contract i'l
order to provide vacation time for employees. This clause is unique among the SHA:.. The
clause states:
Contractor's Vacation (8.6.4 Florida)
8-6.4.1 The contractor will be allowed to suspend operation~ for a period not to exceed 14 days annually, in order to provide vacation time for his employees. These 14 days may be divided into no more than two separate periods of vacation time.
95
8-6.4.2 Two periods of time are established for automatic time suspensions. There periods are Thanksgiving, which includes Thanksgiving Day and the following Friday, Saturday, and Sunday; and Christmas, which includes December 24th through January 1st. Vacation days other than provided at Thanksgivmg and Christmas will require written request as specified in 8-6.4.3 These automatic time suspensions may be approved verbally by the Project Engineer upon notification by the Contractor of his intent to shut down his operations for one or both of these periods. If the contractor does not shut down his operations during these periods, contract time will be charged as usual.
8-6.4.3 The contractor shall submit written request to the District Engineer for permission to suspend operations, other than those specified in 8-6.4.2 , at least 30 days in advance of the date of suspension.
8-6.4.4 The department reserves the right to refuse permission for a suspension (including automatic suspensions) when it might cause undue inconvenience to the traveling public or when, because of other factors, uninterrupted prosecution of the work is essential.
8-6.4.5 The contractor shall retain sufficient personnel at the job site to properly maintain all signs, warning devices and lights.
8-6.4.6 Contract time will not be charged during the period of any approved suspension for vacation, as long as no work (with the exception of that specified in 8-6.4.5) is accomplished on the project.
No other SHA allows the contractor to suspend the contract without incurring time
charges. Tourism and vacations are a major factor in the Florida economy and it is
interesting to see that carried into the construction contracts for the SHA.
Qther Agencies
In the provisions of the other agencies, not all agencies can suspend work on the
contract. Some agencies do not have suspension clauses in their provisions. In these
contracts the issue of how the contractor may recover for agency delays is even more
cloudy. Recovery may still be possible but may have to be sought under the changes
clause.
As mentioned in the introduction, use by cities of no damage for delay clauses is
much more prevalent. Some examples of the clauses used by cities are provided below:
96
Liquidated damages (8.48 Honolulu)
•.. B. Delay caused by the City. Except as provided in subsection 8.1, neither the City nor the Contractor shall be entitled to damages for any delay caused by the City in the performance of the work under the contract. In such event, however, the City shall grant the Contractor an extension of time pursuant to subsection 6.2
Extension of Time (4.05 Tampa)
... The contractor agrees to make no claim for damages for delay in the performance of this contract occasioned by any act or omission to act of the city or any of its representatives or because of any injunction which may be brought against the city or its representatives and agrees that any such clair11 shall be fully compensated for by an extension of time to complete performance of the work as provided herein.
The comments made about state use of these clauses holds true for the cities. Harsh
contract language equals increased bid prices from contractors. Contingencies must be
included to cover the possible costs that cannot otherwise be recovered.
Archeological clauses used by the cities are as poorly written as those used by
most of the SHAs. Great improvement is needed in the quality of these clauses.
The AlA document has a unique provision allowing the contractor to suspend work
if not paid by the owner after a required period of time. The clause states:
Failure of Payment (AlA 201-9.7)
If the architect does not issue a certificate for payment, through no fault of the contractor, within seven days after receipt of the contractor's application for payment, or if the owner does not pay the contractor within seven days after the date established in the contract documents the amount certified by the architect or awarded by arbitration, then the contractor may, upon seven additional days written notice to the owner and architect, stop the work until payment of the amount owing has been received. The contract time shall be extended appropriately and the contract sum shall be increased by the amount of the contractor's reasonable costs of shut-down, delay and start-up, which shall be accomplished as provided in article 7.
Here at last is a provision that gives the contractor some real leverage with the owner.
The owner is required to promptly pay the contractor for work performed if no
97
disagreement exists. With a provision like this in the contract, the contractor may
reduce contingency for financing costs as payment for work performed should be fairly
certain and quick.
Impact and Conclusions:
The various suspension clauses used by agencies in their provisions can have a
significant impact on the amount of contingency that a contractor adds to a bid.
Restrictive language and "No Damage for Delay• clauses cause higher bids due to
increased contractor risk. • Archeological and Historical Deposits" clauses that do not
provide for compensation for the contractor for all associated costs will limit the
contractors cooperation with the clause and reduce reporting of deposits. Better clauses
need to be developed that are fair to all parties and yet preserve items and information
from out past.
98
Liquidated Damages
lntroductjon
On many construction projects, where time is of the essence, the agency uses a
liquidated damages provision in the contract. Under the terms of this clause, the
contractor and the agency agree that if the contractor fails to complete the project
within the time set forth in the contract, the contractor will pay to the agency a pre
determined sum for each and every day project completion is delayed. This payment is
compensation to the agency for financial and other losses for delayed completion. Since
it is difficult to determine the actual value of the losses, the pre-determined sum is used
in lieu of actual damages.
Uquidated damages are used by most agencies and are applied to each and every
day the contractor exceeds the contract completion date. Agencies that may use contracts
that allocate time in more than one of the three methods sometimes have different values
of liquidated damages for calendar day and completion date contracts than is used for
working days. Table 28 presents the number of agencies that use liquidated damage
provisions and those that use separate values for calendar day versus completion date or
working day contracts.
~
All SHAs utilize liquidated damage provisions for late contract completion. The
sums charged per day vary from agency to agency as does the practice of using separate
values for working day contracts versus calendar day and completion date contracts. The
provision used by Wisconsin is typical for the provisions used by those SHAs that use a
separate value of liquidated damages for calendar day and completion date versus
working day contracts. The provision states:
99
Table 28: Are liquidated damages included in the provisions and if so are separate values
used for working day vs calendar day or completion date type contracts ?
LOs Included Separate Values Agency Yes N:> Yes N:> ~
SHAs 50 1 9 24 7
Cities 1 3 4 9
BLM X
Navy X
AlA X
100
Liquidated Damages (108.8 Wisconsin)
Should the contractor fail to complete the work within the time agreed upon in the contract or within such extra time as may have been allowed by extensions, there shall be deducted from any monies due or that may become due the contractor, for each and every calendar day for completion date contracts, or working day for working day contracts, that the work shall remain uncompleted, a sum specified as follows:
Original Contract Amount Daily Charge From More Than To and Including Calendar Day Working Day
$ 0 $ 50,000 $125.00 $ 275.00 50,000 100,000 175.00 300.00
100,000 300,000 225.00 4 75.00 300,000 500,000 375.00 750.00 500,000 1,000,000 475.00 1,200.00
1,000,000 ------- 750.00 1,750.00
This sum shall be considered and treated not as a penalty but as fixed, agreed and liquidated damages due the Stite from the contractor by reason of inconvenience to the public, added cost of engineering and supervision, maintenance of detours and other items which have caused an expenditure of public funds resulting from his failure to complete the work within the time specified in the contract.
Permitting the contractor to continue and finish the work or any part of it after the time fixed for its completion, or after the date to which the time for completion may have been extended, shall in no way operate as a waiver on the part of the Department of any of its rights under the contract.
With the exception of the separate values for different types of contracts, clauses used
by other SHAs are similar with the exception of Michigan. The Michigan clause states:
Liquidated Damages (1.08.07 Michigan )
... b. Failure to Complete on Time - If the Contractor fails to complete the entire project on or before the contract time specified in the proposal or on or before the authorized extension thereof without liquidated damages, the Contractor will be charged , for each calendar day that the work shall remain uncompleted, the applicable sum set forth in Table 1.08-1 except as otherwise provided herein.
The applicable Liquidated Damages per Calendar Day, as set forth in Table 1.08-1, will be reduced to 50 percent of the amount indicated by the schedule after the date the project is accepted for traffic.
Liquidated Damages per Calendar Day will be assessed at 50
1 01
percent of the amount indicated in Table 1.08-1 for projects where traffic is maintained on the facility under construction.
Damages for failure to meet the requirements fer completion of the project will not be assessed during periods of seasonal suspensions.
liquidated Damages for failure to open to traffic on time and for failure to complete on time will not be assessed simultaneously.
This clause allows for the charging of one half of the stated value of liquidated damages if
the contractor has or keeps the project open to traffic but is not otherwise complete.
This is perhaps in recognition of legal challenges that argue that if the project is open •-
traffic there are no damages to the agency.
Other agencjes
All other agencies except the AlA document provide for liquidated damages to be
assessed against the contractor for late completion of work. There are only minor
variations in the wording of the clauses except for the city of Honolulu which presents a
No Damage for Delay clause under the liquidated Damages provision. This clause was
previously presented in the discussion on the Suspensions clause.
Impact and Conclusions
Uquidated damages are used where the calculation of actual damages are complex
and difficult to determine. Most agencies use liquidated damages and as long as the sum
charged per day is not unreasonable the courts have upheld the legality of the clauses.
Agencies must not make the daily charge so large as to have no reflection to the actual
value of the damages the agency could reasonably anticipate as the courts may not
consider these provisions valid and the agency may recover no damages. Contractors
must be aware of the sum to be charged for each day of late completion so as to know the
financial loss to be expected for late completion. If the agency schedule is not reasonable
and the contractor knows that completion will be late, the contractor must add the
102
expected value of liquidated damages to be assessed to the bid.
103
•
•
Inadequate Maintenance
!ntrodyctjon
Many agencies have provisions that allow them to direct the contractor to
perform maintenance on the project if the engineer deems that the contractors
maintenance is inadequate. Adequate maintenance is defined as keeping the roadway and
structures in satisfactory condition, at all times including maintaining the previous
course or subgrade during all construction operations. Safe traffic zones and barricades
are required to be maintained at all times. These clauses are more common in the SHAs
although some cities do use them. The provisions typically allow the contractor 24
hours to perform the required maintenance or the agency may perform it or have it
performed with back charges being assessed against the contractor. Table 29 presents
agency practices on required contractor response to notices of inadequate maintenance.
Thirty of the SHAs have a requirement for the contractor to respond to a notice of
inadequate maintenance. Agencies that have a 24 hour notice requirement use clauses
similar to that used by the state of Mayrland. The Maryland clause states:
Failure to Maintain Entire Project (5.12 Mayriand)
Failure on the part of the Contractor, at any time, to comply with the provisions of 5.11 above, will result in the procurement officer immediately notifying the contractor to comply with the required maintenance provisions. In the event that the contractor fails to remedy unsatisfactory maintenance within 24 hours after receipt of such notice, the procurement officer will immediately proceed with adequate forces and equipment to maintain the project, and the entire cost of this maintenance will be deducted from monies due the contractor.
The provisions of Idaho and New Mexico and Maine indicate that the contractor must
proceed with maintenance immediately after receipt of a notice of inadequate
104
Table 29: How quickly must the contractor respond to notice of inadequate maintenance
of the project?
Agency Immediately
SHAs
Cities
BLM
Navy
AlA
*Idaho, Maine, New Mexico
** New Hampahire
3 *
24 Hours
24
1
105
48 Hours No Clause Other
2 20 1 * *
1 1 1
X
X
X
maintenance. In other respects, their clauses are similar to those of other states. The
Idaho clause is presented here as a contrast to the 24 or 48 hour notice provision:
Failure to Maintain Roadway or Structure (1 05.15 Idaho)
If the Contractor, at any time, fails to comply with the provisions of subsection 105.14, the Engineer will immediately notify the contractor of such non-compliance in writing. If the contractor tails to remedy unsatisfactory maintenance after receipt of such notice, the Engineer may immediately proceed to maintain the project, and the cost of this maintenance will be deducted from monies due to become due the contractor on his contract.
The one state indicated as •other• in Table 29 is New Hampshire. The contractor is
required to respond to a notice of inadequate maintenance but no notice period is stated
and immediate response is not required. Twenty SHAs do not have a requirement for the
contractor to respond to a notice of inadequate maintenance.
Other Agencjes
Only two cities of the other agencies reviewed have a requirement for the
contractor to respond to a notice of inadequate maintenance. The provisions of the two
cities are no different than that used by Maryland. The federal agencies and the AlA
document do not have any such requirement.
Impact and Conclysjons
The presence of a provision allowing the agency to direct the contractor to
remedy inadequate maintenance does not keep agencies which do not have such a provision
from directing and or charging a contractor to maintain the project. If the contract
provisions require the contractor to maintain the project and the contractor does not,
then under the default clauses the contractor can be directed to remedy the situation. A
Failure to Maintain clause makes it easier to direct the contractor and keeps the
relationship better since the default clause is not mentioned in the direction to maintain.
106
----- ------------------------------------------------------------
t
•
•
Such clauses also communicate to bidders that the owner is committed to this issue and
that the successful bidder will be forced to comply.
107
Termination
lntrodyctjon
Termination provisions fall into two categories. Termination for Default and
Termination for Convenience of the agency. In Termination for Convenience provisions,
the agency reserves the right to terminate the contract at any point if it is determined
that the agency cannot continue with the contract. Some agencies limit termination for
convenience to instances where court injunctions or national emergencies prevent the
agency from completing the contract. Other agencies include statements that allow the
agency to terminate for convenience if it is determined to be in the best interest of the
agency to do so. Most Termination for Convenience clauses allow the contractor to
recover costs for work completed up to the point of termination and define what costs the
contractor can recover. Agency use of Termination for Convenience clauses is presented
in Table 30.
The other form of termination clause used is a Termination for Default clause. In
this clause the agency lists conditions under which the agency will terminate the
contract and make claim against the contractor for damages. Termination for Default
provides for serious consequences for the contractor. The project can be halted and
payments to the contractor can be suspended. The contractor is liable for damage to the
agency and the contractor's bond is placed at risk. All agencies reviewed use
Termination for Default clauses. All clauses state the conditions for which the contract
may be terminated for default and most provide for the contractor to receive notice
prior to the agency termination of the contract. Some agencies indicate that the surety
will receive an additional notice after termination prior to the agency assuming the
work. Agency practices on notice requirements for termination for default are
108
Table 30: Can the agency terminate the contract for convenience?
Agency Ye:. N:>
SHAs 45 5 *
Cities 1 0 3
BLM X
Navy X
AlA X
* Indiana, Missouri, Nevada, North Carolina, Rhode Island
109
I
t
•
•
•
•
•
presented in Table 31 and Table 32.
Only four SHAs do not include a provision for termination of the contract for
convenience. Some agencies limit their ability to terminate the contract for convenience
to instances of national emergency or court injunction. One of the more through
Termination for Convenience clauses is that in use by South Carolina. The South
Carolina clause states:
Termination of Contract (1 05.14 South Carolina)
The Department may, by written order, terminate the contract or any portion thereof after determining that for any reasons beyond either Department or Contractor control he is prevented from proceeding with or completing the work as originally contracted, and that termination would therefore be in the public interest. Such re&sons for termination may include, but need not be necessarily limited to, executive orders of the President relating to prosecution of war or national defense, national emergency which creates a serious shortage of materials, insufficient funds by the Department due to extenuating circumstances, orders from duly constituted authorities relating to energy conservation, and restraining orders or injunctions obtained by third-party citizen action resulting from national or local environmental protection laws or where the issuance of such order or injunction is primarily caused by acts or omissions of persons or agencies other than the Contractor.
When the Department orders termination of a contract effective on a certain date, all completed items of work as of that date will be paid for at the contract bid price. Payment for partially completed work will be made either at agreed prices or by force account methods described elsewhere in these Specifications. Items which are eliminated in their entirety by such termination shall be paid for as provided in subsection 1 09.05 of these specifications.
Acceptable materials, obtained by the Contractor for the work but which have not been incorporated therein, may, at the option of the Department, be purchased from the Contractor at actual cost delivered to a prescribed location, or otherwise disposed of as mutually agreed .
11 0
I
•
•
•
•
•
•
Table 31: How long does the contractor have to respond to/or correct deficiencies prior
to the agency termination of the contract?
Agency 5 Days 7 Days 1 0 Days 15 Days
SHAs
Cities
BLM
Navy
AlA
1 1
1
37
4
X
X
3
1
Other
2
X
Not listed
8
5
Table 32: How long does the surety have to take over work prior to agency performing
or having work performed by others?
Agency 5 Days 10 Days 15 Days 20 Days 30 Days Not listed
SHAs 2 1 1 46
Cities 1 3 1 8
BLM X
Navy X
AlA X
1 1 1
I
•
•
•
•
•
•
After receipt of Notice of Termination from the Department, the Contractor shall submit, within 60 days of the effective termination date, his claim for additional damages or costs not covered above or elsewhere in these specifications. Such claim may include cost items as reasonable idle equipment time, mobilization efforts, bidding and project investigative costs, overhead expenses attributable to the project terminated, legal and accounting charges involved in claim preparation, subcontractor costs not otherwise paid for, actual idle labor cost if work is stopped in advance of termination date, guaranteed payments for private land usage as part of original contract, and any other cost or damage item for which the Contractor feels reimbursement should be made. The intent of negotiating this claim would be that an equitable settlement figure be reached with the Contractor, In no event, however, will loss of anticipated profits be considered as part of any settlement.
The Contractor agrees to make his cost records available to the extent necessary to determine the validity and amount of each item claimed.
Termination of a contract or portion thereof shall not relieve the Contractor of his contractual responsibilities for the work completed, nor shall it relieve the Surety of its obligation for and concerning any just claims arising out of the work performed.
The South Carolina clause is complete and provides for a fair settlement with the
contractor for the value of the terminated contract.
All SHAs include provisions for termination of the contract for default. Language
for the Termination for Default clause is fairly standard including the enumerations of
most of the conditions under which the agency may terminate the contract for default. A
typical example of a Termination for Default is that used by Wisconsin:
Default on contract (1 08.9 Wisconsin)
If the contractor: (1) fails to begin the work under the contract within the time specified, or (2) fails to perform the work with sufficient workers and equipment or with sufficient materials to insure the completion of said work within the specified time, or (3) performs the work unsuitably or neglects or refuses to remove materials or to perform anew such work as shall be rejected as unacceptable and unsuitable, or (4) discontinues the prosecution of the work, or (5) fails to resume work which has been discontinued within a reasonable time after notice to do so, or (6) becomes insolvent or is declared bankrupt, or commits any act of bankruptcy or insolvency, or (7) allows any final judgement to stand
1 1 2
I
•
•
•
•
•
•
against him unsatisfied for a period of 48 hours, or (8) makes an assignment for the benefit of creditors, or (9) is determined to be in violation of the provisions of the contract relative to hours of labor, wages, equal opportunity, character and classification of workers employed, or (1 0) for any other cause whatsoever fails to carry on the work in an acceptable manner, the engineer may give notice in writing to the contractor and his surety of such delay, neglect, or default, specifying the same.
If the contractor, within a period of 10 calendar days after the date of such notice, shall not proceed in accordance therewith, then the Department shall, upon written certification by the engineer of the fact of such delay, neglect or default and the contractor's failure to comply with such notice, have full power and authority to forfeit the rights of the contractor and at its option to call upon the surety to complete the work in accordance with the terms of the contract. In lieu thereof, the Department may take over the work, including any or all materials and equipment on the ground as may be suitable and acceptable, and may complete the work by or on its own force account, or may enter a new agreement for the completion of said contract in an acceptable manner. All costs and charges incurred by the Department, together with the cost of completing the work under contract, shall be deducted from any monies due or which may become due on such contract. In case the expense so incurred by the Department shall be less than the sum which would have been payable under the contract if it had been completed by said contractor, then said contractor shall be entitled to receive the difference subject to any claims for liens thereon which may be filed with the Department, or any prior assignment filed with it. In case such expense shall exceed the sum which would have been payable under the contract, the contractor and the surety shall be liable and shall pay to the Department the amount of such excess .
Other Agencjes
Agency practices by the other agencies show little to no variation in the
termination clauses when compared to most SHA provisions with the exception of the AlA
document. In the AlA document, in addition to the owner being able to terminate the
contract, the contractor is given the ability to terminate the contract. The AlA clause
states:
Termination by the Contractor (AlA 201-14.1)
The contractor may terminate the contract if the work is stopped for a period of 30 days through no act or fault of the contractor or a subcontractor, sub-subcontractor or their agents or employees or any
1 1 3
•
•
•
•
•
•
•
•
•
other persons performing portions of the work under contract with the contractor, for any of the following reasons: 1. Issuance of an order of a court or other public authority having jurisdiction; 2. An act of government, such as a declaration of national emergency, making material unavailable; 3. Because the architect has not issued a certificate for payment and has not notified the contractor of the reason for withholding certification as provided in subparagraph 9.4.1, or because the owner has not made payment on a certificate for payment within the time stated in the contract documents; 4. If repeated suspensions, delays or interruptions by the owner as described in paragraph 14.3 constitute in the aggregate more than 100 percent of the total number of days scheduled for completion, or 120 days in any 365 day period, whichever is less; or 5. The owner has failed to furnish to the contractor promptly, upon the contractor's request reasonable evidence as required by subparagraph 2.2.1.
The AlA provision allows the contractor to terminate the contract under the conditions
above. This ability is a powerful tool to ensure owner interference with the work does
not become excessive. The evidence required in subparagraph 5 refers to evidence of
adequate financial resources to complete the project. It the owner cannot provide the
contractor with reasonable evidence of adequate financial resources, the contractor can
terminate the contract. This provision is unique for the documents reviewed .
Impact and Conclusions
There is not a major difference in the provisions used by agencies with respect to
termination. All agencies should consider using Termination for Convenience provisions
similar to the clause used by South Carolina if they use such a clause. Contractor risk
increases slightly with the presence of a Termination for Convenience clause as the
allocation of overhead in unit prices needs to be considered if there is a chance that items
may be deleted from the contract. Bid prices may increase slightly if agencies have a
history of terminating contracts for convenience.
Owner financial resources are not typically a problem with federal agencies,
1 1 4
t
•
SHAs and Cities. The AlA clause is major protection for the contractor working in
private industry. Owners who use the AlA documents need to be aware of this provision
and ensure financing is adequate if they use this provision. Contractors need to push for
the use of this provision as it affords them protection from unreasonable or financially
insolvent owners.
1 1 5
Payments
lotrodyctjon
All contracts provide for payments to the contractor. Almost all contracts
provide for partial payments to the contractor during the course of construction.
Payments may be based on a schedule of values submitted by the contractor after award
or on unit prices established at the time of bid. All of the SHA documents reviewed
provided for payments based upon unit prices. Progress payments are due to the
contractor on a periodic basis as established in the contract documents. Table 33
provides an indication of agency practices as regards to frequency of progress payments.
Most SHAs make progress payments on a monthly basis. Other frequencies for
payments are bi-weekly and twice monthly. Time frames for payment after the
submission of a request for payment were not indicated in the provisions. Many of the
states that indicate payments are made monthly indicate that this is the "normal"
practice which suggests that a more frequent schedule of payments may be negotiated
with the agency.
Other Agencjes
Almost all of the other agencies reviewed indicate that payment will be made
monthly. Of the two responses listed as other (Milwaukee and the AlA document), both
indicate that payments will be made from time to time. Milwaukee's provision states:
Progress Payments (2.9.12 Milwaukee)
If the contractor shall proceed properly and with diligence to perform and complete this contract, the Commissioner may, from time to time as the work progresses, grant to the contractor an estimate of the amount already earned, ...
11 6
Table 33: How often are progress payments made?
Twice Agency Bi-Weekly Monthly Monthly No Mention Other
SHAs 4 7 39
Cities 1 1 1 1
BLM X
Navy X
AlA X
11 7
The frequency for payment is a topic for contractors to consider when determining mark
up values on bids to be submitted. In addition to stating the frequency of partial or
periodic payments, the federal agencies are required to pay the contractor in 14 days
after the date the contractor submits an invoice. This requirement is covered under the
federal Prompt Payment Act which is a part of the contract. The Prompt Patment Act
clause states:
Prompt Payment For Construction Contracts (FAR 52.232-27)
... (a) The due date for making such payments shall be 14 days after receipt of the payment request by the designated billing office, However, if the designated billing office fails to annotate the payment request with the actual date of receipt, the payment due date shall be deemed to be the 14 day after the date the contractor's payment request is dated, provided a proper quantity, quality, or contractor compliance with contract requirements.
(b) The due date for payment of any amounts retained by the Contracting Officer in accordance wit the clause at 52.232-5, Payments Under FixedPrice Construction Contracts, shall be as specified in the contract , if not specified, 30 days after approval for release to the contractor by the Contracting Officer ...
This clause spells out how long the contractor will have to wait to be paid for a partial
payment. The federal agencies and the AlA document were the only documents reviewed
that indicated the time frame for contractor payment. The AlA document states that the
contractor is to be paid within seven days of the date established in the contract.
Impact and Conclusions
The frequency of payments has a direct impact on the contractor's required
financing. More frequent payments reduce the length of time a contractor will be
required to adequately finance materials, labor, and equipment. More frequent payments
should result in a reduction of contractor bid prices. Another benefit to agencies for
more frequent payments is the probable reduction in attempted front-end loading of the
11 8
t
I
I
•
•
•
•
•
bid, i. e., with more frequent payments, the contractor does not have as much of a
problem with cash flow. The benefits to the agency may be worth the increased effort
required to process partial payments on more than a monthly basis.
1 1 9
•
•
•
•
•
•
•
•
•
•
•
VII. Conclusions
Conclusions have been presented on each area of the results already presented .
Some overall conclusions are possible from the data reviewed.
It appears that there is very little consistency in the clauses used by the various
agencies. There are some similarities in the general conditions provisions such as
format and some clauses. For the most part the format of the general conditions follows
the CSI format. Most agencies use 1 0 sections within division one and use standardized
titles for these sections. Sections and titles are as follows:
101- Abbreviations and Definitions
1 02- Bidding Requirememts and Conditions
1 03- Contract Award and Execution of Contract
1 04- Scope of Work
1 05- Control of Work
1 06- Control of Materials
107- Legal Relations and Responsibility to Public
1 08- Prosecution and Progress
1 09- Measurement and Payment
11 0- Control of Environment
Provisions dealing with time are located throughout these sections. The standard
wording found in some agency provisions appears to be driven by the Federal Highway
Administration (FHA). All SHAs have contact with this agency and certain clauses are
required by FHA in order to qualify for federal funding of projects.
The findings of this study are consistent with the findings of Couey's 1987 study.
Different definitions for adverse weather were used in the two studies which accounts
120
•
•
•
•
•
•
•
•
•
•
•
for the difference in the number of agencies that define adverse weather in their
provisions. Most states use standard Differing Site Conditions and Suspensions clauses
th::t are designed to reduce the risk for contractors and thereby reduce bid prices for the
agency .
The contracting practices of Nevada and New York tend to be quite different when
compared with the practices of the remaining states. New York utilizes many
restrictive clauses and has very harsh contract language. It is expected that bids are at a
premium where such language is used. General conditions provisions used by Nevada
indicate that contracting practices are much less formal. Many standard type of clauses
are missing and it appears that a limited number of contractors are utilized. The clauses
contain an option to renew the contract at last years prices which indicates a one year
contract period and no fixed bid quantity. This may be tied to the low population density
and lack of numerous contractors .
The agency provisions were reviewed for provisions dealing with ownership of
contract float. No agencies stated float ownership although some agencies address float in
their scheduling clauses.
Federal and State Highway Administration general conditions provisions are
generally more equal in the allocation of risk than those used by other agencies. This is
witnessed by the more numerous use by city agencies of No Damage for Delay clauses and
the more restrictive Suspensions clauses.
The AlA document presents some unique clauses that provide protection to the
contractor. The ability of the contractor to have the owner prove that adequate financial
resources are available is helpful when not dealing with a public agency. The AlA
provisions granting the contractor the ability to suspend work in case of no payment and
1 21
•
•
•
•
•
•
•
•
•
•
•
to terminate the contract have no equal in the provisions of the public agency documents
that were reviewed. Indeed, many of the agency documents reviewed give the agencies
the power to cause long suspensions of work and all the contractor can recover is
additional contract time .
Most agencies utilize clauses that fairly allocate risk between the agency and the
contractor, but there are still some agencies that presumably receive higher bid prices
as a direct result of their use of more onerous provisions. The differences in agency
practices are sufficient that contractors must be very careful to read and understand the
various nuances of the differences in time provisions used by different agencies.
Practices just across a state line can be as sufficiently different as to dictate whether or
not a contractor will gain or lose money on a particular project.
122
•
•
•
•
•
•
•
•
•
•
VIII. Recommendations
A. lntroductjon
Recommendations are addressed in four parts - State/Federal Agencies, Cities,
Contractors and Research .
B. State/Federal Agencies
Recommendations:
1. Where allowed by law, agencies should consider using uniform clauses. The
Federal Highway Administration should take the lead in this area.
a. Clauses should be developed that are fair to the contractor. Use of the standard
Differing Site Conditions and Suspensions clauses is a start but other clauses need
to be improved. As an example, clauses that deal with Archeological and Historical
Deposits are unfair to the contractor. The clause needs to allow the contractor
monetary compensation for delays during suspended work and payment for any
work done to preserve or remove deposits.
b. Contract terms need to be clearly defined with interpretation not left up to one
party. An example of this are the clauses dealing with time extensions. Most of
the clauses indicate that extensions will be granted for adverse weather but the
definition of what constitutes adverse weather is left up to the Engineer .
c. Time frames for various notices and submittals should be standardized and
clearly stated. The contractor should be given a specific length of time to perform
a required action. Proposals due 7 days after the end of a delay in the standard
Suspensions clause is a good example. Specific requirements should be included
for submission of requests for additional contract time and proposals for equitable
adjustment under the claims clause .
123
•
•
•
•
•
•
•
•
•
•
•
c. Ci1iu
Recommendations
1. Consideration should be given to the use of the provisions of the State Highway
Agency in which the city is located as the standard specification for city work. Any
special requirements can be included in a city issued supplemental specification.
2. Eliminate provisions that place unfair risk on the contractor.
a. No damage for delay clauses should be eliminated .
b. Suspension and Differing Site Conditions clauses that fairly compensate the
contractor for agency delays or unforeseen and unanticipated conditions will
reduce bid prices .
D. Contractors
Recommendations
1. Be aware that there are significant differences between State Highway Agencies in
time provisions.
a. Read the general provisions and make a list of the notice requirements
contained therein.
b. Do not assume that the definition of contract time and how it will be charged is
the same in other states .
2. Lobby for changes in the contract clauses that concem time when the clause puts
the contractor at increased risk or requirements are not clear. Get the contractor
association involvement in pushing for uniform contract clauses .
E. Research
Recommendations
1. Conduct a study similar to this one for a large selection of private owners .
124
•
•
•
•
•
•
•
•
•
•
•
a. Request copies of the general conditions provisions, supplemental provisions
and contract agreement forms.
2. Conduct a study using the existing SHA general conditions data base that examines
one or more of the following areas: Indemnification, payments, disputes
resolution .
125
•
•
•
• IX. APPENDIX A
• SUM\AAY SHEETS FOR STATE HIGHWAY AGENCIES
•
•
•
•
•
• 126
• Are Holidays listed in the contract and H so, how many holidays does the agency observe? (Summarized in Table 1)
Listed tHolidays Not Usted Unusual Days
• Alabama 14 Mardi Gras, Thomas Jeffersons Birthday and • Alaska 11 Stewards Day, Alaska Day Arizona X Arkansas 1 0 California X Colorado 10 • Connecticut X Delaware 13 Day after Thanksgiving, Good Friday Florida 8 Day after Thanksgiving, Georgia 12 Hawaii X Idaho 9
• Illinois X Indiana 14 Good Friday, Election Days, Day after Thanksgiving Iowa X Kansas 8 Kentucky 13 Franklin D. Roosevelt Day, and • Louisiana X Maine 11 Patriots Day
• Maryland X Massachusetts X Michigan 9 Minnesota X Mississippi 10 Missouri X Montana 11 State General Election Day • Nebraska X Nevada X New Hampshire 11 Fast Day New Jersey 11 Presidential Election Day New Mexico 10 New York X
• North Carolina X North Dakota 9 Good Friday Ohio X Oklahoma X Oregon X Pennsylvania X Rhode Island 9 Victory over Japan Day
• South Carolina X South Dakota 10 Pioneer Day Tamassee 11 Good Friday Texas X Utah 11 Pioneer Day Vermont 12 Town Meeting Day, Benningston Battle Day Virginia X • Washington 10 Day after Thanksgiving West Virginia 12 Good Friday, West Virginia Day Wisconsin 9 Good Friday, Christmas Eve, New Years Eve Wyoming 9
• Observes Confederate Memorial Day, Jefferson Davis' Birthday, Robert E. Lee's Birthday
•
• 127
• May the Contractor Withdraw or Modify a bid any time prior to bid opening? (Summarized In Table 2)
• Yes Nl Other
Alabama X Alaska X Arizona X Arkansas X • California X Colorado X Connecticut X Delaware X Florida X Georgia X Hawaii X • Idaho X Illinois X Indiana X Iowa X Kansas X Kentucky X
• Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X Mississippi X • Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X New Mexico X • New York X North Carolina X North Dakota X 01-.io X Oklahoma X Oregon X
• Pennsylvania Not after 9 AM on day of bid opening Rhode Island Not Later Than 2 HR Prior to Bid Opening South Carolina X South Dakota X Temessee X Texas X Utah X • Vermont X Virginia X Washington X West Virginia X Wisconsin X Wyoming X
•
• 128
• How long after bid opening can the agency award the contract? (Summarized in Table 3)
• 30 Days 40 Days 45 Days 50 Days 60 Days 90 Days Not listed or other
Alabama X Alaska X Arizona X Arkansas X California X • Colorado X Connecticut X Delaware X Florida X Georgia X Hawaii X Idaho X • Illinois X Indiana X Iowa X Kansas X Kentucky X Louisiana X
• Maine X Maryland X Massachusetts X Michigan 49 DAYS Minnesota X Mississippi X Missouri X • Montana X Nebraska X Nevada X New Hampshire X New Jersey X New Mexico X New York No MENTION r· Nonh Carolina X Nonh Dakota X Ohio 10 DAYS Oklahoma AS ALLOWED BY LAW Oregon X Pennsylvania X
• Rhode Island X South Carolina X South Dakota X Tennessee X Texas X Utah X Vermont X • Virginia X Washington X West Virginia X Wisconsin X Wyoming X
•
• 129
•
•
•
•
•
Can the contractor withdraw a bid if the contract award is Not made in the stated time? (Summarized in Table 4)
Yes No Mention
Alabama X Alaska X Arizona X Arkansas X California X Colorado X Connecticut X Delaware X Florida X Georgia X Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X Kentucky X Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X Mississippi X Missouri X Montana X Nebra~ka X Nevada X New Hampshire X New Jersey X New Mexico X New York X North Carolina X North Dakota X Clio X Oklahoma X Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X Texas X Utah X Vermont X Virginia X Washington X West Virginia X Wisconsin X Wyoming X
130
How soon after award are bid guarantees of unsuccessful bidders returned? (Summarized in Table 5)
After Award After bid opening Only checks Other other than two low returned
bidders
Alabama 15 DAYS Alaska X Arizona X Arkansas X California 10 DAYS Colorado X Connecticut X Delaware X Florida X Georgia X Hawaii X Idaho X Illinois Indiana
Promptly
Iowa Kansas
• Kentucky 5 Days Louisiana 15 Days Maine X Maryland X Massachusetts 3 DAYS Michigan Promptly Minnesota X • Mississippi X Missouri X X Montana X Nebraska Nevada New Hampshire X New Jersey 3DAYS • New Mexic:c X X New York North Carolina X North Dakota 10 DAYS Ohio X Oklahoma X
• Oregon Pennsylvania Rhode Island 10 DAYS South Carolina X South Dakota X Tennessee X Texas 3DAYS • Utah X Vermont AS SOON AS POSSIBLE Virginia X Washington X West Virginia X Wisc:onsin X
• Wyoming X
• 131
How long does the contractor have to return the signed contract to the agency? (Sum11'181ized in Table 6)
8 Days 10 Days 15 Days 20 Days Other Not Stated
Alabama X Alaska X Arizona X Arkansas X California X Colorado X Connecticut X Delaware X Florida X Georgia X Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X
• Kentucky X louisiana X Maine X Maryland X Massachusens X Michigan 28 Minnesota X • Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X • New Mexico X New York X North Carolina X North Dakota X Otio X Oklahoma X • Oregon 12 Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X Texas X • Utah X Vermont X Virginia X Washing1on X West Virginia X Wisconsin X
• Wyoming 30
• 132
What Is forfeited If the contractor does not return the signed contract within the required number of days? (Summarized in Table 7)
Bid Guarantee Bid Difference No Mention Other Forfeited as LD's Forfeited
Alabama X Alaska X Arizona X Arkansas X California X Colorado X Connecticut X Delawara X Florida X Georgia X Hawaii X Idaho X Illinois X Indiana X BCN:lS FECUIRED Iowa X Kansas X Kentucky X
• louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X New Mexico X New York X North Carolina X North Dakota X Cllio X Oklahoma X Oregon X
• Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X Texas X Utah X
I Vermont X Virginia X Washington X West Virginia X Wisconsin X Wyoming X
I
I 133
What Ia the date of the Notice to Proceed (NTP)? (Sunvnarlzed in Table 8)
When Mailed When Received When Signed Not Stated
Alabama X Alaska X Arizona X Arkansas X Califomia X Colorado X Connecticut X Delaware X Florida X Georgia X Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X Kentucky X
• Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X Mississippi X • Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X New Mexico X • New York X Nonh Carolina X North Dakota X Ohio X Oklahoma X Oregon X • Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X Texas X Utah X • Vermont X Virginia X Washington X West Virginia X Wisconsin X Wyoming X
•
• 134
What Is the Contract Start Date Defined As? (Summarized In Table 9)
As Stated When In NTP _ Days after NTP Signed Other
Alabama 15 Alaska X Arizona X Arkansas X California 15 Colorado X Connecticut X Delaware X Florida X Georgia 10 Hawaii X Idaho X Illinois 10 DAYS AFTER SIGNED Indiana 15 Iowa 15 Kansas X
I Kentucky 31 Louisiana X Maine X Maryland X Massachusetts 15 DAYS AFTER MAILING Michigan 10 DAYS AFTER SIGNED Minnesota X • Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X
• New Jersey X New Mexico X New York 10 DAYS AFTER SIGNED North Carolina X North Dakota 14 DAYS AFTER NTP Otio X Oklahoma X
• Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota 10 Tennessee X Texas 15 • Utah 10 Vermont X Virginia X Washington 10 DAYS AFTER SIGNED West Virginia X Wisconsin X
• Wyoming 1 0
• 135
• When must the contractor submit a schedule for review? (Summarized in Table 10)
• Prior to Prior to the _days N:> starting work Pre-con after award Mention Other
Alabama X Alaska X Arizona X Arkansas X • California 20 Colorado 1 0 Connecticut 14 DAYS AFTER BID OPENING Delaware IMMEDIATELY Florida 30 Georgia IMMEDIATELY FOU.OWING NTP Hawaii 15 • Idaho X Illinois X indiana 1 5 Iowa 1 5 Kansas AS REQUESTED Kentucky 31
• Louisiana PRIOATONTP Maine 10 Maryland 30 Massachusetts 1 0 Michigan PRIOR TO AWARD Minnesota X Mississippi X • Missouri X CONTRACT BY CONTRACT BASIS Montana X Nebraska 7 Nevada X New Hampshire X New Jersey X New Mexico X • New York X North Carolina X 7 DAYS PRIOR TO PRE -CON North Dakota 10 DAYS AFTER BID OPENING Ohio 15 Oklahoma X Oregon X
• Pennsylvania PROVIDED BY AGENCY Rhode Island X South Carolina X South Dakota X Tennessee X Texas 15 Utah X • Vermont 10 Virginia 15 Waahinglon 1 0 West Virginia 15 Wisconsin X Wyoming X
•
• 136
• Ia a Pre-Construction Conference Required? (Summarized in Table 11)
• Yes No
Alabama X Alaska X Arizona X • Arkansas X California X Colorado X ConnecticU1 X Delaware X Florida X
• Georgia X Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X
• Kentucky X Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X I. Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X
• New Jersey X New Mexico X New York X North Carolina X North Dakota X Ohio X Old ahoma X
• Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota X Temessee X Texas X • Utah X Vermont X Virginia X Washington X West Virginia X Wisconsin X
• Wyoming X
• 137
• Must all Materials be Tested and Inspected Prior to Incorporation in the Work? (Summarized in Table 12)
• Yes No
Alabama X Alaska X Arizona X • Arkansas X California X Colorado X ConnecticU1 X Delaware X Florida X
• Georgia X Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X
• Kentucky X Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X • Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X • New Mexico X New York X North Carolina X North Dakota X Ohio X Oklahoma X
• Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X Texas X • Utah X Vermont X Virginia X Washington X West Virginia X Wisconsin X
• Wyoming X
• 138
• What Is the basis of contract time? (Summarized In Table 13)
• Working Calendar Fixed Completion May use Days Days Date Combination
Alabama X X X X Alaska X X X Arizona X X X X Arkansas X X X X • California X Colorado X X X Connecticut X X X Delaware X X X X Florida X X X X Georgia X X X X Hawaii X X X X • Idaho X X X X Illinois X X X X Indiana X X X X Iowa X X X X Kansas X X X X Kentucky X X X X • louisiana X X X X Maine X X X Maryland X X X X Massachusetts X X X Michigan X X X Minnesota X Mississippi X X X X • Missouri X X X Montana X X X Nebraska X Nevada X X X New Hampshire X X X New Jersey X X X Nev. Mexico X X X X • New York X North Carolina X North Dakota X X X X Ohio X X X Oklahoma X X X X Oregon X X X • Pennsylvania X X X Rhode Island X X X X South Carolina X X X South Dakota X X X X Tennessee X X X X Texas X Utah X X X X • Vermont X X X Virginia X X Washington X West Virginia X X X Wisconsin X X X X Wyoming X X X
•
• 139
• Does the Contract Have a Winter Exclusion Period? Does work in the period count (Summarized in Table 14) towards contract time?
• Yes No Period Yes
Alabama X Alaska X NOV 1 -APR 30 X Arizona X • Arkansas X California X Colorado X 1 DEC- 31 MAR X Connecticut X 1 DEC- 31 MAR X Delaware X 16 DEC- 15 MAR X Florida X
• Georgia X Hawaii X Idaho X 1 DEC- 1 MAR X Illinois X 16 DEC • 30 APR X Indiana X 1 DEC· 31 MAR X Iowa X 15 NOV· 31 MAR X Kansas X
• Kentucky X 1 DEC- 31 MAR X Louisiana X Maine X 15 NOV· 15 MAR X Maryland X Massachusetts X Michigan X 15 NOV· 15 APR X Minnesota X 15 NOV· 15 APR X • Mississippi X Missouri X 15 DEC· 15 MAR X Montana X 16 NOV· 15 APR X Nebraska X Nevada X New Hampshire X 1 DEC· 31 MAR X
• New Jersey X New Mexico X New York X 1 NOV- 31 MAR X North Carolina X 15 DEC· 15 MAR X North Dakota X 15 NOV· 15 APR X Ohio X 1 DEC- 30 APR X Oklahoma X
• Oregon X 1 DEC· 1 MAR X Pennsylvania X Rhode Island X 15 DEC- 15 APR X South Carolina X South Dakota X 1 DEC· 31 MAR X Tennessee X Texas X • Utah X 1 DEC· 1 MAR X Vermont X 1 DEC· 15 APR No Work Allowed Virginia X 1 DEC- 31 MAR X Washington X West Virginia X 1 DEC· 31 MAR X Wisconsin X
• Wyoming X 1 DEC- 31 MAR X
• 140
• May the agency require no work be performed on Sundays? (Summarized in Table 15)
• Yes
Alabama X Alaska X Arizona X
• Arkansas X California X Colorado X Connecticut X Delaware X Florida X Georgia X • Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X
• Kentucky X Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X
• Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X • New Mexico X New York X North Carolina X North Dakota X Ohio X Oklahoma X
• Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X Texas X
• Utah X Vermont X Virginia X Washington X West Virginia X Wisconsin X
• Wyoming X
141 •
• May the agency require no work be performed on Holidays? (Summarized in Table 15)
• Yes
Alabama X Alaska X Arizona X • Arkansas X California X Colorado X ConnecticU1 X Delaware X Florida X Georgia X • Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X
• Kentucky X Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X
I• Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X • New Mexico X New York X North Carolina X North Dakota X Ohio X Oklahoma X
• Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota X Tamassee X Texas X • Utah X Vermont X Virginia X Washington X West Virginia X Wisconsin X
• Wyoming X
• 142
May the agency require no work be performed on the day prior to or following Holidays? (Summarized in Table 15)
• Yes
Alabama X Alaska X Arizona X • Arkansas X California X Colorado X Connecticut X Delaware X Florida X
• Georgia X Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X
• Kentucky X Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X • Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X
• New Jersey X New Mexico X New York X North Carolina X North Dakota X Ohio X Oklahoma X
• Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota X TeMessee X Texas X • Utah X Vermont X Virginia X Washington X West Virginia X Wisconsin X
• Wyoming X
143 •
• For a working day contract, does Saturday count as a working day If worked? (Summarized in Table 16)
• Yes ~ Not Stated NA
Alabama X Alaska X Arizona X Arkansas X • California X Colorado X Connecticut X Delaware X Florida X Georgia X
• Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X Kentucky X
• Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X Mississippi X • Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X
• New Mexico X New York X North Carolina X North Dakota X Ohio X Oklahoma X Oregon X • Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X Texas X Utah X • Vermont X Virginia X Washington X West Virginia X Wisconsin X Wyoming X
•
• 144
• For working day contract, does Sunday or a Holiday count as a working day H worked? (Summarized in Table 16a)
• Yes NA
Alabama X Alaska X Arizona X • Arkansas X California X Colorado X Connecticut X Delaware X Florida X
• Georgia X Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X
• Kentucky X louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X • Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X • New Mexico X New York X North Carolina X North Dakota X Ohio X Oklahoma X
• Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota X TeM&ssee X Texas X • Utah X Vermont X Virginia X Washington X West Virginia X Wisconsin X
• Wyoming X
• 145
• For working day contract, how often does the agency submit a record of days charged for the contractor to review? (Summarized in Tabla 17)
• Twice No Weakly Monthly Monthly Mention NA
Alabama X Alaska X Arizona X Arkansas X • California X Colorado X Connecticut X Delaware X Florida X Georgia X Hawaii X • Idaho X Illinois X Indiana X Iowa X Kansas X Kentucky X
• Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X Mississippi X • Missouri X Montana X Nebraska X Navada X New Hampshire X New Jersey X New Mexico X • New York X North Carolina X North Dakota X Ohio X Oklahoma X Oregon X • Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X Texas X Utah X • Vermont X Virginia X Washington X West Virginia X Wisconsin X Wyoming X
•
• 146
• For working day contract, how long does the contractor have to take exception to the agency log of days charged? (Summarized in Table 18)
• O'la Ten Fifteen No Week Days Days Mention Other
Alabama AS SOON AS POSSIBLE Alaska Arizona X Arkansas X • Califomia X Colorado 30 DAYS Connecticut X Delaware X Florida X Georgia X Hawaii X • Idaho X Illinois X Indiana X Iowa X Kansas X Kentucky X
• Louisiana X Maine X Maryland X Massachusetts Michigan 21 DAYS Minnesota X Mississippi X • Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X New Mexico X • New York North Carolina North Dakota X Otio Oklahoma X Oregon
• Pennsylvania X Rhode Island X South Carolina South Dakota X Tennessee X Texas X Utah X • Vermont Virginia Washington X West Virginia X Wisconsin X Wyoming X
•
147 •
• For working day contract, are weather delays excluded from time charges? (Summarized in Table 19)
• No Yes Mention NA
Alabama X Alaska X Arizona X • Arkansas X California X Colorado X Connecticut X Delaware X Florida X Georgia X • Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X
• Kentucky X Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X • Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X • New Mexico X New York X North Carolina X North Dakota X Ohio X Oklahoma X
• Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota X TeMessee X Texas X • Utah X Vermont X Virginia X Washington X West Virginia X Wisconsin X
• Wyoming X
• 148
• In the case of differing site conditions must the contractor Notify the agency prior to distrubing? (Summarized In Table 20)
I • Yes No Mention
Alabama X Alaska X Arizona X • Arkansas X California X Colorado X Connecticut X Delaware X Florida X
• Georgia X Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X
• Kentucky X Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X • Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X
• New Jersey X New Mexico X New York X North Carolina X North Dakota X Ohio X Oklahoma X
• Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota X Temessee X Texas X • Utah X Vermont X Virginia X Washington X West Virginia X Wisconsin X
• Wyoming X
• 149
• Does the contract allow for adjustment of time and price for differing site conditions? (Summarized in Table 21)
• Differing Site Conditions Clause Adjustment to Contract Price & Time
Yes ~ Std Clause Yes ~
Alabama X X X Alaska X X Arizona X X X • Arkansas X X X California X X X Colorado X X X Connecticut X X Delaware X X X Florida X X X
• Georgia X X Hawaii X X X Idaho X X X Illinois X X X Indiana X X X Iowa X X X Kansas X X X
• Kentucky X X Louisiana X X X Maine X X X Maryland X X X Massachusetts X X Michigan X X X Minnesota X X X • Mississippi X X X Missouri X X X Montana X X X Nebraska X X X Nevada X X New Hampshire X X X
• New Jersey X X New Mexico X X X New York X X North Carolina X North Dakota X Ohio X X X Oklahoma X X X
• Oregon X X Pennsylvania X X Rhode Island X X South Carolina X X X South Dakota X X Tennessee X X X Texas X X X • Utah X X X Vermont X X X Virginia X X X Washing1on X X West Virginia X X X Wisconsin X X X
• Wyoming X X X
• 150
• Is Adverse Weather Defined? (Summarized in Table 22)
• Yes N:l
Alabama X Alaska X
Arizona X Arkansas X • California X Colorado X
Connecticut X Delaware X
Florida X Georgia X Hawaii X • Idaho X Illinois Indiana X
Iowa X Kansas X
Kentucky X
• Louisiana X Maine X
Maryland X Massachusetts X
Michigan X Minnesota X
Mississippi X • Missouri X Montana X
Nebraska X Nevada X
New Hampshire X New Jersey X New Mexico X • New York X
North Carolina X North Dakota X
Ohio X Oklahoma X
Oregon X
• Pennsylvania X Rhode ls!and X
South Carolina X South Dakota X
Tennessee X Texas X
Utah X • Vermont X Virginia X
Washington X West Virginia X
Wisconsin X Wyoming X
•
• 151
• Are time extensions allowed? (Summarized in Table 23)
• Yes
Alabama X Alaska X Arizona X • Arkansas X California X Colorado X Connecticut X Delaware X Florida X
• Georgia X Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X
• Kentucky X Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X • Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X • New Mexico X New York X North Carolina X North Dakota X Q1io X Oklahoma X
• Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X Texas X • Utah X Vermont X Virginia X Washington X West Virginia X Wisconsin X
• Wyoming X
• 152
• When are requests tor additional contract time due?
• Within __ days Within _ days Anytime Prior No time stated of start of delay of end of delay to completion
Alabama X Alaska 1 0 Arizona 1 0 Arkansas X • california 7 Colorado 30 Connecticut X Delaware X Florida X Georgia 15 Hawaii 90 • Idaho X Illinois X Indiana X Iowa 7 Kansas X Kentucky 14
• Louisiana X Maine X Maryland 10 Massachusetts X Michigan 7 Minnesota X Mississippi X • Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey 15 New Mexico X • New York X North Carolina X North Dakota X Ohio 30 OW ahoma X Oregon X
• Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X Texas X Utah X • Vermont X Virginia X Washington 10 West Virginia X Wisconsin X Wyoming 10
•
153 •
• Will the contract time be extended for weather delays? (Summarized In Table 23)
• Yes COMMENTS
Alabama X Alaska X Arizona X • Arkansas X California X Colorado X Connecticut X Delaware X Florida X Georgia X • Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X
• Kentucky X Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X • Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X • New Mexico X New York X North Carolina X North Dakota X Otio X Oklahoma X
• Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X Texas X • Utah X Vermont X Virginia X Washington X West Virginia X Wisconsin X
• Wyoming X
• 154
• Are claims allowed? (Summarized In Table 24)
Yes Nl No CLAUSE • Alabama X Alaska X Arizona X Arkansas X California X • Colorado X Connecticut X Delaware X Florida X Georgia X Hawaii X Idaho X • Illinois X Indiana X Iowa X Kansas X Kentucky X Louisiana X
• Maine X Maryland X Massachusetts X Michigan X Minnesota X Mississippi X Missouri X • Montana X Nebraska X Nevada X New Hampshire X New Jersey X New Mexico X New York X • North Carolina X North Dakota X Ohio X Oklahoma X Oregon X Pennsylvania X
• Rhode Island X South Carolina X South Dakota X Temessee X Texas X Utah X Vermont X • VIrginia X Washington X West Virginia X Wisconsin X Wyoming X
•
• 155
• When must claims be submitted to the agency? (Summarized In Table 25)
:e Notice prior to Proposal due within performing disputed work _ days of knowing cost Other
Alabama X Alaska X 60 Arizona X 60 Arkansas X • California NOTICE WITHIN 15 DAYS OF EVENT Colorado NOTICE WITHIN 15 DAYS OF EVENT Connecticut No CLAIMS CLAUSE Delaware X 60 Florida X Georgia X 60 Hawaii X 30 • Idaho X Illinois
No CLAIMS CLAUSE Indiana X Iowa X Kansas X 10 Kentucky X
• Louisiana X Maine X 60 Maryland X 30 Massachusetts X Michigan X 60 Minnesota X Mississippi X • Missouri X Montana X 30 Nebraska No CLAIMS CLAUSE Nevada
No CLAIMS CLAUSE New Hampshire X New Jersey X New Mexico X • New York X North Carolina X 120 North Dakota X 120 Qio X Oklahoma X 30 Oregon X
• Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X 60 Texas No CLAIMS CLAUSE Utah X • Vermont X Virginia X Washington X 30 West Virginia X Wisconsin X Wyoming X 60
•
• 156
• Can the agency suspend work? (Summarized In Table 26)
• Yes I'Cl Standard Clause Proposal
Due in _days
Alabama X Alaska X Arizona X X 7 Arkansas X
• California X X 7 Colorado X X 7 Connecticut X Delaware X X 7 Florida X Georgia X X 7 Hawaii X • Idaho X X 7 Illinois X X 7 Indiana X X 7 Iowa X X 7 Kansas X X 7 Kentucky X
• Louisiana X X 7 Maine X X 7 Maryland X 20 Massachusetts X 30 Michigan X X 7 Minnesota X X 7 Mississippi X X 7 • Missouri X X 7 Montana X X 7 Nebraska X X 7 Nevada New Hampshire X X 7 New Jersey X 1 0 New Mexico X X 7 • New York X North Carolina X 14 North Dakota X X 7 Ohio X Oklahoma X Oregon X X 7 • Pennsylvania X Rhode Island X South Carolina X X 7 South Dakota X Temessee X X 7 Texas X X 7 Utah X X 7 • Vermont X X 7 Virginia X X 7 Washington X West Virginia X X 7 Wisconsin X X 7 Wyoming X X 7
•
• 157
• Is there a clause for suspension of work If historical or archeological finds encountered? (Summarized in Table 27)
• Yes
Alabama X Alaska X Arizona X • Arkansas X California X Colorado X Connecticut X Delaware X Florida X Georgia X • Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X
• Kentucky X Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X • Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X • New Mexico X New York X North Carolina X North Dakota X Ohio X Oklahoma X
• Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X Texas X • Utah X Vermont X Virginia X Washington X West Virginia X Wisconsin X
• Wyoming X
• 158
• Are liquidated damages included in Separate values for calendar day Provisions? vs working or completion date? (Summarized in Table 28)
• Yes N:l Yes NA
Alabama X X Alaska X X Arizona X X Arkansas X X • California X X Colorado X X Connecticut X X Delaware X X Florida X X Georgia X X Hawaii X X • Idaho X X Illinois X X Indiana X X Iowa X X Kansas X X Kentucky X X
• Louisiana X X Maine X X Maryland X X Massachusetts X X Michigan X X Minnesota X X Mississippi X X • Missouri X X Montana X X Nebraska X X Nevada X X New Hampshire X X New Jersey X X New Mexico X X • New York X X North Carolina X X North Dakota X X Ohio X X Oklahoma X X Oregon X X
• Pennsylvania X X Rhode Island X X South Carolina X X South Dakota X X Temessee X X Texas X X Utah X X • Vermont X X Virginia X X Washington X X West Virginia X X Wisconsin X X Wyoming X X
•
• 159
• How quickly must the contractor respond to Notice of inadequate maintenance of project? (Summarized in Table 29)
• No
Immediately 24 Hours 48 Hours Mention Other
Alabama X Alaska X • Arizona X Arkansas X California X Colorado X Connecticut X Delaware X Florida X • Georgia X Hawaii X Idaho X Illinois X Indiana X Iowa X
• Kansas X Kentucky X Louisiana X Maine X Maryland X Massachusetts X Michigan X • Minnesota X Mississippi X Missouri X Montana X Nebraska X Nevada X New Hampshire WITHIN SPECIFIED TIME • New Jersey X New Mexico X New York X North Carolina X North Dakota X Ohio X
• Oklahoma X Oregon X Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X • Texas X Utah X Vermont X Virginia X Washington X West Virginia X Wisconsin X • Wyoming X
• 160
• C~:m the agency terminate the contract for convenience? (Summarized In Table 30)
I Yes N:l COMMENTS
• Alabama X Alaska X Arizona X Arkansas X California X • Colorado X Connecticut X Delaware X Florida X Georgia X Hawaii X Idaho X • Illinois X Indiana X Iowa X NATIONAL EMERGENCY ONLY Kansas X Kentucky X Louisiana X
• Maine X Maryland X Massachusetts X Michigan X Minnesota X NATIONAL EMERGENCY ONLY Mississippi X Missouri X • Montana X Nebraska X Nevada X New Hampshire X New Jersey X New Mexico X New York X • North Carolina X North Dakota X Ohio X Oklahoma X Oregon X Pennsylvania X
• Rhode Island X South Carolina X South Dakota X NATIONAL EMERGENCY ONLY Tennessee X Texas X NATIONAL EMERGENCY ONLY Utah X Vermont X NATIONAL EMERGENCY ONLY • Virginia X Washington X West Virginia X Wisconsin X Wyoming X
•
• 161
• How long does the contractor have to respond to/or correct deficiencies prior to agency terminating contract? (Summarized in Table 31)
• _ day Notice to No Notice period Contractor stated
Alabama 10 Alaska X Arizona 10 Arkansas 10 • California X Colorado 1 0 Connecticut 10 Delaware 10 Florida 1 0 Georgia 10 Hawaii 10 • Idaho 10 Illinois 10 Indiana 10 Iowa X Kansas 10 Kentucky 10
• Louisiana 10 Maine 10 Maryland X Massachusetts 5 Michigan 1 0 Minnesota 1 0 Mississippi 15 • Missouri 10 Montana 10 Nebraska 1 0 Nevada X New Hampshire 10 New Jersey 10 New Mexico 10 • New York X North Carolina 7 North Dakota 1 0 Qlio X Oklahoma 10 Oregon 10
• Pennsylvania 10 Rhode Island 10 South Carolina 15 South Dakota 10 Tennessee 1 5 Texas 10 Utah 10 • Vermont 10 Virginia 1 0 Washington X West Virginia 10 Wisconsin 10 Wyoming 10
•
• 162
• How long does the surety have to take over work prior to agency performing or having work performed by others? (Summarized in Table 32)
• _ day Notice to surety No MENTION
Alabama X Alaska X Arizona X Arkansas X • California X Colorado X Connecticut X Delaware 10 Florida X Georgia 10 Hawaii X • Idaho X Illinois X Indiana X Iowa X Kansas X Kentucky X
• Louisiana X Maine X Maryland X Massachusens X Michigan X Minnesota X Mississippi 20 • Missouri X Montana X Nebraska X Nevada X New Hampshire X New Jersey X New Mexico X • New York X North Carolina X North Dakota X Ohio X Oklahoma X Oregon X
• Pennsylvania X Rhode Island X South Carolina 30 South Dakota X Temessee X Texas X Utah X • Vermont X Virginia X Washing1on X West Virginia X Wisconsin X Wyoming X
•
• 163
• How often are progress payments made? (Summarized in Table 33)
• Monthly Twice Monthly Bi-Weekly Other
Alabama X Alaska X Arizona X Arkansas X • California X Colorado X Connecticut X Delaware X Florida X Georgia X
• Hawaii X Idaho X Illinois X Indiana X Iowa X Kansas X Kentucky X • Louisiana X Maine X Maryland X Massachusetts X Michigan X Minnesota X Mississippi X • Missouri Montana X Nebraska X Nevada NOT STATED New Hampshire X New Jersey X
• New Mexico X New York North Carolina X North Dakota X otio X Oklahoma X Oregon X • Pennsylvania X Rhode Island X South Carolina X South Dakota X Tennessee X Texas X Utah X • Vermont X Virginia X Washington X West Virginia X Wisconsin X Wyoming X
•
• 164
•
•
•
X. APPENDIX B
• SUtJMARY SHEETS FOR OlHER AGENCIES
•
•
•
•
•
•
• 165
•
•
•
•
•
•
•
•
•
•
•
Are Holidays listed in the contract and if so, how many holidays does the agency observe? (Summarized In Table 1)
Listed #Holidays Not Usted Unusual Days
Chicago 5 Good Friday Cincinnati X Dallas X Detroit X EIPaso 9 Day After Thanksgiving Honolulu X los Angeles X louisville X Milwaukee X San Francisco X Seattle 10 Tampa X Tulsa X U.S.BLM X U.S. Navy X AlA X
166
•
•
•
•
•
•
•
•
•
•
•
May the Contractor Withdraw or Modify a bid any time prior to bid opening? (Sunwnarlzed in Table 2)
Yes I'C Other
Chicago X Cincinnati X Dallas X Detroit No Mention El Paso No Mention Honolulu X Los Angeles No Mention Louisville X Milwaukee X San Francisco No Mention Seattle X Tampa No Mention Tulsa X U.S.BLM X U.S. Navy X AlA No Mention
167
•
•
•
•
•
•
•
•
•
•
•
How long after bid opening can the agency award the contract? (Summarized In Table 3)
30 Days 40 Days 4S Days 50 Days 60 Days
Chicago X Cincinnati Dallas Detroit EIPaso Honolulu Los Angeles Louisville Milwaukee X San Francisco X Seattle X Tampa X Tulsa U.S.BLM X U.S. Navy X AlA
168
90 Days Not listed or other
X X X X X X X
X
X
•
•
•
•
•
•
•
•
•
•
•
Can the contractor withdraw a bid If the contract award is not made in the stated time? (Summarized in Table 4)
Yes No Mention Chicago X
Cincinnati X Dallas X
Detroit X EIPaso X
Honolulu X Los Angeles X
Louisville X Milwaukee X
San Francisco X Seattle X Tampa X Tulsa X
U.S.BLM X U.S. Navy X
AlA X
169
• How soon after award are bid guarantees of unsuccessful! bidders returned? (Summarized In Table S)
• Upon award After bid opening Only checks Not mentioned other than two low returned
bidders
Chicago 20 DAYS Cincinnati X Dallas X • Detroit X EIPaso X Honolulu X Los Angeles X Louisville X Milwaukee X
• San Francisco X Seattle X X Tampa 10 DAYS Tulsa X U.S.BLM X U.S. Navy X AlA X •
•
•
•
•
•
• 170
• How long does the contractor have to return the signed contract to the agency? (Sunvnarizad in Table 6)
• 8 Days 10 Days 15 Days 20 Days Other Not Stated
Chicago 13 DAYS Cincinnati X
Dallas X Detroit X EIPaso 12 DAYS • Honolulu X
Los Angeles 30 DAYS Louisville X
Milwaukee X San Francisco X
Seattle 14DAYS
• Tampa X Tulsa X
U.S.BLM X U.S. Navy X
AlA X
•
•
•
•
•
•
• 171
• What Is forfeited if the contractor does not return the signed contract within the required number of days? (Summarized in Table 7)
• Bid Guarantee Bid Difference No Mention Other Forfeited as LD's Forfeited
Chicago X Cincinnati X
Dallas X Detroit X El Paso X • Honolulu X
Los Angeles X Louisville X
Milwaukee X San Francisco X
Seanle X
• Tampa X Tulsa X
U.S.BLM X U.S. Navy X
AlA X
•
•
•
•
•
•
• 172
• What is the date of the Notice to Proceed (NTP)? (Summarized In Table 8)
• When Mailed When Received When Signed Not Stated
Chicago X Cincinnati X
Dallas X Detroit X • EIPaso X
Honolulu X Los Angeles X
Louisville X Milwaukee X
San Francisco X
• Seattle X Tampa X Tulsa X
U.S.BLM X U.S. Navy X
AlA X
•
•
•
•
•
•
• 173
• What Is the Contract Start Date Defined As? (Summarized In Table 9)
• As stated In NTP _ Days after NTP When Signed
Chicago X Cincinnati X Dallas X Detroit X • EIPaso X Honolulu X Los Angeles X Louisville 1 0 Milwaukee X San Francisco X
• Seattle 10 Tampa 30 Tulsa X U.S.BLM 1 5 U.S. Navy 1 5 AlA X
•
•
•
•
•
•
• 174
• When must the contractor submit a schedule for review? (Summarized In Table 1 0)
• Prior to At the _days NJ starting work PRE-CON after award Mention Other
Chicago 10 DAYS AFTER STARTING Cincinnati 15 Dallas IMMEDIATELY UPON AWARD • Detroit X El Paso X Honolulu 7 Los Angeles X Louisville X Milwaukee X San Francisco X • Seattle 14 Tampa 1 5 Tulsa X U.S.BLM 15 U.S. Navy 15 AlA PROMPTLY AFTER AWARD
•
•
•
•
•
•
175 •
• Is a Pre-Construction Conference Required? (Summarized in Table 11)
• Yes No
Chicago X Cincinnati X
Dallas X Detroit X • EIPaso X
Honolulu X Los Angeles X
Louisville X Milwaukee X
5an Francisco X
• Seattle X Tampa X Tulsa X
U.S.BLM X U.S. Navy X
AlA X
•
•
•
•
•
•
• 176
• Must all Materials be Tested and Inspected Prior to Incorporation in the Work? (Summarized in Table 12)
• Yes No No Mention
Chicago X Cincinnati X Dallas X • Detroit X EIPaso X Honolulu X Los Angeles X Louisville X Milwaukee X San Francisco X • Seattle X Tampa X Tulsa X U.S.BLM X U.S. Navy X AlA X
•
•
•
•
•
•
• 177
• What Is the basis of contract time? (Summarized In Table 13)
• Working Calendar Axed Completion May use Days Days Date Combiation
Chicago X Cincinnati X X X Dallas X Detroit X • EIPaso X Honolulu X Los Angeles X Louisville X Milwaukee X X X X San Francisco X
• Seattle X Tampa X Tulsa X X X X U.S.BLM X U.S. Navy X AlA X
•
•
•
•
•
•
• 178
• Does the Contract Have a Winter Exclusion Period? (Summarized in Table 14)
• Yes No Period
Chicago X 16 DEC- 14 MAR Cincinnati X 1 DEC- APR 30
Dallas X Detroit X • EIPaso X
Honolulu X Los Angeles X
Louisville X Milwaukee X
San Francisco X
• Seanle X Tampa X Tulsa X
U.S.BLM X U.S. Navy X
AlA X
•
•
•
•
•
•
• 179
• May the agency require no work be performed on Sundays? (Summarized in Table 15)
• yes no
Chicago X Cincinnati X Dallas X • Detroit X EIPaso X Honolulu X Los Angeles X Louisville X Milwaukee X
• San Francisco X Seattle X Tampa X Tulsa X U.S.BLM X U.S. Navy X AlA X
•
•
•
•
•
•
• 180
• May the agency require no work be performed on Holidays? (Summarized in Table 15)
• yes no
Chicago X Cincinnati X Dallas X • Detroit X EIPaso X Honolulu X los Angeles X Louisville X Milwaukee X San Francisco X • Seattle X Tampa X Tulsa X U.S.BLM X U.S. Navy X AlA X
•
•
•
•
•
•
• 181
•
•
•
•
•
•
•
•
•
•
•
May the agency require no work be performed on the day prior to or following Holidays? (Summarized In Table 15)
Chicago Cincinnati
Dallas Detroit EIPaso
Honolulu Los Angeles
louisville Milwaukee
San Francisoo Seattle Tampa Tulsa
U.S.BLM U.S. Navy
AlA
yes no
X X X X X X X X X X X X X X X X
182
For working day contract, does Saturday count as a working day If worked? (Summarized In Table 16)
• yes no Not Stated NA
Chicago X Cincinnati X
Dallas X Detroit X • EIPaso X
Honolulu X Los Angeles X
Louisville X Milwaukee X
San Francisco X Seattle X • Tampa X
Tulsa X U.S.BLU X
U.S. Navy X AlA X
•
•
•
•
•
•
• 183
•
•
•
•
•
•
•
•
•
•
•
For working day contract, does Sunday or a Holiday count as a working day H worked? (Summarized In Table 16a)
Chicago Cincinnati
Dallas Detroit EIPaso
Honolulu Los Angeles
Louisville Milwaukee
San Francisco Seattle Tampa Tulsa
U.S.BLM U.S. Navy
AlA
yes no
X
X
X X
X
X
NA
X X X X X
X
X
X X X
184
• For working day contract, how often does the agency submit a record of days charged for the contractor to review? (Summarized in Table 17)
Twice No • Weekly Monthly Monthly Mention NA Other
Chicago X Cincinnati X Dallas X Detroit X EIPaso X • Honolulu X Los Angeles PEFO:>IC Louisville X Milwaukee X San Francisco X Seat1le X
• Tampa X Tulsa X U.S.BLM X U.S. Navy X AlA X
•
•
•
•
•
•
• 185
• For working day contract, how long does the contractor have to take exception to the agency log of days charged? (Summarized in Table 18)
• Ole Ten Fifteen No Week Days Days Mention NA
Chicago X X Cincinnati X Dallas X Detroit X • EIPaso X Honolulu X Los Angeles X Louisville X Milwaukee X San Francisco X
• Seattle X Tampa X Tulsa X U.S.BLM X U.S. Navy X AlA X
•
•
•
•
•
•
• 186
For working day contract, are weather delays excluded from time charges? (Summarized In Table 19)
No Yes Mention NA
Chicago X Cincinnati X Dallas X Detroit X EIPaso X Honolulu X los Angeles X Louisville X Milwaukee X San Francisco X Seattle X Tampa X Tulsa X U.S.BLM X U.S. Navy X AlA X
187
In 1he case of differing alta condltons must the contractor notify the agency prior to distrubing? (Summarized In Table 20)
Yes NO CLAUSE
Chicago X Cincinnati X Dallas X Detroit X EIPaso X Honolulu X Los Angeles X Louisville X Milwaukee X San Francisco X Seattle X Tampa X Tulsa X U.S.BLM X U.S. Navy X AlA X
188
Does the contract allow for adjustment of time and price for differing site conditions? (Summarized In Table 21)
Differing Site Conditions Clause Adjustment to Contract Price a. Time
Yes 1\J:) Std Clause Yes 1\J:)
Chicago X Cincinnati X X Dallas X X Detroit X X EIPaso X X Honolulu X X Los Angeles X X Louisville X X Milwaukee X San Francisco X Seattle X X X Tampa X Tulsa X X U.S.BLM X X U.S. Navy X X AlA X X
189
Ia Adverse Weather Defined? (Summarized in Table 22)
Yes 1\b
Chicago X Cincinnati X
Dallas X Detroit X El P.'UO X
Honolulu X Los Angeles X
Louisville X Milwaukee X
San Francisco X Seattle X Tampa X Tulsa X
U.S.BLM X U.S. Navy X
AlA X
190
Ate time extensions allowed? (Summarized in Table 23)
Yes
Chicago X Cincinnati X Dallas X Detroit X EIPaso X Honolulu X Los Angeles X Louisville X Milwaukee X San Francisco X Seattle X Tampa X Tulsa X U.S.BLU X U.S. Navy X AlA X
191
When are requests for additional contract time due?
Within _days Within _days Anytime Prior No time stated of start of delay of end of delay to completion
Chicago 10 Cincinnati 10 Dallas X Detroit 5 EIPaso 10 Honolulu 7 Los Angeles 30 Louisville 5 Milwaukee X San Francisco X Seattle 5 Tampa 7 Tulsa X U.S.BLM 10 U.S. Navy 10 AlA 21
192
Will the contract time be extended for weather delays? (Summarized In Table 23)
Yes
Chicago X Cincinnati X
Dallas X Detroit X El Paso X
Honolulu X Los Angeles X
louisville X Milwaukee X
San Francisco X Seattle X Tampa X Tulsa X
U.S.BLM X U.S. Navy X
AlA X
193
'
•
t
I
I
•
Are claims allowed?
Chicago Cincinnati
:>alias Detroit EIPaso
Honolulu Los Angeles
Louisville Milwaukee
San Francisco Seattle Tampa Tulsa
U.S.BLM U.S. Navy
AlA
Yes
X X X X
X X X X X X X X X X X
(Summarized in Table 24)
Comments
X
194
Wh., must claims be submitted to the agency? (Summarized in Table 25)
Notice prior to performing disputed work
Proposal due within _ days of knowing cost No timeframe stated
Chicago Cincinnati Dallas Detroit EIPaso Honolulu Los Angeles Louisville Milwaukee San Francisco Seanle Tampa Tulsa U.S.BLM U.S. Navy AlA
NOTICE DUE WITHIN 10 DAYS OF START OF DISPUTE 7
NOTICE DUE WITHIN 5 DAYS OF ORDER
NOTICE DUE WITHIN 10 DAYS OF DIRECTION X X
NOT LATER THAN 5 DAYS AFTER COMPLETION X
30 X
X
195
X
X
X X X
Can the agency suspend work? (Summarized in Table 26)
Proposal Yes NJ S'tandard Clause Due in _days
Chicago X Cincinnati X Dallas X Detroit X EIPaso X Honolulu X Los Angeles X Louisville X Milwaukee X San Francisco X Seattle X rampa X Tulsa X U.S.BLM X 10 U.S. Navy X 1 0 AlA X
•
t
I
• 196
Is there a clause for suspension of work H historical or archeological finds encountered? (Summarized in Table 27)
Yes t-«>
Chicago X Cincinnati X Dallas X Detroit X EIPaso X Honolulu X Los Angeles X Louisville X Milwaukee X San Francisco X Seattle X Tampa X Tulsa X U.S.BLM X U.S. Navy X AlA X
197
Are liquidated damages Included In Separate values for calendar day Provisions? vs working or completion date? (Summarized in Table 28)
• Yes N,:) Yes NA
Chicago X X Cincinnati X X Dallas X X Detroit X X • EIPaso X X Honolulu X X Los Angeles X X Louisville X X Milwaukee X X San Francisco X X
• Seattle X X Tampa X X Tulsa X X U.S.BLM X X U.S. Navy X X AlA X
•
•
•
•
•
•
• 198
How quickly must the contractor respond to notice of inadequate maintenance of project? (Summarized In Table 29)
No Immediately 24 Hours 48 Hours Mention Other
Chicago X Cincinnati X Dallas X Detroit X El Paso X Honolulu X Los Angeles X Louisville X Milwaukee X San Francisco X Seattle X Tampa X Tulsa X U.S.BLM X U.S. Navy X AlA X
199
• Can the agency terminate the contract tor convenience? (Summarized in Table 30)
• Yes
Chicago X Cincinnati X Dallas X
• Detroit X EIPaso X Honolulu X Los Angeles X Louisville X Milwaukee X San Francisco X Seattle X Tampa X • Tulsa X U.S.BLM X U.S. Navy X AlA X
•
•
•
•
•
•
200
How long does the contractor have to respond to/or correct deficiencies prior to agency terminating contract? (Summarized in Table 31)
• _ day notice to No notice periord Contractor stat ad
Chicago 10 Cincinnati 10 Dallas 15 Detroit 2 • EIPaso 10 Honolulu 7 los Angeles X louisville X Milwaukee X San Francisco 24HAS Seattle X • Tampa X Tulsa 10 U.S.BlM X U.S. Navy X AlA 14
•
•
•
•
•
•
• 201
How long does the surety have to take over work prior to agency performing or having work perfromed by others? (Summarized in Table 32)
_ day notice to No notice periord surlty stated
Chicago X Cincinnati tO Dallas 15 Detroit X EIPaso 10 Honolulu X Los Angeles 5 Louisville X Milwaukee 10 San Francisco X Seattle X Tampa X Tulsa X U.S.BLM X U.S. Navy X AlA X
202
How often are progress payments made? (Summarized in Table 33)
Chicago Cincinnati Dallas Detroit El Paso Honolulu Los Angeles Louisville Milwaukee San Francisco Seattle Tampa Tulsa U.S.BLM U.S. Navy AlA
Monthly Twice Monthly Bi-Weekly Other
X X X
X X X X
X X X X X X
203
NO MENTION
FROM TIME TO TIME
PER AGREEMEIITT"
XI. APPENDIX C
STAlE a= C?EORG~
DISPUTES RESOLUTION PROVISIONS
204
•
DEPAR'IMENI' OF 'I'RANSPORTATI~ State of Georgia
SUPPLEMENTAL SPEX:'IFICATI~
~ev. ~ovemoer ~b, ~~bb
First Used 01-02-89
Mbelification of the Standard Specifications
m:T!Cfi 105 - CXJma. CF w:JUt
Retain as wntten except as follCMS: Delete SUb-Section 105.13 in it's entir~ty and subst1tute the follow~g:
105.13 ClAIMS ~ ADJtJS'lMEN1'S AR> DISPl1l!S: "'lenever the Contractor believes that it is or will be entitled to additional ccnpensatian,
I whether due to delay, extra work, breach of contract., or other causes, the Contractor shall follow the procedures set forth in this Sub-Sect1on.
•
•
•
•
•
•
•
A. CU\!MS FOR DELAY:
1. 'Ihe Oepartnent shall have no liability for damages due to delay, beyond those items which are spc=ifically payable under this Sub-Section.
2. . The Department will be liable only for those delay damages caused by or arising fran acts or anissions oo the part of the Department which violate legal or contractual duties owed to the Contractor by the Depa.rtnent. 'lbe Caltract.or assl.m!s the risk of damages fran all other causes of ci:!lay.
3. 'Ihe parties anticipate ci:!lays caused by or ar1s1.n9 fran right of way problems, defects in plans or ci:!sign, redesign, changes in the Work by the Department, the actioos of suppliers or other contractors, the shop-drawing approval process, injunctioos, court orci:!rs and other such events, forces or factors caruonly experienced in highway constnJctioo work. Such ci:!lays are specif1cally contemplated by the parties in entering this Contract., and shall not constitute breaches of the Caltract.. ~ver, such D:!lays may constitute a basis far a claim far delay damages, if found to be in accordance with SUb-Section 105.13.A.2 above and other pravisioos of the Caltract1 and/or a request far a time extensioo.
4. 'Ihe term "delay" shall be deened to nean any event, action, force or factor which extends the Contractor's tine of performance. 'Ibis SUb-Sectioo is intended to cover all such events, actions, forces or factors, whether they be styled "ci:!lay", "disruption" 1 "interference" 1 ".iJrpedance" 1 "hindrance" or otherwl&e •
205
•
•
•
•
•
•
•
•
•
•
•
5. Compliance vi th the provisions of this Sub-Section will be an essential condition precedent to any recovery of delay damages by the Contractor.
6. The following items, and only the following items, will be recoverable by the Contractor as "delay damages" caused by a delay:
a. Additional Job site labor expenses.
b. Documented additional costs for materials.
c. Equipment costs, as determined in accordance with this Sub-Section.
d. Documented costs of extended Job-site overhead.
e. An additional 10 percent of the total of items a, b, c, and d for home office overhead and profit .
f. Bond costs.
g. Subcontractor costs, as determined by, and limited to, those items identified as payable under paragraphs a, b, c, d, e, and f above .
7. For purposes of computing extra P.quipment costs, rates used shall be based on the Contractor's actual experienced cost for each piece of equipment. These rates must be supported by equipment cost records furnished by the Contractor. In no case will equipment rates be allowed in excess of those determined utilizing the "Rental Rate Blue Book", with the appropriate adjustments noted in Sub-Section 109.05.
8. The parties ap:ree that, in any claim for delay damages, the Department will have no liability for the following items of damages or expense:
a. Profit, in excess of that provided herein.
b. Loss of profit.
c. Labor inefficiencies •
d. Home office overhead in excess of that provided herein.
e. Consequential damages, including but not limited to loss of bonding capacity, loss of bidding opportunities and insolvency •
f. Indirect costs or expenses of any nature .
206
•
•
•
•
•
•
•
•
•
•
•
g. Attorneys fees, claims preparatioo expenses or costs of litigation.
9. Within ooe week after detennining that a delay has occurred, the Contractor must give the Oepa.rtnent written notice of its intention to file a claim for delay damages. Such notice nust be given in order that the Oepartnent can:
a. Assess the situation.
b. Make an initial determination as to who is responsible for causing the delay .
c. Institute appropriate changes or pro=edures to resolve the matter.
The Department shall have no liability for any delay damages which accnJed nore than one week prior to the filing of such notice • Failure of the Contractor to give such written notice in a timely fashion Wlll be grounds for denial of the claim.
10. After giving the Department notice of intention to file a claim for delay damages, the Contractor must keep daily records of all labor, material, and equipment costs incurred for operations affected by the delay. 'nlese daily records must identify each operation affected by the delay and the specific locations where work is affected by the delay. The Department will also keep records of all labor, material, and equipment used on operaticns affected by the delay. 01 M:>nday, or the first work day, of each ~k follONlng the date of giving notice of intention to file claim for delay damages, the Contractor shall neet with the Department's representative and present the daily records for the preceding week. If the Contractor's records indicate costs greater than those kept by the Oepartnent, the Oepartnent will present its records to the Contractor. The Contractor shall notify the Engineer within three ( 3) work days of any inaccuracies noted in, or disagreements with, the Department's records. Refusal or repeated failure by the Contractor to attend these weekly rreetings and present its records will constitute a waiver by the Contractor of any ct>jectioos as to the accuracy of the Departnent 's records. \ohm the Contractor makes an ct>jectioo as to the accuracy of the Department 1 S records, the Engineer shall review the matter, and correct any inaccuracies he finds in the Depart:Jrent 1 s records. For purposes of carputing delay damages, the Department 1 s records will control.
In the event the Contractor wishes to contest the accuracy of the Department 1 s records, it may file a petitioo pursuant to Rule 672-1-.05 of the Official Rules and Regulations of the Department of Transportation. 'lbe •Jecisioo of the Engineer, or, if contested, the decision of the Agency, will be final and binding upcr1 the parties as to any ct>jec:tions to the accuracy of the Department's records, subj~ct to the Contractor's right to judicial review under O.C.G.A. Sectioo SD-13-19 •
207
•
•
•
•
•
•
•
11. Ql a weekly basis after giving notice of intention to file a claiJn for delay damages, the Contractor shell prepare and sul:lnit to the Engineer written reports providing the follo4ng information:
a. Potential effect to the schedule caused by the delay.
b. Identification of all operations that have been delayed, or are to be delayed.
c. Explanation of ~ the Depart.rrent' s act or anissitrl delayed each Q?eration, and estimation of h""' much tine is requ~red to complete the project.
d. Itemization of all extra costs being incurred, including:
( 1) An explanation as to how those extra costs relate to the delay and heM they are being calculated and measured.
(2) Identification of all project etployees for whan costs are be~ng compiled.
(3) Identification of all manufacturer's mnbers of all items of equipment for which costs are being compiled •
B. Cl..AIMS FOR ACCEI...ERATIOO:
The Depart.rrent shall have no liability for any constructive accelerat~on. If the Departnent gives express written direct~on for the Contractor to accelerate its effort, then both parties shall execute a Supplemental Agreement as prov~ded in SUb-Section 104.03 •
c.
1. In any case in which the Contractor believes that it will be entitled to additional carpensation for reasons other than delay or acceleration, the Contractor shall notify the Engineer in writing of its intent to clail'l'l such additional compensation before beg~nning or proceeding further with the t-brk out of which such claim arises. 1f such notihcaticn is not given, then the Contractor hereby agrees that it shall have waived any additional catpensation for that work and the Contractor shall have no claim thereto •
2. 'lhe liability of the Oepartnent for such claims shall be limited to those items of damages which are specifically identified as payable in connection with delay clail'l'ls as set forth in Sub-Section 105.13.A.6. For such claims, the Departnent will have no liability for those items of damages identified as not payable in connection with delay claims as set forth in SUb-Section 105.13.A.8 •
208
•
•
•
•
•
•
•
•
•
•
•
D. ~ c:.-annn'S OF CIAIMS: All claims nust. be sul::rnitted in writing, and must be sufficient in detail to enable the Engineer to ascertain the basis and the 810Unt of each claim. All informatioo sul:rnitted to the Department under this Sub-Sectioo will be used solely for analyzing and/or resolving the claim. At a mini.nun, the follc:wi.ng informatioo must be provided:
l.
2.
FOR OEI;.Y CLAIMS:
a. A description of the ~rations that were delayed, the reasons for the delay, hoN they were delayed, including the report of all scheduling experts or ot.her consultants, if aTJy.
b. An as-built chart, CPM schere or other diagram depicting in graphic form ~· the operations were adversely affected.
c. 'nle date on which actions resulting in the claim occurred or con~tions resulting in the cla~ became evident.
d. A copy of the "Not.ice of Potential Clailn" filed for the specifl.c clailn by the Contractor.
e. 'nle narre, function, and activity of each Oepartnent official, or errployee, involved in, or knowledgeable about facts that gave rise to such claim.
f. 'nle name, function, and activity of each Contractor or Subcontractor official, or E!lplO.yee, involved in, or knowledgeable about facts that gave rise to such claim .
g. 'nle identification of any pertinent d:ctm:mts, and the substance of any material oral communication relating to such claim.
h. A statenent as to \ltlether the aaditional catpensation or extension of tine sought is based oo the provisions of the Contract or an alleged breach of Contract.
i. '!he arrount of additiooal carpensatioo sought and a break-bm of that amount into the categories specified as payable under Sub-Sectioo 105.13.A.6. above •
j. If an extension of tinE is also sought, the specific days for which it is sought and the basis for such request.
FOR cmiER ClAIMS:
a. A detailed factual staterrent of the claim providing all necessary dates, locations and itE!!n'S of work affected by the claim.
b. 'l'he date on which ac-tioos resulting in the claim occurred or conditions resulting in the claim became evident •
209
•
•
•
•
•
c. A copy of the "Notice of Potential Claim" filed for the specific claim by the Caltractor pursuant to this Sub-Section.
d. 'Ihe nane, function, and activity of each Departnent official, or enployee, involved in, or knCJWledgeable about facts that gave rise to such claim.
e. The narre, function, and activity of each Contractor or Subcontractor official, or etployee, involved in, or kn~·ledgeable about facts that gave rise to such claim.
f. The speciflc provisions of the Contract wtuch support the cla.l.rn, and a staterrent of the reasons why such provisions support the claim.
g. The identification of any pertinent c:bc\.m'ents, and the substance of any material oral camunications relating to such claim.
h. A statement as to whether the additional catpensation or extension of tine sought is based on the provisions of the Contract or an alleged breach of Contract.
i. If an extension of tine is also sought, the specific days for wh1ch it is sought and the basis for such claim as determined by an analysis of the construction schedule.
j . The am:>unt of additional catpensation sought and a breakdown of that arrount into the categories specified as payable under Sub-Section 105.13.A.6. above.
E. JIDJUIRED CERTIFICATIOO OF ClAIMS: When sutrnitting the claim, the Contractor must certify in writing, under oath in accordance with the formalities required by Georgia law, as to the following:
1. 'Ihat the claim is made in CJOOd faith.
2. 'Ihat supportive data are accurate and carplete to the Contractor's best knCJWledge and belief.
3. 'Ihat the anount of the claim accurately reflects what the Contractor in good faith believes to be the De~'s liability.
The Contractor shall use the CERTIFICATE OF c::::IAI.M form, which can be obtained fran the Department, in carplying with these requirenents •
F. AUDITIKi OF CI.J\IMS: All claims filed against the Department shall be subject to audit at any t~ following the filing of such claim, whether or not such claim is part of a suit pending in the courts of this State. The audit may be performed by enployees of the Oepartrrent or by an independent auditor appointed by the OepartJrent.. "lbe audi. t may begin on ten days notice to the Contractor, Subcontractor, ar Supplier. 'l'he taltractor, Subcontractor, or Supplier shall make a good faith effort. to cooperate with the auditors. Failure of the
210
•
•
•
•
•
•
•
•
•
•
•
Contraetor, Subcontraetor, or SUpplier to maintain and retain sufficient records to allON the Departnent 1 s auditor to verify the claiJn shall constitute a waiver of that portioo of such claim that cannot be verified and shall bar recover thereunder.
Wlthout. limiting the generality of the foregoing, and as a mini.nun, the auditors·shall have available to them the following documents:
l. Daily tirre sheets and foreman's daily reports.
2. Union agreements, if any.
3. Insurance, ~lfare, and benefits records .
4. Payroll register.
5. Earnings records.
6. Payroll tax returns .
7. Material invoices, purchase orders, and all material and supply acquisitlon contracts.
8. Material cost distribution worksheet.
9. Equipnent records (list of ccrrpany equipnent, rates, etc.)
10. Vendor rental agreerents, and subcont.r actor invoices.
11. Subcontractor payment certificates.
12. cancelled checks (payroll and vend::>rs ) •
13. Joo cost report.
14. Job payroll ledger •
15. General ledger, general journal, (if used) and all subsidiary ledgers and journals together with all supporting d::x:=lJl'lentatioo pertinent to entries made in these ledgers and journals.
16. Cash Disbursements journal •
17. Financial statements for all years reflecting the operations oo this project.
18. Incate tax returns for all years reflecting the operations oo this project •
19. Depreciation records oo all catpany equi~t whether such records are mal.ntained by the catpany involved, its accountant, ar others.
20. If a source other than depreciatioo records is used to develop costs for the Contractor 1 s internal p.lrpOSeS in establishing the actual cost of owning and operating equ.i.ptent, all such other source drx\lnents.
211
•
•
•
•
•
•
I •
•
•
•
•
21. All doc\ments which reflect the Contractor's actual profit and overhead during the years this Project was t:.eing perforned and for each of the five years prior to the camencenent of this Project.
22. All docurrents related to the preparatioo of the Contractor's bid· including the final calculations on which the bid was based unless such docurrents are placed in escrow under other provisions of the Contract.
23. All documents which relate to each and every claim together with all documents which support the arrount of damages as to each claim .
24. W::>rksheets used components for items labor, l::.enefi ts subcontractors, and periods, ~ndividuals individuals.
to pre?are the cla:iln establishing the cost of the claim includl.ng, but not limited to, and insurance, rraterials, equiptent, all documents which establish the time involved, the h:>urs and the rates for the
G. Rn1EDIES EXCLUSIVE: The parties agree that the Depa.rtnent shall have no liability to the Contractor for expenses, costs, or items of da.'Tiage other than those which are specifically identified as payable under this Sub-Section. In the event any legal act.1on is instituted aga~nst the Departrrent by the Contractor on account of any claim for add.l tional cc:rrpensation, whether on account of delay, acceleration, breach of contract, or otherwise, the Contractor agrees that the De?art.nent 's liability will t:.e limited to th:>se items which are spec~f1cally identified as payable ~ this Sub-Section •
212