Date post: | 19-Feb-2018 |
Category: |
Documents |
Upload: | asif-hameed |
View: | 223 times |
Download: | 1 times |
of 53
7/23/2019 Fidic Assignment Final
1/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
Submitted To:
Dr. Hadikusumo
Submitted By:
Suyog Krishna Shrestha (115573)
Takehiko Yamaji (115663)
Deeptara Luitel (115564)
Muhammad Afzal (115659)
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK)
1999 EDITION
LEGAL & CONTRATUAL RISK MANAGEMNT
7/23/2019 Fidic Assignment Final
2/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
Table of Contents
1.0 Introduction:.............................................................................................................................. 12.0 Management of the project risks by FIDIC:............................................................................. 1
2.1 Project Time:......................................................................................................................... 1
2.2 Project Cost:.......................................................................................................................... 6
2.3 Project Quality:................................................................................................................... 10
2.4 Project Safety:..................................................................................................................... 13
3.0 Project Risks of OWNER (How he can manage them): ........................................................... 14
4.0 Project Risks of CONTRACTOR (How he can manage them): ................................................. 18
4.0 FIDIC Timeline: ........................................................................................................................ 30
5.0 Claim, Suspension and Termination by the Contractor: ......................................................... 30
5.0 Claim, Suspension and Termination by the Contractor: ......................................................... 35
6.0 Clauses that can allow contractor to demand EOT/Additional Payment: .............................. 40
7.0 Conclusion: .............................................................................................................................. 41
Appendix I ..................................................................................................................................... 42
7/23/2019 Fidic Assignment Final
3/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
1
1.0 Introduction:
FIDIC (Fdration Internationale des Ingnieurs Conseils) is an international
organization developed the brief and practical contract types for the international projects. FIDICRed book refers to the general conditions of contract for construction. In order to change/modify
any of the condition in the general conditions of FIDIC based of the specific conditions of the
project, we need to document that in the supplementary conditions of the contract.
In the following part of this report, we have tried to analyze the project risks based on
various perspective such as time, cost, owner, contractor as documented in the general conditions
of the contract of FIDIC RED BOOK (1999 Edition) etc. The analysis is in form of Questions as
stated below.
2.0 Management of the project risks by FIDIC:
FIDIC general conditions of contract provide the structure and guidelines to manage
project risks from various perspectives. Below is the detail of the respective clauses and
explanation of how the document is managing those particular risks.
2.1 Project Time:
MANAGEMENT OF PROJECT RISK BY FIDIC
TIME
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
1 1.1 Definitions
Most of the terms defined are related with time for
example. The contract, commencement date should
be taken into account to make it on specified time.
2 1.2 InterpretationIt should be mentioned very clearly in the contract
during providing conditions.
7/23/2019 Fidic Assignment Final
4/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
2
MANAGEMENT OF PROJECT RISK BY FIDIC
TIME
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
3 1.3 CommunicationsFor the approvals, certificates not to be delayed,
communications must be made out by in writing or
delivered by hand, or sent by email or courier
4 1.4 Law and languageThe language for communications shall be that stated
in the Appendix to Tender.
5 1.5Priority of
documents
The documents should be in proper sequence i.e. The
contract agreement, letter of acceptance, letter of
tender ,the particular conditions, etc.
6 1.6 Contract agreementThe parties should go for contract agreement within
28 days after the Letter of acceptance is awarded.
7 1.9Delayed drawings or
Instructions
The contractor should give notice to the engineer for
the extension of time for any delays concerning the
drawings and cost within the time
8Permits, Licenses or
Approvals
And payment of any cost plus reasonable profit.
2.2
The contractor should be provided reasonable
assistance in getting copies of Laws of the country
relevant to the contract and also provided
Permits, licenses or approvals for delivery of goods
and export of contractorsequipment from site.
9 3.5 Determination
For variation that has been made, then the engineer
will make the determination, whether to approve or
disapprove, where the determination
10 Site data Is binding, unless it is revised by DAB procedure.
7/23/2019 Fidic Assignment Final
5/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
3
MANAGEMENT OF PROJECT RISK BY FIDIC
TIME
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
4.1OThe contractor should inspect the site and collect thedata required before submitting the tender including
all the form and nature of site
Including sub-surface conditions, hydrological
conditions, laws and labor practices of the country
and other contractorsrequirements.
11 4.16 Transport of goods The contractor should prepare material deliveryschedule and submit to the engineer so that he couldcheck the material delivery on site.
12 4.17Contractor's
Equipments
For the mobilization of the equipment, the contractor
needs the engineer's approval so that after use, it can
be removed from the site.
13 4.20Employers
Equipment and
Free Issue Material
Any substandard material supplied for the work and
made use of might negate the original design of theproject. This could lead to failure of the project on
completion. So, standard materials as specified in the
design must be purchased and applied.
14 4.24 Fossils
The artifacts should be removed by the owner
through diplomatic arrangement with the community
to remove them or otherwise to make way for the
contract or to do his work. This done timely will go a
long way to check delay in the execution of work.
7/23/2019 Fidic Assignment Final
6/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
4
MANAGEMENT OF PROJECT RISK BY FIDIC
TIME
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
15 7.3 Inspection
Based on the specification of the designed project,
the monitoring or time to time inspection of the work
with guarantee the job or work being alone according
to the designed standard.
16 7.4 Testing
Contractor should review testing method and
standard in specification or in condition of contract if
they fail to pass test on completion
17 7.5 Rejection
The Engineers duty amongst others is to ensure the
contractor complies and carry out the project
execution according to specification and schedule.
18 7.6 Remedial Work
There should be good relationship between the
client/owner, the Contractor, the Sub-Contractor and
the nominated Sub-contractor
19 8.1Commencement of
Works
The owner in agreement with his Project Engineer on
verification of claims by the Contractor should reach
away forward on time so as to avoid delay in the
work execution.
20 8.3 Program
Contractor should ask for time extension before the
validity period expires. Providing detail explanation to
engineer/owner.
21 8.4Extension of Time
for Completion
Any Circumstances that could lead to extension of
time must be notified within 28 days in writing to the
Engineer who then act within a reasonable time. The
extension of time must be avoided by owner to avoid
the delay in completion.
7/23/2019 Fidic Assignment Final
7/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
5
MANAGEMENT OF PROJECT RISK BY FIDIC
TIME
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
If the access road Is the problem it should benegotiated and provided early enough by the owner
before the commencement of the work; Natural
occurrence is not the fault of either and should be
integrated in the plan.
Variation in design may cause extension of time if
agreed upon by the contractor and the owner.
22 8.7 Delay Damages
Where there is friction, the work can suffer a setback
time wise. This situation can be arrested by mutual
understanding engendered by the Engineer or and
23 8.8 Suspension of Work
The owner as much as possible should avoid a
situation such as this. The consequence of this act
leads to extension of time to which the contractor
can claim.
24 8.9Consequences of
Suspension
The project owner being conscious of the
consequences of acts that could lead to termination
of contract is to avoid it. An amicable resolution of
any issue in the contract terms can be a way out of
the situation. The cost of termination of contract can
be more costly than retendering for completion of
the project.
25 8.10
Payment for Plant
and Materials in
Event of Suspension
The payment issue is sensitive and therefore theproject owner should employ every possible means
to ensure that the contractor is settled so as not to
degenerate to suspension
7/23/2019 Fidic Assignment Final
8/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
6
MANAGEMENT OF PROJECT RISK BY FIDIC
TIME
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
26 8.11Prolonged
Suspension
The project owner, with a good understanding can
settle this claim amicably with the contractor. He may
not allow it out of hand. The two parties could
negotiate unless otherwise, there will be more
dispute and delay.
27 10.1Taking Over of the
Works and Sections
Taking over by the employer is a critical phase as
defect notification period starts and responsibility of
the facility is being transferred to the employer bythis certificate. It is a critical point of potential claims
if could not handle properly. Fiddich entails this
clause with specific procedure, dates and deadlines
to manage the risks.
2.2 Project Cost:
MANAGEMENT OF PROJECT RISK BY FIDIC
Cost
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
1 1.1 Definitions
Few terms related with cost for example, tendering, bill
of quantities, variation, money and payment should be
taken into consideration.
2 1.7 Assignment Either party may, as security in favor of a bank orfinancial institution, assign its right to any moneys due,
or to become due, under contract.
7/23/2019 Fidic Assignment Final
9/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
7
MANAGEMENT OF PROJECT RISK BY FIDIC
Cost
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
3 1.1OEmployer's Use of
Contractor's
Documents
The contractor should give the employer a non-
terminable transferable non-exclusive royalty-free
license to copy, use and communicate the
4 1.12 Confidential details
Contractorsdocuments including modifications.
The contractor should disclose all confidential to verify
the compliance with the contract.
5 1.13Compliance with
laws
The contractor should give the notice regarding allpayments of taxes, duties and fees and obtain all
permits, licenses and approvals
As required by the laws in relation to the execution and
completion of the works and remedying of the any
defects.
6 1.14Joint and Several
liabilityIf partner cannot finish, then engineer should be able
to take the responsibility in case of joint venture.
7 2.1 Right of Access toSite
Before contractor enters the site, he must submit
performance bond about 10% to prevent the delay of
the works.
8 2.4Employer's financial
arrangementReasonable evidence regarding financial arrangements
should be made out to pay contract price and should
be submitted within 28 days.
9 2.5 Employer's claims
After receiving any request from the contractor and
contractor should always be aware of the financial
status of his contract.
The contractor should be informed by the employer
after he finds any even and any circumstances so that
engineer could make determination.
7/23/2019 Fidic Assignment Final
10/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
8
MANAGEMENT OF PROJECT RISK BY FIDIC
Cost
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
And the notice is related with the extension of the
Defects Notification Period that is made before expiry
of such period.
10 3.2Delegation by the
EngineerContractor should clarify with the engineer in some
communications about the claim and the Interim
payment certificate.
11 4.2Performance
SecurityContractor need to buy this bond as insurance to make
sure for the commitment by the contractor to the
works.
12 4.5
Assignment of
benefits of
subcontract
Once the benefit gets transferred to owner, then
responsibility directly goes to owner for material
supply equipment operation.
13 4.6 Cooperation Contractor must identify the price of cooperation orcan be taken as an instruction if not mentioned in the
contract.
14 4.12Unforeseeable
physical conditions
The experienced contractor, during the period of
tender, should consider these unforeseeable
conditions and should notify the engineer within 28
days.
15 4.13Rights of way and
facilitiesContractor should find additional ways to access to the
site and use the other areas not provided and specified
by owner.
16 4.24 Fossils
When fossils, coins, antiquity or archeological artifacts
are found, the owner, on report by the contractor, acts
immediately to avoid delay.
7/23/2019 Fidic Assignment Final
11/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
9
MANAGEMENT OF PROJECT RISK BY FIDIC
Cost
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
17 7.3 Inspection
To ensure quality work, the ownersstaff shall at all
reasonable times have full access to the site for which
the Project is going on. The contractor shall give the
owners personnel full opportunity to carry out their
assigned duties without hindrance.
18 7.4 Testing
Review testing method and standard in specification or
in condition of contract.
19 7.5 Rejection
The contractor has to establish the quality insurance
system in his company to control the quality of work.
20 8.7 Delay Damages
The system monitored shall assist in the desired quality
work and should be audited from time to time.
21 8.9Consequences of
Suspension
Conduct site visit before tendering to gather as much
information as possible about site condition.
Contractor should incorporate such conditions in
contract and to have good comparison later when such
conditions are encountered.
22 8.10
Payment for Plant
and Materials in
Event of Suspension
The detail report on why the payment is delayed
should be given to contractor.eg.it is because of the
unsatisfactory work and part of payment is delayed
until rework is carried out
23 9.4Failure to Pass Tests
on Completion
The failure of test has additional cost and delay risk,
folic managed the risk as to specify the party
(contractor, if under his responsibility) liable of
repeating the test until successful or the contract price
can be reduced to cover reduced value to the
employer.
7/23/2019 Fidic Assignment Final
12/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
10
MANAGEMENT OF PROJECT RISK BY FIDIC
Cost
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
24 12.3 EvaluationThere is a risk for the deciding the quantity and price
for the item of work, folic guides to decide those.
Moreover, it guides on the items of work not specified
in the contract.
2.3 Project Quality:
MANAGEMENT OF PROJECT RISK BY FIDIC
QUALITY
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
1 1.1 DefinitionsTerm related with quality egotist after completion is
carried out according to the particulate conditions.
2 1.8Care and Supply of
documents
The contractor shall keep the copy of contract
documents on the site, named Specification and the
drawings and the specifications should be in custody
and care of the employer.
3 1.11
Contractor's use of
Employer's
Documents
The employers shall retain the copyright and the
intellectual property rights in the Specification, the
drawings and other documents made by the
Employer.
4 3.1Engineer's Duties and
Authority
The engineer has the right to issue variations which
may include omissions i.e. Cancellation of the works.
5 3.3Instructions of the
Engineer
If the contractor should solve the matter regarding
the additional costs due to instruction with the
engineer and if not possible, then the contractor
should send a claim notice, and the instruction should
not be given directly to the contractor or
subcontractor.
7/23/2019 Fidic Assignment Final
13/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
11
MANAGEMENT OF PROJECT RISK BY FIDIC
QUALITY
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
6 3.4Replacement of the
engineer
To replace the engineer, not less than 42 days,employer should give the notice to the contractor,
with supporting particulars.
7 4.3Contractor's
representative
Contractor should appoint the representative on site
who is fluent in the language mentioned in the
contract.
8 4.4 SubcontractorsThe contractor and the subcontractor should transfer
their benefits to the owner.
9 4.7 Setting out
Contractor is responsible for setting out work like
positioning, dimensioning of all parts of the works ND
also should rectify them and if errors occurs, then
should notify to the engineers so that he may ask for
the additional payment and time.
10 4.9 Quality assurance
The contractor must develop quality manual and plan
and Audit should be carried out by engineer or should
be mentioned in particular conditions.
11 4.11
Sufficiency of the
accepted contract
amount
The contactor must fulfil all the requirements so that
the correctness and the sufficiency of the accepted
contract amount can be easily met.
12 4.20
Employers
Equipment and Free
Issue Material
Quality of materials and equipment supplied must be
gauged each by the unit cost (Price) and agreed by
the engineer. The BOQ is used as part of quality
performance Qualitative and cost effective material
are pointer to the quality of work.
13 4.21 Progress ReportsThe monthly report properly guided would help in the
desired quality control for greater performance.
14 6.8Contractor's
Superintendence
Implement method statement and quality insurance
system very strictly.
7/23/2019 Fidic Assignment Final
14/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
12
MANAGEMENT OF PROJECT RISK BY FIDIC
QUALITY
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
15 6.9Contractors
Personnel
Having experienced and committed team members.Having work method statement for each work and
executing work under supervisor.
16 7.2 Samples
The Engineer shall instruct the Contractor submit
Testing Plan for all project. The Contractor has to
submit Testing document that including testing
method/ procedure, standard, form for the Engineer
consideration before testing. The Engineer has to
check progress of work.
17 7.3 Inspection
It is suggested that the quality of work being done is
being gauged through inspection beginning from
materials used and the skills employed. The
inspection report should guide the contractor and
sub-contractor.
18 7.4 Testing
Contractor should review testing method and
standard in specification or in condition of contract if
they fail to pass test on completion
19 7.5 Rejection
The Engineer has to instruct the Contractor submit
shop drawing by compare drawing with survey data
of construction site for approval before starting.
20 11.1
Completion of
Outstanding Work
and Remedying
Defects
This clause clearly makes contractor liable for the
works remaining and the repair of the works of poor
quality. So, the risks of re-work will make the
contractor to maintain his quality during the
execution of the work.
7/23/2019 Fidic Assignment Final
15/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
13
2.4 Project Safety:
MANAGEMENT OF PROJECT RISK BY FIDIC
SAFETY
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
1 2.3 Employer's PersonnelSafety procedures and Protection of the environment
is required.
2 4.1 Contractor's Obligations
The contractor should be responsible for all
contactors documents, temporary works and design
of each plant and materials to be accordance within
the contract and should be able to take responsibilityfor adequacy, stability and safety of all Site
operations.
3 4.8 Safety proceduresThe contractor should be responsible for all
contactors documents, temporary works and design
of each plant and materials to be accordance
temporary works like fencing, guarding etc. So, need
to make safety manual and safety plan.
5 4.15 Access Routes
As government has restrictions for allowance of size
of vehicles passing the roads and the bridges, so the
contractor must consider these things in tendering
and if in case, any damages occurs, then contractor
himself has to handle these problems related with the
local authority.
6 4.21 Progress Reports
Investigation productive in project. Revise scheduling
of project. Make details planning of critical works.
7/23/2019 Fidic Assignment Final
16/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
14
MANAGEMENT OF PROJECT RISK BY FIDIC
SAFETY
S.No. CLAUSE No. CLAUSE RISK MANAGEMENT
7 6.7 Health and safety
The Engineer shall instruct the Contractor submit
Safety Plan for all project. The Contractor has to
submit Safety document that including Safety
method/ procedure, standard, form for the Engineer
consideration. The Engineer has to check progress of
work for consideration whether the Contractor can
Safety Plan is efficient or not. Arrange site meeting to
monitoring status of Safety and construction
progress.
8 7.3 Inspection Making testing plan and submit to the Engineer.
Review testing method and standard in specification
or in condition of contract
3.0 Project Risks of OWNER (How he can manage them):
The Following table shows the risks borne by the owner according to FIDIC and
suggestions to manage these risks.
RISK ON PARTIES (FOR OWNER)
S.No. CLAUSE No. CLAUSE RISK FOR OWNER RISK CONTROL
1 1.1 DefinitionsRisk related with contract
price, site ,etc.
These terms should be
clearly stated in the
contract as the
responsibility for running
works on site and the cost
related to owner.
7/23/2019 Fidic Assignment Final
17/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
15
RISK ON PARTIES (FOR OWNER)
S.No. CLAUSE No. CLAUSE RISK FOR OWNER RISK CONTROL
2 1.2 Interpretation
Risk related with different
terms like 'Agreement,
Written or in writing etc.
The marginal words and
other headings shall not be
taken into consideration in
the interpretation of these
conditions.
3 1.6Contract
agreement
Risk related with the time,
cost ,quality and safety
The contract agreement
should be done within 28
days after contractor
receives the LOA and the
contract agreement shall
be based upon the form
annexed to the particular
conditions.
4 2.1Right of access to
the siteRisk of delay
The owner shall give the
contractor right of access
to the site stated in
appendix to tender.
5 2.2Permits, licenses
or approvalsRisk of compliance
The employers shall
provide assistance to
contractor by obtaining
copies of laws of country
for delivery of good s and
export of contractors
equipment when removed
from the site.
6 2.3Employer's
Personnel
Risk related with safety
procedures and protection
of environment
The employer should
ensure the personnel and
other contractors on the
site (cooperation).
7 2.4
Employer's
Financial
arrangement
Risk of suspension and
termination
The employer should
submit within 28 days after
receiving any request from
the contractor with
detailed particulars.
8 4.5
Assignment of
benefits of
subcontract
Risk of risk transfer
Once the benefit gets
transferred to owner, all
the responsibility goes to
the owner.
7/23/2019 Fidic Assignment Final
18/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
16
RISK ON PARTIES (FOR OWNER)
S.No. CLAUSE No. CLAUSE RISK FOR OWNER RISK CONTROL
9 4.7 Setting out Risk of claim by contractor
Because of delay of
specified items, the
contractor will claim andafter getting the notice,
engineer should go
through sub clause
3.5(determination) to
agree or determine.
10 4.12
unforeseeable
physical
conditions
Risk of claim by contractor
The owner should set out
the reasons why
contractors considers them
to be unforeseeable
11 4.17Contractor's
equipmentRisk of claim by contractor
For the mobilization of
equipment after use, theconsent is needed from
engineer and if delay
occurs in providing
consent, then contractor
will claim.
12 4.20
Employers
Equipment and
Free Issue
Material
The Employer shall, at his
risk and cost provide these
materials at the time and
place specified in the
Contract
Enforcing the engineers
to get all the necessary
permits approved before
the work commence at
the site.
13 4.24 Fossils
Contractors Claims (a) anextension of time for
completion (b) payment of
any such Cost plus
reasonable profit
Detail survey of the site to
check if such ground
condition exists all over or
just in a single spot.
14 7.4 Testing
Contractors Claims (a) an
extension of time for
completion (b) payment of
any such Cost plus
reasonable profit
Define clearly the liability
of Test on Completion in
contract.
15 7.6 Remedial Work
The Employer shall be
entitled to employ and payother persons to carry out
the work
Conduct a check list of
all the activities to beperformed before the
signing the contract.
16 8.4Extension of Time
for Completion
Contractors Claims for an
extension of time for
completion
Enforcing contractor to
prepare shop-drawing and
getting approved before
every construction
7/23/2019 Fidic Assignment Final
19/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
17
RISK ON PARTIES (FOR OWNER)
S.No. CLAUSE No. CLAUSE RISK FOR OWNER RISK CONTROL
Having good relation and
regular communication
with the consultant is vital.Work as per the
specification and approved
drawings
17 8.8Suspension of
Work
Contractors Claims (a) an
extension of time for
completion (b) payment of
any such Cost plus
reasonable profit
Owners Should have
evidence like pictures, test
report before suspending
the work.
18 8.9
Consequences of
Suspension
Contractors Claims (a) an
extension of time for
completion (b) payment ofany such Cost plus
reasonable profit
Owners Should have
evidence like pictures, test
report before suspendingthe work.
19 14.11
Application for
Final Payment
Certificate
After the application, owner
has to take the responsibility
of the product in spite of the
detection of deterioration.
Owner should force the
engineer to confirm the
value of all work done in
accordance with the
contract.
20 14.15Currencies of
Payment
If the exchange rate
negatively changes, actual
payment become bigger
than contract price
Using bank consulting,
appropriate insurance
should be applied.
21 17.3 Employer's Risks
In the stated particular
conditions, owner has to
care the damage from the
issue.
Appropriate insurance is
necessary. Additionally, if
the foretaste is found,
owner should make the
decision how to treat the
issue as soon as possible.
22 18.2
Insurance for
Works and
Contractor's
Equipment
Insurance has the exclusion
statement. If the causing loss
or damage is classified
exclusion, owner has to
discuss with contractor whoshould indemnify.
By using particular
condition, how to
indemnify should be
decided in the contract.
23 19.4Consequences of
Force Majeure
In the stated particular
conditions, owner has to
care the damage from the
issue.
Appropriate insurance is
necessary. Additionally, if
the foretaste is found,
owner should make the
decision how to treat the
issue as soon as possible.
7/23/2019 Fidic Assignment Final
20/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
18
RISK ON PARTIES (FOR OWNER)
S.No. CLAUSE No. CLAUSE RISK FOR OWNER RISK CONTROL
24 20.6 Arbitration
If dispute is judged by
arbitration, owner must
receive any result. And it
becomes the final result.
At first, owner should
mitigate the predictable
risk in the contract. Andafter contracting, owner
should monitor the project
risk. And once problems
and risks causing, owner
should make decision
quickly with
communicating with
stakeholders.
4.0 Project Risks of CONTRACTOR (How he can manage them):
The Following table shows the risks borne by the contractor according to FIDIC and suggestions
to manage these risks.
RISK ON PARTIES (CONTRACTOR)
S.No.CLAUSE
No.CLAUSE RISK FOR CONTRACTOR RISK CONTROL
1 1.1 Definitions
Risk related with the variation,
materials, temporary
worksheet.
The contractor
should carry out
these works so
clearly mentioned
in the contract.
2 1.2 Interpretation
Risk related with different
terms like 'Agreement,
Written or in writing' etc.
The marginal
words and other
headings shall not
be taken into
consideration in
the interpretation
of theseconditions.
3 1.3 Communication
Risk related with issuing
approval, certificates,
consents and determination.
The notice should
be sent by email or
delivered by hand,
courier or other
reliable medium to
prevent delay.
7/23/2019 Fidic Assignment Final
21/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
19
RISK ON PARTIES (CONTRACTOR)
S.No.CLAUSE
No.CLAUSE RISK FOR CONTRACTOR RISK CONTROL
4 1.4 Law and languageRisk related with thecommunication
It should be
according to whathas been stated in
the Appendix to
the tender.
5 1.5 Priority of documents Risk related with the delay
To avoid delay, the
documents should
be in the proper
sequence for the
purpose of
interpretation and
if any ambiguity or
difference found,
then instruction
should be issued
by the engineer.
6 1.6 contract agreementRisk related with the time,
cost ,quality and safety
The contract
agreement should
be done within 28
days after
contractor
receives the LOA
and the contract
agreement shall
be based upon theform annexed to
the particular
conditions.
7 1.7 Assignment Risk related with bankruptcy
If both parties
agree, then
another
subcontractor can
be assigned.
8 1.8Care and supply of
documentsRisk with the specification
The contractor
shall keep on the
site the copy ofdocuments so that
employer's
personnel can see
these documents
at all reasonable
times and check
the variations and
specifications.
7/23/2019 Fidic Assignment Final
22/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
20
RISK ON PARTIES (CONTRACTOR)
S.No.CLAUSE
No.CLAUSE RISK FOR CONTRACTOR RISK CONTROL
9 1.9Delayed Drawings or
Instructions
Risk with the delay of works
or disruption
The contractor
should give noticeto engineer if any
necessary drawing
or instructions is
not issued.
10 1.12 Confidential DetailsRisk with the compliance of
contractor with contract
The contractor
shall disclose all
such confidential
and other
information as the
engineer.
11 1.13 Compliance with the lawsRisk in performing the
contract
The contractor
should comply
with applicable
laws otherwise
contractor shall
give notice, pay all
taxes, duties and
obtain license and
approvals for
execution and
completion of the
works.
12 1.14 joint and several liability Risk with legal status
The contractorshall not alter his
composition or
legal status
without prior
consent of the
employer.
13 2.5 Employer's Claim Risk of claim
The contractor will
be noticed by the
employer after any
circumstances or
event is found.
7/23/2019 Fidic Assignment Final
23/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
21
RISK ON PARTIES (CONTRACTOR)
S.No.CLAUSE
No.CLAUSE RISK FOR CONTRACTOR RISK CONTROL
14 4.1 Contractor's obligations Risk related with works
The contract must
follow what has beenstated in contract,
responsibility of
adequacy, stability and
safety of all site
operations should
submit all details of all
arrangements and
method of execution.
15 4.2 Performance security Risk of claim
Performance
security is
required by owner
as a risk control to
ensure contractor
will perform the
contract.
16 4.4 SubcontractorRisk of termination by
employer
The contractor is
required to obtain
prior consent of
the engineer to
subcontract parts
of the works.
17 4.6 Cooperation Risk of price variation
The Contractor
must identify the
price ofcooperation.
18 4.8 Safety proceduresRisk of obtaining taking over
certificate
The contractor
needs to make
safety manual and
project safety plan
that comply with
govt. safety
regulation.
19 4.1O Site data Risk of claim
The contractor
should provide all
the datasrequiredwhile executing
site works, also
mention site
conditions
,geography etc.
7/23/2019 Fidic Assignment Final
24/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
22
RISK ON PARTIES (CONTRACTOR)
S.No.CLAUSE
No.CLAUSE RISK FOR CONTRACTOR RISK CONTROL
20 4.14 Avoidance of interference Risk for damages and losses
The contractor
should not disturbthe convenience of
public and must
negotiate with
local authority.
21 4.16 transport of goodRisk of claims arising from the
transport
The contractor
should prepare
and update
material delivery
schedule and that
schedule must be
submitted to the
engineer.
22 4.19 Electricity, Water and Gas
The Contractor shall, at his
risk and cost, provide any
apparatus necessary for his
use of these services and for
measuring the quantities
consumed.
Conduct site visit
before tendering
to gather as much
information as
possible about site
condition.
Contractor should
incorporate such
conditions in
contract and to
have goodcomparison later
when such
conditions are
encountered.
23 4.20
Employers Equipment and
Free Issue Material
The Contractor shall be
responsible for each item of
Employer's Equipment whilst
any of the Contractor'sPersonnel is operating it,
driving it, directing it or in
possession or control of it
Owner/Engineer
should provide
details inspection
report if
contractor fail to
remedy defect.
Contractor shouldcheck again to
make sure it is a
fault of contractor
or some external
factors like
environment.
7/23/2019 Fidic Assignment Final
25/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
23
RISK ON PARTIES (CONTRACTOR)
S.No.CLAUSE
No.CLAUSE RISK FOR CONTRACTOR RISK CONTROL
24 6.9 Contractors Personnel
If appropriate, the
Contractor shall then appoint
(or cause to be appointed) a
suitable replacement person.
Having
experienced andcommitted team
members. Having
work method
statement for each
work and
executing work
under supervisor.
25
7.3 Inspection
If the Contractor fails togive the notice, he shall if
and when required by the
Engineer, uncover the work
and thereafter reinstate and
make good, all at the
Contractor's cost.
Contractor should
review testing
method and
standard in
specification or in
condition of
contract if they fail
to pass test on
completion
26
Implement
method statement
and quality
insurance system
very strictly.
27 7.4 Testing
The cost of carrying out this
Variation shall be borne by
the Contractor,
notwithstanding other
provisions of the Contract.
Making testing
plan and submit tothe Engineer.
Review testing
method and
standard in
specification or in
condition of
contract.
Inform the
Engineer about
incur cost and
extra time toextend the
contract if he want
additional test
which does not
follow standard in
specification.
7/23/2019 Fidic Assignment Final
26/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
24
RISK ON PARTIES (CONTRACTOR)
S.No.CLAUSE
No.CLAUSE RISK FOR CONTRACTOR RISK CONTROL
Submission Plant,
Material andWorkmanship to
the Engineer for
approval before
working.
28 7.5 Rejection
If the Engineer requires thisPlant, Materials or
workmanship to be retested,
the tests shall be repeated
under the same terms and
condition. If .the rejection
and retesting cause the
Employer to incur additional
costs, the Contractor shall
subject to Sub-Clause 2.5
[Employer's Claims] pay
these costs to the Employer.
Making testing
plan and submit to
the Engineer.
Review testing
method and
standard in
specification or in
condition of
contract.
Inform the
Engineer about
incur cost and
extra time to
extend the
contract if he want
additional test
which does not
follow standard in
specification.Submission Plant,
Material and
Workmanship to
the Engineer for
approval before
working.
29 7.6 Remedial Work
The Contractor shall comply
with the instruction within a
reasonable time, which shall
be the time (if any) specified
in the instruction, or
immediately if urgency is
specified under subparagraph
(c).
Making testing
plan and submit to
the Engineer.
Review testing
method andstandard in
specification or in
condition of
contract.
7/23/2019 Fidic Assignment Final
27/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
25
RISK ON PARTIES (CONTRACTOR)
S.No.CLAUSE
No.CLAUSE RISK FOR CONTRACTOR RISK CONTROL
Inform the
Engineer aboutincur cost and
extra time to
extend the
contract if he want
additional test
which does not
follow standard in
specification.
Submission Plant,
Material and
Workmanship to
the Engineer for
approval before
working.
30 8.4Extension of Time for
Completion
Contractors Claims for an
extension of time for
completion
Having good
relation and
regular
communication
with the
consultant is vital.
Work as per the
specification and
approveddrawings
31 8.6 Rate of Progress
Unless the Engineer notifies
otherwise, the Contractor
shall adopt these revised
methods, which may require
increases in the working
hours and/or in the numbers
of Contractors Personnel
and/or Goods, at the risk and
cost of the Contractor
Investigation
productive in
project.
Revise scheduling
of project.
Make details
planning of critical
works.
32 8.7 Delay Damages
Damages to the Employer.These delay damages shall be
the sum states in the
Appendix to Tender, which
shall be paid for every day.
However, the total amount
shall not exceed the maximum
amount of delay damages
stated in the Appendix to
Investigationproductive in
project.
Revise scheduling
of project.
Make details
planning of critical
works.
7/23/2019 Fidic Assignment Final
28/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
26
RISK ON PARTIES (CONTRACTOR)
S.No.CLAUSE
No.CLAUSE RISK FOR CONTRACTOR RISK CONTROL
Tender.
33 8.8 Suspension of Work
The Engineer may also notify
the cause foe the suspension.
If and to the extent that the
cause is notified and is the
responsibility of the
Contractor
Investigation
productive in
project.
Revise scheduling
of project.
Make details
planning of critical
works.
34 8.9Consequences of
Suspension
The Contractor shall not be
entitled to an extension of
time for, or to payment ofthe Cost incurred in, making
good the consequences of
the Contractors faulty
design, workmanship or
materials or of the
Contractors failure to
protect, store or secure in
accordance with Sub-Clause
8.8 [Suspension of Work]
Investigation
productive in
project.Revise scheduling
of project.
Make details
planning of critical
works.
35 8.10
Payment for Plant and
Materials in Event of
Suspension
The Contractor shall be
entitled to payment of the
value
Investigation
productive in
project.
Revise scheduling
of project.
Make details
planning of critical
works.
36 8.11 Prolonged Suspension
The suspension under sub-
clause 8.8, the Contractor can
request the Engineers
permission to proceed if the
suspension has continued formore than 84 days.
Investigation
productive in
project.
Revise scheduling
of project.
Make detailsplanning of critical
works.
7/23/2019 Fidic Assignment Final
29/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
27
RISK ON PARTIES (CONTRACTOR)
S.No.CLAUSE
No.CLAUSE RISK FOR CONTRACTOR RISK CONTROL
37 9.2 Delayed Tests
There is a risk of failure of the
contractor to carry out thetests in time or within 21 days
of the notice of the engineer.
If he fails, he has to bear two
consequences:
1. Bear the cost of the test
carried out by someone else
on discretion of the engineer.
2. He has to accept the results
of the test.
The contractor cancontrol the
delayed test risks
as: 1.
Preparing proper
Testing Schedule.
2. Notifying and
Conducting Tests
at Proper time.
38 11.2Cost of Remedying
Defects
According to the FIDIC,
contractor is liable to
complete outstanding and
remedying defects (Sub-clause
11.1). So, the risk and cost is
to be incurred by the
contractor for the repair and
remedying of the works.
Contractor need to
improve its
productivity, so
that the
outstanding works
can be completed
in time as well as
his workmanship
to avoid re-work
of the defects.
39 11.3Extension of Defects
Notification PeriodA risk of Employer's Claim.
Contractor should
carefully see if the
extension is due to
the suspension ofthe works by the
employer then the
liability is not on
contractor for the
delay. Contractor
need to correct
the defects within
time and at most
within defect
liability period.
40 11.4 Failure to Remedy DefectsA risk of Cost claim by the
Employer
The Contractorshould carry out
the work by
himself and if he
sense he cannot
then he should
subcontract the
work by the
approval of the
7/23/2019 Fidic Assignment Final
30/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
28
RISK ON PARTIES (CONTRACTOR)
S.No.CLAUSE
No.CLAUSE RISK FOR CONTRACTOR RISK CONTROL
Employer to avoid
the claim. (A cost-efficient option
41 14.11 Application for FinalPayment Certificate
If contractor cannot receive
the final payment certification
because of his lack, taking-
over date will be delayed. Andin the worst case, the
contractor cannot receive the
performance security.
Contractor must
prepare the
taking-over
procedure, Or if
contractor find
seriousdeterioration, as
soon as possible
they have to treat
it before taking
over.
42 14.15 Currencies of Payment
If the exchange rate
negatively changes, actual
payment become smaller than
contract price
Using bank
consulting,
appropriate
insurance should
be applied.
43 15.2 Termination by Employer
In the stated particular
conditions, contractor has the
probability of termination of
the contract.
The contractorshould understand
the clause's
particular
conditions of
termination. And
they must avoid
causing these
conditions. Good
communication
will help to get the
support of
engineer.
44 17.1 Indemnities
Before the TOC, contractor
has the responsibility of the
property. And they also have
the responsibility of the
damage of staffs.
The practice of
proper project
management
(safety
management,
construction
management and
7/23/2019 Fidic Assignment Final
31/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
29
RISK ON PARTIES (CONTRACTOR)
S.No.CLAUSE
No.CLAUSE RISK FOR CONTRACTOR RISK CONTROL
so on) will prevent
the propertydamage and
human resource
damage.
45 17.2Contractor's Care of the
Works
From the project's
commencement to TOC,
contractor has the
responsibility of thedamage/loss of works and
goods.
The practice of
proper project
management
(safety
management,
construction
management andso on) will prevent
the property
damage and
human resource
damage.
46 18.2Insurance for Works and
Contractor's Equipment
Insurance has the exclusion
statement. If the causing loss
or damage is classified
exclusion, contractor has to
discuss with owner who
should indemnify.
By using particular
condition, how to
indemnify should
be decided in the
contract.
47 19.5Force Majeure Affecting
Subcontractor
Applying force majeure to
subcontractor, constructor
must take the responsibility of
the damage/loss.
If the foretaste is
found, contractor
should make the
decision how to
treat the issue as
soon as possible.
48 20.6 Arbitration
If dispute is judged byarbitration, contractor must
receive any result. And it
becomes the final result.
At first, contractor
should mitigate
the predictable
risk in the
contract. And after
contracting,
contractor should
monitor the
project risk. And
once problems
and risks causing,
contractor should
make decision
7/23/2019 Fidic Assignment Final
32/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
30
RISK ON PARTIES (CONTRACTOR)
S.No.CLAUSE
No.CLAUSE RISK FOR CONTRACTOR RISK CONTROL
quickly with
communicatingwith owner and
engineer.
4.0 FIDIC Timeline:
Kindly refer to the Attached diagram on the proceeding page.
5.0 Claim, Suspension and Termination by the Contractor:
This portion of the document elaborates the clauses of FIDIC that can favor the
contractor to put claim, or to suspend or terminate the contract because of the action or lack of
action of the employer. The employer is in sensitive condition in these clauses and he needs to
consider these carefully. The clauses are:
7/23/2019 Fidic Assignment Final
33/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
31
CLAIM, SUSPENSION AND TERMINATION
CONTRACTOR
S.No.CLAUSE
No.CLAUSE CONSEQUENCES BEAR BY CONTRACTOR
WHAT NEED TO BE DONE BY PROJECT
OWNER
1 1.9
Delayed
drawings or
Instructions
Claim by a contractor. The contractor
should give notice to engineer if works
likely to be delayed if any necessary
drawings and instructions get delayed.
Itsbecause of the failure of engineer to
provide notified drawings. So,
contractor will claim for extension of
time plus additional amount of
contractor will claim for extension of
time plus additional amount of
reasonable profit.Subclause-20.1
After receiving the notice, these matters
should be determined and agreed.
2 2.1Right of
access to site
Claim by contractor The employer shall
give right of access to the site to
contractor to proceed in accordance
with the programme. But if contractor
suffer or incurs cost, then contractor will
claim for EOT plus additional amount of
reasonable profit.
After receiving the notice, it must be
preceded in accordance with Sub clause
(determination) to agree or to determin
these matters.
3 4.7 Setting out
Claim by contractor for the extension of
time for any kind of delay plus
additional amount of reasonable profit
that one should be included in the
contract price.
After receiving this notice, it should be
preceded in accordance with sub clause
(determination) to agree or to determinthese matters.
4 4.12
Unforeseeable
physical
conditions
Claim by contractor after the contractor
encounters adverse physical conditions,
obstructions etc. Claim is for EOT plus
additional payment.
The engineer shall set out the reasons
why the contractor considers it as
unfired seeable.
5 8.4Extension of
Time for
Completion
Claim for additional pay mint
Error in design may entitle
Contractor to claim time/money
Extension of time (EOT) available
for a variation, delay or impediment
of the Employer, exceptionally, adverseweather conditions, shortages of goods
or personnel.
On a project-financed deal, the
Employer and Funder/Sponsor usually
require the deletion of these EOT rights.
7/23/2019 Fidic Assignment Final
34/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
32
CLAIM, SUSPENSION AND TERMINATION
CONTRACTOR
S.No.CLAUSE
No.CLAUSE CONSEQUENCES BEAR BY CONTRACTOR
WHAT NEED TO BE DONE BY PROJECT
OWNER
6 8.5Delay Caused
by AuthoritiesClaim for extension of time
Extension of time (EOT) available fora variation, delay or impediment of
the Employer, exceptionally, adverse
weather conditions, shortages of goods
or personnel.
7 8.8Suspension of
WorkClaim for additional payment
If the contractor suffers delay and /o
incurs Cost from complying with the
Engineers instructions under sub-Clause
8.8[Suspension of Work] and/or from
resuming the work, The Contractor hall
give notice to the Engineer and shall be
entitled subject to Sub-Clause 20.1[Contractors Claims] to:
(a) An extension of time for any such
delay, if completion is or will be delayed
Under sub-clause 8.4 [Extension of Time
for Completion], and
(b) Payment of any such Cost which sha
be included in the Contract Price.
8 8.9Consequences
of SuspensionClaim for additional payment
If the Contractor suffers delay and/or
incurs Cost from complying with the
Engineers instructions under Sub-Clause8.8[Suspension of wok] and h/or from
resuming the work, the Contractor shall
give notice to the Engineer and shall be
entitled subject to Sub-Clause 20.1
[Contractors Claims] to claim for time
extension and payment of any such Cost
9 8.10
Payment for
Plant and
Materials in
Event ofSuspension
Claim for extension of time and
additional payment
The Contractor shall be entitled to
payment of the value (as at the date of
suspension) of Plant and/or Materials
which have not been delivered to site.
10 10.2
Taking Over of
Parts of the
Works
There is a possibility that, after taking
over, the contractor may bear extra cost
in completing the works due to the
partial use of the facility by the
employer.
The employer should be much careful in
using the partially completed facility as
this might pose a claim against him. If no
other option, then taking over should be
much specified and employer need to be
careful that it might not interfere with
the on-going contractor works.
7/23/2019 Fidic Assignment Final
35/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
33
CLAIM, SUSPENSION AND TERMINATION
CONTRACTOR
S.No.CLAUSE
No.CLAUSE CONSEQUENCES BEAR BY CONTRACTOR
WHAT NEED TO BE DONE BY PROJECT
OWNER
11 10.8
Interference
with Tests on
Completion
It is obvious that the contractor has a
tight schedule and any delay in the
works by the actions of the employer
will lead in extra cost borne by the
contractor and ultimately claims from
the Employer.
The employer should be in proper
communication with the engineer and
contractor to inform his availability on
the test on completion date, to avoid
Contractor claims.
12 11.8Contractor to
Search
Any job requested to the contractor
beyond the scope of the contract shall
be claimed by the contractor as he
incurs extra cost for that.
It is duty of the contractor to remedy the
defects (Sub-clause 11.3) in defects
notification period. The engineer should
be competent in the preliminary and
final inspection to highlight the defectsbefore taking over certificate.
13 12.4 Omissions
The omissions are considered as
variations in the tender. The contractor
will claim the cost he incurs as a result
of the omission beside his profit.
The employer should try to make the
scope of the project very clear and fidic
contract clauses (General condition)
should be further refined according to
the project situation in the particular
conditions to avoid any major omission
that can result in potential claim by the
employer.
14 13.2Value
Engineering
This clause refers to the proposal of the
efficient design or construction by thecontractor in the benefit of the
employer. As the contractor is working
for the cost efficiency of the project at
his own cost so, if the proposal results in
cost saving then contractor should be
given benefit of the saving.
The employer should encourage the
value engineering aspect of the
contractor, but the proposal should be
carefully analyzed before approval to
avoid future dispute.
15 13.7
Adjustments
for Changes in
Legislation
The change in the government rules and
regulation can affect the contractor
directly (change in construction laws) or
indirectly (material price change). Such
changes will affect the cash flow n
performance of the contractor.
To avoid such claims, the employer
should mention a range in the particular
conditions for keeping him flexible of
price escalations. If the escalations go
beyond that, he should compensate the
contractor for the increased risk.
7/23/2019 Fidic Assignment Final
36/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
34
CLAIM, SUSPENSION AND TERMINATION
CONTRACTOR
S.No.CLAUSE
No.CLAUSE CONSEQUENCES BEAR BY CONTRACTOR
WHAT NEED TO BE DONE BY PROJECT
OWNER
16 14.8Delayed
Payment
Delay in the payment clearly hinders the
contractor from performance of his
work and he will be entitle to claim the
financing charges (interest) on the loans
he took from bank to maintain his cash
flow to execute the project.
The employer should decide a practical
payment plan in the contract agreed by
both the parties and abide by that durin
the execution of the project.
17 16.1
Contractor's
Entitlement to
Suspend Work
Lack of the engineer's issuing
certifications or others which are
allowed as engineer's right to ask
engineer in the contract causes the
contractor's claim (EOT, additionalpayment).
Owner and engineer should response
the contractual contractor's request
properly.
18 16.4Payment on
Termination
If termination of contract happens,
owner has to pay contractor's finished
work. Contractor will claim the
maximum amount of payment by
according to the contract.
Owner has to decide this condition
carefully with the consideration of
predictable termination cases.
19 17.1 Indemnities
If contractor's personnel receive the
damage or loss by thee employer,
contractor becomes to be entitle to
claim indemnity.
Owner should manage his/her personne
to prevent causing those issues.
20 17.4
Consequences
of Employer's
Risks
Delay of response against the
contractor's request coming from clause
"employer's risk" causes EOT
Owner and engineer should response
the contractual contractor's request
properly.
21 17.5
Intellectual
and Industrial
Property
Rights
If engineer doesn't give notice against
contractor's claim within 28 days,
contractor becomes to get the right to
take any goods and work in the site. And
no notice finally causes
ambition/litigation.
Proper response to the contractor's
claim and request is necessary.
Additionally, if there is important
goods/works in site, owner should
protect this property by using particular
condition.
22 18.1General
Requirements
for Insurances
If owner/owner's personnel/engineer
don't follow insurance policy and cause
damage/loss, contractor can claim
owner to indemnify them.
Owner side should understand and keep
the insurance policy.
7/23/2019 Fidic Assignment Final
37/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
35
CLAIM, SUSPENSION AND TERMINATION
CONTRACTOR
S.No.CLAUSE
No.CLAUSE CONSEQUENCES BEAR BY CONTRACTOR
WHAT NEED TO BE DONE BY PROJECT
OWNER
23 19.4
Consequences
of Force
Majeure
If the external force causes the
damage/loss, contractor will try to apply
this clause as much as possible to claim
the indemnity.
To making contract, owner shouldreview the condition of clause. And if
there are predictable issues (for
example: flood in Thailand), using
particular condition, owner should
mitigate these risk.
24 19.6
Optional
Termination,
Payment and
Release
If termination of contract happens,
owner has to pay contractor's finished
work. Contractor will claim the
maximum amount of payment by
according to the contract.
Owner has to decide this condition
carefully with the consideration of
predictable termination cases.
Additionally, owner should exclude
predictable issue from force majeure.
25 19.7
Release from
Performance
under the Law
When owner applies this clause to
adjust the payment appropriately,
contractor will claim and try to secure
their benefit.
Engineer should estimate the
performance by confirming contractor's
submissions and existing property. And
engineer must make accurate
estimation.
26 20.1Contractor's
Claims
According to this condition, contractor
becomes to be entitled to claim.
Engineer has to inform these condition
to owner correctly to prevent future
owner's misunderstanding. And owner's
understanding will help project
controlling to avoid contractor's claim.
5.0 Claim, Suspension and Termination by the Contractor:
This portion of the document elaborates the clauses of FIDIC that can favor the employer
to put claim against the contractor (multiple reasons), or to suspend or terminate the contract
because of the non-performance of the contractor. The contractor is in sensitive condition in
these clauses and he needs to consider these carefully. The clauses are:
CLAIM, SUSPENSION AND TERMINATION
OWNER
7/23/2019 Fidic Assignment Final
38/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
36
S.No.CLAUSE
No.CLAUSE CONSEQUENCES BEAR BY OWNER
WHAT NEED TO BE DONE BY
PROJECT CONTRACTOR
1 2.5 Employer'sclaims
If the employer considers himself
to be entitled to any payment
under any of the conditions or
connected with the contract or anyextension of defect notification
period, then employer should give
notice and particulars to the
contractors.
The amount may be included in thecontract price and price certificates
2 3.5 Determination
If the agreement end
inconclusively, then the engineer
must give notice to both parties of
determination and each party shall
give the determination and unless
and until revised under clause20
(Claims, disputes andarbitration).This determination is
binding unless revised by DAB
procedure.
Contractor need to follow clause
20.1if he considers himself entitled
for the additional payment and time
3 4.2Performance
security
The employers will not make a
claim under the performance
security, except for amount to
which the employer is entitled
under the contract if failure by the
contractor to extend validity of
performance security and the
failure by the contractor to pay the
performance security and the
failure by the contractor to pay the
employer an amount due, or the
circumstances which entitle the
employer to termination under
sub clause15.2(termination by
employer) i.e. mistake by
contractor occurs then employer
will take the bond after
termination of contract.
Contractor should deliver the
performance security to the
employer within 28 days after
receiving the letter of acceptance.
4 4.19Electricity,
Water and GasClaim for damage
The Contractor shall, at his risk
and cost, provide any apparatusnecessary for his use of these
services and for measuring the
quantities consumed.
5 4.20
Employers
Equipment and
Free Issue
Material
Claim for damage
The Contractor shall be responsibl
for each item of Employer's
Equipment whilst any of the
Contractor's Personnel is operating
it, driving it, directing it or in
7/23/2019 Fidic Assignment Final
39/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
37
CLAIM, SUSPENSION AND TERMINATION
OWNER
S.No.CLAUSE
No.CLAUSE CONSEQUENCES BEAR BY OWNER
WHAT NEED TO BE DONE BY
PROJECT CONTRACTOR
possession or control of it
6 4.4 Subcontractors
Each subcontract should include
provisions that would entitle
employer to require the
subcontract to be assigned to the
employer under sub clause 4.5 or
in the event of termination under
sub clause 15.2(termination of
employer).
The contractor and the
subcontractor should transfer their
benefit to the owner.
7 6.9Contractors
Personnelclaim for change the personnel
If appropriate, the Contractor shal
then appoint (or cause to be
appointed) a suitable replacement
person.
8 7.3 Inspection Claim for damage , re-do of works
If the Contractor fails to give the
notice, he shall if and when
required by the Engineer, uncover
the work and thereafter reinstate
and make good, all at the
Contractor's cost.
9 7.4 Testing Claim for damage , re-do of works
The cost of carrying out thisVariation shall be borne by the
Contractor, notwithstanding other
provisions of the Contract.
10 7.5 Rejection Claim for damage
If the Engineer requires this Plant,
Materials or workmanship to be
retested, the tests shall be
repeated under the same terms
and condition. If .the rejection and
retesting cause the Employer to
incur additional costs, the
Contractor shall subject to Sub-
Clause 2.5 [Employer's Claims] pay
these costs to the Employer.
11 7.6 Remedial Work Claim for damage
The Contractor shall comply with th
instruction within a reasonable time
which shall be the time (if any)
specified in the instruction, or
immediately if urgency is specified
under subparagraph (c).
7/23/2019 Fidic Assignment Final
40/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
38
CLAIM, SUSPENSION AND TERMINATION
OWNER
S.No.CLAUSE
No.CLAUSE CONSEQUENCES BEAR BY OWNER
WHAT NEED TO BE DONE BY
PROJECT CONTRACTOR
12 Retention amount and performancebond to be used for the test
13 8.6 Rate of Progress Claim for damage
Unless the Engineer notifies
otherwise, the Contractor shall
adopt these revised methods,
which may require increases in the
working hours and/or in the
numbers of Contractors Personne
and/or Goods, at the risk and cost o
the Contractor
14 8.8Suspension of
WorkClaim for damage
Unless the Engineer notifies
otherwise, the Contractor shalladopt these revised methods,
which may require increases in the
working hours and/or in the
numbers of Contractors Personne
and/or Goods, at the risk and cost o
the Contractor
15 8.9 Consequences ofSuspension Claim for damage
The Contractor shall not be
entitled to an extension of time
for, or to payment of the Cost
incurred in, making good the
consequences of the Contractorsfaulty design, workmanship or
materials or of the Contractors
failure to protect, store or secure
in accordance with Sub-Clause 8.8
[Suspension of Work]
16 8.10
Payment for
Plant and
Materials in
Event of
Suspension
Claim for damageThe Contractor shall be entitled to
payment of the value
17 9.4
Failure to Pass
Tests on
Completion
Failing to pass the tests can havecritical consequences if the
employer needs to put the facility
in operation. Before
commissioning, he could not do
that and it might affect his plan of
bringing facility in service. Or if the
test fails and owner has to accept
the reduced value facility.
The contractor needs to clearly
understand the project
specifications and work with
acceptable quality in order to
prevent himself from the risk and
claim of failure of facility at test.
7/23/2019 Fidic Assignment Final
41/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
39
CLAIM, SUSPENSION AND TERMINATION
OWNER
S.No.CLAUSE
No.CLAUSE CONSEQUENCES BEAR BY OWNER
WHAT NEED TO BE DONE BY
PROJECT CONTRACTOR
18 11.4Failure to
Remedy Defects
Failure of the contractor to repairthe defect will result in the hiring
of another contractor by the
employer for remedying the
defects. This will incur extra cost
which employer will claim from
the contractor.
The contractor should do the workcorrect in first the first time. And fo
specialized works, he should
subcontract to a competent sub-
contractor to avoid defects in
specialized works that are complex
to rectify.
19 15.2Termination by
Employer
There is the probability of addition
of particular condition about this
clause for mitigate owner's risk.
And owner will terminate the
contract in particular condition.
Contractor should confirm the all
conditions of termination. And if
there is unfair condition, contractor
has to negotiate the correction of
condition.
20 15.3
Valuation at
Date of
Termination
If termination is applied, engineer
start to estimate the contractors
achieving works, property and
delay from master schedule. And it
strongly affects payment after
termination.
Contractor manages the project
properly. And they have to eliminat
the difference b/w actual progress
and reporting progress.
21 15.4Payment after
Termination
Using this clause, owner decides
the payment for the work after
termination. Therefore, if there is
particular condition which cancels
owner's payment after
termination, contractor has to
cover the site recovery cost.
Contractor had to confirm whether
particular condition mitigate owner
payment.
22 17.1 Indemnities
If owner's personnel receive the
damage or loss by the contractor
side, owner becomes to be
entitled to claim indemnity.
Contractor should manage his/her
personnel to prevent causing those
issues.
23 17.5
Intellectual and
Industrial
Property Rights
Delay of response against the
owner's/engineersrequest
coming from clause "owner's risk"
causes litigation/arbitration in theworst case.
Contractor should response the
contractual contractor's request
properly.
24 18.1
General
Requirements
for Insurances
If contractor doesn't use
appropriate insurance, it will cause
the owner's/engineer's claim. And
if the case is serious, owner will
use termination of contract.
Contractor should understand the
condition of insurance correctly. An
they must get correct type of
insurance.
7/23/2019 Fidic Assignment Final
42/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
40
CLAIM, SUSPENSION AND TERMINATION
OWNER
S.No.CLAUSE
No.CLAUSE CONSEQUENCES BEAR BY OWNER
WHAT NEED TO BE DONE BY
PROJECT CONTRACTOR
25 18.2
Insurance for
Works and
Contractor's
Equipment
If contractor doesn't use
appropriate insurance, it will cause
the owner's/engineer's claim. And
if the case is serious, owner will
use termination of contract.
Contractor should understand the
condition of insurance correctly. An
they must get correct type of
insurance.
26 19.6
Optional
Termination,
Payment and
Release
If termination of contract happens,
owner has to pay contractor's
finished work. So owner will claim
the minimum amount of payment
by according to the contract.
Contractor has to decide this
condition carefully with the
consideration of predictable
termination cases.
Additionally, contractor should
negotiate the clause's condition to
remove serious risk.
27 19.7
Release from
Performance
under the Law
When owner applies this clause to
adjust the payment, owner will try
to minimize the payment.
Contractor should confirm
engineersestimation. And if they
find underestimation of payment,
contractor should claim correct pric
with evidence.
6.0 Clauses that can allow contractor to demand EOT/Additional
Payment:
EOT / ADDITIONAL PAYMENT
S.No. CLAUSE No. CLAUSE
1 1.9 Delayed drawings or Instructions
2 2.1 Right of Access to the Site
3 4.7 Setting out
4 4.12 Unforeseeable Physical Conditions
5 8.4 Extension of Time for Completion
6 8.5 Delay Caused by Authorities
7 10.2 Taking Over of Parts of the Works
7/23/2019 Fidic Assignment Final
43/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
41
EOT / ADDITIONAL PAYMENT
S.No. CLAUSE No. CLAUSE
8 10.3 Interference with Tests on Completion
9 11.8 Contractor to Search
10 12.4 Omissions
11 13.2 Value Engineering
12 13.7 Adjustments for Changes in Legislation
13 14.8 Delayed Payment
14 19.4 Consequences of Force Majeure
15 19.6Optional Termination, Payment and
Release
16 20.1 Contractor's Claims
7.0 Conclusion:
This report has been developed by a profound study of the FIDIC general conditions of
contract (1999 Edition). By study of the document we go to know that, FIDIC unequivocally
elaborates the project risks considering multiple practical scenarios and assumptions. One
interesting thing worth mentioning here is that though the contract conditions clearly highlight
project risks with respect to the employer and the contractor perspectives. But the clauses that
pose the risk on the contractor are much more than those of the contractor. So, Contractor needs
to much careful while working in the FIDIC Arrangement.
7/23/2019 Fidic Assignment Final
44/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
42
Appendix I
No Title
Project Risks Management Project RisksClaim, Suspension&
Termination
EOT/Additio
Payment
Time Cost Quality Safety Owner Contractor Contractor Owner
1 GENERAL PROVISION
1 1 Definitions
1 2 Interpretation1 3 Communications
1 4 Law and Language
1 5 Priority if Documents
1 6 Contract Agreement
1 7 Assignment
1 8Care and Supply of
Documents
1 9Delayed Drawings or
Instructions
1 10Employer's Use ofContractor's
Documents
1 11Contractor's Use of
Employer's Documents
1 12 Confidential Details
1 13 Compliance with Laws
1 14Joint and Several
Liability
2 THE EMPLOYER
2 1 Right of Access to theSite
2 2Permits, Licences or
Approvals
2 3 Employer's Personnel
2 4Employer's Financial
Arrangements
2 5 Employer's Claims
7/23/2019 Fidic Assignment Final
45/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
43
No Title
Project Risks Management Project RisksClaim, Suspension&
Termination
EOT/Additio
Payment
Time Cost Quality Safety Owner Contractor Contractor Owner
3 THE ENGINEER
3 1Engineer's Duties and
Authority
3 2Delegation by the
Engineer
3 3
Instructions of the
Engineer
3 4Replacement of the
Engineer
3 5 Deteminations
4 THE CONTRACTOR
4 1Contractor's General
Obligations
4 2 Performance Security
4 3Contractor's
Representative
4 4 Subcontractors
4 5Assignment of Benefit
of Subcontract
4 6 Co-operation
4 7 Setting Out
4 8 Safety Procedures
4 9 Quality Assurance
4 10 Site Data
4 11
Sufficiency of the
Accepted Contract
Amount
4 12Unforeseeable Physical
Conditions
4 13Rights of Way and
Facilities
4 14Avoidance of
Interference
7/23/2019 Fidic Assignment Final
46/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
44
No Title
Project Risks Management Project RisksClaim, Suspension&
Termination
EOT/Additio
Payment
Time Cost Quality Safety Owner Contractor Contractor Owner
4 15 Access Route
4 16 Transport of Goods
4 17Contractor's
Equipment
4 18Protection of the
Environment
4 19Electricity, Water and
Gas
4 20
Employer's Equipment
and Free-Issue
Material
4 21 Progress Reports
4 22 Security of the site
4 23Contractor's
Operations on Site
4 24 Fossils
5NOMINATED
SUBCONTRACTORS
5 1
Definition of
"nominated
Subcontractor"
5 2Objection to
Nomination
5 3
Payments to
nominated
Subcontractors
5 4 Evidence of Payments6 STAFF AND LABOUR
6 1Engagement of Staff
and Labour
6 2Rates of Wages and
Conditions of Labour
6 3Persons in the Service
of Employer
7/23/2019 Fidic Assignment Final
47/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
45
No Title
Project Risks Management Project RisksClaim, Suspension&
Termination
EOT/Additio
Payment
Time Cost Quality Safety Owner Contractor Contractor Owner
6 4 Labour Laws
6 5 Working Hours
6 6Facilities for Staff and
Labour
6 7 Health and Safety
6 8Contractor's
Superintendence
6 9 Contractor's Personnel
6 10
Records of Contractor's
Personnel and
Equipment
6 11 Disorderly Conduct
7PLANT, MATERIALS
AND WORKMANSHIP
7 1 Manner of Execution
7 2 Samples
7 3 Inspection
7 4 Testing
7 5 Rejection
7 6 Remedial Work
7 7Ownership of Plant and
Materials
7 8 Royalties
8
COMMENCEMENT,
DELAYS AND
SUSPENSION8 1
Commencement of
Work
8 2 Time for Completion
8 3 Programme
8 4Extension of Time for
Completion
8 5 Delays Caused by
7/23/2019 Fidic Assignment Final
48/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
46
No Title
Project Risks Management Project RisksClaim, Suspension&
Termination
EOT/Additio
Payment
Time Cost Quality Safety Owner Contractor Contractor Owner
Authorities
8 6 Rate of Progress
8 7 Delay Damages
8 8 Suspension of Work
8 9Consequences of
Suspension
8 10
Payment for Plant and
Materials in Event of
Suspension
8 11 Prolonged Suspension
8 12 Resumption of Work
9TESTS ON
COMPLETION
9 1Contractor's
Obligations
9 2 Delayed Tests
9 3 Retesting
9 4Failure to Pass Tests on
Completion
10EMPLOYER'S TAKING
OVER
10 1Taking Over of the
Works and Sections
10 2Taking Over of Parts of
the Works
10 3
Interference with Tests
on Completion
10 4Surfaces Requiring
Reinstatement
11 DEFECTS LIABILITY
11 1
Completion of
Outstanding Work and
Remedying Defects
7/23/2019 Fidic Assignment Final
49/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
47
No Title
Project Risks Management Project RisksClaim, Suspension&
Termination
EOT/Additio
Payment
Time Cost Quality Safety Owner Contractor Contractor Owner
11 2Cost of Remedying
Defects
11 3Extension of Defects
Notification Period
11 4Failure to Remedy
Defects
11 5 Removal of DefectiveWork
11 6 Further Tests
11 7 Right to Access
11 8 Contractor to Search
11 9Performance
Certificate
11 10 Unfulfilled Obligations
11 11 Clearance of Site
12
MEASUREMENT AND
EVALUATION
12 1 Works to be Measured
12 2Method of
Measurement
12 3 Evaluation
12 4 Omissions
13VARIATIONS AND
ADJUSTMENTS
13 1 Right to Vary
13 2 Value Engineering
13 3 Variation Procedure
13 4Payment in Applicable
Currencies
13 5 Provisional Sums
13 6 Daywork
13 7Adjustments for
Changes in Legislation
7/23/2019 Fidic Assignment Final
50/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
48
No Title
Project Risks Management Project RisksClaim, Suspension&
Termination
EOT/Additio
Payment
Time Cost Quality Safety Owner Contractor Contractor Owner
13 8Adjustments for
Changes in Cost
14CONTRACT PRICE AND
PAYMENT
14 1 The Contract Price
14 2 Advance Payment
14 3Application for Interim
Payment Certificates
14 4 Schedule of Payment
14 5Plant and Materials
intended for the Works
14 6Issue of Interim
Payment Certificates
14 7 Payment
14 8 Delayed Payment
14 9
Payment of Retention
Money
14 10Statement at
Completion
14 11Application for Final
Certificate
14 12 Discharge
14 13Issue of Final Payment
Certificate
14 14Cessation of
Employer's Liability
14 15 Currencies of Payment
15TERMINATION BY
EMPLOYER
15 1 Notice to Correct
15 2Termination by
Employer
15 3Valuation at Date of
Termination
7/23/2019 Fidic Assignment Final
51/53
ANALYSIS OF THE FIDIC CONDITIONS OF CONTRACT (RED BOOK) 1999 EDITION
49
No Title
Project Risks Management Project RisksClaim, Suspension&
Termination
EOT/Additio
Payment
Time Cost Quality Safety Owner Contractor Contractor Owner
15 4Payment after